record keeping for disputes table of...
TRANSCRIPT
RECORD KEEPING FOR DISPUTES
TABLE OF CONTENTS
INTRODUCTION
II. HOW TO AVOID AND DECREASE DISPUTES
A. CONTRACT DOCUMENTSB. PREPARATION OF THE BIDC. DEALING WITH DISPUTES - AVOIDING DELAY
III. DOCUMENTING DELAY
IV. EXTRAS AND CHANGES
V. PREPARATION FOR A CLAIM
VI. RIGHT TO INFORMATION
VII. OBTAINING COMPLETION CERTIFICATES
APPENDICES
- Sample Letter of Request for aCertificate of Substantial Performance
- Certificate of Substantial Performance(Prescribed Form)
- Sample Certificate of SubstantialPerformance
- Notice of Change- Supplementary Instruction Form- Supplementary Contract Conditions- The Builders Lien Act, SSe 3, 41, and 85
(as amend~C!)
PAGE
1
145
8
13
19
20
24
29
30
3132333439
RECORD KEEPING FOR DISPUTES
I. INTRODUCTION
Whether you act for an owner, contractor or subcontractor,
adequate records are essential to prove your case. In many
respects the suggestions contained herein would be more
appropriately given to the parties prior to the tender being
prepared. It is included in these materials so that those
lawyers fortunate enough to have contact with their client
before the tender process begins will be able to advise
their clients of the types of records which may become
useful in proving or defending a claim at a later date. In
addition, since many contractors and subcontractors alread~
have some sort of record keeping system in place, this
material should assist lawyers in asking their clients or
other parties at discovery for the types of records which
one would hope to find. Of course, there is no exhaustive
list of the types of records which will assist in any
particular- action ~.. -
II. HOW TO AVOID AND DECREASE DISPUTES
A. CONTRACT DOCUMENTS
Disputes are more likely to arise in situations where
inadequate contract documents have been executed.
If you are fortunate enough to be consqlted by an owner
Page 2
prior to the tender process, you should ensure that the
owner is satisfied that the bid documents reflect what will
be required to produce the desired result. If the owner has
not employed an experienced consultant (engineer) to
represent him, you should recommend that one be employed.
The bid documents should include:
(i) The Tender Form (inclUding instructions to bidders);
(ii) The proposed contract;
(iii) All specifications for the work including the workschedule, drawings and the list of specific productsto be used (manufacturer and model· number ifpossible).
Most contractors are familiar with the standard form
contract documents pUblished by the· Canadian Construction
Documents committee (CCDC). These documents are available
at a nominal cost from the Saskatchewan Construction
Association. If you wish to alter the terms of the standard
contract document; it-may be in everyone's best interest to
do such alterations by adding a list of supplementary
conditions to the contract document. This will draw the
contractor's attention to the changes you require.
During the tender period owners or their consultants will
often be asked for clarifications to the specifications.
The consultant will reply to the questions posed and should
send a copy of all questions and answers -to each contractor
bidding on the job.
Page 3
These questions and answers are
.'
referred to as "Bid Clarifications" and are usually numbered
sequentially. contractors should retain copies of each of
the Bid Clarifications received and the date they were
received. Similarily, the consultant may issue amendments
to the specifications. These are usually numbered
sequentially
contractor.
and copies should be retained by the
Many disputes arise from a misunderstanding of the
contractor's scope of work. This is especially so on very
large projects where the owner may contract directly with a .-
number of "general" contractors for different phases of the
work. The first source of information to resolve such
disputes is the tender documents, including the Bid
Clarifications and amendments.
There is no subst!tute for clearly defined specifications
but even the most careful consultant may overlook some
particulars which can cause problems during performance of
the contract. In order for a contractor to protect himself
and avoid potential disputes later, the preparation of the
tender should begin as early as possible so that there will
be adequate time to submit any requests for clarifications
to the consultant. If the contractor submits a request for
a bid clarification the day before the tenders close, the
Page 4
consultant may refuse to answer the questions since
providing the answer at such a late date may prejudice other
bidders •..
B. PREPARATION OF THE BID
After the contractor prepares a bid he should retain all of
the working documents used to arrive at the price. These
documents should include the price of materials, labour
requirements (including the work to be performed by each of
the trades), the cost of labour, a schedule of the work
including when the various trades are expected to be
employed on the site and the contractor's "mark up" and
fixed cost or administration cost allowance. This
information will prove to be invaluable from a number of
perspectives if a dispute arises. It should establish the
scope of work contemplated by the contractor when preparing
the bid and will ~ssist with the calculation of damages at a
later date if required.
It will also assist the contractor in clearly stating his
position when a dispute arises with respect to the scope of
work. The same recommendations apply equally to
subcontractors.
Page 5
e.DEALING WITH DISPUTES - AVOIDING DELAY
Since timing is critical on most construction projects it is
essential that disputes be resolved as quickly as possible.
For example, if a contractor or subcontractor insists that
certain work is not his responsibility to perform or insists
that the work should be performed .ina manner other than
that contemplated by the consultant, delays may occur while
the dispute is being resolved. Such delays may affect not
only the contractor, the subcontractor in question, and the
owner, but may also affect the ability of other
subcontractors to perform their work on time.
The general contractor's principal responsibility is to
coordinate the work so that the project is completed in the
time specified. The eeDe contract documents provide that
when a dispute arises which cannot be resolved promptly, the
consultant will ..give the necessary instructions to perform
the work immediately. The parties are then required to
perform the work according to the instructions and by doing
the work they will not jeopardize any claim they may have if
the instructions are in error or at variance with the
contract documents. The objective is to keep the work
moving ahead to completion.
Each of the parties involved in a dispute ~hould state their
Page 6
position as clearly as possible, with reference to the
contract documents, at the earliest possible time. The
first contact is invariably verbal. The parties should make
a record of any discussions and summarize their own
positions and their understanding of the positions of each
of the other parties. They should then provide a written
statement of their position to the other parties.
If the contract documents do not contain a clause providing
for immediate performance of the...disputed work and deferral
to later settlement or arbitration, agreement in writing to
that effect should be obtained.
The instructions given by the consultant or general
contractor for the performance of the disputed work should
be given in writing. If they are not, the party performing
the work should make a record of the instructions and give a
copy to th~ consul~ant or general contractor, as the case
may be, as soon as possible and preferably before commencing
the work. This will decrease the likelihood of a further
dispute with respect to the work to be performed.
The contractor or subcontractor should make a record of the
date the work was commenced and completed, the labour and
materials employed to complete the work including the trades
employed and the time spent completing the work. This
Page 7
information can be used to quantify any claim for extra work
at a later date.
In addition to the cost -to the contractor, or sUbcontractor,
of performing the work, additional costs may arise. For
example, the contractor or subcontractor in addition to
recording the cost of the additional work should also record
any effect that the extra work has had on completion of
other parts of his contract or subcontract. For example,
consider a situation where a concrete subcontractor is
expected to complete a concrete floor within a specified
time. When the concrete subcontractor arrives, a dispute
arises with respect to the amount of reinforcing steel to be
used. Adding the additional reinforcing steel may not
require that additional labourers be employed to install it
but ~he extra time taken to install it may require that the
concrete finishers start later and work overtime or that
additiona~ finish.~s need to be hired to finish the floor on
time. On the face of it, no delay has occurred. However,
additional costs have been incurred.
If the subcontractor has a record of the number of finishers
and- the time estimated to do the work upon which he based
his bid, his claim for additional labour cost is more easily
quantified thereby decreasing the likelihood of a dispute
regarding the cost of the additional work if the additional
· '
Page 8
reinforcing steel is found to be extra to the original
contract. Payroll records will serve to document the labour
cost and, invoices for materials and rentals will provide the
basis for an increased material cost claim. Such information
is invaluable to the lawyer whether the dispute goes to
arbitration or to court. If the subcontractor does not have
a record of the cost assumptions upon which he based his bid
price, his increased cost must be determined by reference to
what would be reasonable if the change had not occurred. Of
course, the subcontractor's cost assumptions can. always be
attacked as being unreasonable but since the bid was
accepted it might be difficult to dispute that the initial
price and the assumptions underlying it were unreasonable.
Records of the productivity achieved by the contractor or
subcontractor on previous similar jobs can also assist in
supporting the reasonableness of the assumptions underlying
the price.
III. DOCUMENTING DELAY
Delay can arise from a number of events or combinations of
events. These include delays caused by materials not
arriving on time, changes or extras to the contract,
drawings not being available when required and failed
coordination. An example of failed coordination would be
where the concrete floor referred to earlier was not
Page 9
completed in the specified time thereby preventing machinery
from being installed when required which might further delay
electrical contractors, finishing carpenters, and other
trades. Failed coordination may also arise where the
consultant refuses to accept the work of a subcontractor and
the subcontractor takes extra time to rectify the work
thereby preventing others from proceeding.
From the owner's perspective delay in substantial completion
will prevent the utilization of the building or structure at
the time anticipated. such delay may give rise to loss of
profits, extra rental charges at the owner's present
location or increased financing charges caused by the
inability to complete the sale of his former premises, to
name a few.
From a contractor's or subcontractor's point of view delay
may increase l~~our costs, equipment rental costs or
administrative costs and may even result in the loss of
opportunity to move to another unrelated job in a timely
manner.
If the contract and subcontract schedules clearly specify
the date upon which work is to be commenced and completed,
there is rarely a question of whether or not a delay
occurred. The question is who caused it and what effect it
Page 10
had on the parties.
In order -to assist in identifying the cause of any delays
the contractor's or subcontractor's job supervisor should
keep a daily log of activities on the job site. The log
should contain,
- the project identification (site, contract number, etc.)
- the date
- the weather
- the manpower and equipment on site
- the work performed
- discussions with others including the names of thosepresent
- other trades on site and work being performed by them
- delays, including reasons for the delays and the workaffected.
Often the general contractor will hold weekly or other
periodic meeting, at which all of the subcontractors are
present. The minutes of the meeting will be taken and
distributed later. Since they have a wide distribution, the
contents of the minutes may carry more weight than the
contractors or subcontractor's notes of the meeting. For
this reason, minutes of project meetings should be reviewed
as soon as they are received in order to ensure that they
accurately reflect the discussions and agreements at the
meeting. If the minutes and handwritten notes taken at the
Page 11
meeting are inconsistent in any way, the person who prepared
the minutes should be advised in writing of the
inconsistency and the note should be attached to the minutes
in the job file.
Minutes of project meetings and your client's notes of the
meeting are a valuable source of information for resolution
of disputes arising out of delay. The minutes will serve to
outline the flow of the job and often the source of delays
will be recorded. One frustrating thing about minutes of
project meetings is that they are rarely written in complete
sentences and often use abbreviations with which you may not
be familiar. Your client's notes of the meeting may help
but often the only thing that can be done is ask your client
to review the minutes with you.
In addition to the daily log and contract meeting minutes,
the follo~ing doc~ents should be maintained in the job
file:
Correspondence: All correspondence relating to the project
should be kept in the job file. It is the practice of some
contractors to file· correspondence on the basis of the
company with whom they are corresponding. since contractors
often work with each other on more than one job at a time, a
particular file may contain many irrelevant pieces of
page 12
correspondence. Therefore ask the contractor to place
correspondence, or copies, on the job file. Correspondence
often contains summaries of the matters in dispute including
the factual assumptions· upon which the writer's position is
based.
Memos to the file: Job supervisors should be encouraged to
write memos to the job file whenever an event occurs which
could affect the performance of the project. The memos are
often directed at one particular point· and therefore may
contain more information on the point than the daily log.
Photographs: Photographs are useful to show the progress of
the job as well as the quality of workmanship. If they are
to be used to help document delay, they must be dated.
Photographs should be taken at each step in the job's
progress and in particular when paYments are requested so as
to record ~he de9~ee of completion of the work at that time.
Inspection Reports: Most contracts provide for periodic
inspections by the consultant. These are most often
required prior to approval of a paYment under the contract.
The inspection reports will help to define the dates by
which certain. work was completed. The job supervisor's
daily log should include a record of any consultants on site
in order to identify when reports may have been made.
Page 13
General contractors will also inspect work periodically and
a record of when those inspections took place and any
discussions at the time should be made. Copies of the
inspection reports will help to identify both the length of
a delay and its cause.
IV. EXTRAS AND CHANGES
Extras and changes to a contract (or subcontract) are
similar for record keeping purposes. A change is usually
initiated by the owner through the consultant and may result
in a change in the contract price. For example, an owner
may decide that more expensive fixtures be installed or that
a larger parking lot be built. In these cases there is no
question that what is being requested is different than that
called for in the specifications included with the contract
documents.
On larger contracts the procedure for making changes is
usually included in the contract general conditions. The
CCDC contract documents contemplate that no changes in the
work shall be proceeded with without a written order signed
by the owner. The procedure is that the owner, through the
consultant, provides a written description of the change to
the contractor who in turn submits a price to the consultant
for approval. Negotiations on the price m~y take place at
"
Page 14
this point. A change order is then issued and work can
commence.
A change order will often give rise to a change in the
contract price and a change in the time for completing the
contract. The change notice will provide a space for the
contractor to include a percentage mar.kup on the cost of the
work. The "normal" markup allowed by consultants is ten
percent. The contractor should be aware that the allowed
markup will often be insufficient to cover the additional
administrative costs incurred in preparing the price,
coordinating the work and the delay caused in completing the
contract. Therefore, when sUbmitting the price for the
change the contractor should type on the face of the
document, a clause such as the following:
"The compensation allowed by this changeorder does not include any amounts forchanges in the sequence of work, delays,disruptiQ~s and/or impact costs, and theright is expressly reserved to make claimsfor any and all of these related items ofcost prior to any final settlement of thiscontract."
Such a clause should protect the contractor from claims by
the owner that the contractor has been fUlly compensated for
the work by the price given. For an example of a case in
which this defence by the owner was successful see: Doyle
Construction Co. v. Carling O'Keefe Breweries of Canada Ltd~
(1987), 23 C.L.R. 143 (B.C.S.C.).
Page 15
Extras to a contract are handled in a similar fashion except
that the' request for approval of an extra is often initiated
by the contractor or a subcontractor and presented to the
consultant who in turn will request a price and issue a
change order after negotiation Qf the price. As noted
earlier (infra, section II.C.) an extra may arise out of a
dispute regarding the scope of the work and resolution may
be deferred to a later date.
The courts have commented on entitlement to payment for
extras as follows:
"Generally speaking, in my opinion, thefollowing rules should apply:
Rule 1. An item specifically provided forin the contract is not an 'extra'.
Rule 2. When the plaintiff suppliedmaterial of a better quality than theminimum quality necessary for thef~lfilmeRtof the contract, without anyinstructions,· express or implied, from thedefendant to do so, he is not entitled tocharge the extra costs as an 'extra'.
Rule 3. When the plaintiff did work orsupplied materials not called for by thecontract (plans or specifications) withoutinstructions,express or implied, from thedefendant, or the consent of thedefendant, he is not entitled to chargethis additional work or materials as an'extra' •
Rule 4.suppliedcontractimplied
When the plaintiff did work ormaterials not called for by the
on the instructions, express orfor the defendant, he is en~itled
Page 16
to charge for additional work or materialsas an I extra I •
What amounted to instructions from thedefendant is dependent on thecircumstances relating to each item. Ifthe defendant, without giving definiteinstructions, knew the plaintiff was doingextra work or supplying extra materialsand stood by and approved of what wasbeing done and encouraged the plaintiff todo it, that, in my opinion, amounts to animplied instruction to the plaintiff, andthe defendant is liable."
Re Chittick and Taylor (1954), 12 W.W.R. 653 (Alta.), at p.
654.
"Extra work, entitling the contractor toadditional payment, must be work which issubstantially different from, and whollyoutside the scope of the work contemplatedby the contract: Goldsmith, CanadianBuilding Contract (3rd ed., 1983), p. 83.Although there appears to be no generallyaccepted definition of "extra work", ithas been suggested that in a lump sumcontract it may be defined as work notexpressly or impliedly included in thework for which the lump sum is payable.If work is included in the originalccmtract ,. _ sum, the contractor cannotrecover extra'payment for it, although hemay not have anticipated that theadditional work would be necessary:Keating, Building Contracts (3rd ed.,1969), p. 63.
Keating has also suggested (at p. 62)that, in order to recover payment for workas an "extra", the contractor must prove:(1) that the "extra" work was not includedin the work for which the lump sum ispayable; (2) that there was a promise,expressed or implied, to pay for the work;(3) that any agent who authorized the workwas authorized to do so; and (4) that anycondition precedent to payment. has beenfulfilled."
Ron's Trucking and Hauling Ltd. v.
Page 17
city of Estevan
(1985), 11 C.L.R. 148 (Sask. Q.B.) at p. 151.
"In the interpretation of buildingcontracts the general rule is that allwork which is indispensable for thecompletion of the project falls within thecontract notwithstanding that it is notspecifically mentioned. See: Halsbury'sLaws of England, 4th ed., para 1175. Itdoes not seem to me to matter that extrawork or materials may be required byvirtue of the nature of the terrain or tosatisfy the lawful requirements of amunicipal authority. Those are matterswhich a contractor must anticipate andinvestigate before agreeing to a price orembarking on the work."
McMillan Bros. Ltd. v. Alex Smith Decorating Ltd. and Alex
Smith Rentals Ltd. (1980) 6 Sask. R. 301 (Sask. Dist. ct.)
at p. 303.
When the construction project is governed by contracts
containing. specific pr~visions for the pricing and approval
of extras much of the documentation will be available by
virtue of the way the contract is administered. However,
many projects are not governed by contracts containing such
clauses. In all cases, but especially where the contract
does not provide procedures for extras or changes, the
following information regarding extras and changes should be
recorded in the job file.
- a description of the extra or change
Page 18
- all discussions regarding the extra or change including arecord of all those persons present while the discussiontook place.
- any agreements regarding the extra or change includingacknowledgements that the work is an extra or a change andthe agreed price.
- the date upon which ~he extracompleted and the materials andcomplete the extra.
work was commenced andlabour expended to
At the earliest opportunity the contractor or subcontractor
should provide a written description of the agreed extra or
change to the owner or contractor, as the case may be, with
a record of the agreed price and a clause similar to the one
already noted reserving the right to claim for additional-
costs. The owner or contractor should be asked to sign the
agreement.
As with the initial contract price, a record should also be
kept of the way in which the price quoted for the extra or
change was determ~~ed. This will help to define the scope of
work contemplated by the contractor or subcontractor.
As noted earlier changes and extras to a contract often
result in additional costs to the contractor which are not
adequately compensated by the agreed price.
The completion date of the contract may be moved back giving
rise to additional expenses for supervis~ry personnel or
Page 19
equipment rentals. The delay in completing one part of the
job may move the date for performance of another part of the
job into· winter months thereby reducing labour productivity,
A contractor or subcontractor may be forced to perform work
in a different sequence than that originally contemplated
(commonly called "disruption") or may be forced to hire
additional labour to complete the contract on time (commonly
c~lled "acceleration"). The same types of costs can also
arise for reasons other than changes or extras. For this
reason the contractor .or.sub.contractor .must keep accurate
records of all costs incurred and the cause of the cost in
the performance of the contract. The records will assist in .
assessing the quantum of damages including impact costs.
For a review of the concept of impact costs which will
assist in identifying the records required to prove such a
claim see: Revay, Stephen G. "Calculating Impact Costs" 27
C.L.R. 239.
v. PREPARATION FOR A CLAIM
The foregoing has outlined some basic types of records which
should be kept by contractors and subcontractors. When you
are contacted by a contractor or subcontractor about a
potential claim, you should ask that the following material
be supplied to you:
(a) The client's written analysis of . the claim covering
Page 20
both the strengths and weaknesses of the claim.
(b) A chronology of events with referenc~ to supportingdocuments.
(c) A list of all documents which may be relevant andcopies of the documents in chronological order.These should include; the client's pricecalculations, the work schedules, the daily logs,relevant correspondence and memos, job site meetingminutes, labour records, photographs, completioncertificates, statutory declarations and inspectionreports.
(d) The name, phone number and address of the principalcontact person from whom you will receiveinstructions.
(e) A list of potential witnesses such as employees,ex-employees and others who were on the job.
which may be( f) A recommended expert or expertsrequired.
(g) A list of all parties including the owner,contractor and subcontractors.
(j)
(h) Written statements from key witnesses ..
(i) copies of all contract documents including: alltender documents including bid clarifications, theprime contract, the relevant subcontracts andchanges orders.
The rele~ant performance and labour and materialbonds. .-
(k) A record of all invoices submitted and paymentsreceived.
VI. RIGHT TO INFORMATION
Sections 82 and 83 of The Builders' Lien Act provide methods
for obtaining information prior to the commencement of an
action.
Page 21
section 82 of The Builders' Lien Act grants owners, lien
claimants or beneficiaries of a trust under the Act the
right to' demand information from other parties. A lien
claimant or beneficiary to a trust under the Act may by
written request require from the owner or his agent:
(i) The terms of the contract and the state of accountsbetween the owner and the contractor;
(ii) The name and address of the financial institution inwhich the holdback trust account has been openedincluding the account number;
(iii) A statement as to the particulars of credits to andpaYments from the holdback trust account includingthe dates and the balance at the time the informationwas given;
(iv) A copy of any labour and material paYment bond postedby the contractor;
(v) Where the owner is the Crown, the names and addressesof lien claimants who have given claims of lien tothe Crown pursuant to Section 52 of the Act.
A lien claimant or beneficiary to a trust under the Act may
also request from a mortgagee or unpaid vendor or their
agent:
(i) The terms of the mortgage or agreement for sale;
(ii) A statement showing the amount advanced under themortgage and the dates of those advances withparticulars of arrears in paYment and interest;
(iii) A statement showing theagreement for sale andinterest.
amount secured under theany arrears in payment and
Pursuant to Section 82(2) the owner may, by written request,
require from a subcontractor when a . claim of lien has been
Page 22
registered or a written Notice of Lien has been received by
him and from a contractor at any time:
(i) The terms of any subcontract inclUding the names ofthe parties, the price, the state of accounts betweenthe parties and this information is to be verified bystatutory declaration.
(ii) A copy of any labour and material paYment bond postedby a subcontractor with the contractor or asubcontractor with another subcontractor.
The persons of whom the requests are made have 10 ten days
from the date the information was served on them to reply.
The Act provides that failure to comply could result in
liability for damages caused by the refusal to reply and in
addition the owner may withhold further paYments to a
contractor who refuses to comply or instruct the contractor
or another subcontractor to withhold payment from another
party who refuses to comply.
Section 83 of the Act allows an Examination for Discovery of
a person who has verified a claim of lien that has been
registered or, on application, Examination for Discovery of
a person other than the person who has verified the claim of
lien that has been registered. It should be noted that only
one examination on a claim of lien can take place pursuant
to this section. Section 90 provides that the evidence
given at the Examination may be used in evidence against the
party on whose behalf the person was examined and all other
parties of like interest. Leave of -the court must be
Page 23
obtained in order to examine the party again after the
action is commenced. Therefore the examination should be as
wide ranging as if an action had been commenced. The
Examination for Discovery can be held on at least seven
days' notice without an order of the Court. Notice must be
given to the person to be examined, every other person
against whose estate or interest in land a lien is claimed,
the contractor and the payer of the lien claimant.
The availability of the section 82 and 83 opportunities for
information should be distinguished. Section 82 allows a
request for information to be delivered to a subcontractor .
who has registered a claim of lien or delivered a Written
Notice of Lien whereas Section 83 only allows Examination
for Discovery of a person who has verified a claim of lien
that has been registered. Delivering a written Notice of
Lien does not fall within the definition of "registered" in
the Act.
In addition to the provisions of The Builders' Lien Act
the contract documents may provide opportunities for
obtaining information. For example, the CCDC contracts
contain the following clause:
"The consultant may, upon reasonablerequest and at his discretion, provide toa subcontractor information as to thepercentage or quantity of thesubcontractors work which has been .
Page 24
certified for pa~ent."
If such a request is made to the consultant and is denied,
it is· open to a subcontractor to make an application under
section 82 (6) for production of records relating to the
contract. The section provides that an application may be
made for inspection of all contracts, subcontracts,
documents, books or records relating to the contract or
sUbcontract or to the payment of the contract or sUbcontract
price. Access to those records should be sufficient to gain
the information sought.
VII. OBTAINING COMPLETION CERTIFICATES
Section 3 of The Builders' Lien Act provides rules for
determining substantial completion of a contract or
subcontract. Generally speaking substantial completion is
achieved when the improvement to be made under the contract
or subcontract 15- ready for use or is being used for the
purpose intended. When this point has been reached the
contractor or subcontractor should refer to the other
provisions of Section 3 to determine whether a request can
be made for a certificate of substantial performance.
Section 41 of The Builders' Lien Act is in the process of
being amended. In addition the regUlations will be amended
and should be included in the November.· 1989 Saskatchewan
Page 25
following
should be
Gazette.
sections
1990 •.· .
The
which
discussion deals with the
proclaimed in force January
new
1,
Briefly a contractor or subcontractor may make a request to
the payment certifier (consultant) for a certificate of
substantial performance. In the case of a subcontractor if
there is no payment certifier, the request is made of the
owner and the contractor and in the case of a contractor,
the request is made of the owner.
If the payment certifier (or the owner and/or contractor)
refuses or fails to certify substantial performance within
the 7 days specified in the Act, the contractor or
subcontractor as the case m~y be may refer the question to
an arbitrator pursuant to Section 85(1) or make an
application· to Court for an order that the contract or
sUbcontr~ct is substantially performed. The date of the
decision of the arbitrator or the court is deemed to be the
date of
Page 26
substantial performance unless that date is
determined to be a different date by the court or the
arbitrator.
When the payment certifier (or owner and/or contractor)
refuses to issue a certificate of substantial performance
the contractor or subcontractor should request that reasons
be given for the decision. Preferably the reasons would be
given in writing. If the reasons are given verbally the
contractor or subcontractor should reoord those reasons as
completely as possible and as soon after the discussion as
possible so that those reasons can be used as part of the
the arbitrator-
material to be forwarded to or as part of the
material used in support of an application to court.
section 45 of The Builders' Lien Act allows payment of the
holdback portion of a subcontract to be paid out 40 clear
days after the ~date of substantial performance of the
subcontract. This is a useful provision for subcontractors
employed on large projects which may take many months to
complete. If the subcontractor, such as the excavating
contractor, is employed at the beginning of the job, there
is no reason why he should have to wait until the completion
of the entire project before receiving the remaining 10
percent of the subcontract value.
Page 27
sections 41 and 85 (as amended) and Section 3 of The
Builders' Lien Act, a sample letter of request for a
certificate of substantial performance, the prescribed form
of the certificate of substantial performance, and a sample
of a certificate of substantial performance used by a
Saskatoon Engineering Consultant are included in the
Appendix to this section of the materials.
Also included in the Appendix to this section of the
materials is a sample of a "Notice of Change", a
Supplementary Instruction Form and a sample of Supplementary
Conditions to the CCDC standard contract 2 which are used by
a Saskatoon Engineering Consultant.
Please note that the recent amendments to The Builders'
Lien Act apply only to contracts and subcontracts arising
thereunder which were entered into on or after the day the
amendments come into force.
(The next page is 29 )
SAMPLE LETTERPERFORMANCE
Page 29
REQUESTING A CERTIFICATE OF SUBSTANTIAL
Date:---------To: [Owner, Owner and General Contractor or Payment
Certifier (Consultant)]
project:
Address of Project:
Request for certificate of Substantial Performance
Pursuant to Section 41 of The Builders' Lien Act
we request that you either:
1. complete and return the enclosedSubstantial Performance withindays)* days of receipt; or,
certificate ofseven (or ten .
2. Agree to arbitration of this request by thefollowing person.
Proposed Arbitrator:Arbitrators Address:
Our address for service is
Yours truly,
(contractor or subcontractor)
(NOTE: be sure to include the certificate of SubstantialPerformance and be sure that the work or contract for whichcertification is being requested is clearly specified init. )
* section 41(1) of the current unamended Act provides tendays for the payment certifier to determine whethersubstantial completion has been achieved.
FormCCERTIFICATE OF SUBSTANTIAL PERFORMANCE
OF CONTRACTOR SUBCONTRACT(Su bsection 41 fl) ofthe Builders' Lien Act)
page 30
This is toc:ertify that the """":"'" _(state whether contract or subcontract)
in relation to the following services or materials:
(Short description ofsen-ices or materials)
to the following improvement:
(Short description ofimprol:ement)
to the following land:
(Ciuic address ofland or legal description)
is substantially performed.
Day/Month/Year
Date certificate signed
(Payment qertifier,ifany)
(Ifno payment certif&er,certificate must be signedby owner and contractorjointly) ( Contractor
Owner
Name of OWner: _
Address for Service: _
Name of Contractor fifcertifyingsubstantial performance ofa contract) :
Name of Subcontractor fifcertifying substantial performance ofa subcontract) :
Name of Payment Certifier: _(Where there is a payment certif&er)
Address of Payment Certifier: _(Where there is a payment certif&er)
Mac:PHEDRAN & ROBB ENGINEERING LTD.STRUCTURAL CONSULTANTS3022 LOUISE STREETSASKATOON, SASKATCHEWAN S7J 3L8
Phone (306) 477-0655
CERTIFICATE OF SUBSTANTIAL PERFORMANCEPage 31
PROJECT:
OWNER:
CONTRACTOR:
CONTRACT DATED:
DATE:
FILE No.:
)
)
THIS IS TO CERTIFY that, based on our observations at the site at intervals appropriate tothe stage of construction, the Work described in the above Contract has been, to the best ofour knowledge, information and belief, Substantially Performed as defined in the ContractDocuments. This certificate is issued in the context of the General Conditions of -theContract.
This Certificate does not constitute an acceptance of any Work not in accordance with theContract Documents or any Work not completed as required by the Contract Documents.
The date of this Certificate shall be taken as commencement of the Lien Period and of thetwelve (12) month Warranty Period.
The Contractor shall continue towards Total Performance of the Work without delay. Contract payments are subject to- a retention to cover Work not Totally Performed.
MacPHEDRAN " ROBB ENGINEERING LTD.
Distribution:
NOTICE OF CHANGEMac:PHEDRAN '" ROBB ENGINEERING LTD.
PROJECT
CONTRACTOR
CHANGE No.
FILE No.
DATE
Page 32
THIS IS NOT AN AUTHORI~TION FOR EXTRA WORK. The COllttaetor ,hall forward the price chance to the Project Coordinator U lOOn U pouible, and Wore any work ia commenced. It approved by the Owner, a CHANGE ORDER wW be iaaueci.
THIS IS AN AUTHORIZATION FOR EXTRA WORK. The COlltractor ,hall forward the price change to the Project Co-ordinator u
SOOIl U pollible. Wbea approved by the Owner, a CHANGE ORDER wiU be iaaued.
DESCRIPTION:
DISTRIBUTION:
.-
MacPBEDRAN " ROBB ENGINEERING LTD.
CONTRACTOR'S REPLY (A complete breakdown ot all quotuiolll to be attached.)
EXTRA CREDIT
OWN WORK • OWN WORK •MARKUP ( %) • WORK BY OTBERS •WORK BY OTBERS • TOTAL •MARKUP ( %) •TOTAL • .' - NO PRIg ClWfGE
DATE
DATE
CHANGE ORDER
___RECOMMENDED
___NOT RECOMMENDED
CONTRACTOR'S SIGNATURE
MacPBEDRAN "ROBB ENGINEERING LTD.
THIS IS AN AUTHORIZATION TO PROCEED WITH THE CHANGES OUTLINED ABOVE. WORK TO BE PERFORMED ANT ).IDFOR IN ACCORDANCE WITH TO TERMS OF TBE CONTRACT.
DATE OWNER'S AUTHORIZED SIGNATURE
Mac:PHEDRAN & ROBB ENGINEERING LTD.Structural Consultants3022 Louise StreetSaskatoon. Saskatchewan S7J 3L8
Phon. (306) 471-0655 Fax: (306) .71-1995
SUPPLEMENTARY INSTRUCTIONS
TO:
Page 33
Dace _
FUe No. _
Inscruccion No. _
PROJECT:
You an requac.d co ClUTY out: ch. foUowinr supplement:ary inst:ruct:iol1l co t:h. cont:ract: which shall noc be .construed asauchoNinr a chanr. in t:h. cont:ract: amount:. Should ch. contraccor hold t:hat: cha. inat:ruct:ions involve a change in theconcract: amount: h. shall notifY che consulcant: in wricinr wichin cen (10) days of che above dace before proceeding wich the
worle.
MacPHEDRAN & ~OBB ENGINEERING LTD.
Pu --'-_
1
2
3
4
5
6
7
8
SUPPLEMENTARY CONDITIONSSECTION 00800
Page 1
AGREEMENT - ARTICLE A-4 (c)page 34
Interest shall be lot.
DEFINITIONS ITEM #2
Insert after " •.• consists of ••• " in the first line," ••• the Instructions to Bidders, ••• ".
DEFINITIONS ITEM #8
ADD:When a PORTION of the work is taken over, accepted, andis being used by the Owner, that PORTION may be defineas "the Work" for the purposes of beginning guarantees,maintenance by the Owner, release of holdbacks, on thePORTION.
ADD To GC 1.4
The Contract Documents are of the abbreviated type andmay include incomplete sentences. omissions of worgsor phrases such as "The Contractor shall", ."Conformitytherewith", "an" and "all" are intentional. Omittedwords and phrases. shall be supplied by inference in thesame manner as if they were in full~ .
When the words "approved", satisfactory", "undirected","SUbmitted", "inspected", or similar words or phrasesare used it shall be assumed that the word "Consultant"follows the verb as obj ect of the clause, such as"approved by the Consultant".
GC 5.2
Change the words "five working days" to read "withinthe time specified by the Consultant".
GC 5.3
Change the words "in the five working days specified"to read "within the time specified by the Consultant".
GC 5.6
Change the word "If" to the word "AS".
GC 11
After "Owner" in 11.1 (b) ADD: "or the Consultant",
SUPPLEMENTARY CONDITIONSSECTION 00800
Page 2
35l2.l(c)plus a
Items
..
ADD: .- GC 12.7Page
The charges determined by methods 12. 1 (a) orshall be computed on an estimated costpercentage fee as determined from Chart #1.generally covered by the percentage fee shall be:1) head office expenses.2) the salaries of superintendents, engineers,
timekeepers, accountants, clerks, watchmen andsimilar personnel normally employed directly on thework. (Wages of workmen and foremen and theassessments thereon for Workers' Compensation,Unemployment Insurance, vacation with pay andCanada Pension payments, etc., are part of theactual cost);
3) use of temporary offices, sheds, etc., includingcost of telephone, light, power, and heat usedtherein;
4) insurance premiums; and5) licenses and permits, exc;ept when these are special
for a particular item of work.
9
The cost of related changes involving both extras andcredits shall be applied against one another and th~.
percentage fee applied to the NET difference.·Unrelated changes shall be considered separately.
Credits may be figured at the actual "cost" and neednot include a credit for overhead and.profit originallyincluded in the stipulated Sum, but, neither shall apercentage fee be applied to the "cost" of a credit toreduce the credit.
Quotations for Changes shall include an itemizeddetailed breakdown of costs including a materials listwith the cost of each item, number of hours of labour,etc. . '
CHART #1Contractor on Subs
Value of Change Subs on Sub-Subs On Own($) (t) (t)
o - 299 17 20300 - 599 15 18600 - 899 13 16900 - 2,999 11 14
3,000 - 5,000 9 125,000 + negotiable negotiable
10 ADD GC13.7
The second and all subsequent applications for paymentshall be accompanied by a statutory Declaration on theform included in these Contract Documents.
11
7
GC 14.2
SUPPLEMENTARY CONDITIONSSECTION 00800
Page 3
Page 36
12
Change " ••• five (5) days .•• " to read" ••• Fifteen(15) days ..• "in the second line.
GC 14.3
12.1 After the first sentence ADD:"With his application, the Contractor will provide alist of the work which the Contractor is aware isincomplete or deficient".
12.2 After the second sentence ADD:"If it is found that the list submitted by theContractor is excessively incomplete and the consultantdisapproves of the application then sUbsequentinspections and assessments of Substantial Performancewill be at the Contractor's expense (ConSUltant's,Owner's, and their staffs' time at current per diemrates)".
13 GC 14.7
After the first sentence ADD:"With his application, the Contractor will provide awritten declaration that the work noted as incompleteor deficient at the time of Substantial Performance hasbeen completed or corrected".
After the second sentence ADO:"If it is found that the work has not been completed orcorrected and the Consultant disapproves theapplication, the subsequent inspections of the Workuntil .Total .Performance shall be at the Contractor'sexpense (ConSUltant's, Owner's and their staffs' timeat current per diem rates)".Second last line change the words .••. "five days"to read ••• "fifteen days".
14 GC 14.12
ADO:(d)
(e)
failure of the Work to comply· withrequirements of the Contract Documents,incompleteness of the Work.
the
15 GC 15.3
ADD the word "unscheduled" prior to the words "changesin such taxes".
+ .....-
). 16 GC 24.1
SUPPLEMENTARY CONDITIONSSECTION 00800
Page 4
Page 37
17
18
19
Add the following at the end of 24.1"and further shall correct at his own expense any andall original accepted work which was not in fact inconformance with the requirements of the ContractDocuments, and in such event the guaranteed period isbegun again at the date when the non-conforming work isreplaced, repaired or otherwise made to conform andcontinued thereafter for the same per iod as theoriginal guarantee. Any materials, fixtures orequipment requiring excessive servicing during theguaranteed period will be considered defective".
GC 25.1
ADD:"The Contractor shall be responsible to carry out andcomplete the Work in accordance with the ContractDocuments and failure ,on the part, of the Consultant orOwner to observe any defect or deficiencies in the work.will not relieve the Contractor of thisresponsibility".
ADD: GC 27.4
standard specifications referred to throughout theSpecifications shall form a part of the ContractDocuments and shall be read in conj unction therewith.Where standard specif ications other than CanadianStandards Association (CSA) are named, equivalent eSASpecifications shall take precedence and shall governwherever applicable. Whenever any product is specifiedin accordance with an ASTM Standard, CSA Specificationsor other Association Standard, the Contractor, ifrequested, ~~hall present an affidavit from the'manufacturer certifying that the product complies withthe particular standard specification. Where necessaryand requested, or specified, supporting test data shallbe SUbmitted to sUbstantiate compliance. Codes,standards, bylaws, statutes and Manufacturer'sAssociation specifications or instructions mentioned inthe Contract Documents refer to the latest revisions·thereof at time of calling for tenders unless otherwisespecifically designated.
ADD: GC 32.6
Warranty Period Inspection - ten months after thewritten acceptance of the Building, the Contractor, theOwner, and the Consultant shall together inspect thebuilding to determine any deficiencies in materials orworkmanship which have occurred or·'become apparentsince acceptance. . ..
19
20
SUPPLEMENTARY CONDITIONSSECTION 00800
Page 5
continued Page 38The Consultant will notity the Contractor to rectifydeticiencies listed within the two months prior to theend of the one-year warranty period.
Immediately before the end of the one-year warrantyperiod provided by the contractor, the Consultant, theOwner and the Contractor shall make a tinal inspectionto assure that the items recorded at the ten-month inspection have been corrected by the Contractor.
ADO: GC 37 - CONTRACT TIME
37.1 Time is ot the essence.
37.2 Extension to the Contract Time for changes ordelays'wi'l! 'only be" 'allowed tor those which are"critical" as in critical Path Method ofConstruction Scheduling. The onus to providethat an activity is "critical" will be on the.·Contractor.
- End of section -
Page 39
The Builders' Lien Act (as amended).
3(1) For the purposes of this Act, a contract orsubcontract is substantially performed:
(a) when the improvement to be made under thatcontract or subcontract or a substantial partof the improvement is ready for use or is beingused for the purposes intended; and
(b) when the improvement to be made under thecontract or subcontract is capable ofcompletion or, where there is a known defect,correction, at a cost of not more than theaggregate of:
(i) 3% of the first $500,000 of the contractprice or subcontract price;
(ii) 2% of the next $500,000 of the contractprice or subcontract price; and
(iii) 1% of the balance of the contract priceor subcontract price.
(2) For the purposes of this Act:
(a)
(b)
where the improvement or a substantial part ofthe improvement is ready for use or is beingused for the purposes intended and theremainder of the improvement cannot becompleted expeditiously for reasons beyond thecontrol - of the contractor or subcontractor, asthe case may be; or
where the owner and the contractor or thecontractor and SUbcontractor, as the case maybe, agree not to co~plete the improvementexpeditiously;
the price of the services or materials remaining tobe provided and required to complete the improvementshall be deducted from the contract or subcontractprice in determining substantial performance.
"
Page 40
41(1) At the request of the sUbcontractor, the paymentcertifier or, if there is no payment certifier, theowner and the contractor jointly shall, within sevendays after the day of the request:
(a) determine,subcontractand
pursuant to section 3, whether thehas been substantially performed;
(b) where he, she or they determinesubcontract has been substantiallycertify the substantial performancea certificate in the prescribeddelivering it to the subcontractor.
that theperformed,by signing
form and
(1.1) A request pursuant to subsection (1):
(a) may be made in the form prescribed in theregulations; and
(b) shall include a declaration by:
(i) the subcontractor; and
(ii) the payer on the subcontract;
SUbstantiallybeenhassubcontractthat theperformed.
(1.2) At the request of the contractor, the paymentcertifier or, if there is no payment certifier,' theowner shall, within seven days after the day of therequest:
(ar determine" pursuant to section 3, whether thecontract has been substantially performed; and
(b) where he or she determines that the contracthas been substantially performed, certify thesubstantial performance by signing acertificate in the prescribed form anddelivering it to the contractor.
(1.3) A request made pursuant to subsection (1.2):
(a) may be made in the form prescribed in theregulations; and
(b) shall include a declaration by the contractorthat the contract has been substantiallyperformed.
(2)
Page 41
Where a contract or subcontract has been certified tobe sUbstantia~ly performed, the payment certifier, bypersonal serv1ce or by registered mail within sevendays after the day the certificate was signed, shallgive a copy of the certificate:
(a) to the owner and the contractor; and
(b) to all persons providing services or materialsin the performance of the contract orsubcontract and who have requested the paymentcertifier in writing, by personal service of arequest, with a return address, to give them acopy of the certificate;
and where there is no payment certifier the ownershall give a copy of the certificate in accordancewith clauses (a) and (b).
(2.1) The contractor or, where there is no contractor, theowner shall post a copy of the certificate described.in subsection (2) in a prominent spot on the main jobsite.
(4) Where a dispute arises with respect to a refusal orfailure to certify substantial performance that hasnot been referred to an arbitrator pursuant tosection 85, the court may, on the application of anyperson, order that the contract or subcontract isSUbstantially performed.
(5) Where, pursuant to this Act, the court or anarbitrator determines that a contract or subcontractis substan~ially performed, the decision of the courtor the arbitrator, as the case may be, has the sameeffect as a certificate of substantial performanceunder subsection (1) or (1.2), as the case may be,and the owner shall give and post copies of thedecision as required of a payment certifier andcontractor with respect to a certificate undersubsection (2) and (2.1).
(6) For the purposes of this Act, the day on which acontract or subcontract is SUbstantially performed isdeemed to be:
(a) the day on which the certificate is signedpursuant to subsection (1) or (1.2); or
(b) where, pursuant to this Act, the court or anarbitrator determines that··the contract or
Paqe 42
subcontract is sUbstantially performed, the dayon which the decision of the court orarbitrator is rendered;
.unless:
(c) the certificate expressly indicates a differentday as the day of substantial performance; or
(d) the day of substantial performance isdetermined to be a different day by the courtor by an arbitrator.
(7) Where a copy of the certificate of substantialperformance is given by registered mail, it is deemedto be given when the addressee actually receives it,or two clear days after the day of registration,whichever is earlier, which time shall be included inthe days allotted for giving the certificate.
85(1) Subject to subsection (1.1), where a dispute arisesat any time during the construction of an improvementwith respect to the payment of money, the dispute,with the consent of the parties to the dispute, maybe referred to a single arbitrator chosen by theparties.
(1.1) Where a dispute arises:
(a) at any time during the construction of animprovement with respect to the failure orrefusal _to certify substantial performancepursuant-to section 41; or
(b) with respect to the payment of moneys to acontractor or subcontractor who has obtained acertificate of substantial performance withrespect to his or her contract or subcontract;
the person making the request, by personal service ofa written notice in the prescribed form, may requirethat the dispute be referred to an arbitrator.
(1.2) Where the parties to the dispute are unable to agreeon an arbitrator within three days of service of thenotice pursuant to .. subsection (1. 1), the personmaking the request may apply to the person specifiedin the regulations for the designation of anarbitrator. .
. .