power supply arrangement and lighting works on turnkey ...nbppl)_(1).pdfexecution of the project...

NTPC-BHEL PONTPC-BHEL PONTPC-BHEL PONTPC-BHEL PONTPC-BHEL POWER PRWER PRWER PRWER PRWER PROJECTS PVTOJECTS PVTOJECTS PVTOJECTS PVTOJECTS PVT..... L L L L LTDTDTDTDTD.....(A Joint Venture Company of NTPC & BHEL)

Power supply arrangement and Lightingworks on Turnkey basis for NBPPL's

manufacturing plant at Mannavaram,Tirupati in the state of Andhra Pradesh on

Turnkey basis

CONDITIONS OF CONTRACT

VOLUME-I

BID DOCUMENT NO. :NESCL/NBPPL/CS-MV-503

CONTENTS

Sl. No. Description Section Page No.

1. Notice Inviting Tender (NIT) I NV 2-7

2. Definition - 9-11

3. Instruction to Bidder I NB 12-25 (Part:A, General Conditions of Contract, Procurement)

4. General Commercial Terms & Conditions G CC 26-45 (Part:B, General Conditions of Contract, Procurement)

5. Annexures Annex 46-79

6. Special Conditions of Contract SCC 83-104


Power Supply arrangement and Lighting CONDITIONSworks in Mannavaram plant of NBPPL OF CONTRACT CONTENT

Bid Doc. No. : NESCL/NBPPL/CS-MV-503 VOLUME-I

NIT INV Page 1 of 5

NESCL/NBPPL/CS-MV-503 Notice Invitation for Tender Page 1 of 5

Corp. Office: “The Corenthum”, 6th floor, Tower-B, A-41, Sector 62, Noida-201309 (UP) Phone : 0120-4001300, 4001356, Fax No : 0120-4001301, E-mail: [email protected]

NOTICE INVITATION FOR TENDER (NIT)

(DOMESTIC COMPETITIVE BIDDING) FOR

Power supply arrangement and Lighting works on Turnkey basis for NBPPL's manufacturing plant at Mannavaram, Tirupati in the state of Andhra Pradesh

NIT No: NESCL/NBPPL/CS-MV-503 Date: 15.09.2012

NTPC BHEL Power Projects Private Limited (NBPPL) proposes for execution of work for ‘Power supply arrangement and Lighting works on Turnkey basis for NBPPL's manufacturing plant at Mannavaram, Tirupati in the state of Andhra Pradesh. The proposed work is to be handed over to NBPPL for operation, ultimate control and maintenance.

1.0 NTPC ELECTRIC SUPPLY COMPANY LIMITED (NESCL), a wholly owned Subsidiary of NTPC Ltd, has been retained by NTPC BHEL Power Projects Private Limited (NBPPL) a Joint venture com pany of NTPC Ltd and BHEL, as ‘ Consultant’ for aforesaid work. NBPPL invites sealed Bids on Single Stage Two Envelope (Part-I: Techno commercial Bid & Part-II: Price Bid) bidding basis for ‘ Power supply arrangement and Lighting works on Turnkey basis for NBPPL's manufacturing plant at Mannavaram, Tirupati in the state of Andhra Pradesh against Package: MV-503’ from the com petent Agencies meeting th e qualifying requirements as stated in Para 5.0 below.

The execution of the proj ect shall be funded by NBPPL and all e ligible paym ents f or the execution of the project under the inte nded contract shall be m ade by the NBPPL. The ownership of the project shall remain vested with NBPPL.

2.0 Brief Scope of Work :

i) For Power supply arrangement works :

a. Supply, installation and commissioning of 01 no. of 33/0.433 kV indoor

substation (3x2.5MVA) in existing switchgear building.

b. Supply of material, installation and commissioning of 2x1000kVA+

NIT INV Page 2 of 5


1x500kVA DG sets.

c. Supply & laying (including jointing and termination) of 33kV 3CX240 sq

mm XLPE cable & LT XLPE power cables.

For Lighting works :

a. Building lighting works in various buildings of the site.

b. Area lighting including Street lighting, garden lighting etc.

ii) Providing engineering data and drawings, as per specified for mat, for em ployer’s review, approval and records.

iii) Complete Manufacturing includ ing Type , Acceptan ce & Routine testing, as specified.

iv) Packing and transportation from the m anufacturer’s works to the site includ ing transit insurance & cu stoms clearan ce/ port clearance (if require d), port handling, clearance for imported goods and further loading (if applicable) "As delivered at site basis".

v) Receipt, Unloading, Storage, Insurance and Preservation of m aterial & accesso ries at site.

vi) Handing over of the completed system to the Owner

vii) Satisfactory conclusion of the Contract

3.0 The aforesaid scope of work is only indicative. The detailed scope is described in the Bidding

Documents, which are availab le on http://www.nbppl.in/tenders. The details of schedule for this tender is as given below:

Sl. No. Details Package: MV-503 1. Bidding Documents No. NESCL/NBPPL/CS- MV-503

2. Availability of Bidding Documents on website From: 15.09.2012 to 16.10.2012

3. Submission of Bids (Part-I & Part-II)

Last Date & Time: 17.10.2012 up to 10.30 am (IST)

4. Bid Opening (Part-I) Date & time Date : 17.10.2012 Time on 11.00 am (IST)

5. Cost of Bidding Documents free of cost 6. Bid Security ` 10,00,000/- (Ten Lacs)

7. Venue of bid submission and opening

NESCL’s office at Room No 221, R&D Building, NTPC Ltd, A-8A, Sec-24, Noida-201301 (U.P.)

Note : Date and time of opening of Price Bid(s) (Part-II) for above package shall be informed to all the eligible bidders at a later d ate and the same shall b e opened in th e presence of th e representatives of those bidd ers who choose to attend the Bid Opening.

NIT INV Page 3 of 5


4.0 All bids (Part-I: Techno Commercial Bid) must be accompanied by Bid Security for an a mount as per point 6 of above referred clause No. 3 (Ref Annexure-IX, X of GCC) in the f orm stipulated in Bidding Docum ents. Bids not accompanied by the requisite Bid Security, in a separate sealed cover or bids accompanied by Bid Security of inadequate value shall not be entertained and in such cases bids shall be returned to the bidders without being opened.

5.0 Qualifying Requirements of Bidders:

5.1 Technical Criterion

5.1.1 The Bidder should have supplied, constructed and commissioned Indoor or Outdoor

type substation of 33kV or higher Voltage class having minimum of 01 no. of bay. The bay shall comprise of Circuit breaker, and associated isolators and current transformers in case of outdoor type Sub Station, (OR) Metal clad Indoor type switchgear cubicle with bus bar, control, instrument transformer, metering, protection equipment in case of indoor type Substation.

5.1.2 The intending Bidder must have executed orders of works, mentioned at Cl. No. 5.1.1 above, within last seven (7) years reckoned from the date of techno commercial bid opening with either of the following:

a. Three orders valuing not less than ` 4.28 Crores each, OR b. Two orders valuing not less than ` 6.42 Crores each. OR c. One order valuing not less than ` 8.56 Crores.

5.2 Financial Criteria

The average annual turnover of the Bidder, in the preceding three (3) financial years as on the Date of techno commercial bid opening, shall not be less than ` 17.11 Crores (Indian Rupees Seventeen point One One Crores only).

NOTE: Other income shall not be considered for arriving at annual turnover.

6.0 Notwithstanding anything stated here in above the owner reserves the right to assess

the capacity and the capability of the bidder should the circumstances warrant such assessment in the overall interest of the owner .This assessment shall inter‐alia include i) Document verification ii) Bidders work/manufacturing facilities

NIT INV Page 4 of 5


iii) Manufacturing capacity, details of work executed, and works in hand, anticipated in future in addition to the works involved in present bid.

iv) Details of plant and machinery, manufacturing and testing facilities, manpower, and financial resources.

v) Details of engineering organization & systems in place. vi) Details of quality systems in place. vii) Past experience and performance. viii) Customer’s feedback and banker’s feedback.

The owner reserves the right not to consider the bid in case anything is found contradictory to the above qualifying requirement (QR). 7.0 The owner reserves the right to reject any or all bids or cancel/withdraw the invitation

for bids without assigning any reason what so ever and in such a case no bidder/intending bidder shall have any claim arising out of such action.

8.0 Bid submitted by any Agency who is Banned/On holiday list of NTPC

Ltd./BHEL/NBPPL/NESCL shall not be considered for opening and further evaluation. Similarly, in case any Bidder is Banned/put on holiday list of NTPC Ltd./BHEL/NBPPL/NESCL subsequent to submission of Bid during evaluation, then in such an eventuality, Bid of such Bidder shall also not be considered for further evaluation.

9.0 In addition to above, bidder to submit documentary evidence viz. Copy of award letter proof of completion in support of similar works executed during last five years reckoned from seven days prior to bid opening.

10.0 The Bidder shall furnish following documents/details with the Bid in support of:

i) Documentary evidence viz. copy of award letter, Approved SLD, certificate of performance in support of satisfactory execution of works in respect of Sl. No. 5.1 in support of meeting the ‘QR’ stipulated duly flagged/marked in the offer.

ii) All documents evidencing compliance to the Financial Criteria as at clause 5.2 above. iii) Complete annual reports together with Audited statement of accounts of the company

for last 5 years immediately preceding date of submission of bid. iv) Detailed information on any litigation or arbitration arising out of the contract

completed or under execution by it over the last five years. A consistent history of litigation against the Bidder may result in the rejection of Bid.

13.0 The successful Bidder will be required to furnish a Contract Performance Guarantee for Ten (10%) for the package.

NIT INV Page 5 of 5


14.0 NTPC Electric Supply Com pany Li mited reserves the right to cancel / withdraw the bid without ass igning any reason for such decis ion. Such decision will not incur any liability whatsoever on the part of NTPC Electric Supply Company limited consequently.

15.0 Bidding documents are non-transferable and a complete set of bidding docum ents may be

downloaded from the web site of NBPPL (http://www.nbppl.in/tenders). Agencies who have downloaded the Bidding Document from the web site are required to send confirmation to DGM (C&M), NTPC Electric Supply Company Ltd at address given below at Para 19, informing about their correspondence address, contact person, contact number, e-mail and fax No.

16.0 Issuance of bid documents to any bidder shall not construe that such bidder is considered to

be qualified. Bids shall be submitted and opened at the address given below in the presence of bidder’s representatives who choose to attend the bid opening.

17.0 NTPC Electric Supply Com pany Limited will not be responsible for misplacement/delay in

receipt of either request for issuance of Bidding Documents or Bids sent by Post/ Courier.

18.0 In the event of date specified for bid receipt and opening being declared as a closed holiday for purchaser’s office, the due date f or submission of bids and opening of bids will be the following working day at the appointed times.

19.0 Any clarification, if any , to the Bid ding Do cument should be subm itted in writing at the

Office of ‘Consultant’ Seven days before the date of clos ing of sale of Tender Docum ent and no subs equent clarification will be ente rtained either verbally or in writing afterwards. All such Clarifications should be addressed to: DGM (C&M), NTPC Electric Supply Company Limited, Room No 221, R&D Building, NTPC EOC, Sec-24, Noida (UP) Telefax No. 0091-(120)-2410907 205 and Telephone Nos. 0091-(120) – 2410689.

Note: Bidders are requested to regularly visit the NBPPL’s website for

amendment/errata (if any) and any other information regarding these tender(s). Bidder(s), who are downloading the bid document from website; are requested inform NESCL about their company details and address for any communication regarding this tender.

NBPPL / GCC ISSUED ON 07.10.2010 REV. 03

GENERAL CONDITIONS OF CONTRACTS

(Procurement) 1. DEFINITION OF TERMS 2. PART–A: INSTRUCTIONS TO BIDDERS 3. PART–B: GENERAL COMMERCIAL TERMS & CONDITIONS

4. ANNEXURE

NTPC- BHEL POWER PROJECTS PVT. LTD (A Joint Venture Company of NTPC & BHEL) The Corenthum, 6th Floor, Lobe No 4, Tower B

A-41, Sector-62, Noida 201309 (U.P.)

Issue 00 Rev. 03

Not for Publication For official use

GENERAL


(Purchase)

PAGE NO.: 1 of 3


DEFINITIONS

DEFINITION OF TERMS Throughout the Tender Documents including the Enquiry Letter, the following words shall have the meanings assigned to them herein, unless the subject matter or the context requires otherwise.

1. The Purchaser shall mean M/s NTPC BHEL Power projects Private Limited (A Joint Venture

Company of NTPC & BHEL) incorporated under the Companies Act 1956 acting through its Corporate Office, NBPPL, The Corenthum, 6th Floor, Lobe No 4, Tower B, A-41, Sector-62, Noida 201309 (U.P.) which expression shall include its successors and assigns. It may also be referred to as NBPPL.

2. The Owner shall mean NBPPL or its Customer or Client for whose project, the enquiry has been

issued by the purchaser and shall include his successors and assigns as well as authorized officer(s)/representative(s), which may also be referred as Customer or Owner/Customer.

3. The Consultant shall mean the agency appointed by the Owner or Purchaser to provide consultancy services for the project and shall include his successors and assigns as well as authorized officer(s)/representative(s).

4. The Tenderer shall mean the Firm/Company/Organization, which quotes against the Tender Enquiry issued by the purchaser. It may also be referred as bidder or vendor.

5. Acceptance of offer shall mean issue of letter of intent/award or memorandum or detailed Order/Contract communicating the acceptance of offer, to the successful tenderer.

6. The Order/Contract shall mean and include the general conditions, bidding conditions, specific conditions, specifications, schedules, drawings, form of tender, covering letters, schedule of prices and quantities, letter of intent/award of the Purchaser, any special conditions applicable to the particular Order/Contract and subsequent amendments mutually agreed upon. It may also be referred as order or contract/order or purchase order or contract.

7. The Seller/Contractor shall mean the firm/company/organization with whom the Order/Contract is made and shall be deemed to include his successors, representatives, heirs, executors, administrators and permitted assigns, as the case may be. It may also be referred as contractor, seller or supplier.

8. The Sub-contractor shall mean the person/firm/company/organization to whom any part of the work has been sub-contracted by the Seller/Contractor, with the written consent of the purchaser and shall include his heirs, executors, administrators, representatives and assigns.

9. The Engineer shall mean officer of the purchaser as may be duly appointed and authorized in writing by the purchaser to act as the engineer on his behalf for the purpose of the Order/Contract.

10. The Specification shall mean the specifications contained in the Tender Documents and any subsequent modifications thereof and the drawings, schedules etc. attached thereto, if any.

GENERAL


(Purchase)

PAGE NO.: 2 of 3


DEFINITIONS

11. The Site shall mean and include the land and place on, into or through which the project/plant and the related facilities are to be constructed and any adjacent land, path, street or reservoir which may be allocated or used by the owner or Seller/Contractor in the performance of the Order/Contract.

12. Tests on completion shall mean such tests as are prescribed by the specifications and/or tests mutually agreed upon by the purchaser and the Seller/Contractor, to be performed by the Seller/Contractor after erection of the equipment to establish satisfactory operation as required by the specifications.

13. Commissioning shall mean successful completion of trial operations and readiness of the contracted/ordered plant and materials for commercial use. This will include all consumables and inputs required for pre-commissioning.

14. Initial operation or Trial operation or Reliability run shall mean continuous integrated operation of the contracted/ordered plant and materials under varying loads to furnish proof of satisfactory operation, for a specified period.

15. Temporary work shall mean all temporary works of every kind required in or for the execution, completion or maintenance of the works.

16. Approved means approved in writing including subsequent written confirmation of previous verbal approval and approval means approval in writing including as aforesaid.

17. Inspection Agency (IA) shall mean any person(s), who may be duly authorized by the purchaser to inspect the stores included in the Order/Contract, at the contractor’s/sub-contractor’s works.

18. Month shall mean calendar month and week shall mean 7 days.

19. Consignee shall mean the official(s)/person(s) to whom the stores are required to be delivered in the manner indicated in the Order/Contract.

20. Plant/Equipment/Stores shall mean the goods, machinery, components, parts, spares, etc. required to be supplied by the Seller/Contractor as per Order/Contract.

21. Contract Engineer (CE) shall mean the official who has signed the Order/Contract on behalf of the Purchaser.

22. Site Engineer shall mean officer of the purchaser as may be duly appointed and authorized in writing by the purchaser to act as the Site Engineer on his behalf for the purpose of receipt & verification of in-coming stores and issue of Material Receipt Certificate (MRC)/Stores Receipt Voucher (SRV).

23. Site Inspection Agency (Site IA) shall mean any person(s), who may be duly authorized by the purchaser to inspect the stores/works included in the Order/Contract, at the Project Site.

24. GENERAL

GENERAL


(Purchase)

PAGE NO.: 3 of 3


DEFINITIONS

The words incorporating singular shall include plural and vice-versa, in the words importing masculine gender shall include feminine and vice-versa and the words importing persons shall include bodies; corporate, limited liability companies, partnership and other legal entities.

25. ABBREVIATIONS

CQ Corporate Quality CIF Cost Insurance Freight CVD Countervailing Duty E&C Erection & Commissioning LC Letter of Credit MRC Material Receipt Certificate MDCC Material Dispatch Clearance Certificate MSMED Micro Small and Medium Enterprises Development NBPPL NTPC BHEL Power Projects Private Limited NIT Notice Inviting Tender QS Quality Surveillance. SAD Special Additional Duty SCC Special Conditions of Contract SDPBG Security Deposit cum Performance Bank Guarantee

GENERAL


(Procurement)

VOLUME I, PART A PAGE NO.: 1 of 14


INSTRUCTIONS TO BIDDERS


Sl. No.

DESCRIPTION

1 GENERAL INSTRUCTIONS

2 PROCEDURE FOR SUBMISSION & OPENING OF TENDERS

3 PART-I (TECHNO-COMMERCIAL BID) - CONTENTS & CHECKLIST

4 PART II (PRICE BID) - CONTENTS AND CHECK LIST

5 BID SECURITY

6 CLARIFICATIONS REQUIRED BY BIDDERS

7 TECHNICAL SPECIFICATIONS

8 DEVIATIONS – LISTING

9 ASSUMPTIONS – LISTING

10 DELIVERY/COMPLETION SCHEDULE

11 STORAGE INSTRUCTIONS

12 VALIDITY OF OFFER

13 LANGUAGE & CORRECTIONS

14 CHANGE OF TERMS & CONDITIONS / PRICE

15 TENDERER TO INFORM HIMSELF FULLY

16 REJECTION OF TENDER AND OTHER CONDITIONS

17 FOREIGN BIDDERS

18 LOADING FOR DEVIATIONS & TENDER EVALUATION

19 PRICE DISCREPANCY

20 DISCOUNTS

21 EVALUATION CRITERIA

TABLE OF CONTENTS

GENERAL


(Procurement)




1 GENERAL INSTRUCTIONS 1.1 Tenderers are advised to study all the tender documents carefully. Any

submission of tender by the tenderer shall be deemed to have been done after careful study and examination of the tender documents and with the full understanding of the implications thereof. The specifications and terms and conditions shall be deemed to have been accepted unless otherwise specifically commented upon by the tenderer in his offer. Non-compliance with any of the requirements and instructions of the Tender Enquiry may result in the rejection of the tender.

1.2 All commercial terms and conditions except price should be submitted as part of techno-commercial offer which may be opened first. The price part (Part-II) is to be submitted in a separate sealed cover along with techno-commercial offer (Part-I). Purchaser reserves the right to open both the parts at the same time.

1.3 A declaration as per Annexure III must be sent before opening of Price Bids.

2 PROCEDURE FOR SUBMISSION & OPENING OF TENDERS

2.1 Tenders shall be submitted in two parts as described below on or before the due date by 10.30 a.m.

PART - I: TECHNO-COMMERCIAL BID :Containing BID SECURITY of specified amount and mode in a separate envelope, Technical offer, Annexure-I & II, Commercial Terms & Conditions and Unpriced Copy of Price Bid, in five (5) sets. PART-II: PRICE BID: Containing Prices, to be submitted in Two sets strictly as per enclosed Price Schedule Format (One original + one copy of the original), for complete scope of the Tender Enquiry.

NOTE: Any changes in the specified price format, if made, other than those specified and

accepted in the unpriced format, the offer is liable to be rejected.

2.1.1 PART-I (techno-commercial bid) may be opened on the due date and time as specified in the Enquiry Letter, in the presence of tenderers who may like to attend.

Incomplete offers are liable to be rejected. Purchaser reserves the right to open both the parts i.e. Part-I and Part-II together.

2.1.2 PART-II containing prices shall be submitted along with Part-I, but in a separate

sealed cover.

Any corrections/amendments shall be properly and fully authenticated. If not done so, the offer is liable to be rejected.

GENERAL


(Procurement)




2.1.3 In case it becomes necessary for the tenderer to make any changes in his original price bid (Part-II) on account of technical/commercial confirmations/clarifications, against the changes raised by the purchaser, to bring the offer in line with the requirement of the specifications, the impact of such changes on price shall be submitted. Revised price bid only if requested by the purchaser shall be submitted, in a separate sealed cover duly superscribed as:

“DISCOUNT/ IMPACT/ REVISED PRICE BID (PART-II) (DELETE WHICHEVER

IS NOT APPLICABLE), REVISION NO ____ AGAINST TENDER ENQ. NO. _____________________________ DATED ________”.

2.1.4 However if any bidder on his own offers price discount or reduce prices, the same

would be acceptable. Other bidders in such a case would also be informed and can submit reduced prices, if so desired by them. No price increase is acceptable till the validity of offer.

2.2 After the tenders have been technically & commercially examined and the

necessary clarifications etc. obtained, Part-II containing FINAL REVISED PRICE BID, if submitted, otherwise, the original Price Bid shall be opened, for which the date and time shall be intimated to the technically and commercially acceptable tenderers only, in case of public opening.

NOTE: NBPPL also reserves the right to open the earlier price bids, if any, submitted by the bidders, if required.

2.3 No correspondence shall be entertained from the tenderers after the opening of

Part-II (Price bid) of the tender.

2.4 Not more than two representatives will be permitted to be present for the tender opening.

2.5 Purchaser may negotiate the tender, if the quoted rates/terms are found to be

unreasonable or in the unacceptable range.

2.6 MARKING ON ENVELOPES

2.6.1 The followings shall be super scribed on the envelopes

PART-I: 1. TENDER ENQUIRY NO. AND ITEM DESCRIPTION 2. DUE DATE FOR OPENING

3. "TECHNO-COMMERCIAL BID”. PART II: 1. TENDER ENQUIRY NO AND ITEM DESCRIPTION 2. DUE DATE FOR OPENING 3. "PRICE BID".

GENERAL


(Procurement)




2.6.2 Impact/Discount through e-mail or letter without proper superscription on the envelope is not acceptable.

2.6.3 Both Parts - I & II shall be submitted in separate sealed covers duly super scribed

as indicated above and shall be enclosed further in a main cover duly sealed and super scribed as :

"TENDER FOR _________________ AGAINST TENDER ENQ. NO. ______________________________________ DUE ON____________ CONTAINING PART-I & PART-II BIDS". 2.6.4 Envelope not marked with tender enquiry number is liable to be ignored and may

not be opened.

2.7 BID SUBMISSION

2.7.1 The tenders shall be addressed to the official inviting Tenders by name and designation and sent at the address mentioned in the NIT

2.7.2 Tenders can either be delivered in person or sent at the above mentioned

address by COURIER/REGISTERED POST. It shall be the responsibility of the bidder to ensure that the tender is delivered in time as tenders received after the Due Date and Time of opening are liable to be rejected.

2.8 Unsolicited tenders shall not be entertained. 2.9 Order/Contract when finalized will be issued in the name of the bidder only and

change of name during tender evaluation and after submission of the tender is liable to make this offer ineligible for participation.

3 PART-I (TECHNO-COMMERCIAL BID) - CONTENTS & CHECKLIST 3.1 The tender shall be submitted in specified number of copies in separate sections

for main equipment, recommended spares, etc., as per scope defined. Bid Security of specified amount and mode shall be submitted in separate envelope clearly indicating on the envelope Bid Security, amount, mode and put in main envelope of Part-I.

3.2 Technical offer for main equipment shall contain:

a) Technical specifications/write-ups. b) Scope of supply & bill of material. c) Catalogues, literature & drawings/data sheets and P&ID with terminals marked

up.

GENERAL


(Procurement)




d) Schedule of commissioning spares and mandatory spares (to be given

separately) giving only description of each item and quantity, as per given format if any.

e) Optional items as per NBPPL price schedule format. f) Recommended list of spare parts for three years of operation as applicable. g) Schedule of supervision for erection & commissioning services,

h) Schedule of maintenance/erection tools and tackles covered in the scope of supply

as per NBPPL price format. i) PERT Network/Bar Chart for engineering, manufacturing, testing & dispatch of the

offered equipments. j) Guarantee offered for the capacity of the system/equipment, auxiliary power

consumption & consumables like chemicals etc. as applicable. k) Listing of technical deviations l) Listing of exceptions & assumptions m) Services and materials to be provided by the purchaser. n) Names of main sub-contractors/vendors and their scope and subcontractor's

ordering schedule

o) Quality plans and Field Quality Plans. p) All other details/documents as listed in tender documents.

3.3 Commercial offer shall contain:

a) Agreed terms & conditions (Annexure-II).

b) Listing of Commercial Deviations, if any w.r.t. GCC & SCC.

c) Unpriced copy of the Price Bid (Part-II), indicating the BOQ as per the Technical Specifications.

d) Delivery schedules.

e) Validity of offer.

GENERAL


(Procurement)




4 PART II (PRICE BID) - CONTENTS AND CHECK LIST 4.1 The BEST offer with FIRM prices( or with PVC as specified in NIT) as per the

PRICE SCHEDULE /PRICE FORMAT given along with NIT shall be submitted in specified number of copies in separate sections for main equipment, O&M spares and supervision offer/erection and commissioning offer, as per scope defined.

4.2 In case any bidder insists for price variation clause (PVC), where NIT specifies FIRM price, the offer should contain :-

a) PVC Formula b) Ceiling for PVC c) Base date and applicable indices for base date

Open ended PVC formula is not acceptable. Indices shall be based on Government of India/ RBI publications/ IEEMA/ LME etc... However, NBPPL reserves the right to accept / reject the offer with PVC.

4.3 Price Bid for MAIN EQUIPMENT shall cover basic equipment price with excise

duty, sales tax, freight, octroi, or any other charges as applicable under any Law, as per format enclosed.

4.4 Price Bid for recommended spares shall cover Item-wise rate and total value, packing and forwarding charges, excise duty, sales tax, freight, insurance, octroi or any other charges as applicable under any Law , as per format enclosed

4.5 Supervision Offer for erection & commissioning/offer for E&C shall cover the following (if applicable)

a. Scope of work.

b. Schedule of tools & plants, civil work, consumables, control &

instrumentation, manpower requirement (to be provided by the purchaser in case of supervision offer).

c. Supervision charges on man-day basis and total period in man-months of supervision required, indicating services and facilities to be provided by the tenderer.

OR Erection and commissioning lump sum charges/unit-wise charges for

elements of Main equipment as applicable.

Note –The total Erection and commissioning charges should be minimum 10% of the total quoted price of the package failing which break up of prices shall be adjusted accordingly for evaluation & ordering

4.6 Authority of person signing the tender on behalf of the tenderer :

GENERAL


(Procurement)




A person signing the tender or any other document in respect of the Order/Contract on behalf of the tenderer, without disclosing his authority to do so shall be deemed to warrant that he has authority to bind the tenderer. If it is discovered at any time that the person so signing had no authority to do so, the purchaser may, without prejudice to any other right or remedy, cancel the Order/Contract and make or authorise the purchase of the stores at the risk and cost of such person and hold such person liable to the purchaser for all costs and damages arising from the cancellation of the Order/Contract including any loss which the purchaser may sustain on account of such purchase.

Notes

a. All bids of Indian origin shall be in Indian Rupees only. b. All bids of foreign suppliers shall be preferably in the currency of the country of

origin and shall be on FOB basis. Details of Shipping arrangements shall be included in the Order/Contract

c. The authorized representative/ agent can only represent one bidder for a given package.

5 BID SECURITY (Applicable for Open Tender Enquiry Only): Every tender must

be accompanied by the prescribed amount of Bid Security. Bid security shall be furnished in accordance with Annexure-IX of this enquiry. Bids not accompanied by the requisite Bid Security in a separate sealed envelope or bids accompanied by Bid Security of inadequate value shall not be entertained and in such cases, bids shall be returned to the bidders without being opened.

NOTE: Cheques, Currency Notes, Money Orders or Postal Orders will not be accepted. Bid Security shall not carry any interest

6 CLARIFICATIONS REQUIRED BY BIDDERS Technical and commercial clarifications required, if any, before submission of

tender, should be given separately in duplicate addressed to the official inviting the tenders.

7 TECHNICAL SPECIFICATIONS

7.1 The tenderer is advised to study the technical specifications, schedules and data

sheets carefully and submit all required information in his tender including scope of supply, bill of materials etc.

7.2 CATALOGUES AND LITERATURES

The tenderer shall submit detailed catalogues, literatures, drawings, technical write-ups, etc., on all equipments offered in the tender, along with each copy of Techno-Commercial Bid.

GENERAL


(Procurement)




8 DEVIATIONS - LISTING 8.1 Tenders shall be submitted strictly in accordance with the requirements of tender

documents. Deviations (Technical as well as Commercial), if any, shall be listed out separately. Technical deviations and Commercial deviations shall be furnished in separate sheets under the headings “TECHNICAL DEVIATIONS” and “COMMERCIAL DEVIATIONS” respectively, along with reasons for taking such deviations. Deviation(s) mentioned elsewhere but not included in the Schedule of Deviations as above, shall not be accepted.

8.2 Deviations from the specifications will not ordinarily be allowed. In case the

tenderer offers an alternative /nearest equivalent equipment/specifications, the alternate offer shall be submitted by the tenderer in a separate sealed cover. The tenderer shall guarantee the performance of the store(s) for the same conditions and ensure as specified in the technical specifications.

9 ASSUMPTIONS - LISTING

If the proposal submitted has any assumptions while making technical specifications

and scope, the same shall be listed separately under the heading “ASSUMPTIONS”.

10 DELIVERY/COMPLETION SCHEDULE

10.1 ZERO DATE: The date of LOI/Order/Contract whichever is earlier shall be treated

as the Zero Date for contractual purpose.

10.2 DELIVERY PERIOD AND PACKING OF MATERIAL

10.2.1 The delivery of Plant / Equipment / Stores as per the scope of the Order / Contract shall be quoted by the bidders as per N.I.T.

10.3 In case of E&C packages the completion of Erection & Commissioning including

successful completion of Performance Guarantee (PG) / Demonstration Test(s) as per scope of the Order / Contract shall be quoted by the bidders as per N.I.T.

10.4 In case of long lead time and involving more than one consignment, delivery

schedule quoted shall be for sequential supplies as per erection & commissioning requirement.

10.5 Date of dispatch for indigenous supply and shipment date for import shall be treated as the date of delivery.

10.6 The mandatory and recommended spares shall not be packed along with the main equipment and shall be packed separately.

GENERAL


(Procurement)




11 STORAGE INSTRUCTIONS The successful tenderer shall be required to submit detailed instructions for storage

of supplies within three (3) months of the date of award of the LOI/Order/Contract.

12 VALIDITY OF OFFER

Offer shall be submitted with following validity periods:

a) Original offer shall be valid for six months from part-I opening. b) If revised price/impact is being asked the validity of the same shall be two

months from the date of price bid opening. c) Valid till successful completion of contract for Recommended spares and

Mandatory Spares (wherever it is optional item) d) Unit price for scope addition/deletion: to be kept valid till successful completion

of contract. NOTE: a. Discount offered, if any, shall be for the full durations of validity. Offers of

shorter validity or discount for shorter durations are liable to be rejected. b. Any conditional discount shall not be considered for evaluation and ordering.

13 LANGUAGE & CORRECTIONS

a) The tenderer shall quote the rates in Hindi/English language and international

numerals only. The rates entered in figures as well as in words. For the purpose of tender, metric system of unit shall be used.

b) All entries in the tender shall either be typed or written legibly in ink. Erasement and over writings are not permitted and may render such lenders liable for rejection.

c) Tenderer’s offer, remark and deviations, shall be with reference to sections and clause numbers given in tender documents.

d) All cancellations and insertions shall be duly self attested by the tenderer.

14 CHANGE OF TERMS & CONDITIONS / PRICE

14.1 Any revision or changes in quoted prices and/or conditions of offer made after tender opening, which will give benefit to the tenderer over others, may result in rejection of the tender.

14.2 Under no circumstances, tenderer shall alter his quoted Prices/Rates during the

validity period after tenders have been opened. Any tenderer who does so, resulting into re-calling of tenders by the purchaser or additional expenditure to the purchaser, shall run the risk of being black-listed by the purchaser, who reserves the right to recover the damages resulting therefrom.

GENERAL


(Procurement)




15 TENDERER TO INFORM HIMSELF FULLY

15.1 The tenderer shall closely peruse all the clauses, specifications and drawings etc., indicated in the tender documents, before quoting. Should the tenderer have any doubt about the meaning of any portion of the tender specifications or find discrepancies or omissions in the drawings or the tender documents issued are incomplete or shall require clarifications on any of the technical aspect, scope of work etc. he shall at once contact the official inviting the tender, for clarifications, before submission of the tender.

15.2 The tenderer shall make independent enquiries as to the conditions and circumstances affecting his tender estimates and to the possibility of executing the supplies/works as described. In assessing the tender, the tenderer shall be deemed to have inspected and examined the site and its surroundings and to have satisfied himself (as far as practicable) as to the form and nature of the site, the quantities and materials necessary for the completion of the work and the means of transport and access to the site, the accommodation he may require, the general labour position at the site and to have quoted his prices taking into consideration, the risks, contingencies and other circumstances which may influence or affect the execution of the Order/Contract.

15.3 It is the responsibility of the tenderer to keep himself informed of the correct rates of customs and other duties and taxes leviable for the materials/services as prevailing at the time of tendering. If the rates assumed by the tenderer are less than the tariff rates prevailing at the time of tendering, the tenderer will be himself responsible for such under quotations

16 REJECTION OF TENDER AND OTHER CONDITIONS

16.1 NBPPL reserve the right to reject any bidder if the past performance found unsatisfactory.

16.2 The acceptance of tender will rest with the purchaser and does not bind him to accept the lowest or any tender and reserves to itself full rights for the following without assigning any reasons, whatsoever :

a) To reject any or all the tenders. b) To split up the work amongst two or more tenderers.(Applicable for the contract

where E&C is not in the scope of tenderers) c) To award the work in part. (Applicable for the contract where E&C is not in the

scope of tenderers) d) To increase or decrease the quantities. e) To reject any commercial or technical deviation given in offer. f) To postpone/ pre-pone the date of opening for the tender with due

communication to the tenderer well within time.

GENERAL


(Procurement)




16.3 Standard pre-printed conditions of the tenderer attached to the offer will not be accepted and only those mentioned in the body of his offer will be considered.

16.4 Purchaser will not be bound by any power of attorney granted by the tenderer or by changes in the composition of the firm made subsequent to the award of the Order/Contract. Purchaser may, however, recognize such power of attorney and changes after obtaining proper legal advice, the cost of which will be chargeable to the Seller/Contractor concerned.

16.5 If the tenderer deliberately gives wrong information in his tender, purchaser reserves the right to reject such a tender at any stage or to cancel the Order/Contract, if awarded and forfeit the security deposit and other money due and no further communication in this regard shall be entertained.

16.6 Canvassing in any form in connection with the tender is strictly prohibited and the

tenders submitted by the tenderers who resort to canvassing are liable for rejection.

16.7 Conditional and un-witnessed tenders, tenders containing absurd or unworkable rates and amounts, tenders which are incomplete or otherwise considered defective and tenders not in accordance with the tender conditions, specifications, etc., are liable to be rejected

16.8 If a tenderer expires after the submission of his tender or after the acceptance of his

tender, NBPPL may at its discretion, cancel such tender. If a partner of a firm expires after the submission of the tender or after the acceptance of the tender, NBPPL may cancel such tender at its discretion unless the firm retains its character.

16.9 Should a tenderer or contractor or in the case of a firm or Company of contractors/ one or more of its Partners/ share holders / Directors have a relation or relations employed in NBPPL, the authority inviting tender shall be informed to the fact along with the offer, failing this NBPPL may, at its sole discretion reject the tender or cancel the contract and forfeit the Earnest Money/ Security Deposit

16.10 No Deviation to the tender conditions will normally be accepted.However if the tenderer insists for certan deviations to the conditions, financial implication thereof shall be loaded to the quoted price for evaluating the tenderer’s offer.

17 FOREIGN BIDDERS

17.1 Quotations/offers shall be submitted by the Principals themselves and not by their Indian agents/representatives. In exceptional cases, however, due to any constraint, if the Principals are unable to submit the Quotations/offers themselves, they should give an undertaking that Quotation/offer shall be submitted by their Indian agent/representative (specifying the name and address) and that they will be

GENERAL


(Procurement)




responsible for all commitments made by such Indian agent/representative and all such commitments shall be fully honoured by them.

17.2 Foreign bidders quoting directly, who have Indian agents/representatives providing

service facilities in India should note the following before submitting the offer : 17.2.1 Tenderers will be required to indicate the name and address of the

agent/associate/representative in India. 17.2.2 Foreign Bidders are required to quote FOB price inclusive of the amount of

agency commission/remuneration etc. payable to the Indian agent/associate/representative. The amount payable to the Indian agent as mentioned above should also be indicated separately. The foreign bidder is required to submit his offer duly signed, directly to the official inviting the tenders.

17.2.3 The Indian agent's commission/remuneration finally payable to the Indian agent/associate/representative in terms of the agreement and as indicated in the offer shall be paid only after successful completion of the Order/Contract, in Indian rupees converted by applying the rate of exchange (TT selling rate of State Bank Of India) prevailing on the date of the price bid opening or the date of L/C negotiations whichever is lower. The above shall not be subject to any further exchange variation.

17.2.4 Foreign bidders are required to indicate percentage and the specific value on which Indian agent's commission/remuneration is to be computed and the rate of exchange taken for this purpose, while submitting the bid.

17.2.5 In the event of breach or default on the part of the principal/manufacturer to disclose the agent/associate/ representative in India, the foreign bidder/principal/ manufacturer will be liable for banning of business, for this tender as well as subsequent tenders.

17.2.6 The Quotation/offer shall, in addition to the other details, include the following information :

i. The precise relationship between the foreign bidder and the agent. ii. Mutual interest between the foreign bidder and the Indian agent/

associate/representative being in the business with each other. iii. Any payment the Indian agent/associate/ or representative receives

in India or abroad from the principal/manufacturer over and above the agency commission/remuneration given above, whether it is as a commission/ remuneration for the contract/enquiry or as a general retainer fee.

iv. Details of the services that will be rendered by Indian agent/associate/representative whether of general nature or in relation to the particular contract/ enquiry.

v. Permanent income tax account number of the Indian agent/associate/ representative.

GENERAL


(Procurement)




vi. Income tax account number of the foreign bidder. 18 LOADING FOR DEVIATIONS & TENDER EVALUATION

18.1 LOADING FOR DEVIATIONS

18.1.1 Deviations (Commercial as well as Technical) from the Tender Specifications are

generally not acceptable. However, if any deviation is considered by the Purchaser, the same shall be loaded for comparison, while evaluating the offer.

18.1.2 Loading/loading criteria in respect of the deviation(s) shall be as specified in part-B of this GCC. If a bidder unconditionally withdraws any deviation before Price Bid opening, the same shall not be loaded.

18.1.3 Interest Rate for loading other than specified in Annexure-XII will be taken as double the Prime Lending rate of State Bank of India (Prevailing on the date of NIT) plus 2% for Administrative Charges.

18.1.4 In case of deviation from NBPPL GCC , the tenderer shall separately quote the price for withdrawal of such deviation in sealed cover

19 PRICE DISCREPANCY The following shall be considered for evaluation and ordering.

• If there is a discrepancy between the unit price and the total price, which is obtained by multiplying the unit price and quantity, or between subtotals and the total price, the correct calculated price shall be considered for evaluation and ordering.

• If there is a discrepancy between words and figures, the correct calculated price shall be considered for evaluation and ordering.

• Unit prices quoted only shall be considered as correct for evaluation and ordering.

• Taxes and duties if not specified clearly as extra shall be considered as included in the basic price & therefore shall not be reimbursed.

20 DISCOUNTS Discount offered by any bidder, against the present Tender Enquiry, which is also indicated to be applicable to any other Enquiry, shall be considered against the present Tender Enquiry only. In case only percentage discount is indicated, the same shall be applicable for optional prices also.

21 EVALUATION CRITERIA 21.1 Though, Foreign Bidders are required to quote FOB price, Price

evaluation and comparison shall be made on the basis of Free Delivery on Project site.

GENERAL


(Procurement)




21.2 Tenders will be evaluated on the basis of delivered cost i.e. total cost to the Purchaser, taking into consideration loadings as per annexure-XII for deviation, if any, and all available financial advantages, including those available from the Owner, taxation, etc.

21.3 For evaluation of exchange rate (TT selling rate of State Bank of India) as on the date of Part-II (Price Bid) opening shall be considered.

21.4 In case of foreign bidders the quoted F.O.B. price shall be loaded by following factors to arrive at total F.O.R. site price:- I. Marine freight and insurance @3% for Europe / Asia / Africa /

Australia and @5% for USA / American Continent II. Custom duty (including CVD & SAD) as per SCC “As prevailing

at time of price bid opening. III. Port handling / clearing charges @ 1% of CIF value. IV. Inland freight including L/C charges @ 1% of CIF value

GENERAL


(Procurement)

VOLUME I, PART B PAGE NO.: 1 of 20


GENERAL COMMERCIAL

TERMS & CONDITIONS

GENERAL COMMERCIAL TERMS & CONDITIONS

S. No. DESCRIPTION 1 CONTRACT 2 PRICES 3 TAXES AND DUTIES 4 STATUTORY VARIATIONS 5 TRANSPORTATION & FREIGHT CHARGES 6 VARIATION 7 SECURITY DEPOSIT CUM CONTRACT PERFORMANCE BANK GUARANTEE 8 TERMS OF PAYMENT 9 RECOVERY OF OUTSTANDING AMOUNT 10 DELIVERY/COMPLETION SCHEDULE 11 PERT CHART AND PROGRESS REPORTS 12 INSPECTION AND TESTING AT CONTRACTOR's PREMISES 13 MATERIAL DISPATCH CLEARANCE CERTIFICATE (MDCC) 14 DELIVERY FAILURE AND TERMINATION / LIQUIDATED DAMAGES 15 GUARANTEE FOR PLANT/EQUIPMENT/STORES 16 INSURANCE 17 INTER CHANGEABILITY AND CHANGES 18 PACKING 19 CONSIGNEE's RIGHT OF REJECTION 20 WITHHOLDING AND LIEN IN RESPECT OF SUM CLAIMED 21 SALES CONDITIONS 22 MATERIAL RECEIPT CERTIFICATE (MRC) 23 RISK IN STORES (FOR E & C CONTRACTS) 24 SHORTAGES/DAMAGES 25 CONFIDENTIALITY 26 DEFAULT/BREACH OF CONTRACT, INSOLVENCY AND RISK PURCHASE 27 TERMINATION OF THE CONTRACT 28 TRANSFER, SUB-LETTING/ASSIGNMENT/ SUB-CONTRACTING 29 FORCE MAJEURE 30 INDEMNIFICATION 31 CONTRACT PERFORMANCE EVALUATION 32 SETTLEMENT OF DISPUTES 33 ARBITRATION 34 LAWS GOVERNING THE CONTRACT 35 JURISDICTION OF COURT

TABLE OF CONTENTS

GENERAL


(Procurement)



GENERAL COMMERCIAL

TERMS & CONDITIONS

1. CONTRACT

The Contract between the Purchaser and Seller/Contractor is merely a Contract only and shall not be treated as a partnership between the parties to the Contract.

2. PRICES

2.1 BASIC PRICES Basic prices shall be for the entire scope of work in line with all instructions, specifications and

terms and conditions specified in the Tender Documents. 3. TAXES AND DUTIES 3.1 EXCISE DUTY 3.1.1 Seller/Contractor is required to ensure that excise duty including surcharge if any is quoted as

per the existing tariff on the date of the offer and all benefits as per existing rules have been considered.

3.1.2 Excise duty actually incurred by Seller/Contractor on self manufactured items alone shall be reimbursed at actuals against requisite documentary evidence.

3.1.3 The invoice cum Excise duty gate pass (Excise Invoice) should contain the name of ultimate consignee as specified in the Order/Contract. If excise duty is paid under protest or dispute, it shall not be reimbursed until and unless the dispute has been finally settled.

3.1.4 No excise duty shall be payable by purchaser on inputs, bought out items, raw materials and components consigned directly to site from sources other than Seller/Contractor's factory/works

3.1.5 If required by purchaser, the seller / contractor will provide a certificate stating that CENVAT benefit has been availed of on the inputs and the same has been passed on to the purchaser.

3.1.6 If the Seller/Contractor claims/obtains any refund of the excise duty paid and gets reimbursed, the same shall be refunded to the purchaser immediately.

3.1.7 Excise duty shall be paid at actual against documentary evidence but restricted to the amount and percentage shown in the Order/Contract.

3.1.8 No statutory variations shall be permissible beyond the contractual delivery period.

3.2 SALES TAX/VALUE ADDED TAX

3.2.1 Central Sales Tax / Value Added Tax shall be reimbursed only if the same is applicable/payable by the Seller / Contractor to the respective Govt. authorities meeting all statutory requirements and availing all exemptions/concessions under the respective Central Sales Tax / Value Added Tax Acts. The offer should clearly indicate CST/VAT percentage and the total amount along with concessional form/s if any.

GENERAL


(Procurement)



GENERAL COMMERCIAL

TERMS & CONDITIONS

3.2.2 Purchaser is registered in NOIDA / U.P. State vide Registration Number: - UP TIN No. : 09465707774

3.2.3 NBPPL’s PAN No. AACCN9505A 3.2.4 Central Sales Tax/Value Added Tax on direct sales by the Seller/Contractor to the purchaser

shall be reimbursed, as per tariff applicable on the approved items, but restricted to the percentage and amount shown in the Order/Contract. If it is shown as included in the quoted price, it will not be eligible for reimbursement by the purchaser.

3.2.5 Purchaser proposes to make sale-in-transit under section 6 (2) (b) of Central Sales Tax Act where goods are moving interstate. "C" form shall be issued and exchanged against E1/E2 forms based on quarterly transactions. Seller/Contractor is required to submit his request in the format enclosed as Annexure-VII. No concessional form will be issued for goods moving within the State of U.P. If the Tenderer / Seller/Contractor/Sub Contractor fails to arrange the required forms well within time and the materials are seized/ kept on hold by any Government Authorities due to lack of Documents, it will be the sole responsibility of the Tenderer / Seller/Contractor/Sub Contractor to get the same released by paying applicable charges/ penalty and then deliver it on the site.

3.2.6 If documents are submitted through bank, issuance of Form “C” shall not be insisted upon at

the time of retirement of document(s).

3.2.7 VAT ( if applicable ) invoice, in proper format prescribed by respective state sales tax act has to be submitted in the name of nodal agency specified in SCC.

3.3 SERVICE TAX:

Service tax paid by the seller/contractor to the Govt. Authorities directly shall only be reimbursed at actuals but restricted to the rate and amount mentioned in the order/ contract. The offer should clearly indicate the percentage and the total amount.

3.4 OTHER TAXES & LEVIES

All other taxes and levies other than ED, Sales tax, service tax shall be deemed to be included in the basic prices unless specified otherwise by bidder in price bid. No variation in other taxes and duties shall be payable by purchaser.

3.5 CUSTOMS DUTY 3.5.1 The customs duty element for imported items shall be included in the basic prices. No variation

in customs duty and exchange rate for imported items shall be payable by purchaser.

3.5.2 Seller/Contractor shall arrange for his own import license, if required, since purchaser will not provide any import license. Therefore, Seller/Contractor alone shall be responsible for any

GENERAL


(Procurement)



GENERAL COMMERCIAL

TERMS & CONDITIONS

delay in getting import license or non-availability of the same or completion of other related formalities. Purchaser shall not be responsible for any financial liability, whatsoever, on this account.

3.5.3 Essentiality or Project Authority (PA) certificate as per Import Policy, if required, to avail concessional customs duty, shall be clearly specified in the offer. The import contents (CIF) in terms of list of items, quantity (CIF value in rupees), foreign currency, country of origin, etc., shall be submitted as part of Price bid. For details refer SCC.

3.6 DIRECT TAX 3.6.1 Purchaser shall not be liable towards income tax of whatever nature including variations

thereof, arising out of this Order/Contract, as well as tax liability of the Seller/Contractor and his personnel.

3.6.2 Deductions of tax at source at the prevailing rates shall be effected by the purchaser before release of payment, as a statutory obligation, if applicable. TDS certificate will be issued by the Purchaser as per provision in Govt. Rules.

4. STATUTORY VARIATIONS 4.1 If the rates for taxes and duties in respect of the quoted materials and/or services assumed by

the Seller/Contractor are less than the tariff rates prevailing at the time of tendering, Seller/Contractor will be responsible for such under quotations. However, if the rates assumed are higher than the correct rates prevailing at the time of tendering, the difference will be to the credit of the Purchaser.

4.2 Statutory variations in Excise Duty, Service Tax and central Sales Tax/Value Added Tax only on self manufactured items/services rendered by vendor himself on the rates prevailing at the time of delivery in comparison to the date of offer, will be to the account of the purchaser. No other variations such as on customs duty, exchange rate, minimum wages, prices of controlled commodities, any other input etc., shall be payable by the purchaser

4.3 Notwithstanding the above, where the actual completion of the supply occurs beyond the period stipulated in the Order/Contract or any extension thereof, variations referred to above, will be limited to the rates prevailing on the dates of such agreed completion periods only. For variations after the agreed completion periods, the Seller/Contractor alone shall bear the impact for the upward revisions and for downward revisions; purchaser shall be given the benefit of reduction in taxes/duties. This will be without prejudice to the levy of penalty for delay in delivery/completion schedule.

5. TRANSPORTATION & FREIGHT CHARGES

5.1 All dispatches shall be only through the road carriers approved by the Purchaser/ Scheduled

Banks.

GENERAL


(Procurement)



GENERAL COMMERCIAL

TERMS & CONDITIONS

5.2 Road permit/entry permit, if required, as per laws of the state shall be arranged by the

Purchaser.

5.3 Owing to any reason, in case the Seller/Contractor has to resort to a mode of transport other than what was contemplated, to keep up the delivery/completion schedule incurring extra expenditure, such extra expenditure shall be borne by the Seller/Contractor.

5.4 Freight charges shall be payable after delivery of the goods at the project site. 6. VARIATION

The prices shall remain firm (or with PVC as specified in NIT) for any increase or decrease in the Order/Contract value up to plus or minus 30% unless specified otherwise in technical specification /price format. The purchaser shall have the right to increase or decrease quantities and scope up to the above extent of value and Seller/Contractor shall be bound to accept the same at the contracted prices without any escalation.

7. SECURITY DEPOSIT CUM CONTRACT PERFORMANCE BANK GUARANTEE 7.1 TIME FOR SUBMISSION 7.1.1 The successful tenderer shall submit security deposit-cum-contract performance bank

guarantee as per format given in Annexure-IV, within thirty (30) days from the date of LOI/Order/Contract to cover the due performance of the LOI/ Order/Contract and to fulfill the guarantee conditions stipulated in the Order/Contract.

7.2 VALUE

The value of bank guarantee shall be 10% of the Order/Contract value excluding taxes, duties and freight charges. If the value of the Order/Contract gets enhanced at any time, the Seller/Contractor shall submit the Bank Guarantee correspondingly to the enhanced value at the time of claiming first payment after Contract amendment, failing which the purchaser shall recover the equivalent amount from the payments due to the Seller/Contractor. For the packages like all types of cables, cable trays, cabling materials, lighting package etc, initially BG is to be submitted for 10% of order value excluding taxes & duties & freight. However BG value can be proportionately reduced after completion of Guarantee period lot-wise as applicable.

7.3 VALIDITY 7.3.1 For supply Order/Contract, the validity of the bank guarantee shall be up-to the contractual

delivery period, initially. It shall be later extended to cover the entire guarantee period plus one month, two months before expiry of its validity period.

7.3.2 For Order/Contract inclusive of erection and commissioning (E&C), the validity of bank

guarantee shall be up-to the contractual E&C completion period, initially. It shall be later

GENERAL


(Procurement)



GENERAL COMMERCIAL

TERMS & CONDITIONS

extended to cover the entire guarantee period plus one month, two months before expiry of its validity period.

7.4 The purchaser shall reserve the right and it shall be lawful on its part to forfeit and encash the

bank guarantee, in the event of any default, failure or neglect on the part of the Seller/Contractor, in fulfillment of performance of the Order/Contract.

7.5 The Security deposit-cum-contract performance bank guarantee shall be revalidated by the

seller/contractor, whenever it is warranted, till the complete fulfillment of the contractual obligations. The bank guarantee shall be extended by the seller/contractor at his cost, for a period not less than three months at a time, on the same terms for full value of the Order/Contract, before expiry of the bank guarantee.

7.6 Equivalent amount together with interest, if any, shall be recovered from the payments due to

the Seller/Contractor before releasing any payment, in the absence of a valid Bank Guarantee. 7.7 The BG should be from Schedule Bank/ Public Financial Institutions as defined in the

Companies Act.

8. TERMS OF PAYMENT

8.1 FOR SUPPLY OF MAIN SYSTEM/EQUIPMENT INCLUSIVE OF START UP AND COMMISSIONING SPARES

8.1.1 For supply package having contract value up to Rs.25 Lakh excluding taxes, duties & freight.

8.1.1.1 Hundred percent (100%) payment along with freight charges against clean receipted LR in

original (as proof of delivery of material at site) and submission of all final documents as built drawings, O & M Manuals etc. as applicable duly certified by NBPPL (Engineering).

8.1.2 For Supply package having contract value more than Rs. 25 Lacs.

8.1.2.1 Ninety percent (90%) of basic price of materials supplied, as per approved billing schedule

along with applicable 100% taxes and duties for the consignment shall be paid against dispatch documents on pro-rata basis.

8.1.2.2 Ten per cent (10%) of basic price along with freight & octroi, if any will be released on pro-rata

basis after submission of Material Receipt Certificate (MRC)which is issued by project site engineer (owner/purchaser) and submission of all final documents as applicable duly certified by NBPPL (Engineering)

8.2 SUPPLY PAYMENT FOR TURN KEY PACKAGES

8.2.1 Five per cent (5%) onetime payment of the total basic price against submission and approval of all basic design documents such as data sheets of major equipments, drawings like PID and layout process calculations, quality plan etc wherever required under category-I or II. Details of the design documents and time schedule shall be finalized in line with the Project requirements

GENERAL


(Procurement)



GENERAL COMMERCIAL

TERMS & CONDITIONS

in the kick-off meeting after award of the order/contract.

AND

Eighty per cent (80%) of basic price of materials supplied, as per approved billing schedule, along with applicable 100% taxes and duties for the consignment shall be paid against dispatch documents on pro-rata basis.

OR 8.2.2 Eighty Five per cent (85%) of basic price of materials supplied, as per approved billing

schedule wherever 5% payment against clause 8.1.1 not billed or not applicable, along with applicable 100% taxes and duties for the consignment shall be paid against dispatch documents on pro-rata

8.2.3 Five per cent (5%) of basic price along with freight and octroi, if any, will be released on pro-rata basis after submission of Material Receipt Certificate (MRC) ,which is issued by the project site engineer (owner/purchaser) after receipt of materials and its physical verification at site Collection of Material Receipt Certificate from the site and its submission for claiming this payment shall be the responsibility of the Seller/Contractor. For only supply contracts MRC shall be arranged by NBPPL based upon receipted LR provided by vendor. (Please refer Clause 22 w.r.t. MRC).

8.2.4 Ten per cent (10%) of the total basic price shall be released after i) submission of all final

documents including as built drawings, O&M Manuals etc., as applicable and ii) successful completion of PG (Performance Guarantee)/Demonstration Test (s) and handing over of the system/package, if applicable as per order/contract.

8.3 FOR ERECTION AND COMMISSIONING

8.3.1 Eighty (80%) percent payment on pro-rata basis for the work completed as per approved billing schedule shall be released as progressive payment, by the Site authorities, on submission of protocols duly signed by NBPPL site official(s)/Owner.

8.3.2 Ten per cent (10%) of the total value shall be released by the site authorities, on successful

commissioning of the complete system/package.

8.3.3 Balance ten per cent (10%) of the total value shall be released by the site authorities, on successful completion of the PG / Demonstration test(s) of the system/package to the Owner.

8.4 FOR SUPERVISION OF E&C

100% payment shall be released by the site authorities, on successful completion of E&C, PG / Demonstration test(s) of the system/package to the Owner.

8.5 FOR SUPPLY OF MANDATORY/O&M SPARES

GENERAL


(Procurement)



GENERAL COMMERCIAL

TERMS & CONDITIONS

8.5.1 Ninety per cent (90%) value of spares supplied, along with applicable 100% taxes and duties

for the consignment shall be paid against dispatch documents on pro-rata basis.

8.5.2 Balance Ten per cent (10%) of spares value along with insurance and octroi, if any as applicable, will be released on pro-rata basis after submission of Material Receipt Certificate (MRC) ,which is issued by the project site engineer after receipt of materials and its physical verification at site.

8.6 PAYMENT TO FOREGIN VENDORS 100% payment against irrevocable letter of credit/sight draft basis. Notes:- I. All payment shall be released within 90 days of submission of complete documents as per

contract. II. All type of payment to MSED vendors will be released within 45 days of receipt of complete

documents as per contract.

III. For indigenous supplies all bank charges to vendor’s account. IV. LC opening / negotiation charges to respective account. LC confirmation charges to

vendor’s account.

8.7 DOCUMENTS TO BE SUBMITTED FOR CLAIMING DISPATCH PAYMENTS 7 SETS – (1 Set consisting of following documents):

a. Invoice b. LR c. Packing List d. MDCC e. CQIR Report f. Test certificate and Guarantee certificates

3 SETS - (1 Set consisting of following documents):-

a. Invoice – Original + 2 copies b. LR – Original + 2 copies / receipted LR as applicable c. Packing list - clearly showing number of packages, gross weight net wet d. MDCC – (NBPPL/Customer as applicable) – as per SCC. e. Guarantee certificates f. Insurance intimation g. CQIR Report h. PVC Calculation and copy of all applicable indices, if PVC applicable. i. Duty drawback documents ( original excise invoice, original disclaimer certificate,

original certificate from excise authority for payment of excise duty) j. Proof of approval of drawing and document from engineering department to

GENERAL


(Procurement)



GENERAL COMMERCIAL

TERMS & CONDITIONS

establish contractual delivery date for the purpose of LD & for claiming initial 5% payment.

k. Proof of submission of final documents including as built drawings, O&M Manual as applicable

8.8 LOADING DETAILS IN CASE OF DEVIATIONS:-

The loading details in respect to deviation in payment terms, LD & PVC indicated in Annexure – XII.

8.9 NBPPL BANKERS FOR LC PAYMENT : Addresses of bankers are: State Bank of Hyderabad, Scope Complex, 7- Institutional Area Lodi Road, New Delhi-110003

8.10 BANK CHARGES All bank charges for negotiation of documents through bank shall be to the account of the Seller/Contractor.

8.11 MODE OF PAYMENT

Where the payment is to be made directly to the Seller/Contractor, the A/c Payee Cheque shall be sent by Registered Post or E-transfer / Courier Service (if feasible). Seller/Contractor to provide necessary information for E-transfer as per annexure-XIV.

8.12 No interest shall be payable by the purchaser on the security amount, bank guarantee amount or balance which may be lying with the purchaser or any money which may become due owing to difference or misunderstanding or any dispute between the purchaser and the contractor, or any delay on the part of purchaser in making periodical or final payment or any other aspects incidental thereto.

9. RECOVERY OF OUTSTANDING AMOUNT

In the event of any amount of money being outstanding at any point in time against the Seller/Contractor, due to excess payment or any other reason whatsoever, in the present order/contract or any other order/contract, the outstanding amount shall be recovered from the payments due to the seller/contractor or at any other appropriate time and manner/mode as deemed fit by the Purchaser at its sole discretion.

10. DELIVERY/COMPLETION SCHEDULE 10.1 The Seller/Contractor shall so organize his resources and perform the Order/Contract so as to

complete it as per stipulated delivery/completion schedule.

GENERAL


(Procurement)



GENERAL COMMERCIAL

TERMS & CONDITIONS

10.2 Supply of plant/equipment/stores shall not be considered complete until they have been

inspected and accepted at the place and destination specified for delivery, by the time stipulated under the terms & conditions of the Order/Contract. Mere payment by itself shall not constitute acceptance of the goods or materials in any manner, whatsoever.

10.3 Supply of plant/equipment/stores shall adhere to the quality and specifications as per

Order/Contract and shall be delivered at the destination specified in the Order/Contract.

10.4 Date of dispatch for indigenous supplies (RR/ GR date) and shipment (AWB/ B/L date) for imported supplies shall be treated as the date of delivery for the purpose of levying Liquidated Damages as per clause 14.

10.5 Terms of delivery shall be FOR Dispatch Station

11. PERT CHART AND PROGRESS REPORTS

The Seller/Contractor shall submit a detailed estimated bar chart/standard network on Prima Vera and progress Report for Master Drawings Delivery Schedule to meet the agreed delivery/completion schedule covering various key phases of the works such as design, procurement, manufacturing, shipment and field erection activities, within a period of thirty (30) days after the date of acceptance of the order/contract. This network shall also clearly indicate the interface facilities/inputs to be provided by the purchaser/owner and the dates by which such facilities/inputs are required.

12. INSPECTION AND TESTING AT CONTRACTOR's PREMISES 12.1 Inspection Agency, unless specified otherwise in the contract shall have, at all reasonable

times, access to the Seller/Contractor's premises or works, and shall have the power at all reasonable times to inspect drawings of any portion of the work or examine the materials and workmanship of the stores during its manufacture, and if part of the stores is being manufactured at other premises, the Seller/Contractor shall obtain from the Inspection Agency, permission to inspect, examine and test as if the store is being manufactured on the Seller/Contractor's premises.

An inspection call is to be issued by the Seller/Contractor as per annexure-VI.

Such inspection, examination and testing by itself shall not relieve the Seller/Contractor from any obligation under the Order/Contract. Non-conformance from the contract specifications shall be reported by the Seller/Contractor as per part – I of Annexure – V.

12.2 The Seller/Contractor shall give the Inspection Agency, reasonable notice of any material being

ready for testing, and the Inspection Agency shall (unless the inspection of tests is voluntarily waived), on giving reasonable notice to the Seller/Contractor, attend at the Seller/Contractor's premises within fifteen (15) days of the date on which the material is notified as being ready. All standard shop tests, physical and chemical tests required by the standards or as may be

GENERAL


(Procurement)



GENERAL COMMERCIAL

TERMS & CONDITIONS

prescribed or approved as per Order/Contract, shall be conducted by the Seller/Contractor. The Inspection Agency reserves the right to waive any of the above tests requirements and to prescribe new tests, if found necessary, to complete the work so as to conform to the best practices. The Seller/Contractor shall forthwith forward to the Inspection Agency, duly certified copies of the test certificates in quadruplicate, for approval. Further copies of the shop test certificates shall be bound with the instruction manuals referred to in “Seller/Contractor's documents, drawings and instruction manuals".

12.3 Where the Order/Contract provides for tests/inspections at the premises or works of the

Seller/Contractor or any sub-contractor, the Seller/Contractor, except specified otherwise, shall provide free of charge, such assistance, labour, materials, electricity, fuel, water, stores, apparatus, measuring instruments and test equipment including any other facilities as may be reasonably required to carry out such tests efficiently.

12.4 INSPECTION MEASURING AND TEST EQUIPMENTS

12.4.1 Inspection measuring and test equipments (IMTE) whether used by the Seller/Contractor or

sub-contractor shall be calibrated, maintained and controlled. Calibration shall be valid and IMTE maintained in sound condition during usage.

12.4.2 In addition to above, Seller/Contractor shall ensure the following:

a) Measurement uncertainty is known and consistent with required measurement capability of the IMTE.

b) Selection of IMTEs is compatible with the necessary accuracy and precision of required measurement.

c) IMTEs are calibrated at the required intervals against certified equipments having known valid relationship to nationally recognized standards, at recognized calibration labs.

d) Calibration records are available and traceable to the particular IMTE. e) In case, during recalibration, the IMTE is found out of calibration, report on action taken to

validate the previous results along with both calibration records of the IMTE to be furnished to Inspection Agency.

f) IMTEs are stored, handled and preserved such that accuracy and fitness are maintained and safeguarded from adjustments.

NOTE: Purchaser's decision on acceptability of the product in such cases shall be binding.

12.4.3 Responsibility of usage of valid and calibrated IMTEs by his sub-contractor(s) shall be of the

Seller/Contractor.

12.4.4 In case, calibration records are required by purchaser, copies of the same shall be furnished.

12.5 Seller/Contractor shall be fully responsible for the Quality of products supplied by sub-contractors.

13. MATERIAL DISPATCH CLEARANCE CERTIFICATE (MDCC)

GENERAL


(Procurement)



GENERAL COMMERCIAL

TERMS & CONDITIONS

13.1 When the tests have been satisfactorily completed at the Seller/Contractor's works, the

Inspection Agency shall issue a certificate to that effect within fifteen (15) days after completion of tests, but if the tests were not witnessed by the Inspection Agency or his representative, the certificate would be issued within fifteen (15) days of the receipt of the test certificates by the Inspection Agency.

13.2 Purchaser/Owner will issue MDCC to the Seller/Contractor based on the QS Note/Report from

the Inspection Agency. 13.3 Seller/Contractor will not dispatch any material before issue of MDCC by the

Purchaser/Owner. 13.4 The satisfactory completion of these tests or the issue of MDCC, shall not bind the

purchaser/Owner to accept the supply/equipment, should it, on further tests after erection, be found not to comply with the contract provisions.

14. DELIVERY FAILURE AND TERMINATION/LIQUIDATED DAMAGES 14.1 The parties hereto agree that the timely dispatch /delivery and completion of other schedules

as stipulated in order/contract shall be the essence of the Order/Contract. If the seller/contractor fails to complete the dispatch/delivery and other schedules within the time period stipulated in the order/contract, or within any extension of time granted by the purchaser, it shall be lawful for the purchaser to recover damages for breach of order/contract without prejudice to any other rights and/or remedies provided for, in the order/contract and hereunder.

14.2 DELAYED DELIVERY 14.2.1 The purchaser reserves the right to recover from the Seller/Contractor, as agreed liquidated

damages and not by way of penalty, a sum equivalent to half percent (½%) of the total contract price per week or part thereof, subject to a maximum of ten per cent (10%) of the total contract price excluding elements of taxes, duties and freight, if the seller/contractor has failed to deliver any part of the ordered stores within the period stipulated in the Order/Contract. NOTE: If the Order/Contract involves supply for two or more Units/Sets/lots of the Power Project, total value of the Order/Contract to be taken for levy of Liquidated Damages, shall be the Order/Contract value of the particular Unit/Set/lot for which the delay has taken place, provided delivery stipulated in the Order/Contract is Unit/Set/lot wise for supply packages. In case of turnkey packages LD shall be leviable on the total value (supply and E & C) in case of delay in E & C. No LD shall be withheld from supply payments.

14.2.2 The purchaser reserves the right to purchase from elsewhere on account of and at the risk and

cost of the seller/contractor with notice to the seller/contractor of the stores due for delivery but not so delivered or their equivalent, without cancelling the order/contract in respect of the stores not yet due for delivery. The manner and the method of such purchase shall be at the discretion of the purchaser.

GENERAL


(Procurement)



GENERAL COMMERCIAL

TERMS & CONDITIONS

14.2.3 Purchaser reserves the right to cancel the order/contract or a portion thereof for the stores not

so delivered at the risk and cost of the seller/contractor and the seller/contractor shall be liable to the purchaser for any excess costs thereof.

14.2.4 Seller/contractor shall continue the performance of the Order/Contract under all circumstances,

to the extent not cancelled. 15. GUARANTEE FOR PLANT/EQUIPMENT/STORES 15.1 The Seller/Contractor shall warrant that the stores supplied shall be free from all defects and

faults in design & engineering, material, workmanship and manufacture and shall be of the highest grade and consistent with the established and generally accepted standards and in full conformity with the Order/Contract specifications, drawing or samples, if any.

15.2 a) Guarantee for Supply Packages: The equipment supplied shall be guaranteed for 18 months from the date of last supply

b) Guarantee for turnkey jobs: The guarantee shall be valid for a period as stipulated in the special conditions of the Order/Contract, otherwise, 18 calendar months from the date of completion of supplies or 12 calendar months from the date of satisfactory commissioning, whichever is later. Seller/Contractor's liability in respect of any complaints, defects and claims shall not be limited to the supply and installation of replaced parts free of charge, or the repair of defective parts to the extent that such replacements are attributable to or arise from faulty workmanship, material or design, in the manufacture, of the stores but at the option of the purchaser, to the payment of the value, expenditure and damages as mentioned hereafter, provided defects on being discovered are brought to the notice of the Seller/Contractor within a period of three (3) months from the date of expiry of the guarantee period.

15.3 All replacements and repairs during the guarantee period shall be delivered and completed

promptly and satisfactorily within a period of three months from the time of reporting the defect/loss/rejection etc. If the Seller/Contractor so desires and the purchaser agrees subject to import control regulation, the replaced parts can be taken over by him or his representative or the same can be arranged to be dispatched by the Seller/Contractor or his representative at Seller/Contractor's cost. No claim, whatsoever shall be entertained by the purchaser on account of such replaced parts.

15.4 All the replaced and replenished stores shall also be guaranteed as per above clauses.

15.5 The decision of the purchaser with regard to Seller/Contractor's liability and the amount

involved, if any, payable by the Seller/Contractor under the guarantee shall be final, conclusive and binding.

16. INSURANCE 16.1 Insurance shall be arranged by NBPPL.

16.2 Bidders/Vendors shall inform the insurance company, appointed/ nominated by NBPPL/

GENERAL


(Procurement)



GENERAL COMMERCIAL

TERMS & CONDITIONS

Purchaser, the details of dispatches under intimation to NBPPL such as LR no. & date, Truck nos., P.O. no., project & value.

16.3 Insurance as applicable for field work such as third party liability, workmen

compensation, Seller/Contractor's own Tools & Plants and automobile shall be arranged by the seller/ contractor.

17. INTER-CHANGEABILITY AND CHANGES 17.1 All similar components or parts of similar equipment supplied by the seller/contractor shall be

interchangeable with one another.

17.2 Even though all the work and materials necessary for satisfactory completion of the works may not be detailed in the specifications and schedules, the cost will be considered to be within the contract price and no extra charges shall be payable. However, if there are substantial changes in the specifications of the stores/plant, consequential changes in prices shall be mutually agreed between the purchaser and the seller/contractor.

18. PACKING 18.1 The packing shall be in conformity with specification and shall be such as to ensure prevention

of damages, corrosion, deterioration, shortages, pilferage and loss in transit or storage.

18.2 Packing list shall be submitted as per standard format along with advance set of documents for claiming payment which shall also indicate:-

a) Packing size. b) Gross weight and net weight of each package. c) Contents of the package with quantity of each item separately.

18.3 In case of shipment by sea, the packing shall be sea-worthy and of international standard. 18.4 PACKING FOR SPARES 18.4.1 Different types of spares i.e. start-up/commissioning spares and initial spares (mandatory

spares and recommended O&M spares) are to be packed separately. 18.4.2 Documents for spares should have stamp/marking for easy identification and separation from

Main Equipment.

18.5 COLOUR CODING OF TAGS/MARKING/STICKERS

18.5.1 Aluminium stickers are required to be attached to large components but plastic sheet tags should be tied with small components, giving details regarding purchase order, description of the components, quantity etc.

18.5.2 Tags should be of the colour as mentioned below:

GENERAL


(Procurement)



GENERAL COMMERCIAL

TERMS & CONDITIONS

Main equipment : Yellow or white tag Mandatory spares : Pink or red tag Start-up/Commissioning spares : Blue tag O&M spares : Green tag

18.5.3 Similar colour scheme should be followed wherever stickers are pasted on components.

19. CONSIGNEE's RIGHT OF REJECTION 19.1 Not withstanding any approval which Purchaser or the Engineer may have given in respect of

the stores or any materials or other particulars or the work or workmanship involved in the performance of the Order/Contract (whether with or without any test carried out by Seller/Contractor or the Inspection Agency or under the direction of the Contract Engineer), and notwithstanding delivery of the stores where so provided to the consignee, it shall be lawful for the consignee, on behalf of the purchaser, to reject the stores or any part, portion or consignment thereof, within 30 days after actual delivery, thereof to him at the stipulated place or destination, if such stores or part, portion of consignments thereof is not in all respects in conformity with the terms and conditions of the Order/Contract whether on account of any loss, storage, deterioration or damage before dispatch or delivery or during transit or otherwise, whatsoever.

19.2 Rejected goods or materials shall be removed by the seller/contractor within a period of 15

days from the date of receipt of notice of such rejection. The expenses to be incurred in respect thereof shall entirely be borne by the seller/contractor.

20. WITHHOLDING AND LIEN IN RESPECT OF SUM CLAIMED 20.1 Whenever any claim or claims for payments of a sum of money arises out of or under the

Order/Contract against the Seller/Contractor, the Purchaser shall be entitled to withhold and also have a lien to retain such sum or sums in whole or sums in part from security, if any, deposited by the Seller/Contractor and for the purpose aforesaid, the purchaser shall be entitled to withhold the said cash security deposit or the security, if any, furnished as the case may be and also have a lien over the same, pending finalization or adjudication of any such claim. In the event of the security being insufficient to cover the claimed amount or amounts or if no security has been taken from the Seller/Contractor, the purchaser shall be entitled to withhold and have a lien to retain to the extent of such claimed amount or amounts referred to from any sum or sums found payable or which at any time thereafter may become payable to the Seller/Contractor under the same Order/Contract or any other Order/Contract with the purchaser or any other person contracting, pending finalization or adjudication of any such claim.

20.2 It is an agreed terms of the Order/Contract that the sum of money so withheld or retained under the lien referred to above will be kept withheld or retained as such by the purchaser till the claim arising out of or under the Order/Contract is determined by the Arbitrator or by the competent court, prescribed as the case may be and that the Seller/Contractor will have no claim for interest or retention under the lien referred to and duly notified as such to the seller. For the

GENERAL


(Procurement)



GENERAL COMMERCIAL

TERMS & CONDITIONS

purpose of this clause, where the Seller/Contractor is partnership firm or a limited company, the Purchaser shall be entitled to withhold and also have a lien to retain towards such claimed amount or amounts in whole or in part from any sum found payable to any partner/limited company as the case may be, whether in his individual capacity or otherwise.

20.3 It is an agreed term of the Order/Contract that the sum of money so withheld or retained under

this clause by purchaser which will be kept withheld or retained as such by the purchaser or till his claim arising out of in the same Order/Contract or any other Order/Contract is either mutually settled or determined by the arbitrator or by the competent court, hereinafter, provided, as the case may be, that the Seller/Contractor shall have no claim for interest or damages whatsoever on this account of or any other ground in respect of any sum of money withheld or retained under this clause and duly notified as such to the seller.

21. SALES CONDITIONS

With tenderer’s acceptance of provision of the terms and conditions, it will be deemed that he has waived and confirmed as cancelled any of his general sales conditions attached with the offer.

22. MATERIAL RECEIPT CERTIFICATE

a) The Seller/Contractor shall arrange Material Receipt Certificate from the concerned project site, duly signed by the purchaser/owner Site Engineer, after receipt of the material at site and its physical verification wherever E&C is in the scope of seller/ contractor

b) For supply packages – MRC shall be arranged by NBPPL. However vendor to provide copy of receipted LRs to enable NBPPL to obtain MRC from site.

23. RISKS IN STORES (FOR E & C CONTRACTS)

The seller/contractor shall perform the Order/Contract in all respects in accordance with the terms and conditions thereof. The stores and every constituents part thereof, whether in the possession or control of the Seller/Contractor, his agents or servants, or a carrier, or in the joint possession of the seller/contractor, his agent or servants and the purchaser, his agents or servants shall remain in every respect at the risk of Seller/Contractor until their actual delivery to the consignee at the stipulated place or destination or where so provided in the acceptance of offer, until their delivery to a person specified by the purchaser as interim consignee for the purpose of dispatch to the consignee. The Seller/Contractor shall be solely responsible for all loss, destructions, damage or deterioration of or to the stores from any cause whatsoever, while the stores after approval by the Inspection Agency are awaiting dispatch.

24. SHORTAGES/DAMAGES

FOR SUPPLY PACKAGES

a) Shortages in sound cases shall be replenished free of cost as early as possible by vendor. b) Shortages/Damages during transit/ handling at site, vendor shall supply replacements as early as

possible at old contractual rates upon intimation to vendor within 3 months of receipted LR.

GENERAL


(Procurement)



GENERAL COMMERCIAL

TERMS & CONDITIONS

24.1 FOR E&C PACKAGES c) Any shortages or damages during transit, transportation or handling at site, including at the

time of erection and commissioning, shall be made good by the Seller/Contractor at his risk and costs, to meet the project schedule. In case of faults/discrepancies in any material, component, sub-assembly, assembly, etc., the same shall be supplied/ replenished free of cost to enable the equipment to be put in service.

25. CONFIDENTIALITY

Seller/contractor shall, at all times, undertake to maintain complete confidentiality of all data, information, software, drawings & documents, etc. belonging to the purchaser and also of the Systems, procedures, reports, input documents, manuals, results and any other company documents discussed and/or finalized during the course of execution of the order/contract.

26. DEFAULT/BREACH OF CONTRACT, INSOLVENCY AND RISK PURCHASE 26.1 If the Seller/Contractor fails to deliver the goods or materials or any installment thereof within

the period(s) fixed for such delivery or delivers goods or materials not of the contracted quality and failing to adhere to the contract specifications or at any time repudiates or otherwise abandons the contract before expiry of such period or refuses or is unable to supply goods or materials covered by the Order/Contract either in whole or in part or otherwise fails to perform the Order/Contract or commits any breach of the Order/Contract not herein specifically provided for or in the event of the death or insanity or if the Seller/Contractor being an individual or if a firm on a partnership thereof, shall at any time, be adjudged insolvent or shall have a receiving order for administration of his estate made against him or shall take any proceeding for composition under any Insolvency Act for the time being in force or make any assignment of the Order/Contract or enter into any arrangement or composition with his creditors or suspend payment or if the firm dissolved under the Partnership Act or if the Seller/Contractor being a company is wound up voluntarily or by order of a Court or a Receiver, Liquidator or Manager on behalf of the debenture holders and creditors is appointed or circumstances shall have arisen which entitles the Court of debenture holder and creditors to appoint a receiver, liquidator or manager, the purchaser without prejudice to his right to recover any expenses, losses or damages to which the purchaser may be put to incur or sustain by reason of the Seller/Contractor's default or breach of Order/Contract shall be entitled to cancel the Order/Contract either in whole or portion thereof without compensation to the Seller/Contractor and if the purchaser so desires, he may procure upon such terms and in such manner as he deems appropriate, stores not so delivered or others of a similar description where stores exactly complying with particulars are not, in the opinion of the purchaser, which shall be final, readily procurable, at the risk and cost of the Seller/Contractor and the Seller/Contractor shall be liable to the purchaser for any excess costs provided that the Seller/Contractor shall continue the performance of the Order/Contract to the extent not cancelled under the provisions of this clause. The Seller/Contractor shall on no account be entitled to any gain on such repurchases.

GENERAL


(Procurement)



GENERAL COMMERCIAL

TERMS & CONDITIONS

26.2 Cost of the purchases made by the Purchaser at the risk and cost of the seller/contractor shall

be worked out after levying 30% overheads as departmental charges on the cost of materials purchased.

27. TERMINATION OF THE CONTRACT 27.1 The purchaser shall have the right to terminate/ cancel the Order/Contract, wholly or in part, in case

he is obliged to do so on account of any decline, diminution, curtailment or stoppage of his business and in that event, the Seller/Contractor compensation claim shall be settled.

27.2 The purchaser shall also have the right to terminate/ cancel the Order/Contract at the risk and cost of the Seller/Contractor in case either the Seller/Contractor himself or any of his representative or agent is found to have been a previous employee of the purchaser immediately before the retirement and has within a period of two years of such retirement accepted the employment of the Seller/Contractor either as a Seller/Contractor or as an employee without having obtained the prior permission of the purchaser.

27.3 In case of termination/ cancellation of main supply order/ contract, all other associated orders/ contracts like, mandatory spares/recommended spares/ E & C/ supervision of E & C also get cancelled.

28. TRANSFER, SUB-LETTING/ASSIGNMENT/SUB-CONTRACTING 28.1 The seller/contractor shall not sublet, transfer or assign this order/contract or any part thereof or

interest therein or benefit or advantage thereof save with the prior consent in writing of the purchaser. In the event of seller/contractor sub-letting, transferring or assigning this order/contract or any part thereof or interest therein or benefit or advantage thereof without such permission, the purchaser shall be entitled to cancel the order/contract and to purchase the stores from elsewhere at risk and costs of the seller/contractor and the seller/contractor shall be liable for any loss or damage which the purchaser may sustain in consequence of, or arising out of such risk purchase.

28.2 If the seller/contractor is an individual or a proprietary concern and the individual or the

proprietor dies or the partnership is dissolved or substantially affected, then unless the purchaser is satisfied that the legal representative of the individual seller/contractor or the proprietor of proprietary concern and in the case of partnership, surviving partners are capable of carrying out and completing the Order/Contract, the purchase shall be entitled to cancel the Order/Contract as to its incomplete and without being in any way liable to payment of any compensation to the estate of seller/contractor and/or to the surviving partners of the seller’s/contractor’s firm on account of the cancellation of the order/contract.

28.3 Terms and Conditions shall not get affected in case of merger/amalgamation/re-

arrangement/takeover etc. 28.4 The decision of the purchaser that the legal representatives of the deceased seller/contractor or

surviving partners of the seller’s/contractor’s firm cannot carry out and complete the order/contract shall be final and binding on the parties hereto.

GENERAL


(Procurement)



GENERAL COMMERCIAL

TERMS & CONDITIONS

29. FORCE MAJEURE 29.1 Notwithstanding anything contained in clause 14.0, if at any time, during the continuance of the

Order/Contract the performance in whole or in part by either party, of any obligations under this Order/Contract shall be prevented or delayed by reason of any war hostilities, acts of the public enemy, restrictions by Govt. of India, civil commotion, sabotage, fires, floods, explosion, epidemics, quarantine restrictions, strike, lock-outs, or acts of God (hereinafter referred to as 'event'), then, provided notice of the happening of such event is given by either party to other within fifteen (15) days from the date of occurrence thereof, neither party shall by reason of such event be entitled to terminate this Order/Contract nor shall have any claim for damages against each other in respect of such non-performance and delay in performance. Performance under the Order/Contract shall be resumed immediately after such event has come to an end or ceased to exist and decision of the purchaser as to whether the deliveries have to be resumed or not shall be final, conclusive and binding on the parties hereto.

29.2 In the event of the parties hereto not able to agree that a force majeure event has occurred, the parties shall submit the disputes for resolution pursuant to the provisions hereunder, provided that the burden of proof as to whether a force majeure event has occurred shall be upon the party claiming such an event.

29.3 Not-withstanding the above provisions, Purchaser shall reserve the right to cancel the

Order/Contract, wholly or partly, in order to meet the overall Project schedule and make alternative arrangements for completion of delivery and other schedules.

30. INDEMNIFICATION Seller/Contractor shall fully indemnify and keep indemnified the Purchaser against all claims of

whatsoever nature arising during the course and out of the execution of this Order/Contract.

31. CONTRACT PERFORMANCE EVALUATION

Performance of the Seller/Contractor in the present Order/Contract shall be evaluated by the Purchaser as per Performance Evaluation System detailed in Annexure – VIII. The Seller/ Contractor may be de-listed or put under hold or retained based on the performance in the present Order/Contract.

32. SETTLEMENT OF DISPUTES 32.1 Except as otherwise specifically provided in the Order/Contract, all disputes concerning

questions of the facts arising under the Order/Contract, shall be decided by purchaser, subject to written appeal by the Seller/Contractor to the purchaser, whose decision shall be final.

32.2 Any disputes or differences shall be to the extent possible settled amicably between the parties

hereto, failing which the disputed issues shall be settled through arbitration.

GENERAL


(Procurement)



GENERAL COMMERCIAL

TERMS & CONDITIONS

32.3 The Seller/Contractor shall continue to perform the Order/Contract, pending settlement of

dispute(s).

33. ARBITRATION 33.1 In the event of any dispute or difference arising out of the execution of the Order/Contract or

the respective rights and liabilities of the parties or in relation to interpretation of any provision by the Seller/Contractor in any manner touching upon the Order/Contract, such dispute or difference shall (except as to any matters, the decision of which is specifically provided for therein) be referred to the arbitrator appointed by the competent authority of the Purchaser.

Subject as aforesaid, the provisions of the Indian Arbitration and Conciliation Act, 1996 or statutory modifications or reenactments thereof and the rules made there under and for the time being in force shall apply to the arbitration proceedings under this clause. The venue of arbitration shall be at New Delhi or any other place whichever the purchaser deems to be fit.

33.2 In case of order/contract on Public Sector Enterprises (PSE) or a Govt. Deptt., the following

clause shall be applicable:-

In the event of any dispute or difference relating to the interpretation and application of the provisions of the Order/Contract, such dispute or difference shall be referred to by either party to the arbitration of one of the arbitrators in the department of public enterprises. The award of the arbitrator shall be binding upon the parties to the dispute, provided, however, any party aggrieved by such award may make a further reference for setting aside or revision of the award to the Law secretary, Deptt. of Legal Affairs, Ministry of Law & Justice, Government of India. Upon such reference the dispute shall be decided by the Law Secretary or the Special Secretary or Additional Secretary when so authorized by the Law Secretary, whose decision shall bind the parties hereto finally and conclusively.

33.3 The cost of arbitration shall be borne equally by the parties.

34. LAWS GOVERNING THE CONTRACT

The Contract including all matters connecting with this contract shall be governed by the Indian Law both substantive and procedural, for the time being in force including modification thereto, and shall be subject to the exclusive jurisdiction of Indian courts at Delhi/ New Delhi.

35. JURISDICTION OF COURT

Courts at Delhi/New Delhi shall have exclusive jurisdiction to decide the dispute, if any, arising out of or in respect of the contract(s) to which these conditions are applicable.


ANNEXURES

No. DESCRIPTION

I OFFER SUBMISSION AS PER NIT II AGREED TERMS & CONDITIONS III DECLARATION IV SECURITY-CUM-PERFORMANCE BANK GUARANTEE

BOND V NON-CONFORMANCE REQUEST (NCR) VI INSPECTION REQUEST VII REQUEST FOR ISSUE OF “C” FORM VIII PERFORMANCE EVALUATION SYSTEM IX BID SECURITY INSTRUCTION X BANK GUARANTEE FORMAT FOR BID SECURITY XI CHECK LIST FOR BANK GUARANTEE XII LOADING CRITERION XIII NEFT DETAILS

NTPC-BHEL POWER PROJECTS PRIVATE LTD

Not for Publication For official use

GENERAL


(Procurement)

PAGE NO.: 1 of 1


ANNEXURE-I

OFFER SUBMISSION AS PER NIT ANNEXURE – I

(To be filled up by the Bidders) Ref. No. : Dated:

NTPC BHEL Power Projects Private Limited. Contract Management & Procurement, The Corenthum, 6th Floor, Lobe No 4, Tower B, A-41, Sector-62, Noida 201309 (U.P.)

Attention: Mr.

Dear Sir, 1. Having examined the tender documents against your tender Enquiry No.

_________________________ dated _________ and having understood the provisions of the said tender documents and having thoroughly studied the requirements of NBPPL related to the work tendered for, in connection with _____(Name of Work & Project Site)____________, we hereby submit our offer for the proposed work in accordance with your terms and conditions mentioned in the tender documents, at the prices quoted by us in your price schedule format and within the delivery schedule required by you.

2. If the work or any part thereof is awarded to us, we undertake to submit security-cum-

contract performance bank guarantee as per your requirement, within thirty days of receipt of Letter of Intent/Order/Contract.

3. We have annexed to this tender the following documents:-

Part-I (Techno Commercial Bid) - in a properly sealed cover

I. BID SECURITY in separate envelope II. Complete Techno-Commercial Offer.

III. Agreed Terms and Conditions (Annexure-II). IV. Schedule of Commercial Deviations giving clause references. V. Schedule of Technical Deviations giving clause references.

VI. Unpriced copy of Price Schedule using your format as given in the tender documents. VII. Any other documents (Please specify).

Part-II (Price Bid) - in a separate, properly sealed cover, giving all tender details as per instructions. Thanking you, Yours faithfully, ( Signature of Tenderer/Bidder)/ Seal

GENERAL


(Procurement)

PAGE NO.: 1 of 2


ANNEXURE-II

ANNEXURE-II

AGREED TERMS AND CONDITIONS (This format duly filled in, signed and stamped must form part of the techno-commercial (Part-I) bid. Clauses confirmed hereunder need not be repeated in the bid.) S.No. Description Bidder’s confirmation

(YES/NO)

1(a) Acceptance of Technical Specifications, Schedules and Data

Sheets and scope of supply as per Tender Enquiry. 1(b) In case of deviations, the same have been highlighted

separately giving clause references under the heading “TECHNICAL DEVIATIONS” at Schedule-6 of Vol-1A.

2(a) Acceptance of Terms and Conditions included in the Enquiry

letter and all Vol-I General Conditions of Contract (Part-A: Instructions to bidders, Part-B: General Commercial Terms & Conditions) and Special Conditions of Contract, if applicable.

2(b) In case of deviations, the same have been highlighted

separately giving clause references under the heading “COMMERCIAL DEVIATIONS” at Schedule-5 of Vol-1A.

3(a) PRICES: Quoted prices shall remain FIRM till complete

execution of the Order/Contract. (Ref G.3 of Schedule-1) 3(b) Prices have been filled up in the Price Schedule format

attached with the tender documents at Vol-1A. 3(c) Rates of excise duty, central sales tax/ VAT & service tax

and requirement of concessional forms, have been indicated in the unpriced copy of price bid, enclosed.

4. Payment Terms: Acceptance of relevant terms of payment

as specified in the Tender Documents. (Ref G.1 of Schedule-1) 5. Bank Guarantee: Security-cum-performance BG shall be

furnished as specified in the Tender Documents.

GENERAL


(Procurement)

PAGE NO.: 2 of 2


ANNEXURE-II

Sl.No. Description Bidder’s confirmation (YES/NO)

6. Delivery: Indicate the shortest delivery period, which shall

not exceed the delivery requirement as per this Tender Enquiry. Date of LR/RR/AWB/BL shall be considered as date of delivery.

7. Liquidated Damages: In case of delay in

delivery/completion schedule, LD clause as per tender documents acceptable. (Ref G.2 of Scheule-1)

8. Part order will be acceptable. (Not applicable for turnkey

packages) 9. Validity of Offer as per clause no. 12 of “Instructions To

Bidders” acceptable. ________________________________________________________________________

Note: - The order of preference shall be N.I.T. covering letter/SCC/GCC terms

(Signature of Bidder with Name, Designation and Company’s Seal)

GENERAL


(Procurement)

PAGE NO.: 1 of 1


ANNEXURE-III

ANNEXURE-III

DECLARATION It is hereby declared that the original/revised* price bids being opened for _____________________ (Name of Package) for ________________ project is complete in all respects and contains prices for complete scope of supply, including tests etc., as per NBPPL's requirement. If in the original/revised* price bids where itemized price is not available for any part of scope of supply, including tests, etc., the same should be treated to have been included in our original/revised* price bid. Also revised price bid, if any, even though generally governed by the terms and conditions indicated in the original commercial/Price bid (unless indicated to the contrary), any price discount, if not mentioned specially in the revised price bid, the one mentioned, if any in the original price bid shall be applicable for computing final price.

It is also agreed that no further chance for seeking clarification/confirmation to any missing point will be necessary. Absence of itemised prices against some items does not mean that they are not included. Even though itemised prices are given for major items, those items which are not specially shown, are also included to meet the entire system as per NBPPL requirements.

Signature of authorised Representative Name and Designation : Name & Address of the Bidder Date Forwarded to: NTPC BHEL Power Projects Private Limited The Corenthum, 6th Floor, Lobe No 4, Tower B, A-41, Sector-62, Noida 201309 (U.P.)

(* Please delete whichever is not applicable.)

GENERAL


(Procurement)

PAGE NO.: 1 of 2


ANNEXURE-IV

SECURITY-CUM-PERFORMANCE BANK GUARANTEE BOND

In consideration of NTPC BHEL Power Projects Private Limited (hereinafter called

the "Company" having agreed from M/s__________________________________________________ (hereinafter called the said Contractor which term includes supplier for the purpose of the bond) to accept the demand under the terms and conditions of the Agreement No.__________________________ dated __________ made between_____________________________________________________ and ___________________________________________________ (hereinafter called the said agreement) of Security Deposit for the due fulfillment by the said contractor of the terms and conditions contained in the said Agreement, on production of a Bank Guarantee for Rs.________________(Rupees _____________________________________________________________ only) we, ____(indicate the name of the Bank)____ (hereinafter referred to as the Bank) at the request of _____________________________ [Contractor(s)] do hereby undertake to pay to the Company an amount not exceeding Rs._______________ against any loss or damage caused to or suffered by or would be caused to or suffered by the Company by reasons of any breach by the said Contractor(s) of any of the terms and conditions contained in the said Agreement.

2. We, ____(indicate the name of the Bank)____, do hereby undertake to pay the

amounts due and payable under this guarantee without any demur, merely on a demand from the Company stating that the amount claimed is due by way of loss or damage caused to or would be caused to or suffered by the company by reasons of breach by the said Contractor(s) of any of the terms or conditions contained in the said Agreement or by reasons of the Contractor(s) failure to perform the said Agreement. Any such demand made on the bank, shall be conclusive as regards the amount due and payable by the Bank under this guarantee. However, our liability under this guarantee shall be restricted to an amount not exceeding Rs._______________.

3. We undertake to pay to the Company any money so demanded notwithstanding any

dispute or disputes raised by the Contractor(s) in any suit or proceeding pending before any Court or Tribunal relating thereto our liability under this present being absolute and unequivocal.

The payment to so made by us under this bond shall be a valid discharge of our liability

for payment there under and the Contractor(s) shall have no claim against us for making such payment.

4. We, ____(indicate the name of the Bank)____ further agree that the guarantee herein

contained shall remain in full force and effect during the period that would be taken for the performance of the said Agreement and that it shall continue to be enforceable till all the dues of the Company under or by virtue of the said Agreement have been fully paid and its claim satisfied or discharged or till _______________

GENERAL


(Procurement)

PAGE NO.: 2 of 2


ANNEXURE-IV

office/Department/Division of NTPC BHEL Power Projects Private Limited certifies that the terms and conditions of the said Agreement have been fully and properly carried out by the said contractor(s) and also including the satisfactory performance of the equipment during guarantee period and accordingly discharge this guarantee. Unless a demand or claim under this guarantee is made on us in writing on or before the __________________*__, we shall be discharged from all the liability under this guarantee thereafter.

5. We, ____(indicate the name of the Bank)____ further agree with the Company that the

Company shall have the fullest liberty without our consent and without affecting in any manner our obligations hereunder to vary any of the terms and conditions of the said Agreement or to extend time of performance by the said contractor(s) from time to time or to postpone for any time or from time to time any of the powers exercisable by the company against the said contractor(s) and to forbear or enforce any of the terms and conditions relating to the said Agreement and we shall not be relieved from our liability by any reason of any such variation or extension being granted to the said contractor(s) or for any forbearance, act or omission on the part of the company or any indulgence by the company to the said contractor(s) or by any such matter or thing whatsoever which under the law relating to sureties would but for this provision have effect of so relieving us.

6. This guarantee will not be discharged due to the change in the constitution of the Bank

or the Contractor(s). 7. We, ____(indicate the name of the Bank)____ lastly undertake not to revoke this

guarantee during its currency except with the previous consent of the Company in writing.

Date _____________ Day of __________ for____(indicate the name of the Bank)__

(Signature of Authorized signatory)

* This date to be indicated should not be earlier than 60 days after the date contemplated under the contract.

GENERAL


(Procurement)

PAGE NO.: 1 of 3


ANNEXURE-V

NON-CONFORMANCE REQUEST (NCR)

(GRANTING OF NCR DOES NOT ENTITLE ANY INCREASE IN PRICE OR EXTENTION OF SCHEDULE, TO VENDOR)

PART-I (TO BE FILLED BY VENDOR)

NAME OF VENDOR: NCR NUMBER:

SPECIFICATION TITLE:

SPECIFICATION NUMBER:

PROJECT SITE: LOI/PO NUMBER:

DRAWING TITLE: DRAWING NUMBER:

DATE BY WHICH DECISION REQUIRED ON NCR:

SL.NO. REQUIREMENT AS PER SPECIFICATION/DRAWING

NON-CONFORMANCE OBSERVED/REQUESTED

REASON

PROPOSED ACTION:

CE IA TO

SITE IA (2 Copies)

SIGNATURE DATE SEAL

GENERAL


(Procurement)

PAGE NO.: 2 of 3


ANNEXURE-V

NON-CONFORMANCE REQUEST (NCR) (GRANTING OF NCR DOES NOT ENTITLE ANY INCREASE IN PRICE OR EXTENTION OF

SCHEDULE, TO VENDOR)

PART – II (TO BE FILLED BY IA OR SITE IA)

NCR RECOMMENDED NCR RECOMMENDED AS PER REMARKS BELOW

NCR NOT RECOMMENDED REMARKS:

ACTION Returned to Vendor

Forwarded to CE (NBPPL) (2Copies)

NAME SIGNATURE DATE

PART-III (TO BE FILLED IN BY PROJECT ENGINEER (NBPPL)

NCR APPROVED NCR APPROVED AS PER REMARKS NCR NOT APPROVED REMARKS: ( A ) WITHOUT INCREASE IN CONTRACT PRICE ( B ) WITH REDUCTION IN CONTRACT PRICE (DETAILS ENCLOSED) ( C ) WITHOUT AFFECTING PROJECT SCHEDULE ACTION

Returned to Vendor (Only in case NCR not approved) Forwarded to CMP on _____ (For issue of PO amendment)

NAME SIGNATURE DATE NOTE: Project Engineer (NBPPL) shall approve the NCR after obtaining consent/approval of affected departments/agencies and also of SH and DH.

PART- IV (TO BE FILLED BY CONTRACT ENGINEER (NBPPL)

PO No. PO Date PO Amendment No. PO Amendment Date

DISTRIBUTION VENDOR

(1COPY EACH) SITE IA

IA

ENGG.

NAME SIGNATURE DATE

GENERAL


(Procurement)

PAGE NO.: 3 of 3


ANNEXURE-V

INSTRUCTIONS FOR THE VENDOR REGARDING NON-CONFORMANCE REQUEST (NCR) 1. Photo-copies of the NCR Form can be used by the Vendor, whenever required. 2. Non-conformances, due to the following and/or other reasons, shall be raised by the Vendor,

in this form, in order to obtain NBPPL decision on the same. a) Changes from Bid Specification and Deviations agreed during negotiations

OR Changes f rom Contract S pecification r equired as a r esult o f d etailed design a nd preparation of drawings by the Vendor.

b) Changes in Contract Drawings and Documents approved by NBPPL. c) Inaccurate workmanship, procedure or practice.

d) Use of material other than the size, type of grade as called for in the specification/drawing.

3. Vendor shall send two copies of the NCR to : a) Contract Engineer (CE) of NBPPL, Contracts Department for non-conformances required

as a result of detailed design and preparation of drawings by the Vendor etc. b) Inspection A gency ( IA) f or all non -conformances dur ing m anufacture/fabrication,

assembly etc. c) Site I nspection A gency ( Site I A) f or a ll n on-conformances du ring s ite f abrication,

erection and commissioning. 4. Vendor shall mark copies of NCRs and all correspondence, in this respect, to Contract

Engineer (CE) of NBPPL, Contracts Department 5. The names and addresses of Inspection Agency and Site Inspection Agency are given in

the Letter of Intent/Purchase Order. 6. Non-conformances raised in this form only, will be entertained by NBPPL. 7. NCRs shall be kept to a minimum. 8. A summary of non-conformances granted, if any, shall be included by the Vendor in the

Quality A ssurance D ocument P ackage t o b e f orwarded t o N BPPL & C ustomer, o n satisfactory completion of inspection and tests.

9. Granting of N CR b y N BPPL doe s not e ntitle t he V endor t o a ny i ncrease i n price or

extension of schedule.

GENERAL


(Procurement)

PAGE NO.: 1 of 1


ANNEXURE-VI

I N S P E C T I O N R E Q U E S T (From Vendor to NBPPL Inspection Agency)

1. Project Site: 2. Name of Vendor: 3. NBPPL’s LOI/PO No. Date: 4. System/Item description:

5. Items being offered for inspection with Sl.No. as per LOI/PO/Billing schedule: 6. Description and Sl.No. of inspection as per quality plan: 7. Quantity offered for inspection: 8. Place of inspection (full address and name of sub-vendor, if any) Place: Address:

9. Contact person (For Sl.No. 8 above) Name: _____________________ Designation: ____________ Telephone: __________ Fax: _________ E-MAIL: _________________________________________________ 10. Following documents are approved by NBPPL and are available at the place of inspection : (A) Quality Plan (B) Drawings (C) Data Sheets, Characteristic curves etc.

(D) Plant standards 11. Required date of inspection: __________Weekly off day: ________________

Working hours: ___________ Likely duration (no. of working days): _______ (At least 15 days prior notice shall be given by the Vendor to Inspection Agency) We hereby certify that the above items are complete in all respects and have been fully inspected/ tested by us and are found to be as per technical specification/approved drawings/data sheets/characteristics curves and are acceptable to our QC department. The detailed inspection and test reports of our QC department are enclosed.

VENDOR’S PARTICULARS

Name Designation Signature Place Date Seal

GENERAL


(Procurement)

PAGE NO.: 1 of 1


ANNEXURE-VII

(Request for Issue of "C" Form)

Head (Finance Deptt.) Contract Management & Procurement, NTPC BHEL Power Projects Private Limited The Corenthum, 6th Floor, Lobe-4, Tower-B A-41, Sector-62, Noida-201309 (U.P.)

Dear Sir, Sub: Request for Issue of “C” Forms

We request you to issue us "C" forms for the invoices for which following details are being given herewith:

I. Invoice number and date : II. Items Description : III. "C" Form value :

IV. LR/R/GR number and date: We are enclosing herewith photocopies of Bill/Invoice and LR/RR/GR.

Thanking you, Yours faithfully, (Signature of the bidder with Name, Designation and Company’s Seal)

GENERAL


(Procurement)

PAGE NO.: 1 of 2


ANNEXURE-VIII

PERFORMANCE EVALUATION SYSTEM

1. PERFORMANCE EVALUATION

Performance of the Seller/Contractor shall be calculated for each Order/Contract, with respect to the following main factors and their weightages:

Rating Weightage

Quality = 60 Delivery = 30 Service = 10

Total 100

1.1 Quality Rating (QR) 60% Weightage Quality rating is based on acceptable quantity of material delivered by the Seller/Contractor.

Quality Rating (QR) = (Q1 + 0.75 X Q2 + 0 X Q3) X 60 Q Where Q = Quantity inspected Q1 = Quantity accepted

Q2 = Quantity accepted with concession/deviation Q3 = Quantity rejected 1.2 Delivery Rating (DR) 30% Weightage Seller/Contractor will be rated on delivery parameters as follows: (a) - Adherence to P.O. delivery - 30 (b) -One mark shall be deducted for each day's delay. In case of rectification / replacement of item, the delivery to be reckoned from date of completion of rectification / replacement and not the original supply date. 1.3. Service Rating (SR) 10% Weightage

Service Rating shall be given on the basis of the following criteria: (Cooperation and readiness to help in emergency; Submission of support documents such as GA Drawings, TC, GC etc., as applicable; Submission of final technical documents, O & M manuals and as built drawings complete and in time. ): 5

Promptness in reply / attending quality problems at site: 5

The above rating will also be subject to further feedback from Inspection Agency on the following criteria:

a) Item not offered as per Inspection Requirement. b) Non - availability of calibrated instruments at the time of inspection at Seller/Contractors'

works.

GENERAL


(Procurement)

PAGE NO.: 2 of 2


ANNEXURE-VIII

c) Acceptance after rework.

In above cases, Seller/Contractor will be allocated negative five marks (-5) for service rating.

Total Rating (TR) of the Seller/Contractor = QR + DR + SR 2.0 DEMERIT FACTOR Total Rating of the Seller/Contractor will be multiplied by the demerit factor (DF) to calculate the final Seller/Contractor’s Performance Score (SPR). The demerit factor is determined as detailed below:

b) Items /systems meets all design and guarantee parameters : 1.0 c) Items / systems satisfy the design / guarantee parameter : 0.9

with minor deviations & functionally acceptable. d) Items / s ystems a re p ut in to service with r ework a t site

: 0.8 e) Contractual requirements like timely erection : 0.7

/warranty obligations/service after sales etc. not met f) Items / systems rejected & replaced due to not meeting design : 0.5

/ performance requirement. SPR = TR x DF. 3.0 Based on the SPR, performance will be rated as below:

SPR RATING ACTION

100 A1 To be retained in the Vendor List as Preferred Seller/Contractor

Above 90 but less than 100 A To be retained in the Vendor List 80-90 B To be retained in the Vendor List provided

there is specific commitment to improve the area of deficiency in a time bound manner

60-79 C Tender Enquiry may not be issued in future. However, under special circumstances, enquiry may be issued with the approval of competent authority only.

Below 60 D To be de-listed/put under HOLD.

GENERAL


(Procurement)

PAGE NO.: 1 of 1


ANNEXURE-IX

1) The Bid Security is only applicable to “Open Tender Enquiry”

2) The bidder shall furnish, as part of its bid, a bid security in a separate sealed envelope in the amount and currency as stipulated in the Enquiry terms & Conditions.

3) The bid security, shall at the in any of the following forms : a. Call deposit receipt duly pledged in favour of NBPPL or pay order or demand draft. b. Post Office / National Savings/National Defence Deposit Certificated duly endorsed in favour of

NBPPL. c. Bank Guarantee from an acceptable bank –irrevocable and operative till the validity of the offer. d. Fixed deposit receipt issued by acceptable banks endorsed in favour of NBPPL.

4) Any Bid not accompanied by an acceptable bid security, in a separate sealed envelope, shall be rejected as being non-responsive and returned to the Bidder without being opened.

5) The Bid Security may be forfeited : - If the tenderer/ bidder withdraws the bid during the period of bid validity specified by the

tenderer/ bidder in their bid - If the tenderer/ bidder does not accept the correction of its Bids Price (resulting from the

arithmetical errors) as per provision in the Price Bid / Schedule of Prices. - If the tenderer/ bidder does not withdraw any deviation at the cost of withdrawal indicated by

him. - In the case of a successful tenderer/ bidder , if the tenderer/ bidder fails within the specified

time limit to furnish the Security Deposit Cum Performance Bank Guarantee.

6) The bid security of the unsuccessful tenderers /bidders will be refunded expeditiously after the award of the contracts.

7) The bid security of the successful bidder will be returned when the bidder has furnished the required Security Deposit Cum Contract Performance Bank Guarantee.

8) The bid security will be liable to be forfeited on revocation of tender before validity of the quotation (offer) expires or on refusal to enter into a contract after the award is made to the tenderer.

GENERAL


(Procurement)

P a g e N o . 1 of 2


ANNEXURE-X

PROFORMA FOR BANK GUARANTEE FOR BID SECURITY (To be issued on appropriate valid non-judicial stamp paper)

This Deed of Guarantee made this …………………… Day of 200 by …………………………………… Bank Ltd. (hereinafter called the ’Bank’), in favour of NTPC-BHEL Power projects Private Limited, “The Corenthum”, 6th floor, Tower-B, A-41, Sector 62, Noida-201309 (hereinafter called the ‘Purchaser’) through ……………….unit. Whereas M/s ………………………………………… (hereinafter called the Tenderer) have submitted a tender ………………… in response to tender specification No/ Enquiry No………………………………………… (hereinafter called the said ‘Tender Documents’) of the Company. And whereas the said tender documents provide that the Tenderer shall submit a bank guarantee for a sum of Rs…………….. (Rupees……………………………………… only) towards Bid Security to be made in the form and manner therein specified. And whereas the Tenderer ………………………… have approached ………………………………… …… (Bank) and at their request and in consideration of the arrangement arrived at between the said Tenderer and the said Bank, the said Bank has agreed to give such guarantee as hereinafter mentioned to the aforesaid Purchaser. Now, therefore, these presents witness that we …………………………… (Bank) by the hand of Shri…………………………………………. its lawfully and duly constituted attorney do hereby undertake to pay the aforesaid Purchaser a sum of Rs……………… (Rupees ……………………………………..) by virtue of this Guarantee against any loss or damage caused to or suffered by the said Purchaser by reason of any breach by the aforesaid Tenderer of any of the terms, conditions, stipulations undertakings or any one of them contained in the said Tender Documents, and for the payment of any money or moneys payable by the said Tenderer to the said Purchaser under the terms and conditions of the tender documents (the decision regarding the breach, loss, damage or payment due, being solely in the discretion of the said Company. We further undertake to pay the aforesaid amount in a lump sump on demand irrespective of the fact whether the said Tenderer admits or denies such claim or questions its correctness in any Court, Tribunal of Arbitration proceedings or before any authority. The aforesaid guarantee will remain in force and we shall be liable under the same, irrespective of any concession for the time being granted by the said Purchaser to the Tenderer in or for fulfilling conditions of the tender documents and the guarantee will remain in full force irrespective of any change of terms, conditions or stipulations or any variation in the terms of the said Tender Documents irrespective of whether notice of such change and/or variation is given to us or not and claim to receive such notice of any change and or/variation is given to us or not and claim to receive such notice of any change and or/variation of the terms and/or conditions of the said tender document is hereby specifically waived by us. Further, we shall not be released from this guarantee by any forbearance of the exercise or non-exercise of any of the powers or rights under the said tender documents by the said Purchaser against the Tenderer irrespective of whether notice of such forbearance, enforcement or non-enforcement of any powers or rights, modifications or changes made in the said tender documents or concessions shown to the Tenderer by the Purchaser is given to us or not.

GENERAL


(Procurement)

P a g e N o . 2 of 2


ANNEXURE-X

The guarantee herein contained shall not be determined or affected by the liquidation or winding up or insolvency or change in the constitution of the Tenderer but shall in all respects and for all purposes be binding and operative until all payments of all moneys due or that may become due to the said company in respect of any liability or obligation of the Tenderer under the said tender document. We the said Bank further agree that the guarantee hereinafter contained shall remain in full force and effect during the period that would be taken for the finalisation of the tender and execution of agreement thereof and that it shall continue to be enforceable till the required Contract Performance Guarantee is issued by the successful Tenderer, as stipulated in the said Tender Documents or till the Purchaser certifies that the terms and conditions of the said tender documents have been fully and properly carried out by the said Tenderer and accordingly discharges the guarantee. Unless a demand or claim under this guarantee is made on us in writing on or before the ……………….(date – tender validity date plus two months) we shall be discharged from all the liability under this guarantee thereafter. But where such claim or demand has been preferred by the Company with the Bank before the expiry of the said date, the claim shall be enforceable notwithstanding the fact that the said enforcement is effected after the said date. Any claim or dispute arising under the terms of this document shall only be enforced or settled in the Courts having jurisdiction at New Delhi only. And lastly, the …………………………………………………Bank undertakes not to revoke this guarantee during its currency except with the previous consent of the Purchaser in writing. The Bank hereby declares that it has power to issue this guarantee under the Bank’s Memorandum and Articles of Association and the undersigned has full powers to do so on its behalf under the Power of Attorney dated……………… granted to him by the proper authorities of the bank. Dated the Day of Attorney (signature of the person duly authorised to sign on behalf of the bank) ____________________________ Witness

GENERAL


(Procurement)

PAGE NO.: 1 of 1


ANNEXURE-XI

ANNEXURE-XI

Sl Details of Check Yes/No

1 Is the BG on Non-judicial stamp paper of appropriate vale, as per Stamp Act (i.e__________________________)

2 Whether the date, purpose of purchase of stamp and name of the purchaser are indicated on the back of stamp paper under the Signature of Stamp Vendor? (The date of purchase of stamp paper should not be later than the date of execution of BG and stamp paper should be purchased either in the name of the executing Bank or the Bidder on whose behalf the BG has been issued. Also, the stamp paper should not be older than six months from the date of execution of BG).

3 Has the executing officer of BG indicated his name, designation and Power of Attorney No. / Signing Power No. On the BG?

4 Is each page of BG duly signed / initialled by executants and whether stamp of Bank is affixed thereon? Whether the last page is signed with full particulars including one witness under seal of Bank as required in the prescribed proforma?

5 Does the Bank Guarantee compare verbatim with the Proforma prescribed in the Bidding Documents?

6 Are the factual details such as Bidding Document No. / Specification No., Amount of BG, Validity of BG correctly mentioned in the BG?

7 Whether overwriting/ cutting, if any on the BG have been properly authenticated under signature & seal of executants?

8 Whether BG has been issued by a Bank in line with the provisions of Bidding Documents?

GENERAL


(Procurement)

PAGE NO.: 1 of 1


ANNEXURE-XII

Annexure-XII A. PAYMENT TERMS ( LOADING )

Normally no deviation for payment is allowed, however NBPPL accept the deviation only in case of exceptional circumstances, bids shall be loaded as per following during bid evaluation

a) Supply Package Loading Criteria i) Direct payment No loading ii) Payment through Bank 4% of total price including taxes &

duties b) Supply/Turnkey Packages i) Payment demanded in 60 days 2% of total price including taxes &

duties ii) Payment demanded in 45 days 3% of total price including taxes &

duties. iii) Payment demanded in 30 days 4% of total price including taxes &

duties. iv) Last 10% supply Payment against PG Test

demanded without conducting PG test 10% of total package value (all inclusive price) & submission of additional BG for 10% value.

B. BANK GUARANTEE :- Non submission bank guarantee : No deviation is permitted

C. LIQUIDATED DAMAGES :-

i. If max limit asked for is 10% or 5% of undelivered portion - 10% value of total quoted price excluding taxes, duties & freight.

ii. If maximum limit asked is 5% of contract value instead of 10% - 5% value of quoted price excluding taxes, duties & freight

D. PRICE VARIATION CLAUSE:-.

PVC Instead of Firm Price : Maximum ceiling of PVC as demanded by vendor.

GENERAL


(Procurement)

PAGE NO.: 1 of 1


ANNEXURE-XIII

Annexure-XIII

NEFT Application Form

Name of the party

Name of the Bank

Address of the Bank

Party's A/c no

Type of A/c

IFSC CODE

Vendor’s E-MAIL ADDRESS

Authorised Signatory

Seal

THE ABOVE DETAILS ARE TO BE SUBMITTED ON THE COMPANY'S LETTERHEAD.

THE DETAILS MAY EITHER BE ATTESTED BY YOUR BANKERS OR ACCOMPANIED BY A CANCELLED CHEQUE LEAF WITH IFSC CODE & A/C NO.PRINTED ON IT.

UNDERTAKING TO REPORT IMMEDIATELY ANY CHANGES IN THE ABOVE TO BE SUBMITTED ON THE COMPANY'S LETTER HEAD

Dt. 02.05.2012. Annexure-XIV SUBMISSION OF BANK GUARANTEE FOR BID SECURITY (EMD) UPDATED SCHEDULED COMMERCIAL BANK LIST A SBI AND ASSOCIATES

1. State Bank of India 2. State Bank of Bikaner & Jaipur 3. State Bank of Hyderabad 4. State Bank of Mysore 5. State Bank of Patiala 6. State Bank of Travancore

B NATIONALISED BANKS 1. Allahabad Bank 2. Andhra Bank 3. Bank of India 4. Bank of Maharashtra 5. Canara Bank 6. Central Bank of India 7. Corporation Bank 8. Dena Bank 9. Indian Bank 10. Indian Overseas Bank 11. Oriental Bank of Commerce 12. Punjab National Bank 13. Punjab & Sind Bank 14. Syndicate Bank 15. Union Bank of India 16. United Bank of India 17. UCO Bank 18. Vijaya Bank 19. Bank of Baroda

C SCHEDULED PRIVATE BANKS (INDIAN BANKS)

1. Bank of Rajasthan 2. Catholic Syrian Bank 3. City Union Bank 4. Dhanalakshmi Bank Ltd. 5. Federal Bank Ltd 6. Jammu & Kashmir Bank Ltd 7. Karnataka Bank Ltd 8. Karur Vysya Bank Ltd

9. Lakshmi Vilas Bank Ltd 10. Nainital Bank Ltd 11. Kotak Mahindra Bank 12. Ratnakar Bank Ltd 13. South Indian Bank Ltd 14. Tamilnad Mercantile Bank Ltd 15. ING Vysya Bank Ltd 16. Axis Bank Ltd. 17. SBI Commercial & International Bank Ltd 18. IndusInd Bank Ltd 19. ICICI Bank 20. HDFC Bank Ltd. 21. Development Credit Bank Ltd 22. Yes Bank

D SCHEDULED PRIVATE BANKS (FOREIGN BANKS)

1. Abu Dhabi Commercial Bank Ltd 2. The Royal Bank of Scotland N.V. ( upto 1.07.2012) 3. Bank of America NA 4. Bank of Behrain & Kuwait B.S.C. 5. Mashreq Bank p.s.c. 6. Bank of Nova Scotia 7. Crédit Agricole Corporate and Investment Bank 8. BNP Paribas 9. Barclays Bank 10. Citi Bank N.A. 11. Deutsche Bank A.G. 12. The HongKong Shangai Banking Corporation Ltd 13. Oman International Bank S.A.O.G. 14. Societe Generale 15. Sonali Bank Ltd. 16. Standard Chartered Bank 17. J.P. Morgan Chase Bank 18. State Bank of Mauritus Ltd. 19. DBS Bank Ltd. 20. Bank of Ceylon 21. Bank International Indonesia 22. Arab Bangladesh Bank 23. Shinhan Bank. 24. China Trust commercial Bank. 25. Mizuho Corporate Bank Ltd 26. Krung Thai Bank public company Ltd. 27. Antwerp Diamond Bank N.V. 28. The Bank of Tokyo-Mitsubishi UFJ Limited. 29. Austalia & Newzealand Banking Group Limited ( upto 30.04.2013)

E OTHER PUBLIC SECTOR BANKS

1. IDBI Ltd

02.05.2012 Annexure-XV SUBMISSION OF BANK GUARANTEE AS SECURITY FOR SD/ADVANCES AND CONTRACT PERFORMANCE UPDATED SCHEDULED COMMERCIAL BANK LIST A SBI AND ASSOCIATES

1. State Bank of India 2. State Bank of Bikaner & Jaipur 3. State bank of Hyderabad 4. State Bank of Mysore 5. State Bank of Patiala 6. State Bank of Travancore

B NATIONALISED BANKS 1. Allahabad Bank 2. Andhra Bank 3. Bank of India 4. Bank of Baroda 5. Bank of Maharashtra 6. Canara Bank 7. Central Bank of India 8. Corporation Bank 9. Dena Bank 10. Indian Bank 11. Indian Overseas Bank 12. Oriental Bank of Commerce 13. Punjab National Bank 14. Punjab & Sind Bank 15. Syndicate Bank 16. Union Bank of India 17. United Bank of India 18. UCO Bank 19. Vijaya Bank

C SCHEDULED FOREIGN BANKS

1. Bank of America NA 2. BNP Paribas 3. Crédit Agricole Corporate and Investment Bank 4. Citi Bank N.A. 5. Deutsche Bank A.G 6. The HongKong and Shangai Banking Corporation Ltd

7. Standard Chartered Bank. 8. Societe Generale 9. Barclays Bank 10. The Royal Bank of Scotland N.V. ( upto 01.07.2012) and except for Main

plant Packages. 11. Bank of Nova Scotia 12. DBS Bank Ltd. 13. The Bank of Tokyo –Mitsubishi UFJ Ltd. 14. Mizuho Corporate Bank Ltd (upto 31.03.2014) 15. Shinhan Bank( upto 31.03.2013) 16. Austalia & Newzealand Banking Group Limited ( upto 30.04.2013) and except

for packages whose value exceeds Rs5000 million.

D SCHEDULED PRIVATE BANKS 1. ING Vysya Bank Ltd 2. ICICI Bank Ltd 3. HDFC Bank Ltd 4. Axis Bank Ltd. 5. Yes Bank Ltd. (Up to 30.09.2015) and except for Main Plant

Packages/Packages with estimated cost exceeding Rs.10000 Million). 6. IndusInd Bank Ltd. (upto 30.06.2012) (Except for Main Plant packages with

estimated cost exceeding Rs5000million). 7. Kotak Mahindra Bank (upto 01.03.2013) (Except for Main Plant packages with

estimated cost exceeding Rs5000million). 8. South Indian Bank Ltd. ( upto 31.08.2012) (Except for Main Plant

packages/package with estimated cost exceeding Rs5000million).

F OTHER PUBLIC SECTOR BANKS IDBI Ltd . -------------------------------------------

ANNEXURES

ANNEXURE-XVI

PROFORMA OF LETTER OF UNDERTAKING

(To be submitted by the Bidder along with his Bid)(To be executed on non-judicial stamp paper of requisite value)

Ref. ................................ Date .................................................To

NBPPL***

--------------------------

Dear Sir,

1. I*/We* have read and examined the following bid documents relating to the ................. (fullscope of work).

a) Notice Inviting Tender

b) General Conditions of Contract along with Annexures.........to.............. , Invitation toBid (INV), “Instructions to Bidders (INB)” and “Special Conditions ofContract(SCC)”.

c) Drawing Nos. ..................................

d) Technical Specifications.

2. I*/We* hereby submit our Bid and undertake to keep our Bid valid for a period ofSix (6) calendar months from the date of bid i.e. upto ........................ I*/W e*hereby further undertake that during the said period I/W e shall not vary/alter orrevoke my/our Bid.

This undertaking is in consideration of .................. *** agreeing to open my/our*Bid and consider and evaluate the same for the purpose of award of Work interms of provisions of clause entitled “A ward of Contract”, Section-INB, Conditionsof Contract in the Bid Documents.

ANNEXURES

Should this Bid be accepted, I*/we* also agree to abide by and fulfill all the terms & conditions ofprovision of the above mentioned bid documents.

Signature alongwith Seal of Company..........................................................

(Duly authorised to sign the Bid onbehalf of the Contractor)

Name ..................................................

Designation ......................................

Name of Company .............................. (in Block Letters)

WITNESS :

Signature ......................................... Date & Postal Address

Date ............................................... ..........................................................

Name & Address .......................... ..........................................................

..................................................... Telephone No. ..................................

Fax No. .............................................

* Strike out whichever is not applicable.

ANNEXURES

ANNEXURE-XVII

PROFORMA OF INDEMNITY BOND TO BE EXECUTED BYTHE CONTRACTOR FOR EQUIPMENT HANDED OVER

FOR PERFORMANCE OF ITS CONTRACT

(Entire Equipment consignment in one lot)(On non-Judicial stamp paper of appropriate value)

INDEMNITY BOND

THIS INDEMNITY BOND is made this ........................... day of ............... 20 ............... by............................. a Company registered under the Companies Act, 1956/Partnership Firm/Pro-prietary Concern having its Registered Office at ......................... (hereinafter called as ‘Contrac-tor’ or ‘Obligor ’ which expression shall include its successors and permitted assigns) in favourof ................ ***, a Company incorporated under the Companies Act, 1956 having its Reg-istered Office at ...................... and its project at ...................... (hereinafter called“......................” which expression shall include its successors and assigns) :

WHEREAS ................. *** has awarded to the Contractor a Contract for .............................vide its Letter of Award/Contract No. ......................... dated ........................... and its Amend-ment No. .........................and Amendment No. ............................. (applicable when amendmentshave been issued) (hereinafter called the “Contract”) in terms of which ..................... *** isrequired to hand over various equipment to the Contractor for execution of the Contract.

And WHEREAS by virtue of Clause No. .................... of the said Contract, the Contractor isrequired to execute an Indemnity Bond in favour of .............. *** for the Equipment handedover to it by ................... *** for the purpose of performance of the Contract/Erection portionof the Contract (hereinafter called the “Equipment”).

NOW THEREFORE, This Indemnity Bond witnesseth as follows :

1. That in consideration of various equipment as mentioned in the Contract, valued atRs. ...................... (Rupees ................................................................ ) handed over to theContractor for the purpose of performance of the Contract, the Contractor hereby under-takes to indemnify and shall keep ............*** indemnified, for the full value of the Equip-ment. The Contractor hereby acknowledges receipt of the Equipment as per dispatch titledocuments handed over to the Contractor duly endorsed in their favour and detailed inthe Schedule appended hereto. It is expressly understood by the Contractor that handingover of the dispatch title documents in respect of the said Equipment duly endorsed by

ANNEXURES

...................... *** in favour of the Contractor shall be construed as handing over of theEquipment purported to be covered by such title documents and the Contractor shallhold such Equipment in trust as a Trustee for and on behalf of ..................... ***.

2. That the Contractor is obliged and shall remain absolutely responsible for the safe transit/protection and custody of the Equipment at ............ *** project Site against all risks,whatsoever, till the Equipment are duly used/erected in accordance with the terms of theContract and the Plant/Package duly erected and commissioned in accordance with theterms of the Contract, is taken over by ................. ***. The Contractor undertakes tokeep ................ *** harmless against any loss or damage that may be caused to theEquipment.

3. The Contractor undertakes that the Equipment shall be used exclusively for the perfor-mance/execution of the Contract strictly in accordance with its terms and conditions andno part of the equipment shall be utilized for any other work or purpose whatsoever . Itis clearly understood by the Contractor that non-observance of the obligations under thisIndemnity Bond by the Contractor shall inter-alia constitute a criminal breach of trust onthe part of the Contractor for all intends and purpose including legal/penal consequences.

4. That .................. *** is and shall remain the exclusive Employer of the Equipment freefrom all encumbrances, char ges or liens of any kind, whatsoever . The Equipment shall atall times be open to inspection and checking by Engineer-in-Charge/Engineer or otheremployees/agents authorised by him in this regard. Further , .............*** shall always befree at all times to take possession of the Equipment are likely to be endangered, mis-utilised or converted to uses other than those specified in the Contract, by any acts ofomission or commission on the part of the Contractor or any other person or on accountof any reason, whatsoever , and the Contractor binds himself and undertakes to complywith the direction of demand of .............. *** to return the Equipment without any demuror reservation.

5. That this indemnity Bond is irrevocable. If at any time any loss or damage occurs to theEquipment or the same or any part thereof is mis-utilised in any manner whatsoever , thenthe Contractor hereby agrees that the decision of the Engineer-in-Charge/Engineer of...............*** as to assessment of loss or damage to the Equipment shall be final andbinding on the Contractor . The Contractor binds itself and undertakes to replace the lostand/or damaged Equipment at its own cost and/or shall pay the amount of loss of ..........*** without demur , reservation or protest. This is without prejudice to any other right orremedy that may be available to ................. *** against the Contractor under the Con-tract and under this Indemnity Bond.

ANNEXURES

6. NOW THE CONDITION of this Bond is that if the Contractor shall duly and punctuallycomply with terms and conditions of this Bond to the satisfaction of ............. ***,THEN, the above Bond shall be void, but otherwise, it shall remain in full force andvirtue.

IN WITNESS WHERE OF , the Contractor has hereunto set its hand through itsauthorised representative under the common seal of the Company , the day , month andyear first above mentioned.

SCHEDULE______________________________________________________________________________Particulars of Quantity Particulars of Despatch Value of Signature ofthe Equipment Title Documents the Attorneyhanded over ____________________ Equipment (authorised

representative)RR/GR No.\ Carrier as a token ofDate of Bill receiptof Lading

______________________________________________________________________________

______________________________________________________________________________

For and on behalf of

M/s ..............................................

WITNESS :

1. 1. Signature .................................. Signature ......................................

2. Name ....................................... Name ...........................................

3. Address .................................... Designation ..................................

Authorised representative $

ANNEXURES

2. 1. Signature ....................................

2. Name ........................................ (Common Seal in case of Company)

3. Address ....................................._______________________________________________________________________________

$ Indemnity Bonds are to be executed by the authorised person and (i) in case of Contract-ing Company under common seal of the Company or (ii) having the Power of Attorney issuedunder common seal of the company with authority to execute Indemnity Bonds, (iii) In case of(ii), the original Power of Attorney if it is specifically for this Contract or a photostat copy ofthe Power of Attorney if it is General Power of Attorney and such documents should be at-tached to Indemnity Bond.

ANNEXURES

ANNEXURE-XVIII

PROFORMA OF INDEMNITY BOND TO BE EXECUTED BYTHE CONTRACTOR FOR THE EQUIPMENT HANDED OVER IN

INSTALMENTS FOR PERFORMANCE OF ITS CONTRACT(On Non-Judicial Stamp Paper of Appropriate Value)

INDEMNITY BOND

THIS IN DEMINITY BON D is made this ........................... day of ................ 20 ...............by ............................. a Company registered under the Companies Act, 1956/PartnershipFirm/Proprietary Concern having its Registered Office at ......................... (hereinafter calledas ‘Contractor ’ or ‘Obligor ’ which expression shall include its successors and permitted as-signs) in favour of ................ ***, a Company incorporated under the Companies Act, 1956having its Registered Office at .......................... and its project at ...................... (hereinaftercalled “...............................” which expression shall include its successors and assigns).

WHEREAS ................. *** has awarded to the Contractor a Contract for .............................vide its Letter of Award/Contract No. ............................. dated ........................... and itsAmendment No. .........................and Amendment No. ............................. (applicable whenamendments have been issued) (hereinafter called the “Contract”) in terms of which..................... *** is required to hand over various equipment to the Contractor for executionof the Contract.

And WHEREAS by virtue of Clause No. .................... of the said Contract, the Contractor isrequired to execute an Indemnity Bond in favour of .............. *** for the Equipment handedover to it by ................... *** for the purpose of performance of the Contract/Erection portionof the Contract (hereinafter called the “Equipment”).

NOW THEREFORE, This Indeminity Bond witnesseth as follows :

1. That in consideration of various equipment as mentioned in the Contract, valued atRs. ............................. (Rupees .....................) handed over to the Contractor in install-ments from time to time for the purpose of performance of the Contract, the Contractorhereby undertakes to indemnify and shall keep ............*** indemnified, for the full valueof the Equipment. The Contractor hereby acknowledges receipt of the initial installmentsof the equipment as per details in the Schedule appended hereto. Further , the Contractoragrees to acknowledge receipt of the subsequent installments of the Equipment as re-quired by .............. *** in the form of Schedules consecutively numbered which shall beattached to this Indemnity Bond so as to form integral parts of this Bond. It is expressly

ANNEXURES

understood by the Contractor that handing over the dispatch title documents in respect ofthe said Equipment duly endorsed by ............. *** in favour of the Contractor shall beconstrued as handing over the Equipment purported to be covered by such title docu-ments and the Contractor shall hold such Equipment in trust as a Trustee for and onbehalf of .............. ......................***.

2. That the Contractor is obliged and shall remain absolutely responsible for the safe transit/protection and custody of the Equipment at ............ *** project Site against all risks,whatsoever, till the Equipment are duly used/erected in accordance with the terms of theContract and the Plant/Package duly erected and commissioned in accordance with theterms of the Contract, is taken over by ................. ***. The Contractor undertakes tokeep ................ *** harmless against any loss or damage that may be caused to theEquipment.

3. The Contractor undertakes that the Equipment shall be used exclusively for the perfor-mance/execution of the Contract strictly in accordance with its terms and conditions andno part of the equipment shall be utilized for any other work or purpose whatsoever . Itis clearly understood by the Contractor that non-observance of the obligations under thisIndemnity Bond by the Contractor shall inter-alia constitute a criminal breach of trust onthe part of the Contractor for all intends and purpose including legal/penal consequences.

4. That .................. *** is and shall remain the exclusive Employer of the Equipment freefrom all encumbrances, char ges or liens of any kind, whatsoever . The Equipment shall atall times be open to inspection and checking by Engineer-in-Charge/Engineer or otheremployees/agents authorised by him in this regard. Further , .............*** shall always befree at all times to take possession of the Equipment are likely to be endangered, mis-utilised or converted to uses other than those specified in the Contract, by any acts ofomission or commission on the part of the Contractor or any other person or on accountof any reason, whatsoever , and the Contractor binds himself and undertakes to complywith the direction of demand of .............. *** to return the Equipment without any demuror reservation.

5. That this indemnity Bond is irrevocable. If at any time any loss or damage occurs tothe Equipment or the same or any part thereof is mis-utilised in any manner whatsoever ,then the Contractor hereby agrees that the decision of the Engineer-in-Charge/Engineerof ...............*** as to assessment of loss or damage to the Equipment shall be finaland binding on the Contractor . The Contractor binds itself and undertakes to replace thelost and/or damaged Equipment at its own cost and/or shall pay the amount of loss of.......... *** without demur , reservation or protest. This is without prejudice to any otherright or remedy that may be available to ................. *** against the Contractor underthe Contract and under this Indemnity Bond.

ANNEXURES

6. NOW THE CONDITION of this Bond is that if the Contractor shall duly and punctuallycomply with terms and conditions of this Bond to the satisfaction of ............. ***,THEN, the above Bond shall be void, but otherwise, it shall remain in full force andvirtue.

IN WITNESS WHERE OF , the Contractor has hereunto set its hand through itsauthorised representative under the common seal of the Company , the day , month andyear first above mentioned.

SCHEDULE NO. 1______________________________________________________________________________Particulars of Quantity Particulars of Despatch Value of Signature ofthe Equipment Title Documents the Attorneyhanded over ____________________ Equipment (authorised

representative)RR/GR Carrier as a token ofNo. / Date receiptof Bill ofLading

______________________________________________________________________________

(Please number subsequent Schedules)

______________________________________________________________________________

For and on behalf of M/s ..................................................

WITNESS :

1. 1. Signature .................................. Signature ......................................

2. Name ........................................ Name ........................................

3. Address .................................. Designation ..................................

Authorised representative $

ANNEXURES

2. 1. Signature ..................................

2 Name........................................ (Common Seal in case of Company)

3. Address .................................._______________________________________________________________________________

$ Indemnity Bonds are to be executed by the authorised person and (i) in case of Contract-ing Company under common seal of the Company or (ii) having the Power of Attorney issuedunder common seal of the company with authority to execute Indemnity Bonds, (iii) In case of(ii), the original Power of Attorney if it is specifically for this Contract or a photostat copy ofthe Power of Attorney if it is General Power of Attorney and such documents should be at-tached to Indemnity Bond.

SPECIAL CONDITIONS OF CONTRACT

(SCC)

VOLUME-I

VOLUME-ISECTION : SCC

CONTENTSSL. NO. DESCRIPTION PAGE NO.

1.0 General Information 12.0 Scope of Work 23.0 Qualifying Requirements 44.0 Prices 45.0 Price Adjustment 56.0 Mode of Payment 57.0 Functional Guarantees, Liquidated Damages for

Non-Performance (Applicable for Power Transformer) 58.0 Evaluation of Bid 69.0 Work Schedule 1110.0 Functional Guarantees 1111.0 Indemnity Bond 1112.0 Storage-Cum-Erection Insurance 1213.0 Defence of Suit 1414.0 Facilities to be provided by Owner 1515.0 Progress Reports 1516.0 Ineligibility For Future Tenders 1617.0 Trial Operation 1618.0 Handing Over & Taking Over 1619.0 Fraud Prevention Policy 1620.0 Solving of Statutory Approval 1621.0 License 1722.0 Materials handling and Storage 1723.0 Security 1924.0 Safety 1925. 0 Reconciliation of Accounts 22


Power Supply arrangement and Lighting SPECIAL CONDITIONSworks in Mannavaram plant of NBPPL OF CONTRACT SECTION : SCC Page 1 of 1






VOLUME- I

All the conditions stipulated in Special Conditions of Contract (SCC) shall supplement theGeneralConditions of Contract (Purchase) (GCC), Instructions to Bidders (INB) and Tech-nical Specification Vol. II, Wherever there is a conflict, the provisions herein shall prevailover those in the GCC, INB and Techncal Specification & Data Sheet Vol. II .

1.0 GENERAL INFORMATION

1.1 NTPC Electric Supply Company Ltd. (NESCL),a wholly owned subsidiary of NTPCLtd., incorporated under the Companies Act, 1956, having its Registered Office at NTPCBhawan, Scope Complex, 7 Institutional Area, Lodi Road, New Delhi-110003 (hereinaftercalled the ‘Consultant’) has been retained by NTPC BHEL Power Projects PrivateLimited (NBPPL), a Joint venture company of NTPC Ltd. and BHEL, NTPC Bhawan,Scope Complex, 7 Institutional Area, Lodi Road, New Delhi-110003 (hereinafter calledthe Owner or Employer) for providing the consultancy services for ‘Power supplyarrangement and Lighting works on Turnkey basis for NBPPL's manufacturing plantat Mannavaram, Tirupati in the state of Andhra Pradesh’ (As specified in the INVof the bidding documents).

1.2 NBPPL invites sealed Bids (on Domestic Competitive Bidding basis) on Single Stage TwoEnvelope (Part-I: Techno commercial Bid & Part-II: Price Bid) bidding basis for 'Power supplyarrangement and Lighting works on Turnkey basis for NBPPL's manufacturing plant atMannavaram, Tirupati in the state of Andhra Pradesh against Package: MV-503. NESCL, there-fore shall receive, evaluate and conduct pre award discussion against this package alongwith post award engineering activities etc. for and on behalf of NBPPL .

Bidding document No. As specified in the INV of the bidding documents

1.3 The project shall be executed and funded by NTPC BHEL Power Projects PrivateLimited (NBPPL) and the Ownership of the aforesaid package shall remain vested withNBPPL. All eligible payments against this work shall be made by NBPPL.

1.4 “Owner” shall mean NTPC BHEL Power Projects Private Limited

For the purpose of execution of the Contract, the contractual activities on the part of the‘Owner’, wherever context requires so, shall be performed by NBPPL.

1.5 Wherever reference to NTPC Electric Supply Company Ltd is made in the bidding docu-ments, Contract,Notification/Letter of Award (in the event of Award of Contract) orany related papers/documents, it shall be deemed to be for and on behalf of NTPCBHEL Power Projects Private Limited.

1.6 The contents of Bidding Documents are as as follows:




a) Invitation to Bid-Section-INV (Vol.-I).

b) Instructions to Bidders (INB), Part-A of GCC (V ol.-I).c) General Conditions of Contract Part-B of GCC (V ol.-I).d) Special Conditions of Contract-Section-SCC (V ol.-I).e) Bid Proposal Sheet (BPS) and Price Schedules (V ol.-IA).f) Technical Specifications (V ol.-II)

In case of any discrepancy between the provisions of this Special Conditions ofContract (SCC) and other volumes/sections of the Bidding Documents, the provisionsof this SCC shall prevail.

1.7 Unless brought out clearly, the Bidder shall be deemed to conform strictly to the provisionsof Bidding Documents. Any discrepancy between Specifications and the technical literature/catalogues and drawings with the Bid will not be considered.

1.8 The respective rights of the Consultant/Owner and Bidders/Contractors shall be gov-erned by the Bidding Documents/Contracts signed between the Owner and the Con-tractor for the respective packages.

2.0 SCOPE OF WORK

2.1 The scope of the work shall be completely covering all the equipments andtheir Installation/Erection specified under the accompanying Technical Specifications. Itwill include the following:

i) For Power supply arrangement works :

a. Supply, installation and commissioning of 01 no. of 33/0.433 kV indoorsubstation (3x2.5MVA) in existing switchgear building.

b. Supply of material, installation and commissioning of 2x1000kV A+ 1x500kVADG sets.

c. Supply & laying (including jointing and termination) of 33kV & L T XLPEpower cables.

(ii) For Lighting works :

a. Building lighting works in various buildings of the site.b. Area lighting including Street lighting, garden lighting etc.

ii) Providing engineering data and drawings, as per specified format, foremployer's review, approval and records.

iii) Complete Manufacturing including Type, Acceptance & Routine testing, as




specified.iv) Packing and transportation from the manufacturer's works to the site

including transit insurance & customs clearance/ port clearance (ifrequired), port handling, clearance for imported goods and further loading (ifapplicable) "As delivered at site basis".

v) Receipt, Unloading, Storage, Insurance and Preservation of material &accessories at site.

vi) Handing over of the completed system to the Ownervii) Satisfactory conclusion of the Contract

2.2 The detailed scope of work covered under the package is specified in theTechnical Specifications, Volume-II (TS) and Technical Data Sheet (V ol. II)for specific packages.

2.3 Before proceeding with the work, the Contractor shall fully familiarise himself with the siteconditions. It shall be the responsibility of the Contractor to arrange all inputs required fordetailed engineering and execution. The Bidders are advised to visit the site, collect allnecessary inputs and acquaint themselves with the topography, infrastructure etc. The Con-tractor shall be fully responsible for providing all equipment, materials, systems and servicesspecified or otherwise which are required to complete the work and successful testing &commissioning of the system.

2.4 All materials including Steel and cement required for the civil works (If any) shall be sup-plied by the Contractor.

2.5 Any other items not specifically mentioned in the Specifications but which are required forerection, testing, commissioning and satisfactory operation of the system are deemed to beincluded in the scope of the Specifications unless specifically excluded.

2.6 Exclusion from Scope of work:

(i) Owner shall be responsible for obtaining at its cost Right of way for the transmissionline/cable laying works, forest claerance, environmental clearance, Crop compensa-tion, Land compensation, Tree compensation, PTCC clearance, Railway Crossing Clear-ance etc., if required.

(ii) Requisite leveled land including the acquisition of land for construction of substation alongwith construction power (if required) or any site survey shall be done by owner.

(iii) Following facilities shall also be provided by Owner:

(a) Construction of switchgear room




(b) Sheds for DG sets (2X1000+1X500kVA) shall be constructed.

(c) Construction of cable trenches including RCC covers and GI cable trays in the

i. Fabrication building for power supply to respective machinery

ii. Switchgear room

(d) Readiness of all building and structures/equipment, so that fronts are available forcompletion of erection works.

3.0 QUALIFYING REQUIREMENTS

3.1 The Qualifying Requirements for the Bidders are based on meeting the minimum pass/fail criteria specified in Section-INV of the bidding documents.

4.0 PRICES

4.1 The items/equipment/materials/works (referred to as ‘items’ for the sake of brevity) gener-ally required for completion of the scope of work as per the Technical Specifications (TS),Vol.-II of Bidding Documents, are described and given in Schedules of Items and Prices(Price Schedules) forming part of Bid Proposal Sheets (BPS) of Bidding Documents. How-ever, the brief descriptions of work shall not be construed to limit the scope of work, and thesame shall be read in conjunction with corresponding sections of TS including amendment/errata, if any, thereto.

4.2 Bidder shall quote price of equipment/material inclusive of all taxes and duties, levies, cessetc. and Freight& Insurance Charges as applicable for FOR destination site delivery of allthe item/material.

4.3 Bidder shall quote charges for erection, testing & commissioning (which shall be inclusive ofcharges for unloading, storage, insurance etc.) of all items, which are to be supplied and/orerected/installed at site and charges of associated civil works as specified in TS. Thesecharges together for all equipment/materials/spares, as applicable, shall be deemed to beincluded in the ‘Erection Charges’ to be quoted against the items indicated in relevant scheduleof BPS. In addition, the cost of all materials required for successful erection, testing andcommissioning of the system including the associated civil works, not indicated separately inthe schedule of supply items in the BPS but required as per TS, shall be deemed to beincluded in the ‘Erection Charges’.

4.4 Bidders shall include the cost of type tests and other tests, to be carried out in line with theTechnical Specifications, in the bid price.

4.5 Bidders shall include the Service Tax in the bid price.




5.0 PRICE ADJUSTMENT

Prices for Ex-works price component for all equipments/items, Erection Charges,Charges for Inland Freight charges etc shall be FIRM and no price adjustment shallbe applicable for these components for the entire duration of the Contract.

6.0 Mode of Payment

6.1 All invoices under the Contract shall be raised by the Contractor on ‘M/s NBPPL’, andall payments shall be made to the Contractor by NBPPL, as per terms and conditions ofLOA/PO.

7.0 FUNCTIONAL GUARANTEES, LIQUIDATED DAMAGES FOR NON-PER-FORMANCE (APPLICABLE FOR POWER TRANSFORMER)

7.1 The bidder shall guarantee that the Power Transformer offered shall meet the rating andperformance requirements stipulated for various equipment covered in this specification.The Bidder shall also furnish a declaration and details in the manner prescribed in the rel-evant schedule of Bid Proposal Sheets for guarantees which shall attract levy of liquidateddamages for non-performance as given below:

7.2 If the guarantees are not established at factory tests, then NTPC Electric Supply CompanyLtd. at its discretion may reject or accept the equipment after assessing the liquidated dam-ages against the Contractor and such amounts shall be deducted from the Contract Price orotherwise recovered from the Contractor.

7.3 Conditions for Losses Exceeding Guaranteed Values

Power Transformer

a) Employer reserves the right to reject any transformer, if during testing it is found that totallosses exceed the guaranteed maximum total losses, declared in Bid Proposal Sheet.

b) If the total losses exceed the declared maximum value up to 10%, the same may be ac-cepted with liquidated damages. The liquidated damages shall be calculated as below.

c) No incentive shall be given, if measured losses are less than the guaranteed losses. For eachkW of losses in excess to the guaranteed losses, an amount of `2,74,816/-(2*1,37,408/-)per kW for excess No load losses (Iron loss) and ̀ 82,444/- (2* 41,222/- ) per kW forexcess load losses (including losses due to cooling fan) will be deducted from contract price.

7.4 Loss capitalisation of Transformers and evaluation

The factors and respective Indian Rupees values per unit loss of the transformers for thepurpose of calculation of the loss capitalization for the bid as specified in clause 7.0 of the




.olSnoitpircseD

noitasilatipaCnisegrahC ` rof

norI(ssoLdaoLoNCged57ta)ssoL

noitasilatipaCnisegrahC ` rof

ssoLdaoL)ssoLreppoC(

Cged57ta

.1 Vk334.0/33AVM5.2)aremrofsnarTrewoP Wkrep804,73,1 Wkrep222,14

The supplier shall furnish the maximum guaranteed values of no load and full load losses (at75 deg C) with no plus tolerance. This offer shall be evaluated on the basis of capitalizationof losses.

For the purpose of evaluation of transformers the best of the individual parameters for ironand copper losses for same rating of transformers quoted by any of the bidder in relevantschedule of BPS vol. IB shall be taken as the base and the difference between this and thosequoted by the other bidders multiplied by the evaluation factor and the number of trans-former included in the scope shall be used to arrive at the adjustment on the basis of per kWdifferential losses in Rupees indicated above, will be added to Bid price.

7.5 The amount of liquidated damages so recoverable shall be without any ceiling and shall notprejudice the Contractor's other liabilities under the Contract in any manner. The liquidateddamages for shortfall in guaranteed parameters and for delay in completion are independentof each other and shall be applicable separately and concurrently.

7.6 Particulars, Performance & Efficiency of Equipment/Materials

Bidder shall state the guaranteed technical particulars, performance or efficiency of differentequipment/materials in response to the Technical Specifications. Goods offered shall haveminimum acceptable particulars/performance/efficiency specified in Technical Specification.

8.0 EVALUATION OF BID

8.1 EVALUATION OF TECHNO COMMERCIAL BID (PART-I)

8.1.1 NTPC Electric Supply Company Ltd. will initially examine the Techno Commercialbids to determine whether they are complete, whether any computational errors have

SCC shall be stipulated as below,




whether each bid is of acceptable quality , is generally complete and is substantiallyresponsive to the bidding documents. For purpose of this Clause, a substantiallyresponsive bid is one, which conforms to all the terms, conditions and specification ofthe Bidding Document without material deviations. A material deviation, objections,conditionality, or reservation is one

(i) which limits in any substantial way the scope, quality , or performance of contract , or

(ii) that limits in any way , inconsistent with the bidding documents, the Owner's rights orthe bidder ’s obligation under the contract or

(iii) whose rectification would affect unfairly the competitive position of other bidderspresenting substantially responsive bids and which affects in any way the prices,quality, quantity or delivery period of the equipment or which limits in any way theresponsibilities or liabilities of the Bidder of any right of the Owner as required inthese specifications and documents. NTPC Electric Supply Company Ltd.’ sdetermination of a bid’ s responsiveness shall be based on the contents of the biditself without recourse to extrinsic evidence.

8.1.3 A bid determined as not substantially responsive will be rejected and may notsubsequently be made responsive by the Bidder by correction of the non-conformity .

8.1.4 NTPC Electric Supply Company Ltd may waive any minor informality or non-conformity or irregularity in a bid which does not constitute a material deviationprovided such waiver does not prejudice or af fect the relative ranking of any Bidder .

8.1.5 The Consultant, by the examination of Techno-Commercial Bid, will determine to itssatisfaction whether the participating bidders are qualified to satisfactorily perform thecontract in terms of the qualifying requirements stipulated in the Bidding Documentunder Section-INV. The determination will take into account the bidder's financial andtechnical capabilities, in particular its contracts, works in hand, future commitmentsand current litigation. It will be based upon an examination of documentary evidenceof bidder's qualification submitted by the bidder in Schedule-1 1 of BPS of Techno-Commercial Bid as well as such other information as the Owner deems necessaryand appropriate. The bidder shall furnish required information promptly to theemployer. The Owner/Consultant will shortlist the bidder meeting the stipulatedQualifying Requirements.

8.1.6 An a ffirmative determination will be a prerequisite for further evaluation of Techno-Commercial bid and holding post bid discussions, if any , with the Bidder . A negativedetermination will result in rejection of the Bidder's Techno-Commercial Bid in whichevent the Owner/Consultant will return the earlier submitted sealed Price Bid envelope

been made, whether required sureties have been furnished, whether the documentshave been properly signed, and whether the bids are generally in order .

8.1.2 Prior to the detailed evaluation, NTPC Electric Supply Company Ltd. will determine




to the concerned bidder within 30 days of Price bid opening.

8.1.7 The capabilities of the vendors and subcontractors, proposed in Schedule-4 of BPS,will also be evaluated for acceptability . Their participation should be confirmed with aletter of intent between the parties, as needed. Should a vendor or subcontractor bedetermined to be unacceptable, the bid will not be rejected, but the Bidder will berequired to substitute an acceptable vendor or subcontractor without any change inthe bid price quoted in Price Proposal prior to award.

8.1.8 The Consultant will then carry out the evaluation of Techno-Commercial Bid (of thequalified bidders shortlisted as above) on the basis of their responsiveness to thescope of services, Technical Specification and other terms and conditions specified inthe Bidding Documents to ascertain whether Techno-Commercial bid is generallycomplete, whether required securities have been furnished, whether documents havebeen properly signed, whether bids are generally in order and are substantiallyresponsive.

8.1.9 The Consultant will carry out a detailed evaluation of Techno-commercial Bids inorder to determine to be substantially responsive whether the technical aspects are inaccordance with the requirements set forth in the bidding documents. In order toreach such a determination, the Consultant will examine and compare the technicalaspects of the bids on the basis of the information supplied by the bidders, takinginto account the following factors:

(a) Overall completeness and compliance with the Technical Specifications and tenderDrawings; and quality , function and operation of any process control concept includedin the bid. The bid that does not meet acceptable standards of completeness,consistency and detail will be rejected for non-responsiveness.

(b) Any other relevant factors listed in the General Conditions of Contract, SpecialConditions of Contract and Instruction to Bidders, or that the Owner/Consultantdeems necessary or prudent to take into consideration.

(c) Compliance with the time schedule as specified in the bidding documents.

(d) Functional Guarantees of the facilities as specified in Bid Proposal Sheet. GCC, SCC& Technical Specification of Bidding Document.

8.1.10 Bidder may note that deviations, variations and additional conditions etc. are to beindicated in Schedule-5 & 6 and if found anywhere in the bid, shall not be giveneffect to in evaluation and it will be assumed that the Bidder complies to all theconditions of Bidding Documents. In case the Bidder refuses to withdraw , withoutany cost to the Employer , the deviations found anywhere in the bid, his bid will berejected and the bid security will be forfeited.




8.2 OPENING OF PRICE PROPOSAL (PART-II) AND EVALUAT1ON8.2.1 After the evaluation process of Techno-Commercial bid is completed, the Consultant

will inform in writing the eligible Bidders regarding date, time and venue set for theopening of Price Proposal Bidders, whose Techno commercial Bid is not substantiallyresponsive, shall also be informed in writing and their Price Bid will not be openedand the same shall be returned along-with bid security with in 30 days of Price bidopening.

8.2.2 Price Bid of those Bidders, whose Techno-Commercial Bid is found to besubstantially responsive, will be opened in presence of the Bidder's authorizedrepresentatives (not exceeding two per Bidder) who choose to attend. All importantinformation and any such other detail, as may be considered appropriate by theEmployer will be read out during the bid opening.

8.2.3 The consultant will determine whether the Price Bid is complete, (i.e. whether theyhave taken into account cost of all services/items of the corresponding Techno-Commercial bid) otherwise, the consultant will add cost of the same to the initialprice and correct any computational/ arithmetical errors.

8.2.4 Arithmetical errors in the Price Bid will be rectified on the following basis:

(a) If there is a discrepancy between the unit price and the total price that is obtainedby multiplying the unit price and quantity , the unit price shall prevail and total priceshall be corrected. If there is a discrepancy between words and figures, the amountin words will prevail. If the Bidder does not accept the correction of the errors asabove, his Bid will be rejected and the amount of Bid guarantee forfeited.

(b) All errors in totaling in the amount column and in carrying forward totals shall becorrected.

(c) The totals of various sections of Schedule of Quantities as amended shall be carriedover to the General Summary and the bid sum amended accordingly . The bid sumso altered shall, for the purpose of bid, be substituted for the sum in Original bidand considered for evaluation and comparison of the bids and also for acceptance ofthe bid, instead of the original sum quoted by the Bidder .

(d) The Bidder should ensure that the prices furnished in same price schedule(identified as unique schedule number) are consistent with each other . In case ofany inconsistency in the prices furnished in the same price schedule, the Owner/Consultant shall be entitled to consider the highest price for the purpose of evaluationand for the purpose of award of the Contract use the lowest of the prices in thisschedule.

8.2.5 The evaluation shall be based on the evaluated cost of fulfilling the contract incompliance with all commercial, contractual and technical obligations under this BiddingDocument.




8.2.6 Technical Evaluation

Consultant will carry out a detailed evaluation of the bids previously determined tobe substantially responsive in order to determine whether the technical aspects are inaccordance with the requirements set forth in the bidding documents. In order toreach such a determination, the Consultant will examine and compare the technicalaspects of the bids on the basis of the information supplied by the bids. The bidthat does not meet minimum acceptable standards of completeness, consistency anddetail, will be rejected / non-responsiveness.

8.3 BASIS OF EVALUATION & COMPARISON OF BIDS

8.3.1 Bidder has to quote for the complete scope of work for the packages as stated inTechnical Specifications, Volume-II. Bids for individual items or incomplete servicesshall be treated as incomplete and are liable to be rejected.

8.3.2 The bid evaluation for the package(s) shall be carried out package wise. However ,discount(s) of fered, if any , shall also be considered in evaluation.

8.3.3 Conditional discounts/rebates, if any , of fered by the bidder shall not be taken intoconsideration for evaluation. It shall, however , be considered in case of award.

8.3.4 Bid stipulating commissioning dates beyond that specified under the Clause 9.0 titled“Work Schedule” in of SCC Vol-I run the risk of rejection.

8.3.5 Bids shall be evaluated and compared on the basis of lump sum price for the Entirescope of work under the package. The lump sum price shall include:

(i) FOR destination (site) price of equipment/ materials, including F&I, type testand mandatory spares (if any).

(ii) Charges for erection, which shall include unloading, handling, storage, insur-ance, erection, testing & commissioning of the complete system and all asso-ciated civil works. Service Tax Shall also be taken for evaluation

(iii) Differential price on account of deficiency in the equipment and services offered. (iv) Loading on account of diffirent parameters as indicated in bidding document and at

Annexure-XII of GCC and as per clause 18 of Part-A of GCC (Instruction to Bidders).

Price of Recommended spares (If any) shall not be taken for evaluation purpose.

8.3.6 The prices of all such items against which bidder has not quoted rate/amount (viz.items left blank or against which ‘-’ is indicated) in the schedules will be deemed tohave been included in other item(s)/total quoted bid price.

8.3.7 For the purpose of evaluation of transformer , the best of the individual parameters for




iron and copper losses for same rating of transformers quoted by any of the bidderin relevant schedule of BPS Vol. IA shall be taken as the base and the differencebetween this and those quoted by the other bidders multiplied by the evaluation fac-tor and the number of transformer included in the scope shall be used to arrive atthe adjustment on the basis od per kW differential losses in Rupees indicated inSCC, will be added to Bid Price.

8.3.8 The bids shall be compared on the basis of lump-sum prices (i.e. for supply portionand prices for services to be rendered as quoted by the Bidder) for the entirescope of the Proposal as defined in the Bidding Document.

8.3.9 All evaluated bid prices of all the Bidders shall be compared among themselves todetermine the lowest evaluated bid and, as a result of this comparison, the lowestBid will be selected for the award of the Contract.

9.0 WORK SCHEDULE

9.1 The Bidder shall include in his proposal his programme for furnishing and erectingthe equipments covered under the package. The programme shall be in the form ofa bar chart / master network identifying key phases in various areas of total worklike procurement of raw material/bought out items/components, manufacturing, typetesting, supply of materials and field activities such as foundation, erection etc. andtesting & commissioning of transformers, DG sets s o a s t o achieve testing &commissioning of all equipments/materials under each of the Package within 06(Six) months from the date of Letter of Award/Purchase Order .

9.2 The schedule shall be reckoned from the date of issue of Leter of Award/PO, Within 15(fifteen) days of issuance of Letter of Award/PO, Contractor shall submit Bar Chart/PERTNetwork conforming to the delivery/erection dates mentioned in Letter of Award /PO forreview and approval. After approval of Bar Chart/PERT Network, one reproducible withsufficient number of prints as desired by Owner, shall be submitted.

9.3 The provisions of liquidated damages leviable in case of delay in completion pursuant toClause 14 of Part-B, GCC shall become effective after the period mentioned above forsuccessful completion of testing and commissioning.

10.0 FUNCTIONAL GUARANTEES

Particulars, Performance & Efficiency of Equipment/Materials Bidder shall state the guar-anteed technical particulars, performance or efficiency of different equipment/materials inresponse to the Technical Specifications. Goods offered shall have minimum acceptableparticulars/performance/efficiency specified in Technical Specification.

11.0 INDEMNITY BOND




11.1 For the materials/equipment to be provided by the Owner/Consultant, it will be the respon-sibility of the Contractor to take delivery, unload and store the materials at site and executean indemnity bond as per proforma at Annexure-XIV, Conditions of Contract, Vol.-I infavour of NBPPL. against loss, damage and risks involved for the full value of the materials.This indemnity bond shall be furnished by the Contractor before commencement of thesupplies and shall be valid till the scheduled date of testing, commissioning and handing overthe equipment and entire system to owner.

12.0 STORAGE-CUM-ERECTION INSURANCE

12.1 The Contractor at his cost shall arrange, secure and maintain all insurance as may be perti-nent to the Works and obligatory in terms of law to protect his interest and interests of theEmployer against all perils detailed herein. The form and the limit of such insurance as de-fined herein together with the under-writer in each case shall be acceptable to the Employer.However, irrespective of such acceptance, the responsibility to maintain adequate insurancecoverage at all time during the period of Contract shall be of Contractor alone. TheContractor’s failure in this regard shall not relieve him of any of his contractual responsibili-ties and obligations. The insurance covers to be taken by the Contractor shall be in the jointname of the Employer and the Contractor. The Contractor shall, however, be authorized todeal directly with Insurance Company or Companies and shall be responsible in regard tomaintenance of all insurance covers. Further the insurance should be in freely convertiblecurrency.

12.2 Any loss or damage to the equipment during handling, transportation, storage, erection,putting into satisfactory operation and all activities to be performed till the successful comple-tion of commissioning of the equipment shall be to the account of the Contractor. The Con-tractor shall be responsible for preference of all claims and make good the damages or lossby way of repairs and/or replacement of the equipment, damaged or lost. The transfer oftitle shall not in any way relieve the Contractor of the above responsibilities during the periodof Contract. The Contractor shall provide the Employer with copy of all insurance policiesand documents taken out by him in pursuance of the Contract. Such copies of documentsshall be submitted to the Employer immediately after such insurance coverage. The Con-tractor shall also inform the Employer in writing at least sixty (60) days in advance regardingthe expiry/cancellation and/or change in any of such documents and ensure revalidation,renewal etc., as may be necessary well in time.

12.3 The perils required to be covered under the insurance shall include, but not be limited to fireand allied risks, miscellaneous accidents (erection risks) workman compensation risks, lossor damage in transit, theft, pilferage, riot and strikes and malicious damages, civil commo-tion, weather conditions, accidents of all kinds, etc. The scope of such insurance shall beadequate to cover the replacement/reinstatement cost of the equipment for all risks upto andincluding delivery of goods and other costs till the equipment is delivered at Site. The insur-




ance policies to be taken should be on replacement value basis and/or incorporating escala-tion clause. Notwithstanding the extent of insurance cover and the amount of claim availablefrom the underwriters, the Contractor shall be liable to make good the full replacement/rectification value of all equipment/materials and to ensure their availability as per projectrequirements.

12.4 All costs on account of insurance liabilities covered under the Contract will be on Contractor’saccount and will be included in Contract Price, However, the Employer may from time totime, during the pendency of the Contract, ask the Contractor in writing to limit the insurancecoverage, risks and in such a case, the parties to the Contract will agree for a mutual settle-ment, for reduction in Contract price to the extent of reduced premium amount. The Con-tractor, while arranging the insurance shall ensure to obtain all discounts on premium, whichmay be available for higher volume or for reason of financing arrangement of the project.

12.5 All the equipment and materials including spares, if any, being supplied by the Contractorshall be kept completely insured by the Contractor at his cost from time of dispatch from theContractor’s works/Sub-Vendor’s works, upto the completion of erection, testing & com-missioning at site and taking over of the system by the owner in accordance with the Con-tract.

12.6 Further all equipment and materials being supplied by NBPPL free of cost for the erection(as per Technical Specification) shall be kept insured by the Contractor against any loss,damage, theft, pilferage or fire from the point of unloading upto the time of taking over byowner. including handling, transportation, storage, erection, testing and commissioning etc.The premium paid to the Insurance company by the Contractor for such insurance shall bereimbursed by NBPPL to the Contractor. The Contractor shall obtain competitive quota-tion for such insurance and shall take prior approval from NBPPL before taking the insur-ance. The insurable value of the equipment being supplied by NBPPL shall be intimated tothe Contractor for arranging the insurance.

12.7 It will be the responsibility of the Contractor to lodge, pursue and settle all claimswith the insurance company in case of any damage, loss, theft, pilferage or fireduring execution of Contract and NBPPL. shall be kept informed about it. TheContractor shall replace the lost/damaged materials promptly irrespective of the under/full/non-settlement of the claims by the underwriters and ensure that the work progressis as per agreed schedules. The losses, if any , in such replacement will have to beborne by the Contractor .

12.8 In addition to above insurance policies as per following shall also be taken bycontractor:

(a) Workmen’s Compensation Insurance




The contractor will be responsible for taking out workmen compensation insurance.This insurance shall protect the Contractor against all claims applicable under theWorkmen’s Compensation Act, 1948 (Government of India). This policy shall alsocover the Contractor against claims for injury, disability, disease or death of his or hisSub-Contractor’s employee, which for any reason are not covered under theWorkmen’s Compensation Act, 1948. The liabilities shall not be less than:

Workmen’s Compensation : As per statutory Provisions

Employee’s liability : As per statutory Provisions

(b) Comprehensive Automobile Insurance

The contractor will be responsible for taking out comprehensive vehicle insurance.

This insurance shall be in such a form to protect the Contractor against all claims forinjuries, disability, disease and death to members of public including the Employer’smen and damage to the property of others arising from the use of motor vehiclesduring, on or off the Site operations, irrespective of the Employer ship of suchvehicles. The liability covered shall be as herein indicated:

Fatal Injury : Rs.100,000 each person

Rs.200,000 each occurrence

Property Damage : Rs.100,000 each occurrence

(c) Comprehensive General Liability Insurance

The contractor will be responsible for taking out comprehensive general liabilityinsurance. The insurance shall protect the Contractor against all claims arisingfrom injuries, disabilities, disease or death of members of public or damage toproperty of others, due to any act of omission on the part of the Contractor, hisagents, his employees, his representatives and Sub-Contractors or from riots,strikes and civil commotion. This insurance shall also cover all the liabilities of theContractor arising out of the Clause entitled ‘Defence of Suits’ given below.

(d) The hazards to be covered will pertain to all the works and areas where theContractor, his Sub-Contractors, his agents and his employees have to performwork pursuant to the Contract.

The above are only illustrative list of insurance covers normally required and it will be theresponsibility of the Contractors to maintain all necessary insurance coverage to the extentboth in time and amount to take care of all his liabilities either direct or indirect, in pursuanceof the Contract.

13.0 DEFENCE OF SUITS

If any action in court is brought against the Owner/Consultant or Engineer or an officer or




agent of the Owner/Consultant, for the failure, omission or neglect on the part of the Con-tractor to perform any acts, matters, covenants or things under the Contract, or for damageor injury caused by the alleged omission or negligence on the part of the Contractor, hisagents, representatives or his Sub-Contractors, or in connection with any claim based onlawful demands of Sub-Contractors, workmen, suppliers or employees, the Contractorshall in all such cases indemnify and keep the Employer, and the Engineer and/or his repre-sentative, harmless from all losses, damages, expenses or decrees arising of such action.

14.0 FACILITIES TO BE PROVIDED BY OWNER

14.1 Power for Office and construction work shall be provided if available with owner onchargeable basis based on prevailing local tariff for temporary connection at one singlepoint.

14.2 Water for drinking and construction/erection purpose shall be provided free of cost if avail-able with owner at one single point.

14.3 Land for construction of field office, workshop, stores, assembling yard, etc. shall be pro-vided free of cost.

15.0 PROGRESS REPORTS

15.1 During execution of the Contract, the Contractor shall furnish monthly progress reports toOwner/Consultant in a format as specified by Owner/consultant indicating the progressachieved during the month, and total progress upto the month against scheduled and antici-pated completion dates in respect of activities covered in programmes/schedules referred toabove. Contractor shall also furnish to Owner/Consultant resources data in a specified for-mat including photographs by digital camera and time schedule. The Contractor shall alsofurnish any other information that is necessary to ascertain progress, if called for by Owner/Consultant.

16.0 INELIGIBILITY FOR FUTURE TENDERS

If a bidder after having been issued the Letter of Award/PO, either does not submitacceptable Contract Performance Guarantee pursuant to Clause 7.0 of Part-B ofGCC, such bidder may be considered ineligible for participating in future tenders ofNBPPL/NESCL,. for a period as may be decided by the owner .

17.0 TRIAL OPERATION

For T rial Operation, the system for a particular package, system shall be ener gized inpresence of the representative of Owner/Consultant officials and same shall be




maintained in energized condition for a period of atleast twenty-four (24) hours. Incase of any defect is observed, then such mutually agreed defect shall be liquidatedwithin a maximum period of one week by the bidder . Thereafter, the system shall bemaintained in energized condition.

18.0 HANDING OVER & TAKING OVER

Upon successful completion of all the tests to be performed at site on equipment furnishedand erected by the contractor, the owner shall issue to the contractor a Taking Over Certifi-cate as proof of the final acceptance of the equipment. Such certificate shall not unreason-ably be withheld nor will the owner delay the issuance thereof on account of minor omissionsor defects, which do not affect the commercial operation and/or cause any serious risk tothe equipment. Such certificate shall not relieve the contractor of any of his obligationswhich otherwise survive, by the terms and conditions of the contract after issue of suchcertificate.

19.0 Fraud Prevention Policy

The contractor along with their associate/collaborator/subcontractor/sub-vendors/consult-ants/service providers shall strictly adhere to the fraud prevention policy of the NTPC dis-played on its tender website http://www.ntpctender.com. The contractor along with theirassociates /collaborators/subcontractor/sub-vendors/consultants/service providers shallobserve the highest standard of ethics and shall not indulge or allow anybody else working intheir organization to indulge in fraudulent activities during execution of the contract. The con-tractor shall immediately apprise the Consultant about any fraud or suspected fraud as soonas it comes to their notice.

20.0 SOLVING OF STATUTORY APPROVAL

20.1 Notwithstanding anything specified in the Bidding Document, it shall be the CONTRACTOR’Ssole responsibility to obtain all approvals from any authority (except for environment clear-ance) required under any statute, rule or regulation of the Central or Andhra Pradesh StateGovernment for the performance of the contract and/or the contractual work. The applicationon behalf of the OWNER for submission to relevant authorities alongwith copies of requiredcertificates complete in all respects shall be prepared and submitted by the CONTRACTORwell ahead of time so that the actual construction/commissioning of the works is not delayedfor want of the approval/inspection by the concerned authorities. The CONTRACTOR shallarrange for the inspection of the works by the authorities and will undertake necessary coor-dination and liaison required and shall not be entitled to any extension of time for any delay inobtaining such approvals.




20.2 Statutory fees, if any, paid for all such inspections and approvals shall be reimbursed atactuals to the CONTRACTOR by the OWNER on production of documentary evidence.

20.3 Any deficiency (ies) as pointed out by any such authority shall be rectified by the CON-TRACTOR within the scope of relative supply and/or work at no extra cost to the OWNER.The inspection and acceptance of the work by such authorities shall, however, not absolve theCONTRACTOR from any of its responsibilities under this contract.

20.4 Settlement of any dispute with the Public/Statutory bodies/Local Authorities/Tax Authoritiesetc. shall be carried out by the CONTRACTOR. The expenditure aganist any award by theabove Statutory bodies/authorities shall be borne by the bidder.

20.5 LICENSE:

a) PROJECT LICENSE: Contractor has to obtain project license in respect of the projects fromthe competent authority at his own cost, prior to commencement of works.

b) ELECTRICAL LICENSE: All electrical jobs shall be carried out only through contractors possessing valid licenses as applicable for the project site/location of work, except in the case ofpackages / turnkey jobs where electrical jobs may be sub-contracted by the Main Contractor. Inall such cases, the Main contractor shallget the work executed only through agencies having suchvalid licenses.

21.0 MATERIALS HANDLING AND STORAGE

21.1 All the equipment furnished under the Contract and arriving at Site shall be promptlyreceived, unloaded, transported and stored in the storage spaces by the Contractor.

21.2 Contractor shall be responsible for examining all the shipment and notify the Engineer imme-diately of any damages, storage, discrepancy etc, for the purpose of Engineer’s informationonly. The Contractor shall submit to the Engineer every week a report detailing all the receiptsduring the week. However, the Contractor shall be solely responsible for any shortages ordamages in transit, handling and/ or in storage and erection of the equipment at Site. Anydemurrage, wharfage and other such charges claimed by the transporters, railways etc, shallbe to the account of the Contractor.

21.3 The Contractor shall maintain an accurate and exhaustive record-detailing out the list of allequipment received by him for the purpose of erection and keep such record open for theinspection of the Engineer in-charge.

21.4 All equipment shall be handled very carefully to prevent any damage or loss. No bare wireropes, slings, etc. shall be used for unloading and/or handling of the equipment without thespecific written permission of the Engineer. The equipment stored shall be properly pro-tected to prevent damage either to the equipment or to the floor where they are stored.The equipment from the store shall be moved to the actual location at the appropriate time




so as to avoid damage of such equipment at Site.

21.5 All electrical panels, control gears and such other devices shall be properly dried by heat-ing before they are installed and energized. Exposed parts shall be protected against mois-ture ingress and corrosion during storage and periodically inspected.

21.6 All the electrical equipment shall be tested for insulation resistance at least once in threemonths from the date of receipt till the date of commissioning and a record of such mea-sured insulation values maintained by the Contractor. Such records shall be opened forinspection by the Engineer.

21.7 The Contractor shall ensure that all the packing materials and protection devices, used forvarious equipment during transit and storage, are removed before the equipment are in-stalled.

21.8 The consumable and other supplies likely to deteriorate due to storage must be thoroughlyprotected and stored in a suitable manner to prevent damage or deterioration in quality bystorage.

21.9 All the materials stored in the open or dusty location must be covered with suitable weath-erproof and flame proof covering material wherever applicable.

21.10 If the materials belonging to the Contractor are stored in areas other than those ear-marked for him, the Engineer will have the right to get it moved to the area earmarked forthe Contractor at the Contractor’s cost.

21.11 The Contractor shall be responsible for making suitable indoor storage facilities to store allequipment, which require indoor storage. The Engineer, in addition, may direct the Con-tractor to move certain other materials, which in his opinion will require indoor storage, toindoor storage areas, which the Contractor shall strictly comply with.

22.0 In addition to conditions stipulated at Para-5 of Annexure-IX of GCC for forfeiture of BidSecurity; following shall also be applicable:

(a) If the bidder/his representative commits any fraud while competing for this contract pur-suant to Fraud Prevention Policy of NTPC, or;

(b) If the Bidder refuses to withdraw, without any cost to the owner, any deviation not listedin prescribed deviation schedules of BPS but found elsewhere in the bid.

(c) In case of a successful Bidder, if the Bidder fails to furnish the Contract PerformanceGuarantee within 30 calendar days after the date of LOA/PO, the bid guarantee amountwill be forfeited by the Owner without any notice of proof of damages, etc.




23.0 SECURITY

The Contractor shall have total responsibility for all equipment and materials in his custody/stores, loose, semi-assembled and/or erected by him at Site. The Contractor shall makesuitable security arrangements including employment of security personnel to ensure theprotection of all materials, equipment and works from theft, fire, pilferage and any otherdamages and loss. All materials of the Contractor shall enter and leave the project site onlywith the written permission of the Engineer in the prescribed manner.

24.0 RESPONSIBILITIES OF CONTRACTOR IN RESPECT OF SAFETY OF MEN,EQUIPMENT, MATERIAL AND ENVIRONMENT.

24.1 All safety rules and codes applied by NBPPL and its customer at site shall be observed bythe contractor and his workmen without exception. The contractor shall be responsible forthe safety of the equipment / material and work to be performed by him and shallmaintain all lights, fencing guards, signs etc. or other protections necessary for the purpose.Contractor shall also take such additional precautions as may be indicated from time totime by the Engineer, with a view to prevent pilferage, accidents, fire hazards etc. Suitablenumber of clerical staff, watch and ward, store keepers to take care of equipment,materials, construction tools and tackles shall be posted at site by the contractor till thecompletion of the work under this contract. The contractor shall arrange for suchsafety devices as are necessary for this type of work and carry out the requisite site testsof handling equipment, lifting tools, tackles etc. as per usual standards and practices.

24.2 The contractor shall provide to its work force and ensure the use of the following personalprotective equipment as found necessary and as directed by the authorized NBPPLofficials.

(a) Safety Helmets conforming to IS-2925

(b) Safety Belts conforming to IS-3521

(c) Safety shoes conforming to IS-1989

(d) Eye & Face Protection devices conforming to IS-8520 and

IS-8940

(e) Hand & body protection devices conforming to IS-2573,IS-6994, IS-8807 & IS-8519.




24.3 All tools, tackles, lifting appliances, material handling equipment, scaffolds, cradles, safetynets, ladders, equipment etc. used by the contractor shall be of safe design and construction.These shall be tested and certificate of fitness obtained before putting them to use andfrom time to time as instructed by authorized NBPPL official who shall have the right toban the use of any item.

24.4 All electrical equipment, connections and wiring for construction power , it'sdistribution and use shall conform to the requirements of Indian Electricity Act and Rules.Only electricians licensed by the appropriate statutory authority shall be employed bythe contractor to carry out all types of electrical works. All electrical appliances includingportable electric tools used by contractor shall have safe plugging system to source ofpower and be appropriately earthed.

24.5 The contractor shall not use any hand lamp energized by electric power with supply voltageof more than 24 volts. For work in confined spaces, lighting shall be arranged with powersource of not more than 24 volts.

24.6 Where it becomes necessary to provide and / or store petroleum products, explosives,chemicals and liquid or gaseous fuel or any other substance that may cause fire orexplosion, the contractor shall be responsible for carrying out such provision and/or stor-age in accordance with the rules and regulations laid down in the relevant GovernmentActs, such as Petroleum Act, Explosives Act, petroleum and Carbides of Calcium Manualof the Chief Controller of Explosives, Government of India etc. Prior approval of theauthorized NBPPL official at the site shall also be taken by the contractor in all such matters.

24.7 The contractor shall arrange at his cost (wherever not specified) appropriate illumination atall work spots for safe working, when natural daylight may not be adequate for clearvisibility.

24.8 In case of a fatal or disabling injury / accident to any person at construction sites due tolapses by the contractor, the victim and / or his / her dependents shall be compensated bythe contractor as per statutory requirements. However, if considered necessary, NBPPLshall have the right to impose appropriate financial penalty on the contractor and recoverthe same from payments due to the contractor for suitably compensating the victim and /or his / her dependents. Before imposing any such penalty, appropriate enquiry shall be heldby NBPPL giving opportunity to the contractor to present his case.




24.9 In case of any damage to property due to lapses by the contractor, NBPPL shall havethe right to recover the cost of such damages from the payments due to the contractorafter holding an appropriate enquiry.

24.10 In case of any delay in the completion of a job due to mishaps attributable to lapses by thecontractor, NBPPL shall have the right to recover cost of such delay from thepayments due to the contractor, after notifying the contractor suitably and giving himopportunity to present his case.

24.11 If the contractor fails to improve the standards of safety in its operation to the satisfactionof NBPPL after being given reasonable opportunity to do so and / or if the contractor failsto take appropriate safety precautions or to provide necessary safety devices and equip-ment or to carry out instructions regarding safety issued by the authorized NBPPL official,NBPPL shall have the right to take the corrective steps at the risk and cost of thecontractor after giving a notice of not less than seven days indicating the steps that would betaken by NBPPL.

24.12 The contractor shall submit report of all accidents, fires, property damage and dangerousoccurrences to the authorized NBPPL official immediately after such occurrence, but inany case not later than 12 hours of the occurrence. Such reports shall be furnished in themanner prescribed by NBPPL. In addition, periodic reports on safety shall also be submit-ted by contractor to the authorized NBPPL official from time to time as prescribed.

24.13 During the course of construction, alteration or repairs scrap lumbers with protruding nails,sharp edges etc., and all other debris including combustible scrap shall be kept cleared fromworking areas, passage ways and stairs in and around site.

24.14 Cylinders shall be moved by tilting and rolling them on their bottom edges. They shall notbe intentionally dropped, struck or permitted to strike each other violently. Whencylinders are transported by powered vehicles, they shall be secured in a vertical position.

24.15 The contractor shall be responsible for the safe storage of his radioactive sources.

24.16 All the contractor's supervisory personnel and sufficient number of workers shall be trainedfor fire fighting and shall be assigned specific fire protection duties. Enough number ofsuch trained personnel must be available during the tenure of the contract.




24.17 Contractor shall provide enough fire protecting equipment of the types and numbers at hisoffice, stores, erection site, other temporary structures, labour colony area etc. Access tosuch fire protection equipment shall be easy and kept open at all times. Compliance of theabove requirement under fire protection shall in no way relieve the contractor of any of hisresponsibility and liabilities to fire accident occurring. In the event fire safety measuresare not to NBPPL's satisfaction, NBPPL shall have option to provide the same andrecover the cost plus incidentals from contractor's bills and / or impose penalty as deemedfit by the Engineer.

24.18 Before commencing the work, the contractor shall appoint /nominate a responsible officerto supervise implementation of all safety measures and liaison with his counterpart of NBPPL.

24.19 If safety record of the contractor in execution of the awarded job is to the satisfaction ofSafety Department of NBPPL, issue of an appropriate certificate to recognize the safetyperformance of the contractor may be considered by NBPPL after completion of the job.

25.0 RECONCILIATION OF ACCOUNTS

The Contractor shall prepare and submit every four months, a statement covering pay-ments claimed and the payments received vis-à-vis the works executed, for reconciliationof accounts with the Employer. The Contractor shall also prepare and submit a detailedaccount of Employer Issue materials received and utilized by him for reconciliationpurpose in a format to be discussed & finalized with the Employer before the award ofContract.




IMPORTANT SCC INSTRUCTIONS/GUIDELINES

All the conditions stipulated in Special Conditions of Contract (SCC) shall supplement theGeneral Conditions of Contract (GCC), and Instructions to Bidders (INB). Wherever there isa conflict, the provisions herein shall prevail over those in the GCC and INB.

Special Conditions Clauses Ref., Special Conditions(SCC) No. if any Read as

1. Definitions/ Name of the Consultant:Abbreviation NTPC Electric Supply Company Ltd.

(A WHOLLY OWNED SUBSIDIARY OF NTPC)

Address of Consultant : Contract ServicesRoom No. 221, EOCNTPC, R&D Centre Building,Plot A-8A, Sector-24,Gautam Budh Nagar,NOIDA–201301 (U.P).

Telephone No. : 0120-2410892/2410689Fax No. : 0120-2410907Registered office address:NTPC Bhawan, Scope Complex,7 Institutional Area, Lodhi Road,New Delhi-110003The Symbol is _______________** forName of state is: Andhra Pradesh

The Symbol is _______________*** for Name of the Owner /employer:

NTPC BHEL Power Projects Private Limited Address of the Owner :

NTPC BHEL Power Projects Private Limited (NBPPL)(A Joint venture company of NTPC Ltd. and BHEL)NTPC Bhawan, Scope Complex,7 Institutional Area, Lodi Road,New Delhi-110003Telephone No.: 0120 4001313Fax No.: 0120 4001301, 1322