presentation materials - arnold & porter llp
TRANSCRIPT
GovCon On Demand:
Sequestration – What to Expect and How
to Prepare
Mark D. Colley & Caitlin K. Cloonan
Government Contracts Practice Group
July 2012
Agenda
• Sequestration – Background
• Sequestration’s Impact on Federal Contracts
• What Can Contractors Do Now to Protect
Themselves?
2
Background – How Did We Get Here?
3
• Sequestration was not intended as the final budget solution…it
was intended to ―drive‖ an outcome
− Budget Control Act of 2011--raised the federal debt ceiling
and included measures intended to reduce deficits by roughly
$2 trillion through FY2012-FY2021 spending reductions
− Congressional ―Super Committee‖ was charged with
recommending $1.5 trillion in additional cuts, but its failure
triggered $1.2 trillion in automatic spending reductions over
nine years
− Absent further Congressional action, the first automatic cuts
for FY 2013 will begin January 2013:
• $54.7 billion in Department of Defense programs
• $54.7 billion in non-defense programs
− Many exemptions, including most large mandatory programs
Sequestration – New Fiscal Realities
4
• Sequestration in January 2013 would force dramatic action by
agencies and contractors.
• Federal agencies may be compelled to reprioritize, down-size
projects, de-scope work and even terminate programs.
• Contractors may be required to do (even) more with (even) less,
and should act proactively to protect themselves.
Sequestration Planning
5
• Government representatives have indicated that agencies are not
yet making specific plans for Sequestration
• Legislation is pending to require agencies to disclose how they
plan to handle potential across-the-board spending cuts
• With no formal, publicly announced plan, contractors are left to
navigate the risks and realities of Sequestration
• Sequestration and contract impacts may give rise to new contract
disputes and litigation, with eventual decisions by the Courts and
Boards of Contract appeals
• Contractors should exercise caution, but should also take steps
now to mitigate risks and manage strategically
Near Term Effects – Contractor Layoffs
6
• Reports that contractors may need to issue layoff notices as early as
November 2012 should be viewed skeptically.
• Worker Adjustment and Retraining Notification Act, 29 U.S.C. §§ 2101-
2109 (1994) (―WARN Act‖)
Requires employers to issue 60 days advance written notice to affected
employees or their union representatives (see id. at § 2102(a))
Defines ―employers‖ as businesses having 100 or more employees, (excluding
part-time) or 100 or more employees working at least 4,000 hours (Id. at §
2101(a))
―Mass layoffs‖ can be as few as 50 people at a single site (see id. at §
2101(3)(B)
• Not required for layoffs ―caused by business circumstances that were not
reasonably foreseeable‖ 29 U.S.C.A.§ 102(b)(2)(A)(Supp. 1998)
There is precedent that government contract termination may fall within the
exception, depending on circumstances (the A-12 termination). There should
be more than merely a layoff possibility.
Tests include ―commercially reasonable business judgment‖ and ―sudden‖
circumstances ―outside of the employer’s control.‖
Near Term Effects – Contractor Layoffs, cont’d
• Whether to issue a WARN Act notice must be subject to careful
consideration, and may not be the ―conservative‖ or ―least risk‖
approach
Such a notice could cause workforce disruption, leading critical
employees to depart
Potential adverse impacts on continued performance, creating
termination for cause excuse
Longer term risks to future contracts and competitions
(workforce resources, performance ratings, task orders, etc.)
Think about potential strategic business effects, and consult
with employment counsel and HR professionals
7
Long-Term Effects – More Disputes
8
• In the context of heightened budget pressures, contractors have
already observed increased enforcement activity to secure
repayments or to limit cost recoveries, which may escalate further:
Inspector General or DOJ referrals, DCAA audits, suspension and
debarment actions.
• With fewer federal funds available, performance issues once
resolved as routine contract administration matters (e.g., requests
for equitable adjustments, change orders, economic price
adjustments, delay claims, etc…) may increasingly lead to more
litigation.
Long-Term Effects – Accounting, Cost & Pricing
(AC&P) Considerations
• Extensive contract terminations or scope restructurings could impact
AC&P
– Shift of causal/beneficial relationship of costs
• impact indirect costs rates
• allocations of home office expense or G&A under CAS
– Reduced contract efforts could precipitate:
• Segment closure adjustments under CAS 413; reorganizations or
spin offs (FAR 31.205-27)
• Facility costs: depreciation (CAS 409/FAR 31.205-11); idle
facilities/capacity (FAR 31.205-17)
• Change in cost accounting practices – cost impacts
• Compensation: Severance/Mass Severance (FAR 31.205-6(g));
Deferred compensation (CAS 415); relocation costs (FAR 31.205-
33)
• Pricing and Compliance Implications 9
10
• How might contracts change during Sequestration?
Agencies have various tools to reduce contract obligations, depending
on the type of contract and the individual facts
For prospective contracts, agencies have broad rights to:
• Cancel a solicitation,
• Decline to exercise an option, and
• Not allot additional funding to cost-reimbursement contracts, even if the
contractor has expended costs in preparing a bid or proposal
For current contracts, agencies retain flexibility and may, for instance:
• Reduce contract scope pursuant to FAR ―Changes‖ clause,
• Cancel multi-year contracts if funds are not available for contract
performance for a subsequent program year,
• Suspend or delay performance, or issue stop work orders,
• Opt not to purchase more than the minimum under an IDIQ contract, or
• Terminate contracts for the Government’s convenience
• Not renew programs
Sequestration – Uncharted Waters
11
• Are delays caused by Sequestration excusable?
Excusable delays (e.g., FAR 52.212-4(f), 52.249-8(c), and 52.249-14)
Contractor is liable for default unless non-performance is caused by an
occurrence beyond the reasonable control of the Contractor and
without its fault or negligence
FAR examples include:
• acts of God or the public enemy,
• acts of the Government in either its sovereign or contractual capacity,
• fires, floods, epidemics, quarantine restrictions,
• strikes,
• freight embargoes, and
• unusually severe weather.
Contractors must notify the Contracting Officer in writing as soon as
reasonably possible after the commencement of any excusable delay
Excusable delays entitle contractor to additional time and/or limits
contractor liability for failing to meet the schedule
Sequestration – Uncharted Waters
12
• Are delays caused by Sequestration compensable?
Compensable delay is a subset of excusable delay
Entitles the contractor to both additional time and a price adjustment
Compensable delays generally include:
• Acts of the Government in its contractual, but not sovereign,
capacity
• Contract contingencies for which the contract assigns the risk to the
Government (e.g., differing site conditions, delayed change orders)
• Federal Circuit precedent has held that to recover damages for a
Government-caused delay, the contractor must prove:
The extent of the delay
That the delay was proximately caused by Government action
That the delay harmed the contractor
When both parties contribute to a delay neither can recover absent clear
apportionment of the delay and the expense attributable to each party
Sequestration – Uncharted Waters
Sequestration – Uncharted Waters
• Does Sequestration fall within “force majeure” clauses?
• FAR does not define force majeure
Addressed in other FAR clauses (e.g., FAR 52.212-4(f), 52.249-8(c),
and 52.249-14)
• Force majeure provisions are common in subcontracts and commercial
supplier agreements, which may affect the parties’ obligations in the event
of certain ―unforeseen‖ circumstances
• Force majeure provisions are commonly tailored, depending on the nature
of the contract. They typically cover more than merely ―acts of God.‖
• Force majeure provisions often apportion business risks equitably between
the parties, and describe the parties’ respective responsibilities in the case
of unforeseen events
• Study the contract clause language! Force majeure provisions do not
always relieve parties fully of their mutual obligations should they
encounter something ―beyond their reasonable control.‖
13
Recommendations for Contractors
14
1. Ensure compliance and continued contract performance
• Suggestions to prepare for the worst by scaling back and slowing down to
mitigate risk may in fact create greater risks
• Federal contract obligations remain in force until formally ended/changed
and contractors must continue performance as required--maintain key
personnel, performance milestones and delivery schedules
• Contractors cannot and should not scale back contract performance
unless directed by the CO
Consider written communications with the CO to confirm that,
notwithstanding impending Sequestration risks, contract performance
should continue unabated
• Avoid actions that disrupt or prevent future contract performance
• DO NOT give the Government a reason to terminate contracts for Cause
or Default
Agency does not pay the contractor for work performed under the
contract, and may later seek to recover re-procurement costs
Recommendations for Contractors
15
2. Assess contract portfolio
• Review current contract requirements Examine order exercising/canceling options against Sequestration’s current timeline
Examine prime/subcontract mix - subcontracts to large primes with larger programs
may be more secure than smaller prime contracts that may be allowed to expire or
even terminated
Review Forward Pricing Rate Agreements (FPRA) and Award Fee; budget reductions
may impact pricing and fee calculations
• Review prospective bid/proposal schedule for future contracts Assume that non-mission essential contracts will be phased out, non-renewed, options
will not be exercised or even terminated
Focus on work supporting core Government missions
Recognize that service contracts are often the first targeted and agencies may
increasingly in-source various services
Be aware that current contracts may be extended versus issuing new solicitations
Note that agencies have broad discretion in cancelling solicitations prior to contract
award, and contractors must generally show that cancellation was in bad faith or
otherwise unreasonable in order to recover the costs of preparing bids or proposals for
canceled solicitations
Recommendations for Contractors
16
3. Prepare to mitigate financial consequences
• As disruptions in contracts and cash flow begin -- contractors
with heavy debt loads will face significant risk
• Invoice the Government now for all current amounts the
contractor seeks to recover under each contract
• Confirm that record-keeping and accounting practices are
current and up to date—essential to T for C claims
• Where possible, begin preparing claims to recover contract
costs
With mass contract reductions, and potentially thousands of
contract claims, the claims process will likely take even longer
• Evaluate potential aggressive cost reductions now before
automatic spending cuts set in
– Are there preferable descoping options that could be presented to
the contracting officer when sequestration hits?
Recommendations for Contractors
17
4. Enhance ability to make wise judgments
• Wise judgments depend on information and expertise
• Continue communication with Agency customer and
Government policy leaders
• Stay informed through business organizations, political groups
and trade associations
• Have an experienced board of directors/advisory board in
place to help make solid judgments about what to do when
the Government’s decisions take effect
• Ensure access to experienced professionals to help make
decisions and/or respond to Government actions
Government contracts
Employee/HR/personnel
Investment/business
Audit/CPA
Thank you and good luck!
18
Caitlin K. Cloonan Counsel
Northern Virginia
Suite 900
1600 Tysons Boulevard
McLean, VA 22102-4865
+1 703.720.7021
+1 703.720.7399 (fax)
Mark D. Colley Partner
Washington, D.C.
555 12th Street, NW
Washington, D.C. 20004-1206
+1 202.942.5720
+1 202.942.5999 (fax)