haryana state industrial & infrastructure...
TRANSCRIPT
HARYANA STATE INDUSTRIAL & INFRASTRUCTURE DEVELOPMENT
CORPORATION LIMITED __________________________________________________________
TENDER
FOR
PROVIDING ELECTRIFICATION AND STREET
LIGHTING IN
PHASE-II, IE MANAKPUR
1
HARYANA STATE INDUSTRIAL &
INFRASTRUCTURE DEVELOPMENT
CORPORATION LIMITED PART-1 OF 2
INSTRUCTIONS TO BIDDERS
&
CONDITIONS OF CONTRACT
TENDER FOR PROVDING ELECTRIFICATION AND STREET LIGHTING IN PHASE-II,IE MANAKPUR
2
HARYANA STATE INDUSTRIAL & INFRASTRUCTURE DEVELOPMENT
CORPORATION LIMITED ELECTRICAL WING, VANIJYA NIKUNJ, UDYOG VIHAR,
PHASE-V, GURGAON
INDEX
Sr. No.
Name of Contents Page No.
SECTION-1
I Press Notice 3
II Detailed Notice Inviting Tender 4-9
SECTION-2
Instructions to Bidders ,Eligibility Criteria &
Conditions/ Guidelines of E-Tendering
10-16
SECTION-3
Tender Form for filling Rates (Form of Bid) 17-18
SECTION-4
I Conditions of Contract 19-50
II Special terms and Conditions of Contract 51
SECTION-5
Agreement Format
52-53
SECTION-6
Bill of Quantities and List of makes
54-65
3
SECTION-1 (I)
Press Notice
Haryana State Industrial & Infrastructure Development Corporation
NOTICE INVITING TENDERS
Tenders are invited from the enlisted contractors in HSIIDC, PWD(B&R)/Haryana, NDMC/New –Delhi, CPWD & MES through online
bids in the Website http://hsiidc.etenders.in for the following work.
1) The eligibility criteria has been defined as under: 1. The bidder should have HT license issued by Chief Electrical
Inspector for execution of HT electrical works of any state of India. The bidder should also submit the affidavit that if the
work is awarded to him he would arrange the license from Chief electrical Inspector, Haryana, within one month of award of contract.
2. “The agency should have successfully completed one similar
nature of work of costing not less than 80% of value of this work or two similar works costing not less than 50% of value of this work or three similar works costing not less than 40% of value of
this work during the last five years.”
2) For details and e-tendering schedule, visit website http://hsiidc.org
& http://hsiidc.etenders.in
Superintending Engineer(E) Udyog Vihar, Vanijya Nikunj Phase-V, Gurgaon
Phone No.0124-2341573 Email: [email protected]
Name Of Work Estimated Cost
(Rs. in lakhs)
Earnest Money
(Rs. in lacs)
Time Limit
Cost of Bid
Document (Rs.)
Date and time for bid
preparation to Hash
Submission
Providing electrification and
street lighting in Phase-II,IE
Manakpur
330.19 6.61 Nine Months
15000/- 25-06-2013
From 17.01 Hrs. to
17-07-2013
Upto 17.00 Hrs.
4
SECTION-1 (II)
DETAILED NOTICE INVITING TENDER/BIDS
Tenders/Bids are invited from enlisted bidders with HSIIDC/PWD (B&R),
Haryana/NDMC/CPWD/MES through online bids on the website
http://hsiidc.etenders.in for the following work:
Name of Work : Estim
ated
Cost
(Rs. in
lakhs)
Earnest
Money
(Rs. in
Lacs)
Cost of
Tender
Documents
(Rs. )
Time Limit
Date and time for bid
preparation to Hash
Submission.
Providing
electrification and street lighting in Phase-II,IE Manakpur
330.19 6.61 15000/- Nine Months
25-06-2013
From 17.01 Hrs. to
17-07-2013
Upto 17.00 Hrs.
1. Bidding Documents can be downloaded online from the Portal
http://hsiidc.etenders.in by the Contractors registered on the Portal.
2. The bids are required to be submitted as single percentage basis
above or below the Total DNIT Cost at the space provided after
the priced BOQ in figure as well as in words. In any discrepancy,
the writing in words will be applicable.
3. As the Bids that are to be submitted online are required to be
encrypted and digitally signed, the Bidders are advised to obtain the
Digital signature at the earliest. For obtaining Digital Certificate, the
Bidders may contact the representative of Next Tenders, the service
Providers of Electronic Tendering System.
5
4. The bidders can submit their tender documents (Online) as per dates
mentioned in the key dates mentioned in the tender documents.
Sr. No.
HSIIDC Stage
Contractor Stage
Start Date & Time
Expiry Date & Time
Envelops
1 Release of Tender
- 20.06.2013 09.00 Hrs.
25.06.2013 17.00 Hrs.
-
2 - Download Tender
Document
25.06.2013 17.01 Hrs.
17.07.2013 17.00 Hrs.
3 - Online Tender
Document fee payment, Bid Preparation &
Hash Submission
25.06.2013 17.01 Hrs.
17.07.2013 17.00 Hrs.
Price Bid
Envelope, Technical Envelope
4 Technical and Financial
Lock
-
17.07.2013 17.01 Hrs.
19.07.2013 17.00 Hrs.
Price Bid Envelope, Technical
Envelope
5 - Re-encryption
of Online Bids
19.07.2013 17.01 Hrs.
22.07.2013 17.01 Hrs.
Price Bid
Envelope, Technical Envelope
6 - Manual Submission of
BS and (Technical) Documents.
18.07.2013 10.00 Hrs.
23.07.2013 11.30 Hrs.
BS & Documents
7 Open BS & Technical /
PQ bid
- 23.07.2013 11.31 Hrs.
23.07.2013 17.00 Hrs.
Technical Envelope
8 Technical
Evaluation
- 23.07.2013 17.01 Hrs.
29.07.2013 12.00 Hrs.
Technical
Envelope
9 Open Financial/Pr
ice bid
- 29.07.2013 12.01 Hrs.
29.07.2013 17.00 Hrs.
Price Bid Envelope
5. The Bidders can download the bidding documents from the Portal
www.hsiidc.org & hsiidc.etenders.in. Tender Document Fees
Rs.15,000/- has to be paid online during the Bid Preparation and
Hash Submission stage and Bid Security has to be submitted in a
separate sealed BS envelope. The desired Contractors shall have to
6
pay the Tender Document Fees mentioned against the work at the
time of Bid Preparation and Hash Submission stage. The Bid security
will have to be in any one form as specified in the Bidding Document.
The BS envelope has to reach the Office of the Superintending
Engineer(Elect.), HSIIDC Udyog Vihar,Vanijya Nikunj, Phase-V,
Gurgaon on or before the date as mentioned in the above table.
However, as the details of the BS are required to be filled at the time
of Bid Preparation and Hash Submission stage, the Bidders are
required to keep the BS ready appropriately.
6. The tender shall be submitted by the tenderer in the following three
separate envelopes online: 1. Bid Security/Earnest Money- Envelope 'BS' 2. N.I.T. and Technical Bid Envelope 'T1'
3. Tender in Form – A (Price Bid) Envelope 'C1'
Note: Online Bidders are required to submit the physical BS in
a physical BS Envelope - ‘BS’ and any other document related to
Technical Bid which cannot be submitted online in a physical
Technical Envelope - ‘T1’. Price Bids are to be submitted
mandatorily online and shall not be accepted in any physical form.
Reference of the BS is to be mentioned online. Also, in case of Technical
Bids, the list of documents being submitted physically is to be uploaded
online.
Above envelopes, as applicable, shall be kept in a big outer envelope,
which shall also be sealed. In the first instance, the Envelope - 'BS' of all
the Bidders containing the Earnest Money shall be opened online and
physically. If the Earnest Money is found proper, the Envelope 'T1'
containing Technical Bid shall be opened in the presence of such
contractors who choose to be present. The Financial Offer in Envelope
'C1' shall be opened only if the Tenderers meet the qualification criteria
of the Technical Bid document. The date of opening of Financial Bid shall
be fixed at the time of opening of Technical Bid.
7
THE CONTRACTUAL AGENCIES WILL SUBMIT THE NECESSARY DOCUMENTS AS UNDER.
Envelope ‘BS’ – Bid Security/Earnest Money Envelope
Physical BS Envelope – The Bid Security will have to be in any one of the forms as specified in the Bidding Document.
Online BS Envelope – Reference details of the Earnest Money Deposit instrument and scanned copy of the Bid Security.
Envelope ‘TI’ – Technical Bid Envelope Online Technical Envelope – All the information and scanned copies of
the Documents / Certificates as required to be submitted as per the Tender and also, the
list of such documents that cannot be submitted online, if any.
Physical Technical Envelope – All the Information and Documents / Certificates as required to be submitted as per the Tender that cannot be submitted
online, if any.
In case financial bid is submitted and technical bid, Bid Security is
not submitted by any bidder, and then bidder would be debarred from
further tendering in HSIIDC for a period of minimum one year.
Envelope ‘CI’ – Price Bid Envelope
To be submitted mandatorily online.
The Contractual Agencies can submit their tender documents
(online and physical) as per the dates mentioned in the Key Dates above.
CONDITIONS:-
1) DNIT & eligibility criteria can be seen on any working day during office hours in office of the undersigned.
2) Conditional tenders will not be entertained & liable to be rejected.
8
3) In case of the day of opening of tenders happens to be holiday, the tenders will be opened on the next working day. The time and place of receipt of tenders and other conditions will remain
unchanged.
4) The undersigned reserve the right to reject any tender or all the tenders without assigning any reason.
5) The tender without earnest money will not be opened.
6) The jurisdiction of court will be at Gurgaon.
7) The tender of the bidders who does not satisfy the qualification
criteria in the bid documents are liable to be rejected, summarily
without arising any reason and no claim whatsoever on this
account will be considered.
8) The bid for the work shall remain open for acceptance during the
bid validity period to be reckoned from the last date of ‘manual
submission of (Technical) documents & BS. If any bidder /
tenderer withdraws his bid / tender before the said period or
makes any modifications in the terms and conditions of the bid,
the said earnest money shall stand forfeited. Bids would require
being valid for 90 days from the date of bid closing i.e. from last
date of manual submission of (Technical) documents & BS. In case
the last date to accept the tender happens to be a holiday, validity
to accept tender will be next working day.
9) If the agency submitted financial bids through e-tendering but fails
to submit either security or the technical bid or both, then the
agency will be debarred from further e-tendering in HSIIDC for two
year.
9
Endst.No. Dated:-
CC: For information please
1. The General Manager (IA), HSIIDC, Panchkula.
2. All Branch In charges of HSIIDC
3 All approved Contractors of HSIIDC. (Through Registered Post).
4. Notice Board.
Superintending Engineer(E) Udyog Vihar, Vanijya Nikunj, Phase-V, Gurgaon Phone No.0124-2341573
10
SECTION 2
INSTRUCTIONS TO BIDDERS
1. Scope of Bid
1.1. The Employer (named in Appendix to ITB) invites bids for the construction of works (as defined in these documents and referred
to as “the works”) detailed in the table given in IFB. The bidders may submit bids for any or all of the works detailed in the table given in IFB.
1.2 The successful bidder will be expected to complete the works by the intended completion date specified in the Contract data.
1.3. Throughout these bidding documents, the terms ‘bid’ and ‘tender’
and their derivatives (bidder/tenderer, bidding/tendering, etc.) are synonymous.
1.4 The bidding document consists of two books as below Book 1 – ITB and Conditions of Contract Book 2 – Bill of quantities and List of makes
2. Eligibility Criteria
This Invitation for Bids is open to all bidders registered with HSIIDC, PWD (B&R) Haryana, NDMC New Delhi, and CPWD & MES who fulfill the qualification criteria prescribed as under:
1. The bidder should have HT license issued by Chief Electrical Inspector for execution of HT electrical works of any state of India. The bidder should also submit the affidavit that if the work is
awarded to him he would arrange the license from Chief electrical Inspector, Haryana, within one month of award of contract.
2. “The agency should have successfully completed one similar nature of work of costing not less than 80% of value of this work or two similar works costing not less than 50% of value of this work
or three similar works costing not less than 40% of value of this work during the last five years.”
For this, a Certificate from the employer shall be submitted along with the applicant incorporating clearly the name of the work,
Contract value, billing amount, date of commencement of works, satisfactory performance of the Contractor and any other relevant information.
NOTE:- The proof of the above mentioned eligibility criteria shall be
submitted by the contractor in the technical envelope.
11
SUBMISSION OF BIDS
Conditions/Guidelines for e-tendering.
1. These conditions will overrule the conditions stated in the tender documents, wherever relevant and applicable.
2. Registration of Contractors on HSIIDC’s website http://hsiidc.etenders.in.
All the Contractors register with HSIIDC, intending to buy the tender document online are required to register for Electronic Tendering on the
website- http://hsiidc.etenders.in order to participate in the tenders located using the Electronic System.
The Contractors registered with other Departments who are also eligible to participate in the Tenders process by HSIIDC, are also required to be
registered on the Electronic Tendering System in GENERAL category. For more details, please see the information in Registration Info link on
the Home Page. 3. Obtaining a Digital Certificate:
The Bids required to be submitted online should be signed electronically
with a Digital Certificate to establish the identity of the Bidder, bidding online. These Digital Certificates are issued by an approved Certifying Authority, authorized by the Controller of Certifying Authorities,
Government of India.
A Digital Certificate is issued upon receipt of mandatory identity proofs and verification letters attested by the banker with whom the contractor maintains the account with. Only upon the receipt of the required
documents, a Digital Certificate can be issued.
The registered contractors may obtain Class – II B Digital Certificates
from any Certifying Authority or Sub-Certifying Authority authorised by the Controller of Certifying Authorities or may obtain information and
application format and documents required to issue of digital certificate from:
1. NexTender (India) Pvt. Ltd.
Yuchit, Juhu Tara Road, Mumbai-400049
Email: [email protected]
12
2. NexTender (India) Pvt. Ltd.
Old PWD (B&R) Haryana, Nirman Sadan Building
(Basement) Plot No. 1, Dakshan Marg, Sector-33A, Chandigarh – 160020 Tel. 0172-2618292
Email : [email protected] for Technical Assistance at Gurgaon :
Mr. Sanjay Kumar, Cell No. +91 8743042801 for Technical Assistance at Rohtak : Mr. Kapil Ghai, Cell No. + 91 9255125260
3. The registered contractors may obtain the digital certificates
from any other Certifying Authority of Sub-certifying Authority authorised by the Controller of Certifying Authorities., Government of India.
Bid for a particular Tender may be submitted only using the Digital Certificate, which is used to encrypt the data and sign the hash during
the stage of Bid Preparation and Hash Submission. In case, during the process of a particular Tender, the Authorised User looses his / her
Digital Certificate (i.e. due to virus attack, hardware problem, operating system problem); he / she may not be able to submit the Bid online. Hence, the Authorised User is advised to back up his / her Digital
Certificate and keep the copies at safe place under proper security to be used in case of emergencies.
In case of online tendering, if the Digital Certificate issued to the
Authorised User of a Firm is used for signing and submitting a Bid, it will be considered equivalent to a no-objection certificate / power of attorney to that User. A Firm has to authorize a specific Individual via an
Authorisation Certificate / Letter signed by the majority of the Partners to use the Digital Certificate as per Indian Information Technology Act
2000. Unless the Digital Certificate is revoked, it will be assumed to represent adequate authority of the Authority User to bid on behalf of the Firm for the Tenders processed by the HSIIDC as per Information
Technology Act 2000. The Digital Signature of this Authorized User will be binding on the Firm. It shall be the responsibility of Partners of the Firm to inform the Certifying Authority or Sub Certifying Authority, if the
Authorized User changes, and apply for a fresh Digital Certificate and issue an Authorization Certificate for the new Authorised User. The
procedure for application of a Digital Certificate will remain the same for the new Authorised User.
The same procedure holds true for the Authorized Users in a Private /
Public Limited Company. In this case, the Authorisation Certificate will have to be signed by the Directors of the Company.
13
4. Opening of an Electronic Payment Account:
For purchasing the tender documents online, contractors are required
to pay the tender document fees online using the electronic payments gateway service as mentioned in the Bid Documents.
Following modes of electronic payments are accepted on the electronic
tendering system.
a) Credit Cards – Electronic Credit Card Transactions through the following Credit Card sypes are supported: Master Card / VISA /
American Express / Diners Club International / JCB Cards / Citibank E-Cards.
b) Internet Banking– Electronic Internet Banking Transactions
through Internet Banking Accounts of the following Banks are supported: HDFC Bank / Citi Bank / ICICI Bank / IDBI Bank /
UTI Bank / Oriental Bank of Commerce – Global Trust Bank / Federal Bank / Centurion Bank of Punjab Limited / IndusInd Bank / Kotak Mahindra Bank / Punjab National Bank.
5. Set up of Machine
In order to operate on the electronic tender management system, a
user’s machine is required to be setup. A help file on setting up of the system can be obtained from NexTender (India) Pvt. Ltd. Or downloaded from the home page of the website http://hsiidc.etenders.in
6. Online Viewing of Detailed Notice Inviting Tenders:
The Contractors can view the detailed Notice Inviting Tenders and the detailed Time Schedule (Key Dates) for all the packages processed by
HSIIDC using the Electronic Tendering System on the http://hsiidc.etenders.in
7. Purchase of Tender Documents
Online Purchase/Download of Tender Document : The tender documents can only be downloaded from the electronic tendering website
–“ http://hsiidc.etenders.in in after logging in with a valid Username and Password or from HSIIDC website http://hsiidc.org It is to be noted that it is mandatory that the tender document is download from the electronic
tendering website to be able to submit electronic bids. The payment of the Tender Document fee has to be made before preparation and
submission of bid. The last date of the submission of Tender Document Fee is as indicated in Detailed Notice Inviting Bids.
14
8. In case online Query processing facility of online bidding is functional:
Prospective bidder should notify the Employer through the query processing facility available online set up to the date and time indicated
in the Notice Inviting Tender. In Such case, the copies of the employer response will be displayed on line including a description of the enquiry, but without identifying its source.
Prospective bidders can participate in the pre-bid meeting using the Query processing facility available online. Prospective bidders can use
the Query processing facility available on-line to do so but not later than one week before the meeting. Responses given will be displayed online
without delay. 9. Submission of Bid Seal (Hash) of Online Bids:
Submission of Bids will be preceded by submission of the digitally signed Bid Seals (Hashes) as stated in the Tender Time Schedule (Key Dates)
published in Detailed Notice Inviting Bids.
The information related to bids should be filled in or uploaded in the available templates under each envelope. After filing templates/uploading documents online, the hash of each envelope is
required to be generated and digitally signed by a digital certificate of the person duly authorised to sign on behalf of the bidder.
10. Generation of Super Hash:
After the expiry of the time of submission of digitally signed Bid Seals (Hashes) by the Contractors, has lapsed, the bid round will be closed and a digitally signed Tender Super Hash will be generated by the authorised
Official of HSIIDC. This is equivalent to sealing the Tender Box.
11. Submission of actual online Bids:
Contractors have to submit their encrypted Bids online and upload the relevant documents for which they generated the respective Hashes during the stage of Bid Preparation and Hash Submission after the
generation of Super Hash within the date and time as stated in the Detailed Notice Inviting Bids (Key Dates). The Electronic Bids of only the Contractors who have submitted their Bid Seals (Hashes) within the
stipulated time, as per the Tender Time Schedule (Key Dates), will be accepted by the Electronic Tendering System. A Contractor who does not
submit his Bid Seals (Hashes) within the stipulated time will not be allowed to submit his Bid.
Note: The bidder shall fill/upload the information related to bids in the available templates under two separate envelopes marked “TI” and “CI”.
15
After filling templates/uploading documents online, the hash of each
envelope is required to be generated and to be digitally signed. The documents that cannot be submitted online should be submitted as in manual Bids in the relevant physical envelopes. The physical envelops
should be submitted before the end time and date of the stage – ‘Re-encryption and Submission of Bid Data’ as indicated in the Notice
Inviting Tenders. In case of online Bids, no information related to “Financial Bid” shall be accepted manually.
12. Submission of Cost of Bid Documents and Bid Security(BS):
Contractor has to submit cost of bid documents online and BS in the form of Demand Draft of Rs. 6.61 lakhs(Demand Draft in favour of
HSIIDC payable at Gurgaon, as prescribed in the contract data). Bid Security in the form as prescribed in Section – I (ITB) of bid document is to be delivered alongwith cost of documents in a sealed envelope to the
officer well in stipulated time as prescribed in list of important dates.
13. Opening of Electronic Bids: Electronic bid of contractors, whose cost of bid document and bid
security have been received before stipulated time, will only be opened. The online bid data will be taken opened through the website http://hsiidc.etenders.in.The hashes of each bid will be matched with the
hash generated and submitted during the state – “Bid preparation and Hash Submission’. In the event of a mismatch, the bid in question will be
liable for a due process of verification by HSIIDC. 14. Key Dates:
The contractors are strictly advised to follow dates and times as
indicated in the Detailed Notice Inviting Bids. The date and time as
indicated in the top-right of the web-page is the system time and will be binding on all contractors. All online activities are time tracked and the
system enforces time-locks that ensure that no activity or transaction can be take place outside the start and end dates and time of the stage as defined in the Notice Inviting Tenders.
15. Online query system is not functional for this package.
16. In case there is any contradiction in tender process then
instruction contained in the guidelines for e-tendering will
prevail. 17. Deadline for Submission of the Bids
Complete Bids (including technical and financial) must be received by the Employer at the address specified above not later than the date indicated
16
in schedule. In the event of the specified date for the submission of bids
declared a holiday for the Employer, the Bids will be received upto the appointed time on the next working day.
18. The Employer may extend the deadline for submission of bids by issuing an amendment in which case all rights and obligations of the
Employer and the bidders previously subject to the original deadline will then be subject to the new deadline.
17
SECTION 3 (FORM FOR PRICE BID)
I/We hereby tender for the execution of the works for the Haryana State Industrial & Infrastructure Development Corporation Limited (herein after
referred to as HSIIDC) specified in the underwritten memorandum within the time specified in such memorandum.
Single percentage rates are to be quoted in the box specified below in figures as
well as in words above/below applicable on each items of bill of quantities:
I
(In figures) (In Words)
And in accordance, in all respects, with the specifications, drawings and instructions in writing referred to in Section 1 to 6 of this document and with such materials as are Provided by the Engineer-in-charge in all other respect
in accordance with such conditions so far as applicable.
Enter both the rates in words as well as figures only in this space provided
above. In the event of variation of rate in words and figures, the lower value only shall be considered. Only single percentage on all items of DNIT/BOQ is to be entered. In case more than one percentage is entered, the tender will be
liable to be rejected.
We Quote our rates_________
Above/below which will be
applicable on the rate of each item of Bill of Quantities
We Quote our rates_________
Above/below which will be
applicable on the rate of each item of Bill of Quantities
18
MEMORANDUM
a) General Description: Providing electrification and street lighting in Phase-II, IE Manakpur
b) Estimated Cost: Rs. 330.19 lakhs
C )Earnest money : Rs 6.61 lakhs
d) Security Deposit: 5% (including earnest money)
e) Percentage, if any, to be deducted 5% from each running bill in lieu of security deposit:
f)Time allowed for the work from date of allotment of work: Nine Months
If this tender be accepted I/We hereby agree to abide by and fulfill all the terms and provisions of the said conditions of contract annexed hereto so far as applicable or in default thereof forfeit to and pay to the
Corporation or its successors in office, the sums of money mentioned in the said conditions. The sum of Rs.--------- is herewith forwarded in demand draft No.---------
----Dated --------as earnest money the full value of which is to be absolutely forfeited by the Corporation or its successors in office,
without prejudice to any other rights or remedies of the said Corporation , or its successors in office should I/We fail to commence the works specified in the above memorandum or otherwise the said sum of Rs.-----
--- shall be retained by the Corporation on account of the security deposit specified in clause 1 of the said conditions of contract. Should
I/We withdraw or modify the tender within the period of bid validity, my/our earnest money will stand forfeited to the said Corporation.
(Signature of the Contractor) Dated the ________ Day of________2013 Witness
Occupation The above tender is hereby accepted by me for and on behalf of the
Corporation. Dated the_________ Day of___________ 2013
Superintending Engineer (E) HSIIDC, Electrical Wing
19
Condition of Contract
Clause 1: The person/persons whose tender may be accepted (hereinafter called the contractor), shall permit the Engineer-in-charge, HSIIDC. Udyog Vihar, Gurgaon
hereinafter called the Engineer-in-charge at the time of making any payment to him for work done under the
contract to deduct such sum amount to five percent of all money so payable. Such deductions to be held by HSIIDC by way of security deposits.
Security deposit. This will be
the same percentage as
that in the tender at (e)
Clause 2: The time allowed for carrying out the work as entered in the tender shall be strictly, observed by the contractor and shall be reckoned from the 7th day from
which the order to commence work is given to the contractor. The work shall throughout the stipulated period of the
contract be proceeded with all due diligence (time being deemed to be the essence of the contract on the part of the contractor). To ensure good progress during the execution of
work the contractor shall be bound in all cases in which the time allowed for any work exceeds one month to complete
one half of the work before one half of such time has elapsed and three fourth of the work before the three fourth of such time has elapsed. In the event of the contractor failing to
comply with this conditions he shall be liable to pay a compensation as mentioned below: i) The time permitted for the entire work of supply,
installation, testing and commissioning in all respects to the satisfaction of the Engineer-in-charge shall be
reckoned from the 7th day of award of work. ii) If work is not initiated or left before the middle
stage i.e. work paid is less than 60% and delayed
beyond half of the completion period the penalty will be levied @2% per week of delay subject to maximum of 10% of the original tender cost as advertised in the
paper. iii) If 80% work is over and paid and then if left
incomplete or delayed beyond the completion time, percentage compensation will be levied @2% per week subject to a maximum of 5% of the tender cost.
iv) The MD/HSIIDC will have the power to reduce or waive the penalty/compensation after receiving the
representation from the contractor and it is felt that penalty is wrong fully imposed but such representation will be entertained only after the contractor first
completes the work and then makes the representation. The decision of MD/HSIIDC will be final and will not be challengeable before the arbitrator or any other court of
law in the country. v) The date of completion of work will be the one on
Penalty/ compensation
of delay
Completion Period
20
which the contractor has received the completion
certificate from the Engineer-in-charge. vi) The time period, however, can be extended by the
Engineer-in-charge if he is satisfied with the reasons
stated by the Contractor for the delay being due to unforeseen circumstances beyond the control of
Contractor. vii) In case the work is slow and/or not completed
within a reasonable time as decided by Engineer-in-
charge, HSIIDC reserves the right to get the work executed from other agencies at the risk and cost of contractor.
Clause 3: In any case in which under any clause or clauses of this contract the contractor shall have rendered himself
liable to pay compensation amounting to the whole of his security deposit (whether paid one sum or deducted by installment) the Engineer-in-charge shall have power to
adopt any of the following courses, as he may deem best suited to the interests of HSIIDC.
a) To rescind the contract (of which decision, notice in
writing to the contractor under the hand of the Engineer-
in-charge shall be conclusive evidence) and in which case the security of the contractor shall stand forfeited, and be absolutely at the disposal of HSIIDC.
b) To employ labour paid by the HSIIDC and to supply
materials to carry out the work, or any part of the work debiting the contractor with the cost of the labour and the price of the materials (of the amount of which cost and
price against the contractor) and crediting him with the value of the work done, a certificate of the Engineer-in-charge shall be final and conclusive in all respects in the
same manner and at the same rates as if it had been carried out by the contractor and is the terms of his
contract, the certificate of the Engineer-in-charge as to the value of the work done shall be final.
c) To measure up the work of the contractor and to take such part thereof as shall be unexecuted out of his hands
and to give it to another contractor to complete, in which case any expenses which may be incurred in excess of the sum which would have been paid to the original
contractor if the whole work had been executed by him (certificate of Engineer-in-charge for excess amount so incurred, shall be final and conclusive) shall be born and
paid by the original contractor and may be deducted from money due to him by HSIIDC under the contract or
Action when whole security
deposit is forfeited.
21
otherwise or from his security deposit or the proceeds of
sale thereof a sufficient part thereof.
In the event of any or the above recourses being adopted
by Engineer-in-charge the contractor shall have no claim to compensation for any loss sustained by him by reason
of his having purchased or procured any materials, or entered into any engagement or made any advances on account of or with a view to the execution of the work for
the performance of the contract. And in the case the contract shall be rescinded under the provision aforesaid the contractor shall not be entitled to recover or be paid
any sum for any work therefore actually performed under the contract, unless and until the Engineer-in-charge will
have certified in writing the performance of such work and the value payable in respect thereof and he shall only be entitled to be paid the value so certified.
Clause 4: In any case in which any of the powers, conferred upon the Engineer-in-charge by clause 3 thereof shall become exercisable and the same not be exercised, the non
exercise thereof shall not constitute a waiver of any of the conditions here of and such powers shall not withstanding be exercisable in the event of any future case of default by
the contractor for which by any clause or clauses hereof he is declared liable to pay compensation amounting to the whole
of his security deposit and the liability of the contractor of past and future compensation shall remain unaffected. In the event of the Engineer-in-charge putting in force either, or
the powers (a) or (c) vested in him under the proceeding clause he may, if he so desires take possession of all or any tools, plant, materials and stores in or upon the works, or
the site thereof or belonging to the contractor, or procured by him and intended to be, used for the execution of the work
on any part therof paying or allowing for the same ;in account at the contract rates, or in case, of these not being applicable at current market rates to be certified by the
Engineer-in-charge whose certificate hereof shall be final other wise the Engineer-in-charge may give notice in writing
to the contractor or his clerk of the works, foreman or other authorities agent require him to remove such tools, plant, materials, or store from the premises (within a time to be
specified in such notice) and in the event of the contractor failing to comply with any such requisition, the Engineer-in-charge may remove them at the contractor’s expenses or sell
them by auction or private sale on account of the contract and at his risk in all respects and the certificate of the
22
Engineer-in-charge as to the expenses of any such removal
and the account of the proceeds and expenses of any such sale shall be final and conclusive against the contractor.
Clause 5: If the contractor shall desire an extension of the time for completion of the work on the ground, of his having
been unavoidable hindrance in its execution or any other ground, he shall apply in writing to the Engineer-in-charge Gurgaon within 30days of the date of the hindrance on
account of which he desires, such extension as aforesaid but before the expiry of contract period and the Engineer-in-charge shall in his opinion (which shall be final) responsible
grounds be shown therefore authorise such extension of time if any as may, in his opinion be necessary or proper.
Clause 5(a): The contractor shall deliver in the office of the Engineer-in-charge on or before the 10th day of every month
during the continuance of the work covered by this contract, a return showing details of any work claimed for as extra,
and such return shall also contain the value of such work as claimed by contract, which value shall be based upon the rates and prices mentioned in the contract or in the
schedule of rates force in the District for the time being. The contractor shall include in such monthly return particulars of all claims of whatever kind and however arising, which at
the date thereof he has or may claim to have against the Engineer-in-charge under or in respect or in any manner
arising out of execution of work and the contractor shall be deemed to have waived all claims not included in such return and will have no right to enforce any such claims not
so included, whatsoever be the circumstances.
Clause 6: Without prejudice to the rights of Corp. under any clause hereinafter contained on completion of the work,
the contractor shall be furnished with a certificate by the Engineer-in-charge (thereinafter called the Engineer-in-charge) of such completion, but no such certificate shall be
given, nor shall the work be considered to be complete until the contractor shall have removed from the premises on
which the work shall be executed all scaffolding surplus materials, and rubbish and cleaned of the dirt from all wood works, door, windows, walls, floors or other parts of any
building, in upon or about which the work is to be executed, or of which he may have had possession for the purpose of the execution thereof and the measurements in the said
certificate shall be binding and conclusive against the contractor. If the contractor shall fail to comply with the
Contractor to submit return every
month for any work claimed as
extra.
District rates means the HSIIDC rates
for that District.
Final certificate.
Payment on intermediate
certificate to be regarded
23
requirements of this clause as to removal of scaffolding,
surplus materials and rubbish, and cleaning off dirt on or before the date fixed for the completion of the work, the Engineer-in-charges may at the expenses of the contractor,
remove such scaffolding, surplus materials and rubbish and dispose off the same as he thinks fit and clean off such dirt
aforesaid and the contractor shall forthwith pay the amount of all expense so incurred and shall have no claim in respect of any such scaffolding or surplus materials as aforesaid
except for any sum actually realized by the sale thereof less any expense by the Engineer-in-charge in connection therewith.
Clause 7: No payment shall be made for work estimated to
cost less than rupees one thousand, till after the whole of the works shall have been completed and a certificate of completion given. But in case of works estimate to cost more
than rupees one thousand the contractor shall be submitting the bill thereof be entitled to receive a monthly payment
proportionate to the part thereof than approved & passed by the Engineer-in- charge whose certificate of such approval and passing of the sum so payable shall be final and
conclusive against the contractor. But all such intermediate payments shall be regarded as payments byways of advances against the final payment only and not as payment for work
actually done and completed and shall not preclude the requiring of bad, unsounded and imperfect or un-skilful
work to be removed and taken away and reconstructed or re-erected, or be considered as an admission of the due performance of the contract, or any part thereof in any
respect or the according of any claim, nor shall it conclude, determine or affecting any way the powers of the Engineer-in-charge under these conditions, or any of them as to the
final settlement and adjustment of the accounts or otherwise or in any other way vary or affect the contract. The final bill
shall be submitted by the contractor within one months of the date fixed of completion of the work otherwise the Engineer-in-charge certificate or the measurement and of the
total amount payable for the work accordingly shall be final and binding on all parties.
as advance.
Clause 7(a) : The deductions referred to in clause 1 herein before or such part thereof as may be due to the contractor
under this contract shall be payable to the contractor against Bank Guarantee of same amount. 7(b) : Security deducted from each running and final bill will
be refunded after completion of defect liability period of twenty four months for the entire electrical works from the date of
24
handing over the installation.
Clause 8: A bill shall be submitted by the contactor each month on or before the date fixed by the engineer-in-charge for
all work executed in the previous month and the Engineer-in-charge shall take or cause to be taken the requisite
measurements for the purpose of having the same verified and the claim, as far as admissible if possible, before the expiry of ten days from the presentation of the bill, if the contractor
does not submit the bill within the time fixed as aforesaid, the Engineer-in-charge may depute a subordinate to measure up to the said work in the presence of the contractor, whose
counter signature to the measurement list will be sufficient warrant, and the Engineer-in-charge may prepare a bill from
such list which shall be binding on the contractor in all respects.
Bill to be
submitted monthly.
Clause 9: The contractor shall submit all bills in triplicate on the printed forms to be had on applications at the office of the
Engineer-in-charge, and the charges in the bill shall be entered at the rates specified in the tender or in the case of any extra work always be ordered in pursuance of these
conditions/and not mentioned or provided for in the tender at the rates hereinafter provided for such work.
Bill to be
printed forms.
Clause 10: If the specification of estimate of the work
provides for the use of any special description of materials to be supplied from the engineer-in-charge store or if it is
required that the contractor shall use certain store to be provided by Engineer-in-charge (such materials and stores, and the prices to be charged thereof as hereinafter mentioned
being so far as practicable for the convenience of the contractor but not so as in any way to control the meaning or effect of this contract specified in the schedule or
memorandum have to be annexed), the contractor shall be supplied with such materials and stores as required from time
to time be used by him for the purposes of the contract only and value of the full quantity of materials and stores so supplied at the rates specified in the said schedule or
memorandum may be set off or deducted from any sums then due or thereafter to become due to the contractor under the
contract or otherwise against or from the security deposit or the proceeds of sale thereof if the same is held in government securities the same or the sufficient portion thereof being in
this case sold for the purpose. All materials supplied to the contractor shall remain in the property of the contractor but shall not on any account be removed from the site of the work
without the written permission of the Engineer-in-charge and shall at all times be open to inspection by him. Any such
Stores supplied by Government
25
materials unused and in perfectly good condition at the time of
determination of the contract shall be returned to the Engineer-in-charge’s store if by a notice in writing under his hand he shall so require but the contractor shall not be
entitled to return any such materials unless with such consent and shall have no claims for compensation on account of any
such material so supplied to him as aforesaid being unused by him or for any wastage in damage to any such materials.
Clause 11: The contractor shall execute the whole and every part of the work in the most substantial and work man like manner and both as regard material and otherwise in every
respect in strict accordance with the specifications. The contractor shall also conform exactly, fully to the designs, contract drawings and instructions in writing relating to the
work signed by the engineer –in-charge and lodged in his office and to which the contractor shall be entitled to have
access at such office or at the site of the work for the purpose of inspection during office hours, and the contractor shall if he so requires be entitled at his-own expense to make
or cause to be made copies of the specifications and of all such designs, drawings and instructions as aforesaid. 11 (a) : The work shall be done in accordance with the
relevant IS codes as applicable to the said work and amended upto date. The above codes shall also apply in
addition to by laws, rules and regulations as per I.E Act. 11 (b) : The tenderer shall submit detailed schematic diagram for the approval of the Engineer-in-charge. He will
make sure that the equipments offered shall fulfill the design conditions. All the equipment and their installation shall be
suitable for the environment conditions countered at the location. If any deviations from the specifications are contemplated, these shall be clearly brought out in the
tender. If the tenderer fails to bring out specific deviations, it will be presumed that the work shall be carried out as per the specifications.
11 (c) : The Engineer-in-charge shall have full powers at all
times to object to the employment of any workmen, foreman or other employees on the works by the contractor and if the contractor shall receive notice in writing from the Engineer-
in-charge requesting the removal of any such man or men from the work the contractor shall comply with the request
forthwith. No. such workman, foreman or other employee after his
removal from the works by request of the engineer-in-charge
Works to be executed in accordance
with specification drawings
order etc.
Removal of employees
workman.
26
shall be re-employed or reinstated on the work by the
contractor at any time, except with the previous approval in writing of the Engineer-in-charge.
The contractor shall not be entitled to demand the reason from the Engineer-in-charge for requiring the removal of any
such workman, or foreman or other employees. Clause 12: The Engineer-in-charge shall have power to make any alterations in or commissions from additions to or
substitutions for the original specifications, drawings, designs and instructions that may appear to him to be necessary or advisable during the progress of the work and
the contractor shall be bound to carry out the work in accordance with any instructions which may be given to him
in writing signed by the Engineer-in-charge and such alterations, omission additions or substitutions shall not invalidate the contract, and any altered additional or
substituted work which the contractor may be directed to don in the manner above specified as part of the work shall
be carried out by the contractor on the same conditions in all respect on which he agreed to do the main work and at the same rates as are specified in the tender for the main work.
The time for the completion of the work shall be extended in the proportion that the altered additional or substituted work bears to the original contract work and the certificate of the
Engineer-in-charge shall be conclusive as to such proportion. And if the altered, additional or substituted work
include any class of work for which no rate is specified in this contract than such class of work shall be carried out at the rates entered in the schedule of rates of the district,
subject to the same percentage above or below, as for the items included in the contract and if such class of work is not entered in the schedule of rates of the district, the
contractor shall within seven days of the date of his receipt of the work order to carry out the work inform the Engineer-in-
charge of the rate which is his intention to charge for such class of work, and if the Engineer-in-charge does not agree to this rate he shall by notice in writing be at liberty to cancel
his order to carry out such class of work and arrange to carry it out in such manner as he may consider advisable
provided always that if the contractor shall commence work or incure any expenditure in regard there to before the rates shall have been determined as lastly herein before mentioned
then and in such case he shall only be entitled to be paid in respect of the work carried out or expenditure incurred by him prior to the date of determination of the rates as
aforesaid according to such rate or rates as shall be fixed by the Engineer-in-charge, in the event of dispute, the decision
Alternation in specifications
and designs. DO not
invalidate contract.
Extension of
time in consequence of alteration.
Rates of work not in
estimate or schedule of
rates of the Distt.
27
of General Manager(IA)/MD,HSIIDC shall be final.
Clause 13: If at any time after the issue of work order or commencement of the work, the Corp. shall for any reason whatsoever not require the whole work there of as specified
in the tender to be carried out, the Engineer-in-charge shall give notice in writing of the fact to the contractor who shall
have no claim to have any payment or compensation whatsoever on account of any profit or advantage, which he might have derived from the execution of the work in full, but
which he did not derive in consequence of the full amount of the work not having been carried out, neither shall he have any claim compensation by reason or any alteration having
been made in the original specification, drawings, designs and instructions which shall involve any curtailment of the
work, as originally contemplated.
No. compensation
for alteration in quantum
or restriction of work to be carried out.
Clause 14: If it shall appear to the Engineer-in-charge or his subordinate in charge of the work. That any work has been
executed with unsounded, imperfect or unskillful workmanship, or with materials of any inferior description,
or that any materials of articles provided by him for the work are unsound or of a quality inferior to that contracted fro, or otherwise not in accordance with the contract, the contractor
shall on demand in writing from the Engineer-in-charge specifying the work materials of articles complained of not with standing that the same may have been inadvertently
passed certified and paid for, forth with rectify, or remove and reconstruct the work so specified in whole or in part, as
the case may require as the case may be remove the materials or articles so specified and provide other, proper and suitable material or article at his own cost, and in the
event of his falling to do so within a period to be specified by the Engineer-in-charge in his demand aforesaid, the contractor shall be liable to pay compensation at the rate of
one percent on the amount of the estimated cost of work covered by this contract for everyday exceeding ten days
while his failure to do so shall continue and in the case of any such failure the Engineer-in-charge may certify or remove and re-execute the work or remove and replace with
other materials or articles complained of as the case may be at the risk and expense in all respects of the contractor.
Action and
compensation payable in
case of bad work.
Clause 15: All work under or in course of execution of executed in pursuance of the contract shall at all times be open to the inspection and supervision of the Engineer-in-
charge and his subordinates and the contractor shall at all times, during the usual working hours and at all other times at which reasonable notice of the intension of the Engineer-
in-charge or his sub-ordinate to visit the works shall have been given to the contractor either himself be present to
Work to be open to inspection.
Contractor or agent
responsible to be present
28
receive orders and instructions or have a responsible agent
duly accredited in writing present for that purpose, orders given to the contractor’s agent shall be considered to have the same force as if they had been given to the contractor
himself.
Clause 16: The contractor shall give not less than five days
notice in writing to the Engineer-in-charge or his subordinate-in-charge of the work before covering up or otherwise placing beyond the reach of the measurement any
work that the same may be measured and correct dimensions thereof be taken before the same is so covered up or placed beyond the reach of measurement and work
without the consent in writing of the Engineer-in-charge of his subordinate-in-charge of the work if any work shall be
covered up or placed beyond the reach of measurement without such notice having been given or consent obtained, the same shall be uncovered at the contractor’s expense or in
default thereof, no payment or allowances shall be made for such work/ materials with which the same was executed.
Notice to by given before works
covered up.
Clause 17: If the contractor and his work people or his servant shall break, deface injure or destroy any part of property in which they may be working or any building, road
fence, enclosure or grass cultivated ground continuous to premises on which the work or any part of it is being executed or if any damage shall happen to the work, while in
progress from any cause what ever or any imperfections become apparent in it within three months after a certificate
final or other of its completion shall have been given by the Engineer-in-charge as aforesaid, the contractor shall make the same good at his own expense, or in default the
Engineer-in-charge may cause the same to be made good by other workman and deduct the expense of which the certificate of the Engineer-in-charges shall be final from any
sums that may be than or at any time thereafter may become due to the contractor or from his security deposit or the
proceeds of sale there of or of a sufficient portion thereof.
Contractors liable for damage done
and for imperfection for 3months
after certificate.
Clause 18: The contractor shall supply at his own cost all
materials (except such special material if any as may in accordance with the contract be supplied from the Engineer-in-charge’s stores) plant, tools appliances implements
necessary test instruments ladders, college tackle, scaffolding and temporary works requisite or proper for the
execution of the work whether original altered or substituted and whether included in the specification or other documents forming part of the contract or referred to in
these conditions or not which may be necessary for the
Contractor to supply plant ladders
scaffolding etc.
29
purpose of satisfying or computing with requirements of the
Engineer-in-charge as to any matter as in which under these conditions he is entitled to be satisfied or which he is entitled to require together with carriage thereof to and from the
work. the contractor shall also supply without charges the requisite number of persons with the means and materials is
necessary for the purpose of setting out work and counting, weighing and assigning in the measurement of examination at any time and from time and from time to time of the work
or materials. Failing his so doing the same may be provided by the Engineer-in-charge at expenses of the contractor and the expenses may be provided by the Engineer-in-charge at
expenses of the contractor and the expenses may be deducted from any money due to the contract or from his
security deposit or the proceeds of sales thereof or of sufficient portion thereof.
The contractor shall also provide all necessary fencing and heights, required to protect the public from accident and
shall be bound to bear the expenses of defence of every suit, action or other proceedings at law that may be brought by any person for injury, sustained owing to neglect of the
above precaution and to pay any damage and costs which may be awarded in any such suit, action or proceedings to any such persons or which may with the consent of the
contractor be paid to compromise any claim by any such person.
Contractor
liable for damages
arising from non provision of light
fencing etc.
Clause 19: Contractor shall be liable to indemnify the Crop. against all claims.
Clause 19(a): No labour below of 14 years shall be employed on the work. Clause 19(b): The contractor shall not pay his labourers less
than the wages paid for similar work in neighborhood.
Clause 20: No work shall be done on Sunday without the
sanction in writing of the Engineer-in-charge. Clause 20(a) : In every case in which by virtue of the provisions of Section-12 sub-section(1) of the workman’s
Compensation Act, 1923 Corp. is obliged to pay compensation to a workman employed by the contractor, in
execution of the works, Corp. will recover from the contractor the amount of the compensation so paid and without the prejudice to the rights of Government under section 12 sub-
section(2) of the Act, Corp. shall be at liberty to recover such amount or any part there of by deducting it from the security deposit or from any sum due by Corp. to the contractor
whether under this contract or otherwise. Corp. shall not be bound to contest any claim made against
30
it under section 12sub-section (1) of the said Act except on
the written request of the contractor and upon his giving to Corp/Full security for all costs for which Corp. might become liable in consequence of contesting such claim.
Clause 21 : The contract shall not be assigned or sublet
without the written approval of the Engineer-in-charge, and if the contractor shall assign or sublet his contract or attempt to do or become insolvent or commence any in-
solvency proceedings or make any compensation with his creditors or attempt to do or if any bribe, gratuity/gift loan, requisite reward of advantage, pecuniary or otherwise shall
either directly or indirectly be given promised or offered by the contractor or any of his servants or agents to any Public
Officer or person in the employee of Corp. in any relating to his office or employment or any such officer, or person shall become in any way directly-or indirectly interested in the
contract the Engineer-in-charge may thereupon by notice in writing rescind the contract and the security depose of the
contractor shall thereupon stand forfeited and be absolutely at the disposal of Corp. and the same consequences shall ensure as if the contract had been rescind under clause 3
here of and in addition the contractor shall not be entitle to recover or be paid for any work therefore actually performed under the contract.
Work not to
be sublet. Contract may
be rescind and security deposit
forfeited to subletting
bribing for contract becomes
insolvent.
Clause 22: All sums payable by way of compensation under
any of these conditions shall be considered as reasonable compensation to be applied to the use of Government without reference to the actual loss or damage sustained and
whether or not any damages shall have been sustained.
Sum payable
by way of compensation to be
considered as reasonable compensation
without reference to
actual loss. Deduction of amounts due
to Corp. Clause 22(A): Any excess payment made to the contractor
inadvertently or otherwise under this contract or any account whatever and any other sum bound to be due to Government by the contractor in respect of this contract or
any other contract or work order or any account whatever may be deducted from sum whatever payable by Government to the contractor either in respect of this contract or any
work order or any other account by any other department of the Government.
On any
account whatsoever to be
permissible from sums payable to
contractor.
31
Clause 23: In the case of tender by partners any change in
the constitution of the firm shall be forthwith notified by the contractor to the Engineer-in-charge for his information.
Changes in
constitution of firm.
Clause 24: All works to be executed under the contract shall be executed under the direction and subject to the
approval in all respects of the General Manager(IA) of the Corp. for the time being who shall be entitled to direct at
what points and in what manner they are to be commenced from time to time.
Clause 25: No claims for payment of an extraordinary nature, such as claims for a bonus for extra employed in completing the work before the expiry of the contractual
period at the request of the Engineer-in-charge or claims for compensation where work has been temporarily brought to a
standstill though no fault of the contractor shall be alcove unless _____________ extent that the same shall have been expressly ______________________ for payment and
______________ any nature to be referred to corp. for decision by the MD/HSIIDC.
Claim for payment of an
extraordinary nature to be
referred to Crop. For decision.
Clause 25(A): (1) If any dispute or difference of any kind
whatsoever shall arise between the Corporation/his authorised agents and the contractor in connection with or arising out of the contract of the execution of the work that is
(i) whether before its commencement or during the progress of the work or after its completion (ii) and whether before or after
the termination abandonment or breach of the contract it shall in the first instance be referred to for being settled by the Engineer-in-charge incharge of the work at the time and
he shall within a period of sixty days after being requested in writing by the contractor to do so convey his decision to the
contractor and subject to arbitration as hereinafter provided such decision in respect of every matter so referred shall be final and binding upon the contractor. In case the work is
already, in progress, the contractor will proceed with the execution of the work on receipt of the decision by the Engineer-in-charge incharge as aforesaid with all due
diligence whether he Corp. authorised agent requires arbitration as hereinafter provided or not if the Engineer-in-
charge incharge of the work has conveyed his decision to the contractor and no claim to arbitration has been filed with him by the contractor with in a period of sixty days from the
receipt of letter communicating the decision. The said decision shall be final and binding upon the contractor and
32
will not be subject matter of arbitration at all. If the Engineer-
in-charge incharge of the work fails to convey his decision within a period of sixty days after being requested as aforesaid the contractor may within further sixty days, of the expiry of
first sixty days from the date on which request has been made to the Engineer-in-charge request General Manager(IA) that
the matters in dispute be referred to arbitration as hereinafter provided.
2). All disputes or differences in respect of which the decision is not final and conclusive shall at the request in writing of either party, made in communication sent through
Registered AD Post be referred to the sole arbitration of any serving GM(IA) to be nominated by designation by
the MD/HSIIDC at the relevant time, it will be no objection to any such appointment that the arbitrator so appointed is Corp. servant or that he had to deal with the matters to
which the contract relates and that in the course of his duties as Corp. servant he had expressed his views on all
or any of the matters in dispute. The Arbitrator to whom the matter is originally referred being transferred or vacating his office, his successor in office as such shall be
entitled to proceed with the reference from the stage at which it was left by his predecessor.
3). It is also a term of this arbitration agreement that no
person other than a person appointed by MD/HSIIDC shall Act as arbitrator and if for any reason that is not possible
the matter shall not be referred to arbitration at all. In all cases where the aggregate amount awarded exceeds than 20% of claim amount or Rs.1.00 lacs whichever in less, the
arbitrator must invariably give reasons for his award in respect of each claim and counter claim separately.
4). The arbitrator shall award separately giving his award
against each claim and dispute raised by either party including any counter claim individually and that any
lump sum award shall not be legally enforceable. 5). The following matters shall not lie within the purview of
arbitration :-
(a) Any dispute relating to the levy of compensation as liquidated damages which has already been referred to
the GM(IA) and is being heard or/and has been finally decided by the Engineer-in-charge in charge of the work.
(b) Any dispute in respect of substituted, altered additional work/omitted work/defective work referred by contractor for the decision of the Engineer-in-charge
incharge of the work. If it is being heard or has already been decided by the Engineer-in-charge.
33
(c) Any dispute regarding the scope of the work or its
execution of suspension or abandonment that has been referred by the contractor for the decision of the Corp. and has been so decided finally by the HSIIDC.
6). The independent claim of the party other than the own
getting the arbitrator appointed, as also counter claims of any party will be entertained by the arbitrator notwithstanding that the arbitrator has been appointed
at the instance of the other party. 7). It is also a term of this arbitration agreement that where
the party invoking arbitration is the contractor no
reference for arbitration shall be maintainable unless the contractor furnished to the satisfaction ;of the Engineer-
in-charge incharge of the work a security deposit of a sum determined according to details given below and the sum so deposited shall on the termination of the
arbitration proceedings be adjusted against the cost if any, awarded by the arbitrator against the claimant party
and the balance remaining after such adjustment in the absence of any such cost being awarded the whole of the sum will be refunded to him within on months from the
date of the award:-
Amount of Claims Rate of Security Deposit
i) For claims below Rs.10000/- - 2% of amount claimed
ii) For claims of Rs.10000/- and above - 5% of
amount claimed. and below Rs.100000/- iii) For claims of Rs.100000 and above 10% of amount
claimed. The stamp fee due on the award shall be payable by the party as desired by the arbitrator and
in the event of such party’s default stamp fee shall be recoverable from any other sum due to such party under this or any other contract.
8). The venue of the arbitration shall be such place or places as may e fixed by the arbitrator his sola discretion. The
work under the contract shall continue during the arbitration proceeding.
8(a): Jurisdiction:
All disputes arising out of or relating to the contract shall be deemed to have arisen in Chandigarh and only courts having jurisdiction over Chandigarh shall determine the
same.
34
9). Neither party shall be entitled to bring a claim for
arbitration if the appointment of such arbitrator has not been applied within six months:- a) of the date of completing of work as certified by the
Engineer-in-chargeincharge or b) of the date of abandonment of the work or
c) of its non-commencement within six months from the date of abandonment or written orders to commence the work as applicable, or
d) of the completion of the work through any alternative agency or means’ after withdraw of the work from the contractor in whole or in part and/or its recession. or
e) of receiving an intimation from the Engineer-in-charge incharge of the work that final payment due to or
recovery from the contractor had been determined which he may acknowledge and/or receive. Whichever of (a) to (e) above is the latest.
If the matter is not referred to arbitration within the
period prescribed above all the rights and claim of any party under the contract shall be deemed to have been forfeited an absolutely barred by time vain for civil
litigation notwithstanding. 10). It is also a term of this arbitration agreement that no
question relating to this contract shall be brought before and Civil Court without first involving and completing the
arbitration proceedings as above if the scope of the arbitration specifies here in converse issue that can be brought before the arbitrator i.e. any matter that can be
referred to arbitration shall not be brought before a Civil Court. The pendency of arbitration shall not restraint Crop. to terminate the contract and make alternative
arrangement for the completion of the work.
11). The arbitrator shall be deemed to have entered on the
reference on the day he issued notices to the parties fixing the first date of hearing. The arbitrator may from
time to time with the consent of the parties, enlarge the initial time for making and publishing the award.
12). It is also a term of arbitration agreement that subject to the stipulation herein mentioned, the arbitration proceeding shall be conducted in accordance with the
provision of the arbitration Act, 1940 or any other law in force for the time being
35
Clause 26: The contractor shall obtain from the stores of the
Engineer-in-charge ail stores articles of European or American manufacture which may be required thereof or in connection therewith unless he has obtained permission in
writing from the Engineer-in-charge to obtain such stores and articles elsewhere. The value of such stores and articles as
may be supplied to the contractor by the Engineer-in-charge will be debited to the contractor in his account at the rates shown in the schedule attached to the contract, and if they
are not entered in the schedule they will be debited at cost price which for the purposes of this contract shall include the cost of carriage and all other expenses whatsoever which shall
have been incurred in obtaining delivery of the same at the stores aforesaid.
Stores of
European or American manufacture
to be obtained
from Corp.
Clause 26(a): Any fluctuations in Railway rates which may occur during the substance of and affecting freights of any
material to be supplied under this contract shall be brought to the notice of the Engineer-in-charge by the contractor
within 15 days from such date without prejudice to the rights of Corp. should the contractor fail to comply with the above requirement any excess for short charge on account of such
increase or decreased shall be admissible in consequence of fluctuation in railway freight when such railway freight is on account of materials which is required by a contractor in the
manufacture of an article to be supplied under this contract e.g. fluctuation of railway freight on coal enquire for burning
bricks will not be taken into consideration or for an article which forms part of a finished work for purpose of t his clause. Similarly no alteration in rates will be allowed when a
manufactured article is transported by rail from place A to place B to form part of a finished work.
Fluctuation
of Railway Freight
Clause 27: The contractor shall be responsible for making his own arrangements for securing priorities and license for
material and transportation required for the works and Engineer-in-charge shall not be held responsible in any way for making such arrangements for any of them.
Clause 28: In the case of any clause of work for which there
is no such specification as is mentioned in rule 1 such work shall be carried out in accordance with the district specification and in the event of there being no district
specifications then in such case the work shall be carried out in all respects, in accordance with the instructions and requirement of Engineer-in-charge.
36
Clause 29: The expression ‘work or “works” where used in these conditions
shall unless there be something either in the subject or context repugnant to such construction be constructed and taken to mean the work by virtue of the contract contracted to be executed whether temporary or permanent and
whether original altered substituted or additional.
29(a) The work shall be done in accordance with the relevant IS codes as applicable to the said work and amended upto date. The above codes shall also apply in addition to by laws, rules and regulations as per I.E Act.
29(b) DESIGN EQUIPMENT SELECTION AND DEVIATIONS The tenderer shall submit detailed schematic diagram for the approval of
the Engineer-in-charge. He will make sure that the equipments offered shall fulfill the design conditions. All the equipment and their installation
shall be suitable for the environment of conditions countered at the location. If any deviations from the specifications are contemplated, these shall be clearly brought out in the tender. If the tenderer fails to bring
out specific deviations, it will be presumed that the work shall be carried out as per the specifications.
29(c) The tenderer shall quote the prices strictly on the basis of the
specifications and schedule of work. In case of deviations as per para
above the tenderer may give reduction or addition on prices quoted as per specifications, towards the same.
29(d) SITE INFORMATION
The tenderer is advised to visit the site for any detail and, technical particulars and other site requirement by him before tendering.
29(e) WORKS TO BE DONE BY THE CONTRACTOR
In addition to supply, installation, testing and commissioning of all equipments, as per schedule of work. The following work shall be deemed
to be included with in the scope of work to be executed by the contractor. i) Provisions of supports and the clamps for equipment cables trays,
ducts, etc.
ii) Sealing of the cable entry points in sub-stations against seepage of water, rodent etc.
iii) Tools and tackles required for handling and installations. iv) Necessary testing equipments for commissioning. v) The contractor shall, on supply of material and equipment for
bonafide use on work at site, continue to be responsible for their safe custody till they are installed in position, tested, commissioned and handed over to the engineer-in-charge. The contractor shall furnish
an unstamped receipt to the engineer-in-charge for all the items of
37
materials and equipments supplied at site before requesting for
secured advance payment. 29(f) COMPLETENESS OF TENDER
All sundry fittings, assemblies' accessories, hardware items. Foundation bolts and all other sundry items which are useful and necessary for
efficient working of the various components of the work shall be deemed to have been included in the tender, whether such items are specifically mentioned in the tender documents or not.
29(g) EXCLUSIONS
The items exclude from the offer but required functionally, should be
clearly defined & listed giving description of the items, quantity & estimated cost.
Clause 30: The percentage referred to at page 3 of the tender will be calculated on the gross amount (value of finished work including cost of
material whether purchased from Corp. or direct ) of (1) the items of work to which the tender apply and also (2) the items of work to which rates exist in
the schedule of rates of the direct……………. 30 (a) RATES
The rates quoted by the tenderer shall be firm inclusive of all taxes and duties and no escalation in the rates shall be permitted due to any increase in case of labour and/or of materials either due to statutory
variations on account of taxes and duties or on any other account. The tenderer should quote the rates of labour work on the basis of
HSEB/PSEB Schedule of rates as indicated in the scope of work, wherever applicable.
30(b) TAXES & DUTIES i) Being a through contract, the statutory deductions as applicable, viz.,
WCT, Income tax, Worker welfare cess,Service tax etc shall be deducted
from each running/secured advance bill.
ii) Sales tax on individual items of materials and equipment as may be necessary shall be paid by the contractor directly to the supplier, and the same shall not be separately reimbursed to him.
iii) No octroi shall be paid separately.
Clause 31: PAYMENT TERMS
i) The contractor on submitting bill thereof shall be entitled to receive payment after checking of measurement and satisfaction of Engineer-in-charge.
38
ii) 75% of the contract rates for the materials and equipment supplied
will be paid on initial inspection and receipt of materials at site in good condition.
iii) Further 20% of the contract rates will be paid on completion of pro-
rate installation. iv) Balance 5% value of work after testing and commissioning of
line/equipments to the satisfaction of Engineer-in-charge and after handing over the installation.
v) Security deposit shall be deducted from each running and final bill
to the extent of 5% of gross amount payable. The earnest money of Rs 6.61 lakhs will be adjusted towards security deposit.
v) Security deducted from each running and final bill will be refunded
after completion of defect liability period of twenty four months from the date of handing over the installation.
vi) The payment will be made through cheque payable at Gurgaon. The bank charges, if any, will be borne by the firm.
vii) Any excess payment made to the contractor inadvertently or
otherwise on any account whatsoever will be returned back by them immediately otherwise the said amount will be deducted from their
deposits lying with any of the Govt./Semi Govt. Deptt. viii) The contractor shall indemnify to HSIIDC such material for
which 75% amount received against damage, theft/loss of any
kind whatsoever in relation there to. The Indemnify Bond to this effect shall be submitted on NJSP of value Rs.25/- duly attested by Notary.
Clause 32: MOBILISATION ADVANCE:
No mobilisation advance shall be paid for the work. Clause 33: GUARANTEE
The contractor shall guarantee all material, equipment and workmanship supplied & installed by him for a period of twenty
four(24) months from the date of commissioning and handing over the electrical system installation and replaces the defective parts without
any charge to the department.
Clause 34: DEFECTS LIABILITY
The period of defect liability shall be a period of twenty four(24) months to be reckoned from the date the installation is commissioned & handed over to the Engineer-in-charge in perfect working condition.
39
TOOLS FOR HANDLING AND ERECTION
All tools and tackles required for handling of equipments and materials at site of work as well as for their assembly and erection
and also necessary test instruments shall be the responsibility of the contractor.
Clause 35: CO-ORDINATION WITH OTHER AGENCIES
The contractor shall co-ordination with all other agencies involved in the site work so that the site work is not hampered due to delay in his work.
CARE OF BUILDINGS/SITES
Care shall be taken by the contractor to avoid damage to the building/site during execution of his part of the work. He shall be
responsible for repairing all damaged and restoring the same to their original finish at his cost. He shall also remove at his cost all
unwanted and waste materials arising out of his work from the site. Clause 36: TESTING AND HANDING OVER
a) The contractor shall carry out tests on different equipments as specified in various sections in the presence of Engineer-in-charge in order to enable them to determine whether the plant equipment and installation in
general comply with the specification.
b) All equipments shall be tested after carrying out necessary adjustment and balancing to establish equipment rating and all other design condition. At least four sets of readings shall be taken for each item tested and
submitted in a standard detailed form or any other acceptable test form. Instrument required for testing shall be furnished by the contractor alongwith initial requirements of all consumables.
c) The plant shall be handed over after satisfactory testing along with four sets of documentation each consisting of
(i) Detailed equipment data in the Performa approved by the Engineer-in-charge.
(ii) Manufacturer's maintenance and operating instructions.
(iii) 3 sets of as built drawings, showing plant layouts. (iv) Approved Test Readings.
(v) Certificate of approval from statutory or local Authorities for the operation and maintenance of the installation and the equipment.
(vi) List of recommended spares.
(vii) Certificate from the contractors that they have cleared the site of all debris and litter caused by them during the construction.
Submission of the above documentation shall form a precondition for the final acceptance of the plant and installation and final payment.
40
Clause 37: SAFETY PRECAUTIONS a) A competent and authorized supervisor shall be on the site whenever the contractor's men are at work. The supervisor should ensure that all the
plant and machinery used on the site are rendered safe for working and meets with the Indian or international safety standards applicable for the use and
operation of such machinery. The supervisor should also ensure that the workmen are supplied with and made to use safety appliances such as safety belts, helmets etc. The supervisor shall not leave the work site without
permission from the Engineer-in-charge.
b) Smoking shall not be encouraged at site but altogether strictly
prohibited in areas where combustible and inflammable goods/materials are stored.
c) Any hot jobs such as welding, soldering, gas cutting shall not be carried out without the permission of the Engineer-in-charge. Such jobs shall
not be carried out where inflammable materials are stored or lying about. All electric connections shall be through adequately sized mechanically protected
cables without any joints and with proper and adequate terminals.
d) It is entirely the responsibility of the contractor to practice the principles
of "SAFETY FIRST" during the entire tenure of work with adequate insurance covering injury or death to workmen loss by theft or damage to materials and property in position or not and third party. The Contractor shall pay the
compensation to the workers under Workmen Compensation Act in case of any accident occurring at the site of work: HSIIDC shall recover the amount from
contractor bill if the amount becomes payable by them.
e) The contractor should clear the site of all debris every day to avoid
accidents. In case this is not done, the department may engage necessary labour to maintain the cleanliness of the premises and removal of debris, and debit all or part of the expenditure so incurred from the contractor.
Clause 38: The sample of PG clamp, bolted type dead end fittings, GSL, Pin
insulator, LT shackle insulator, Egg insulator, GI wire, GI/MS flat and various sizes of MS angle/channel, GI Nuts and Bolts etc. will be got approved from Engineer-in-charge before arranging the material at site.
Clause 39: The terms and conditions of the agreement have been explained
to me/us and I/we clearly understand them. Clause 40: The contractor states that he is not related to
any of the officers employed by the HSIIDC.
Action where
specifications. Clause 41: No pit shaft be dug by the contractor near the site of the work for taking out earth for use on the work in
case of default the pit as dug will be filled in by the Corp. at the cost of the contractor.
Definition of work.
41
Clause 42: Fair wages clause attached.
Clause 43: The contractor shall have to pay sales tax to the Excise and Taxation Deptt. in accordance with the rules in force from time to time.
Clause 44: All payments for work done under this contract shall be made by cheque to the contractor. The work covered by this contract as shown on
plan which have been signed by the contractor are annexed herewith. Clause 45: Should the tenderer withdraw or modify his tender within three
months from the date of opening of tender he is liable to be black listed & earnest money forfeited.
Clause 46: When a final bill is likely to be for a minus amount, the security deposit will be withheld till the final bill is passed and the recoverable amount
is first made good. Clause 47: All royalty and compensation for building stone, bajri and stone
metal etc. should be included in the rates to be quoted and is payable by the contractor.
Clause 48: The rates given are for the finished work inclusive of octroi charges, sales taxes etc.
Clause 49: It will be responsibility of the contractor to ensure that trees at the site of work and in the vicinity of their fruit etc. are not damaged by his
labour or agent assessed the cost of such damage. If any will be at the discretion of the Engineer-in-charge and deducted from the bit of the
contractor. Clause 50: The contractor shall provide at his own cost separate latrine,
bathing enclosures and platform for use of the men and women labour and kept them clean to the satisfaction of the Engineer-in-charge. He should also
arrange at his own expense or clean drinking water, housing, medical facilities necessary for the welfare of the labour employed at his fork. In case of his failure the same shall be provided by the corp. at contractor’s cost. Any
disputes regarding this will be settled by the Engineer-in-charge whose decision will be binding.
Clause 51: Any material left on the site of work after one month from the date of completion of the work shall become the property of the Corp. and no
payment shall be made for It. Clause 52: The amount of the work can be increased or decreased
according to the requirement of the Corp. and no claim whatsoever on this account will be entertained. The quantum of work can be
increased/decreased at any time without assigning any reason or as per the
42
actual site conditions. The payment will be regulated as per the actual work
executed at site. The firm will arrange the material as per the actual site requirement and HSIIDC will not be responsible if material is arrange in excess of actual requirement.
Clause 53: The Crop. reserve option to take away any items of the work or
part thereof any time during the currency of the contract and re-allot it to another agency with due notice to the contractor without liability or compensation.
Clause 54: It is not obligatory on the contractor to employ labour through employment exchange but the may avail of the facilities offered by
employment exchange incase he wished to do so.
Clause 55: No claim on account of fluctuation in prices due to war or any other cause will be entertained.
Clause 56: The contractor shall be liable to make good all damages caused by breakage from the moment the stores, pipes and fittings etc. are handed
over to his charge. Clause 57: No compensation whatever be payable on account of any delay
or default in the supply of material mentioned in the list of material to be issued to the contractor by the Corp. and consequence delay in the execution of work.
Clause 58: The contractor will inform the CMO about the employment of
laborer on the work for carrying out Malaria Surveillance. Clause 59: Sale Tax/Income tax will be deducted from gross payment as per
Govt. instructions. Clause 60: The contractor shall be liable to pay the ESI/CPF/EPF
contribution etc. under the provision of Provident Fund Act to the persons engaged and shall have the registration with Regional Provident Fund
Commissioner under Provident Fund Act as applicable from time to time. The Corp. shall not be responsible for any default committed under these Acts. Clause 61: HSIIDC reserves the right to reject any tender without assigning
any reason. Work can be allotted to more than one contractor.
Clause 62: All equipments/materials shall conform to laid down specification/HVPN/UHBVN/DHBVN specifications. No material shall be despatched without inspection/clearance of HSIIDC at manufacturer work.
Clause 63: Tender should be valid for 90 days from date of its opening.
Clause 64: The contractor shall obtain the NOC from Chief Electrical Inspectorate for all HT installations before commissioning.
43
Clause 65: The contractor shall be responsible for safety of material at site till it is commissioned and formally handed over to HSIIDC/HVPN/UHBVN/DHBVN.
Clause 66: The carriage of material, it's loading/unloading from one
location to another will be done by the Contractor at his own cost. No extra cost will be paid on this account.
Clause 67: If the tenderer/firm withdraw his/its tender after coming lowest. He may be blacklisted and earnest money will be forfeited.
Clause 68: Contractor shall submit PERT CHART of different activities starting from survey, supply of material, approval of drawings, execution
of work, commissioning of line within 10 days of issue of letter of acceptance.
Clause 69: Field quality plan will be followed for foundations, erection of tower and stringing similar to HVPN.
Clause 70: Dismantled material will be returned by contractor to UHBVN/DHBVN/HVPN after obtaining detailed permission in writing
from HSIIDC. Superintending Engineer(E)
HSIIDC Ltd., Udyog Vihar, Gurgaon
44
FAIR WAGES CLAUSES a) The contractor shall pay not less than the fair wage to
labour engaged by him on the work. explanation: ‘Fair Wage’ means wage whether for time or piece work notified at the time of inviting
tenders of the work and where such wages have not been so notified the wages prescribed by the Public Works Department, Building and Road Branch, Labour Deptt. Haryana for the district in which the work
is done. b) The contractor shall notwithstanding the provisions of
any agreement to the contrary, caused to be paid fair wages to labours,
indirectly engaged on the work including any labour engaged by his sub-contractors in connection with the said work. As if the labourers
had been directly employed by him. c) In respect of labour directly employed on the works for
the performance of the contractors part or this agreement the contract
shall comply with or cause to be complied with the Haryana Public Works Deptt., Contractors, Labours Regulations made by Government
from time to time in regard to payment of wages period deduction from wages recovery of wages not paid and deductions un-authorisedly made maintenance of wage work, wage slip, publication of wages and other
terms of employment inspection and submission periodical return and all other matters of alike nature.
d) The Engineer-in-charge concerned shall have the right
to deduct from the money due to the contract any sum required or estimated to be required for making good the loss suffered by the
worker of workers by reason of non-fulfillment of the conditions of the contract for benefit, of the workers, non payment of wages or deductions made from his or their wages, which are not justified by the
terms of the contract for non observance of the regulations referred to in clause (c) above.
e) Vis-à-vis Corp. the contractor shall be primary liable
for all payments to be made under and for the observance of the regulations aforesaid without prejudice to his right to claim indemnity
from his sub contractors. f) The regulations aforesaid shall be deemed to be a part
of this contract.
g) Attendance card should invariably be issued by the contractors to their/workers, which should be returned to the
contractors concerned at time of receiving payment of their wages. h) Before making payments to the contractors the
authorities concerned should obtain a certificate from the contractors
that he has made payments to all the workers connected with the execution of the work for which the payment is being made.
i) Contractors employing 50 or more workers on the site
of a particular work should provide facilities of housing, latrines, water and light to their workers at their own expense.
45
j) The normal working hours of workers employed by
contractors for the execution of work allotted to them should be 8 hours per day with a break of 2 hours during summer, one hour during winter after continuous work of 4 hours at the latest. The spread over
should in no case exceed 10 hours, workers working beyond these hours, should be paid over time wages at the double the ordinary rate
of their wages calculated by the hour. Superintending Engineer(E)
HSIIDC Ltd., Udyog Vihar, Gurgaon
46
HARYANA STATE INDUSTRIAL DEVELOPMENT CORPORATION LIMITED
CONTRACTORS LABOUR REGULATION 1. Short Title: These regulations may be called HSIIDC Contractors Labour
Regulations.
2. Definition: In these regulations, unless otherwise expressed or indicated the following words and expression shall have the meaning hereby assigned to them respectively, that is to say.
1) Labour means workers employed by HSIIDC contractor’s directly or indirectly, a sub contractor or other persons of by an agent on his behalf.
2) ‘Fair’ wages means, whether for item or piece work, notified at the time of inviting tenders for the work and where such wages have not been so notified
the wages prescribed by the Labour Deptt. Haryana of the district in which the work is done. 3) Contractor shall include every person whether a subcontractor or
headman or agent employing labour on the work taken on contract. 4) “Wages” shall have the same meaning as defined in the payment of Wages
Act and includes time and piece rate wages. 3. Display of notice regarding wages etc.
The contractor shall before he commences his work on contract, display and correctly maintain & continue to display and correctly in a clean and
legible condition in conspicuous place of the work notice in English and in the local language spoken by the majority of the workers giving the
rates of wages. Which have been certified by the Engineer-in-charge or Regional Labour Commissioner ad fair wages and the hours of work for which such wage are earned and a copy of such notices to the District
Labour Welfare Officer. 4. Payment of Wages
i) Waged due to every worker be paid to him directly.
ii) All wages shall be paid in current coin or currency or in both. 5. Fixation of wages periods
i) The contractor shall fix the wage periods in respect of which the wages
shall be payable. ii) No wage period shall exceed one month. iii) Wages of every workman employed on the contract shall be paid before
the expiry of ten days after the last of the wage period in respect of which the wages are payable. iv) When the employment of any worker is terminated by or on behalf of the
contractor the wages earned by him shall be paid before the expiry of succeeding the one on which his employment is terminated.
47
v) All payment of wages shall be made on a working day excepting the work
is completed before the expriy of the wages period in which case final payment shall be made within 48 hours of the last working day.
Note : The terms working day means a day, on which the work on which the labour is employed is in progress.
6. Wages Book and Wages Slip etc.
i) The contractor shall maintain a wage book of each worker in such form as may be convenient but the same shall include the following particulars:-
a) Rate of daily or monthly wages.
b) Nature of work for which employed. c) Total number of day worked during each wage period. d) Total amount payable for the work during each wage period.
e) All deductions made from the wages with an indication in each case of the ground for which the deduction is made from the wage.
f) Wages actually paid for each wage period. ii) The contractor shall also maintain a wage slip for each worker
employed on the work. The wage slip shall contain all the particulars given in the wage book.
iii) The Engineer-in-charge may grant exemption from the maintenance of
wage book and wage slips to a contractor who in his opinion may not directly or indirectly employ more than 50 persons on the work.
7. Fines and deductions which may be made from wages
1. The wages of workers shall be paid to him without any deduction of any kind except the following:-
a) Fines. b) Deductions for absence from duty viz, from the place or places whereby
the terms of the employment is required to work. The amount of deduction shall be in proportion to the person for which he was absent. c) Deductions for damage to or loss of goods expressly entrusted to the
employed person for custody, or for loss of money for which he is required to account, where such damage or loss is directly attributable to his neglect or
default. d) Any other deductions which the Corp. may time to time allow.
2. No fine shall be imposed on a worker and no deduction for damage or loss be made until the worker has been given an opportunity of showing case against such fines or deductions.
48
3. The total amount of fine which may be imposed in any one wage period on
a worker shall not exceed an amount equal to half anna in a rupee of wage payable to him in respect of that wage period. 4. No fine imposed on any worker shall be recovered from him by
installments, or after the expiry of 90 days from the date in which it was imposed.
8. Register of Fine etc.
1. The contractor shall maintain a Register of fine and of all deduction for damage or loss such Register shall maintain the reason for which fine was imposed or deduction for damage or loss made.
2. The contractor shall maintain, both in English and local Indian language, a list approved by the chief Labour Commissioner clearly stating the acts of
commissions for which penalty or fine may be imposed on workman and display it is a good condition in a conspicuous place on the work.
9. Preservation of Registers
The wage book, the wage slips and the Register of fines, deductions required to be maintained under these regulations shall be preserved for 12 months after the date of last entry mad in them.
10. Power of Labour Welfare Officer to make investigation Enquiry
The labour Welfare Officer or any person authorised by the Government on their behalf shall have power to make enquiries with a view to
ascertaining and enforcing due and proper observance of the fair wage clause and provisions of these regulations. He shall be investigating into any complaint regarding the default made by the contractor or sub
contractor in regard to such provision. 11. Report of Labour Welfare Officer
The Labour Welfare Officer or any other person authorised as aforesaid
shall submit a report of the result of his investigation enquiry to the Engineer-in-charge concerned indicating the extent, if any to which the default has been committed and the amount of fine recoverable in respect
of the acts of or mission and commission of the labourer with a note that necessary deduction from the contractor’s bill be made and the wages and
other dues be paid to be labourers concerned.
12. Appeal against the decision of Labour Welfare Officer
An person aggrieved to the decision and recommendation of the Labour
Welfare Officer or other person so authorised may appeal against such decision to the Regional Labour Commissioner within 30 days from the
49
date of decision forwarding simultaneously a copy of his Engineer-in-
charge concerned but subject to such appeal the decision of the Labour Welfare Officer shall be final and binding upon the contractor.
13. Representation of Parties
1) A workman shall be entitled to be represented in any investigation or enquiry under these regulations by:-
a) An officer of a registered trade union to which he is a member. b) An officer of Federation of trade unions to which the trade union
referred to in clause, (a) is affiliated.
c) Where the worker is not a member of any registered union as officer of registered trade union connected with or by any other workman
employed in the industry in which the worker is employed. 2) An employer shall be entitled to be represented in any investigation or
enquiry under these regulations by:- a) An employer of an association of employers of which he is member.
b) An officer of an association of employees to which the association referred to in clause (a) is affiliated.
c) Where the employer is not a member of any association or
employees by an officer of an association of employer connected with or by any other employer is engaged.
14. Inspection of Books
The contractor shall allow inspection of Wages Book, the wages slips and Register or fines and deduction to any of his worker or his agent at a convenient time place after notice is received or the Labour Welfare Officer
or any other person authorised by the Government on his behalf. 15. Submission of Returns
The contractor will be (regulation and abolition Act 1970) and the
contract labour (regulation and abolition Central Rule 1971) enforced by Haryana labour and employment Department memo no.12(26-78-4 labour dated 10-6-79). The contractor shall submit periodical returns
may be specified from the time to time.
16. Licencing of Contractor
Every contractor who employs or who employed on any day of the
proceeding 12 calendar months 23 or more workman is covered by the act and is required to obtain a licence. The contractor should obtain the necessary licence as required under section 12 of contract labour
(regulation and abolition act 1970 before commencing the work).
50
17. Amendments
The Haryana Government may from time to time and or amend these regulations as any question as to application interpretation or effect of
these regulation the decision of the Labour Commissioner to Haryana Government in that behalf shall be final.
Superintending Engineer(E) HSIIDC Ltd., Udyog Vihar, Gurgaon
51
Section-4 (II)
SPECIAL TERMS & CONDITIONS OF CONTRACT
In addition to the terms & conditions as stipulated in contract
agreement, following special conditions shall also be applicable in this
contract:
5% security will be deducted from running and final bills and
the 100 % of same will be refunded after completion of defect liability
period of twenty four (24) months .
2 Work contract Tax and Income tax, will be deducted from all the
bills as applicable from time to time. It is also being made clear that the
rates to be quoted by the bidders shall be inclusive of total service tax
liability for this work. The service tax liability of the HSIIDC, as per
applicable law, in respect of this work shall be borne by the bidder,
notwithstanding the fact that part of Service Tax liability is also to be
borne by the bidder itself. The deduction in respect of Service Tax
liability part of HSIIDC will be made from running bills as well as final
bill of the bidder. This deduction will be applicable if the bidder is
not a Company under the Companies Act, 1956 as in case of a
Company, 100% service tax liability is to be borne by the Company
itself.
3 Cess @ 1% of the total cost of construction of project from the
payment of contractor under section-3 of the “Building & Other
Construction Workers Welfare Cess Act-1996” & registration of
establishment under section-7 of the “Building & Other Construction
Workers” (regulation of employment and condition of service tax act
1996) shall be deducted from all running & final bills.
52
AGREEMENT Articles of Agreement made this_____day of ___________ between Haryana
State Industrial & Infrastructure Development Corporation Ltd. having its registered office at Plot No. C-13-14, Sector-6, Panchkula, (hereinafter
referred as Employer which expression shall mean and include its successor in office, executor, administrator and assigns) of the one part and_________________________________________________hereinafter referred
to as 'Contractor which expression shall include his heir, executor, administrator and assigns) of the other part.
WHEREAS the Employer is desirous of executing the External Electrification Works for Haryana State Industrial & Infrastructure
Development Corporation Ltd., and has caused drawings, Specifications and schedule of qualities describing the works to be done, to be prepared by the Employer and WHEREAS the said drawings issued by the
Employer from time to time, and Notice inviting Tenders, instructions to Tenders, General and special Conditions of Contract, Technical
Specification and Schedule of Quantities have been signed by or agreed to execute upon and subject to the conditions set forth herein (hereinafter referred to as the said conditions) and the special conditions
of the work shown upon the said drawings and/or described in the said Specifications and included in the said schedule of quantities at rates therein set forth amounting to the sum of
Rs.__________(Rupees___________________________________________) hereinafter referred to as "the said contract amount".
NOW ITS HEREBY AGREED AS FOLLOWS:
1. In consideration of the said contract amount to be paid at the time and in the manner set forth in the said conditions, the Contractor shall, upon and subject to the said conditions, execute and
complete the work shown upon the said drawings and described in the said drawings and described in the said Specifications and/or
the schedule of quantities and other conditions and within months of the date of commencement of the work the latest day by___________.
2. The date of commencement of the work will be taken as the 7th day
from date of issue of the letter of intent/order for award of the contract.
The Contractor clearly understands that the time is the essence of the Contract, and penalty will be imposed for delay in execution of the work as per the terms of the contract.
53
3. The Employer shall pay the Contractor the said contract amount or
such other sum as shall become payable at the times and the manner hereinafter specified in the conditions.'
4. The following documents shall be deemed to form and be read and construed as part of the Agreement along with the amendments,
negotiated and confirmed in various subsequent letter exchanged as mentioned hereinafter.
i) Notice Inviting Tender ii) Instructions to Tenderers iii) General & Special Conditions of the Contract
iv) Technical Specifications
v) Schedule of Quantities vi) Employer's letter No & date ____/_____/_____ to the
Contractor awarding the Contract
vii) Contractor's letter dated ____/____/_______ to the Employer in acceptance of the award of Contract.
viii) _____________________________________________________ ix) _____________________________________________________ x) _____________________________________________________
xi) _____________________________________________________ 5. Parties here to shall respectively abide by submitting themselves to
the conditions and perform the agreement on their part respectively in such conditions contained.
As witness our hands this __________ day of _______________ 2013 .
SIGNED BY THE SAID
(EMPLOYER) IN THE PRESENCE OF___________________________________________
ADDRESS_______________________________________________________
SIGNED BY THE SAID (CONTRACTOR)
IN THE PRESENCE OF __________________________________________ ADDRESS______________________________________________________
HARYANA STATE INDUSTRIAL &
INFRASTRUCTURE DEVELOPMENT
CORPORATION LIMITED PART- 2 OF 2
(BOQ)
TENDER FOR PROVIDING ELECTRIFICATION AND STREET LIGHTING IN PHASE-II,IE MANAKPUR
Scope of work for Electrification of Phase-II, IE Manakpur
Sr. No. Description Supply & Erection Rate (`) Total Amount (`)
Part- A 11KV HT Line 9,703,352.15 9,703,352.15
Part- B 200 KVA Distribution Transformers & feeder
pillars for LT supply.7,540,443.78 7,540,443.78
Part- C Street Light System 14,630,554.00 14,630,554.00
Part- D High Mast 20 Mts long 1,144,977.40 1,144,977.40
TOTAL 33,019,327.33 33,019,327.33
Say ` 3,30,19,327/-
( Rupees Three Crore Thirty Lakhs Nineteen thousand three hundred and twenty seven only)
Executive Engineer(E) Suprintending Engineer(Elect.)
HSIIDC, Sec-6 HSIIDC
Panchkula Gurgaon
ABSTRACT
Scope of work for Electrification of Phase-II, IE Manakpur
1 Supply & erection of 11 M 400 Kg PCC Poles of size
410x140 mm at bottom and 200x140 mm at top as per
UHBVN specification.
Nos.
420.00 4,900.00 735.00 735.00 6,370.00 2,675,400.00
2 Supply & erection of 9 M 200 Kg PCC Poles of size
315x105 mm at bottom and 115x105 mm at top as per
UHBVN specification.
Nos.
40.00 2,013.00 301.95 301.95 2,616.90 104,676.00
3 Supply & erection of 100 mm2 ACSR conductor `Dog'
including for jumpering and binding etc.
KM41.00 56,151.00 5,615.10 8,422.65 70,188.75 2,877,738.75
5 a) Supply & erection of GSL No. 6 SWG Kg. 3,900.00 55.10 5.51 8.27 68.88 268,612.50
b) Supply & erection of GSL No. 8 SWG Kg. 600.00 55.10 5.51 8.27 68.88 41,325.00
6 Supply & erection of Dead end bolted type aluminium alloy
die cast fittings complete with 20 mm dia U Bolts and Nuts
suitable for :-
a) 100 mm2 ACSR Dog' conductor. Nos 180.00 140.00 14.00 21.00 175.00 31,500.00
7 Supply & erection of PG clamps suitable for :-
a) 100 mm2 ACSR 'Dog' conductor. Nos 950.00 40.00 4.00 6.00 50.00 47,500.00
8 Supply & erection of 4500 Kg Ball and Socket type Disc
insulator make WSI/NP/BHEL/Jayshree/ Rashtriya.
Nos
600.00 293.00 29.30 43.95 366.25 219,750.00
9 Supply & erection of 11 KV 10 KN pin insulator complete
with 250 mm long Pins with Nuts make WSI/NP/BHEL/
Jayshree/ Rashtriya.
Nos.
610.00 73.00 7.30 10.95 91.25 55,662.50
10 Supply & erection of V shape cross arms made out of 1650
mm long MS channel of size 100x50x6 mm.(wt. 16.16 Kg)
Nos.
194.00 857.60 85.76 128.64 1,072.00 207,968.00
11 Supply & erection of Top hamper suitable for 11 M PCC
pole out of MS flat size 50x6 mm (U shaped, wt. 2.96 Kg).
Nos.
194.00 160.00 16.00 24.00 200.00 38,800.00
UHBVN/ Market
Rates (`)
Erection
Charges (`)
Overhead
charges (`)
Total Supply
& Erection
Rate (`)
Total Amount
(`)
Part A - 11 KV HT Line
Sr.
No. Description of Material/equipment. Unit Qty.
12 Supply and erection Stay Sets 8' long complete with X-Plat
460mm of Angle 65x65x6 Elbow & rod Wt. 13.80 Kg.
Nos.
170.00 732.00 73.20 109.80 915.00 155,550.00
13 Supply & erection of GSS wire 7/8 SWG (4 mm) Kg.1,800.00 56.70 5.67 8.51 70.88 127,575.00
14 Supply & erection of GI Nuts & Bolts off sizes Kg. 3,400.00 75.00 7.50 11.25 93.75 318,750.00
15 Supply and erection of MS channel, iron size ISMC
100x50x6 mm (ISI marked) including fabrication charges.
Kg.
3,800.00 45.76 4.58 6.86 57.20 217,360.00
16 Supply and erection of MS channel, iron size ISMC
75x40x6 mm (ISI marked) including fabrication charges.
Kg.
2,850.00 45.76 4.58 6.86 57.20 163,020.00
17 Supply & erection of MS angle iron, size 50x50x6 mm (ISI
Marked) including fabrication charges.
Kg.4,800.00 45.76 4.58 6.86 57.20 274,560.00
18 Supply & erection of MS flat size 50x6 mm including
fabrication charges.
Kg.6,200.00 45.76 4.58 6.86 57.20 354,640.00
19 Supply & erection of 20 mm dia, 2.5 m long Earth electrode
with GI wire 6 SWG wire upto end terminations etc as
required for earthing purpose.
Nos.
120.00 328.00 32.80 49.20 410.00 49,200.00
20 Supply & erection of 11 KV HT XLPE cable size 3x300 mm
sq. to be laid in horizontal boring across the road or in
trench, I mtr.deep with sand and brick covering, refilling of
trench etc. make Gemscab/ Havell's/ Incabe/Fort
gloster/CCI/Sterlite.
Mtr.
800.00 854.39 42.72 128.16 1,025.27 820,214.40
21 Supply & erection of heat shrink type cable sealing ends
suitable for 11 KV, 3x300 sq.mm XLPE cable make
Raychem/Denson/3M/Cabseal.
- - -
a) Outdoor type No22.00 1,220.00 61.00 183.00 1,464.00 32,208.00
22 Supply & erection of 100 mm dia GI pipe B-class. Mtr. 600.00 798.65 47.92 846.57 507,942.00
23 Supply & erection of danger plates of 2 mm thick plate. Nos.420.00 66.00 6.60 9.90 82.50 34,650.00
24 Barbed wire as per UHBVN specifications Kg.1,260.00 50.00 5.00 7.50 62.50 78,750.00
Net Amount 9,703,352.15
NOTE:-
1) The length of line can increase or decrease as per the site condition/requirements.
2) Poles will be painted upto 6' with alternative strips of green and white colour.
3) All metallic parts will be painted with 2 coats of aluminium over and above 2 coats of primer.
The make of the paint shall be Asian/Berger.
4) The choice of make/firm lies with HSIIDC.
Executive Engineer(E) Superintending Engineer(Elect.)
HSIIDC, Sec-6 HSIIDC
Panchkula Gurgaon
Scope of work for Electrification of Phase-II, IE Manakpur
Part B-200kVA distribution transformers with LT panels
Overhead Charge(Erection
Charges)
1 Supply & erection of 200KVA, 11/0.433 KV three phase 50Hz
outdoor type Aluminium wound distribution transformer,
Delta/Star, DYN 11, ONAN cooled with first filling of oil, standard
accessories like Silica gel breather, temperature gauge etc. as
per UHBVN practice on H-pole structure, conforming to 4 star
rating of BEE make Svasca/ Vijay Electricals /CGL /Kanohar
/Indian /Nucon/Century/Jaybee
No.
15.00 294,150.00 - 5,883.00 300,033.00 4,500,495.00
2 Supply & erection of transformer Platform as per UHBVN
specifications.
No.15.00 3,123.00 468.45 187.38 3,778.83 56,682.45
3 Supply & erection of 11KV 400Amp., GO switch complete with
handle pipe & supporting channel as per UHBVN specifications
with RD Fuse arrangement.
No.
15.00 5,452.00 817.80 327.12 6,596.92 98,953.80
4 Supply & erection of 9KV 10KA heavy duty lighting arrestor, 1set
of 3 No. Make:
ELPRO/NP/RAYCHEM/OBLUM/LAMCO/RASHTRIYA
Set
15.00 2,420.00 363.00 145.20 2,928.20 43,923.00
5 Supply, erection, testing & commissioning of outdoor type
double door, 415V, LT Main feeder pillar made out of 2.5mm
(12SWG) CRC sheet comprising of 36kA, 400Amp.,TPN MCCB
as incomer and 5 no. 30kA/25 kA, 125 Amp., TPN MCCB as
outgoing including one set of metering, Busbar, Links.
Indications, Support channels, Canopy and paint with RL 7302
(Siemens Grey) epoxy/PU paint, complete in all
respect.MCCB/MCB: L&T/ Siemens/ Schneider /ABB/ GE
No.
15.00 106,231.00 - 6,373.86 112,604.86 1,689,072.90
6 Supply of material & construction of Foundation for Main LT
feeder pillar as per dimensions.
No.15.00 1,870.00 - - 1,870.00 28,050.00
7 Supply of LT XLPE cable size 3.5Cx300 mm sq. to be laid in
horizontal boring across the road or in trench, I mtr.deep with
sand and brick covering, refilling of trench etc. make as per list
enclosed. Make: GEMSCAB /HAVELLS /CCI /KEI /GRANDLAY
/RALLISON
Mtr
240.00 760.36 - 38.02 798.38 191,610.72
8 Supply and termination of the size 3.5C x 300 sq. mm of
armoured cable with double compression heavy duty brass
glands make Comet and copper lugs make Dowell/Jainsons
Set
15.00 3,277.55 - 163.88 3,441.43 51,621.41
Total Supply
+ Erection
rates (Rs)
Total Amount (Rs) Sr.
No. Description of Material/equipment. Unit Qty. Supply Rate (Rs.)
Loading & Erection Charges
9 Supply and erection of earth pit complete with brick masonary
chamber with CI cover and earth electrode made out of 6 mtr.
long, medium class 40mm (NB) GI pipe duly perforated
complete with salt and charcoal as per stranded earthing
practice. Two Runs of GI flat size 50x6 mm to be provided on
both sides of GI pipe for the whole length.
No.
120.00 4,800.00 - - 4,800.00 576,000.00
10 Supply and erection of GI Strip of 50x6mm size for earthing
purpose.
Kg.2,050.00 67.82 - 4.04 71.86 147,313.00
11 Supply and erection of GI Strip of 25x3mm size for earthing
purpose.
Kg.400.00 70.16 - 4.18 74.34 29,736.00
12 Supply of 100 mm dia GI pipe B-class. Mtr.150.00 798.65 - 47.92 846.57 126,985.50
Total 7,540,443.78
1) All metallic parts will be painted with 2 coats of aluminium over and above 2 coats of primer.
The make of the paint shall be Asian/Berger.
2) The choice of make/firm lies with HSIIDC.
Executive Engineer(E) Suprintending Engineer(Elect.)
HSIIDC, Sec-6 HSIIDC
Panchkula Gurgaon
STREET LIGHT
Scope of work for Electrification of Phase-II, IE ManakpurPart C-Street Light system
1
Supply & erection of 11 M 400 Kg PCC Poles of size 415x140 mm at bottom
and 200x140 mm at top as per UHBVN/DHBVN specification. No. 8 4900 735.00 735.00 6,370.00 50,960.00
2
Supply & erection of 63 KVA, 11/0.433 KV three phase 50Hz outdoor type
Aluminium wound distribution transformer, Delta/Star, DYN 11, ONAN cooled
with first filling of oil, standard accessories like Silica gel breather,
temperature gauge etc. with LT fuse board as per UHBVN specifications on H-
pole structure, conforming to 4 star rating of BEE make Svasca/Vijay
Electricals/Jaybee/CGL/Kanohar/Century/Indian/Nucon
No.
4.00 81,270.00 12,190.50 1,625.40 95,085.90 380,343.60
3Supply & erection of transformer Platform having 2 no. ISMC channels of size
100x50x6mm.
No.4.00 3,123.00 468.45 312.30 3,903.75 15,615.00
4Supply & erection of ISMC channels of size 75x40x6mm including
fabrication charges.
Kg.280.00 45.76 6.86 4.58 57.20 16,016.00
5
Supply and erection of 11KV 400Amp., GO switch complete with handle pipe
& supporting channel and RD fuse arrangement as per UHBVN specifications.
No.
4.00 5,452.00 817.80 327.12 6,596.92 26,387.68
6Supply & erection of 11 KV 10 KN pin insulator 320 CD complete with 250
mm long Pins with Nuts make WSI/NP/BHEL/ Jayshree/ Rashtriya.
No.24.00 73.00 10.95 7.30 91.25 2,190.00
7Supply & erection of 4500 Kg Ball and Socket type Disc insulator 320 CD
make WSI/ NP/ BHEL/ Jayshree/ Rashtriya.
No.20.00 293.00 43.95 29.30 366.25 7,325.00
8 Supply & erection of GI Nuts & Bolts off sizes Kg. 300.00 75.00 11.25 7.50 93.75 28,125.00
9Supply & erection of V shape cross arms made out of 1650 mm long MS
channel of size 100x50x6 mm.(wt. 16.16 Kg)
No.8.00 857.60 128.64 85.76 1,072.00 8,576.00
10
Supply and erection of material & construction of Foundation for STREET
LIGHT feeder pillar as per dimensions.
No.
4.00 1,870.00 1,870.00 7,480.00
11
Supply and erection Stay Sets 8' long complete with X-Plat 460mm of Angle
65x65x6 Elbow & rod Wt. 13.80 Kg.
No.
16.00 732.00 109.80 73.20 915.00 14,640.00
12
Supply and erection of GI Strip of 50x6mm size for earthing purpose. Kg.
400.00 52.62 7.89 5.26 65.78 26,310.00
13
Supply and erection of Stay wire 7/8 SWG Kg.
100.00 56.70 8.51 5.67 70.88 7,087.50
Erection
Charges
Total Supply &
Erection RateTotal AmountSr. No. Description of Material/equipment. Unit Qty. Rates
Overhead
Charges
Page 7
STREET LIGHT
14
Supply and erection of earth pit complete with brick masonary chamber with
CI cover and earth electrode made out of 6 mtr. long, medium class 40mm
(NB) GI pipe duly perforated complete with salt and charcoal as per stranded
earthing practice. Two Runs of GI flat size 50x6 mm to be provided on both
sides of GI pipe for the whole length(for transformer and feeder pillar).
No.
32.00 4,800.00 4,800.00 153,600.00
15/HSR 31.22(i)Supply and erection of Earthing with GI earth pipe 4.5 mts long and 40 mm
dia with masonary enclosures on the top etc as required
No.392.00 378.00 1,323.00 1,701.00 666,792.00
16/HSR 31.22(ii)Extra for using salt and charcoal/coke for pipe earth electrode as required No.
392.00 125.00 437.50 562.50 220,500.00
17/HSR 31.22(viii)Supplying and laying 25mmx5mm GI strip at 0.5 mtr below ground as strip
earth electrode including soldering etc as required
Mtr.3,920.00 16.20 56.70 72.90 285,768.00
18Supply of 9KV 10KA heavy duty lighting arrestor, 1set of 3 No.
Make: ELPRO/OBLUM/NP/RAYCHEM/LAMCO/RASHTRIYA
Set4.00 2,420.00 363.00 145.20 2,928.20 11,712.80
19
Supply and erection of 415, 3 phase 4 wire outdoor type, Astronomical type,
Microprocessor control system with time of day sequencing & Auto/manual
facility, street light panel comprising of 125 A MCCB as incomer and 4 no. 63
amp. MCB for outgoing, complete with internal wiring, Al. Bus bar links, set of
three 105/110Amp.(AC3 type) Contactors, one for individual phase, cable
termination lugs for connecting outgoing cable of 4x25 sq. mm & 4x16 sq. mm
XLPE cable, indication, metering, support channels etc., complete in all
respect of CRCA sheet of thickness 2.5mm paint with PU. MCCB/MCB:
L&T/Schneider/Legrand/GE/ABB/Siemens Astronomical
Timer: ABB/L & T/Legrand
No.
4.00 67,065.00 6,706.50 73,771.50 295,086.00
20
Supply and erection of hot dip galvanized Octagonal Pole of 3mm thickness,
with base plate including cost of nuts and bolts and all accessories supplied
by manufacturer including cost of foundation accessories etc. The foundation
bolts as per manufacturer design should be hot dipped galvanized pole
complete with door locking arrangement. Hinged Terminal plate consisting of
2 Nos. 100 A, 4 Pole natural links including connection etc. with suitable
connecting arrangement for 2 No. MCBs/ kit kat including cost of R.C.C
1:1.5:3 for foundation of size 0.7 M x 0.7 M x 1.8 M with minimum 8 Nos. 12
mm dia longitudinal MS reinforcement rods with rings of 8 mm dia not more
than 200 mm C.C. For fixing the pole with all labour & material required to
complete the job in all respect upto the entire satisfaction of Engineer in
Charge of the work as per list of makes enclosed
- - -
HSR 31.68(ii) 8 Mtr. Long pole with top dia 70 mm and bottom dia 135 mm with base plate
of size 225x225x16 mm.
No.310.00 15,320.00 - - 15,320.00 4,749,200.00
HSR 31.68(iii) 9 Mtr. Long pole with top dia 70 mm and bottom dia 155 mm with base plate
of size 260x260x16 mm.
No.82.00 17,470.00 17,470.00 1,432,540.00
21
Supply and erection of street light luminaire minimum IP- 65/66 level
protected single piece die cast aluminum/aluminum sheet housing with pot
optic reflector,heat resistant,glass cover for HPSV lamp complete with copper
wound ballast capacitor,ignitor holder,prewired up to terminal block,1 no.
HPSV lamp etc. including making connection and erection of the same on
existing pole/bracket irrespective of height of pole/mounting height with cost
of all labour and material required to complete the job in all respect .
- - -
Page 8
STREET LIGHT
HSR 31.60(iii)
Sodium 250 W Street Light Luminaire(IP-66) of Philips SGP-338M 1xSONT
250W GB(Velocity bowl glass)/GE (SGN-P25S6SG)(Skygen Pro)
No.
82.00 11,360.00 - - 11,360.00 931,520.00
HSR 31.60(ii) Sodium 150 W Street Light Luminaire(IP-66) of Philips SGP-438
1xSON150W (Secura)/GE (GER-150SP PT/DPP)(Olympia-I)
No.78.00 5,220.00 - - 5,220.00 407,160.00
HSR 31.60(i) Sodium 70 W Street Light Luminaire(IP-65) of Philips SGP-301 1xSON70W
FG/GE (GENx-70)
No.232.00 3,080.00 - - 3,080.00 714,560.00
22
Supply and erection of mark double walled corrugated (DWC)HDPE pipe laid
1 Mtr. below ground level including digging and refilling of earth including cost
of suitable size socket/coupler for HDPE pipe including the cost of labour and
material required to complete the job in all respect upto the entire satisfaction
of Engineer- incharge of the work
HSR 31.67(i) HDPE pipe 63/50 mm outer dia/inner dia. Mtr. 9,500.00 95.00 95.00 902,500.00
24
Supply,fabrication and erection of single arm bracket 1500mm overhang
made of 48 mm OD dia MS pipe(3.25mm thick) as per IS:1161 welded to
canopy 400mm long with an angle of inclination of 105 degree to the vertical.
The canopy should be suitable for 70 mm top dia pole. The bracket should be
hot dip galvanized alongwith 3 numbers 10mm dia SS bolts.
Make-Philips/GE/Bajaj/Valmont/Paruthi
No.
352.00 2,999.70 179.98 3,179.68 1,119,248.06
25
Supply,fabrication and erection of double arm bracket 1500mm overhang
made of 60 mm dia MS pipe(3.25mm thick)as per IS:1161 welded to canopy
400mm long with an angle of inclination of 105 degree to the vertical. The
canopy should be suitable for 70 mm top dia pole. The bracket should be hot
dip galvanized alongwith 3 numbers 10mm dia SS bolts. Make-
Philips/GE/Bajaj/Valmont/Paruthi
No.
40.00 3,999.60 239.98 4,239.58 169,583.04
26
Supply and erection of 3 C, 2.5 sq. mm PVC insulated sheathed LT copper
stranded cable make HAVELLS/GEMSCAB/KEI/RALLISON/GRANDLAY.
Mtr.
3,920.00 72.42 3.62 76.04 298,080.72
27
LT cables:- Supply and laying of following armoured aluminum cable including
excavation to 1meter from GL refilling make
HAVELLS/GEMSCAB/KEI/RALLISON/GRANDLAY
- - -
a)
3.5x70 sq. mm XLPE armoured aluminum cables. Mtr.
70.00 219.97 11.00 230.97 16,167.80
b)4Cx25 sq. mm XLPE armoured aluminum cables. Mtr.
11,000.00 109.65 5.48 115.13 1,266,457.50
28
Cable termination with double compression cable gland and heavy duty
copper sockets for the following cables heavy duty make Comet and copper
lugs make Dowells/Jainsons.
- - -
a) 3.5x70 sq. mm XLPE armoured aluminum cables. No. 4.00 1,203.80 60.19 1,263.99 5,055.96
b)
4Cx25 sq. mm XLPE armoured aluminum cables. No.
15.00 764.54 38.23 802.77 12,041.51
29 Supply and laying GI Strip of 25x3mm size for earthing purpose. Kg. 80.00 56.13 5.61 61.74 4,939.44
30
Horizontal boring for crossing the street light cable across the roads, 1 mtr.
Deep from the road level including laying of 65 mm dia B-Class GI pipe.
Mtr.
350.00 425.64 624.75 1,050.39 367,636.50
Page 9
STREET LIGHT
31/HSR 31.17(A)
(ii)
Supply and erection of miniature circuit breaker 240 V in the existing
distribution board including making necessary connections of 9 KA breaking
capacity( 6 amp to 32 amp). Makes :-
ABB/Schneider/ legrand/siemens/L&T/GE.
No.
392.00 95.00 28.50 123.50 48,412.00
32 Supply & erection of GI Pipe 65 mm dia. B-class Mtr. 24.00 425.64 42.56 468.20 11,236.90
33
Supply and fixing of danger plates of 2 mm thick plate with red enamelled
letter on white enamelled back ground.
No.
8.00 66.00 9.90 6.60 82.50 660.00
Total (Supply+Erection) 14,630,554.00
1) All metallic parts will be painted with 2 coats of aluminium over and above 2 coats of primer.
The make of the paint shall be Asian/Berger.
2) The BOQ can increase or decrease as per the site condition/requirements.
3) PCC Poles will be painted upto 6' with alternative strips of green and white colour.
Executive Engineer(E) Superintending Engineer(Elect.)
HSIIDC, Sec-6 HSIIDC
Panchkula Gurgaon
Page 10
Scope of work for Electrification of Phase-II, IE ManakpurPart D-High Mast 20 mts.
1
Supply,erection, testing and commissioning of 20 Meter High Mast, Galvanized steel Mast Poles
manufactured from BSEN 10025 or equivalent grade material suitable for wind velocity as per
IS:875 part 3 of Philips/GE/Bajaj/Valmont/Paruthi make having dia. Of 166 mm to 200 mm at
the top end & 460 mm to 489 mm at the bottom end. The mast will consist of two sections having
minimum thickness of 4 mm for the bottom section & 4 mm for the top section including
construction of suitable shallow foundation as per standard design of the manufacturer with 1:1.5:3
cement concrete for the High Mast considering the safe soil bearing capacity at site as 10 T/Sqmtr.
And 2.5 Mtr. Depth with all material and labour. The mast should be suitable for 12 no. 2x400
Watts luminaries . These shall consists of : a) Head Frame
b) Movable Lantern Carriage c) Double drum Winch
d) 6 mm 316 grade SS Hoisting Ropes of 7/19 construction with 3 rope construction
e) Trailing cable 9 core x 2.5 sq mm or 5x4 sq.mm f) Foundation Nuts & Bolts
including anchor plate & template g) GI Lighting finial
h) Twin dome aviation light (LED Type) I) Three Phase Power tool
(Integral) (ABB/ SIEMENS/ BHARAT BIJLEE/JYOTI/HAVELLS/KIRLOSKAR)
No. 2 237476 23,747.60 261,223.60 522,447.20
2
Supply,testing and commissioning of complete non-integral type flood light fittings conforming to
IP65/IP66 and suitable for 2x400 Watt HPSV tubular lamps and control gear boxes as per Philips
Cat No. RVP-302/2xSONT-400W or GE GLANZ of 254 + GBC 1400SVx2 Watt including ballast,
Lamp etc.
No. 24 17123 1,712.30 18,835.30 452,047.20
3
415,3 Phase 4 wire outdoor type,Astronomical type, Microprocessor control system with time of day
sequencing & Auto/manual facility,street light panel comprising of 125 a, 35 KA TPN MCCB as
incomer and 3 No. 63 amp. MCB for outgoing, complete with internal wiring ,Al.Bus bar links,set of
105/110 Amp. Contactor(AC3 type) for individual phase,cable termination lugs for connecting
outgoing cable of 4x25 Sq. mm XLPE cable,indication,metering,support channels etc. complete in
all respect with space/arrangement for meter mounting .MCCB:
L&T/GE/ABB/SIEMENS/SCHNEIDER.
Astronomical Timer: L & T/Legrand/ABB
No. 2 67065 6,706.50 73,771.50 147,543.00
4
Providing 2 PCC Column of size 200 mm for the foundations of high Mast Metering Panel Board
with 300mm below NGL and 400 mm above NGL compatible with street light metering panel
board.
No. 2 1870 1,870.00 3,740.00
5
supply and providing of earth pit complete with brick masonry chamber with CI cover and providing
earth electrode made out of medium class GI pipe 6 mtr. Long, 40 mm dia fitted with funnel etc.
duly perforated complete with salt and charcoal as per slandered practice. Two runs of GI flat size
50X6 mm to be welded on both sides for complete length of GI pipe and one run from earth pit to
High mast. GI strip size 50X6 mm.
No. 4 4800 4,800.00 19,200.00
Total (Supply+Erection) 1,144,977.40
Executive Engineer(E) Superintending Engineer(Elect.)
HSIIDC, Sec-6 HSIIDC
Panchkula Gurgaon
Total Supply & Erection
Rate (Rs.)Total Amount (Rs.)
Sr.
No. Description of Material/equipment. Unit Qty.
Supply Rate
(Rs.)
Erection Charges
(Rs.)
List of Makes
1. Distribution transformers - Svasca/ Indian/Nucon/Vijai Electricals/ Century/
JayBee (Nalagarh) /CGL/Kanohar.
2. Octagonal poles - Philips/GE/Bajaj/Valmont/Paruthi.
3. GI Brackets - Philips/GE/Bajaj/Valmont/Paruthi.
4. Street light Fittings -
(i) 70 W Street Light Luminaire :- (IP-65) of Philips SGP-301 1xSON70W
FG / GE(GENx-70).
(ii)150 W Street Light Luminaire :- (IP-66) of Philips SGP-4381xSON150W
(secura) / GE(GER-150SP PT/DPP)(Olympia-1).
(iii) 250 W Street Light Luminaire :- (IP-66) of Philips SGP-338M 1xSON250W
GB(velocity bowl glass) / GE (SGN-P25S6SG)(Skygen Pro)
5. HT-LT Cables - Havells/KEI/Rallison/ Grandlay/Gemscab/ Dellton/
Fortgloster/CCI/Sterlite .
6. DWC HDPE Pipe - Duraline/REX/Gemini/ Tirupati.
7. Termination kits - Densons/CABSEAL/RAYCHEM/3M.
8. Disc/Pin Insulators - BHEL/WSI/RASHTRIYA/NP/JAYSHREE.
9. Lightning arrestors - ELPRO/NP/RAYCHEM/OBLUM/LAMCO/RASHTRIYA
10. Double Compression Cable Glands/Copper Lugs - Comet/Dowells/Jainson.
11. MCCB/MCB :- L&T/ABB/Siemens/Schneider/GE/Legrand .
12. Astronomical Timer : ABB/L & T/Legrand.
13. High Mast : Philips/GE/Valmont/Bajaj/Paruthi