environmental monitoring report€¦ · (as of 1 april 2013) currency unit – riel (kr) kr1.00 =...
TRANSCRIPT
Environmental Monitoring Report Monthly Report March 2013
GMS: Rehabilitation of Railway in Cambodia
Prepared by Nippon Koei in association with JARTS. for the Ministry of Public Works and Transport, the Kingdom of Cambodia, and the Asian Development Bank.
CURRENCY EQUIVALENTS (as of 1 April 2013)
Currency unit –
riel (KR)
KR1.00 = $0.00025 $1.00 = KR3,995
NOTE
In this report, "$" refers to US dollars unless otherwise stated.
This environmental monitoring report is a document of the borrower. The views expressed herein do not necessarily represent those of ADB's Board of Directors, Management, or staff, and may be preliminary in nature. In preparing any country program or strategy, financing any project, or by making any designation of or reference to a particular territory or geographic area in this document, the Asian Development Bank does not intend to make any judgments as to the legal or other status of any territory or area.
ABBREVIATIONS ADB – Asian Development Bank CSC – construction supervision consultant EMP – environmental management plan GMS – Greater Mekong Subregion IEE – initial environmental examination MPWT – Ministry of Public Works and Transport NR – national road PIU – project implementation unit PPE – personal protective equipment RRL – railroad line
KINGDOM OF CAMBODIA
MINISTRY OF PUBLIC WORKS AND TRANSPORT
RAILWAY REHABILITATION MANAGEMENT OFFICE
ADB LOAN NO 2288-CAM [SF], OFID P1125
ADB LOAN NO 2602, AUSAID GO187
GMS: REHABILITATION OF RAILWAY IN CAMBODIA
ENVIRONMENTAL MONITORING REPORT No.22
March 2013
NIPPON KOEI CO.LTD.
In association with Japan Railway Technical Services
GMS: REHABILITATION OF THE RAILWAY IN CAMBODIA ADB LOAN NO. 2288-CAM, OFID P1125, ADB LOAN NO. 2602, AUSAID G0187 Nippon Koei in association with JARTS
Environmental Monitoring Report 22, March 2013 Page 1
Table of Content
Page
1. General Background .......................................................................................................................... 2
1.1 Project overall .................................................................................................................................. 2
1.2 Project progress .............................................................................................................................. 2
1.3 Purpose of the report ..................................................................................................................... 2
2. Environmental Monitoring Program ................................................................................................ 3
2.1 Scope of works ................................................................................................................................ 3
2.2 Methodology .................................................................................................................................... 3
3. Results of Environmental Monitoring .............................................................................................. 4
3.1 Reviewing on Environmental Report of TSO .............................................................................. 4
3.1.1 Environmental Issues and Corrective Works ...................................................................... 4
3.2 Field monitoring by CSC/Local Environmental Specialist .......................................................... 4
3.2.1 Southern Line ........................................................................................................................... 4
3.2.2 Northern Line ......................................................................................................................... 14
4. Summary and recommendations ................................................................................................... 14
4.1 Summary ........................................................................................................................................ 14
4.2 Recommendations ........................................................................................................................ 15
List of Annex
Annex 1: Environmental Monitoring Matrix
Annex 2: Borrow Pits Matrix
Annex 3: Complaint letter from people living close to the borrow pits
Annex 4: Accident report of TSO
GMS: REHABILITATION OF THE RAILWAY IN CAMBODIA ADB LOAN NO. 2288-CAM, OFID P1125, ADB LOAN NO. 2602, AUSAID G0187 Nippon Koei in association with JARTS
Environmental Monitoring Report 22, March 2013 Page 2
1. General Background
1.1 Project overall
The GMS Rehabilitation of the Railway in Cambodia (RRC) involves two lines, Southern
Line and Northern Line. Southern Line connected from Phnom Penh to Sihanoukville with
total length of 265 km, and Northern Line connected from Phnom Penh to Poipet (Thai
border) with total length of 386 km.
The project is under management of MPWT. The design and construction supervision
consultants is NIPPON KOEI CO.,LTD in association with JARTS. The construction
contractor for RRL1 (Southern Line) and RRL2 (Northern Line) is TSO-AS & NAWARAT
Joint Venture (France and Thailand), but for RRL1, JV partners were changed to TSO-
SPCC Consortium since October 21, 2011).
1.2 Project progress
The project activities include design, platform improvement, bottom ballast relay, sleeper
and track relay, sleeper tamping, top ballast relay, welding (for Southern Line), and
rehabilitation/reconstruction some culverts in both lines, rehabilitation of bridge in SL, and
reconstruction of drainage system in Sihanoukville station.
Based on the monthly progress report No. 61, February 2013, the both project lines
(Southern and Northern Line) rehabilitation work as actual overall progress on site including
sleepers and track installation had been completed same as last month:
- RRL-1: Southern Line is 97.1% for whole line and 99.9% for section 2 (Touk Meas to
Sihanoukville)
- RRL-2: Northern Line still same progress value as last month due to no activities in
project site since the end of July 2012.
o Section 1: Phnom Penh to Sisophon is 4.1%
o Section 2: Sisophon to Poipet is 70.7%
1.3 Purpose of the report
As full implementation of the IEE procedure of the project, the environmental specialists of
Construction Supervision Consultant (CSC) have two main roles as following:
- supervise the monitoring of implementing mitigation measure of the contractor
during the construction stage, and submit the environmental monitoring report to
MPWT-PIU and ADB;
- provide environmental management training (class room and field) to MPWT-PIU
staffs and key persons of contractor who responsible on field of environmental
safeguard.
The environmental monitoring report is to follow up the contractor’s implementation on
environmental mitigation measure in construction stage as stated in EMP and other
environmental safeguards in construction contract documents. Guidance and instruction will
be prepared to enforce the contractor to follow the environmental mitigation measure as
stated in IEE report and construction contract documents.
GMS: REHABILITATION OF THE RAILWAY IN CAMBODIA ADB LOAN NO. 2288-CAM, OFID P1125, ADB LOAN NO. 2602, AUSAID G0187 Nippon Koei in association with JARTS
Environmental Monitoring Report 22, March 2013 Page 3
2. Environmental Monitoring Program
2.1 Scope of works
The major tasks for the environmental monitoring in construction stage include:
Reviewing the environmental report in previous month that prepared by
contractor (TSO/SPCC);
Field monitoring on contractor’s environmental mitigation measure performance
in both project lines (Northern and Southern lines);
Guidance to MPWT’s staff/PIU and TSO’s environmental engineers on
environmental monitoring aspect, in the field practice;
Recommend to TSO to implement all EMP as stated in IEE report and other
environmental safeguards in construction contract documents; and
Instruct TSO/SPCC to take an action to mitigate or rectify on other issues that
find out in the construction stage.
2.2 Methodology
Two simple ways have been applied in this monitoring stage, reviewing the previous
environmental reports that prepared by TSO/SPCC and site investigation in both project
lines.
Reviewing environmental report of contractor:
- Screen the result of environmental mitigation measure performed by
contractor, and the issues that happened in the field;
- Review the result of rectifying or improvement activities on the environmental
issues; and
- Find out the compliance with EMP in IEE report and Cambodia’s regulation
and law.
Site monitoring: Use environmental monitoring matrix, borrow pit matrix, hearing
(directly ask the question to the project workers and people living nearby the
project sites), and visual: During the field observation on environmental
mitigation measure that implemented or rectified by contractor (TSO/SPCC), the
CSC/Environmental Specialist used the environmental monitoring matrix for
construction phase (Annex 1). Visual and hearing methodology also has been
applied for other environmental monitoring items, and degree of impact have be
recorded and photograph to proof the impacts (good or bad) are used.
GMS: REHABILITATION OF THE RAILWAY IN CAMBODIA ADB LOAN NO. 2288-CAM, OFID P1125, ADB LOAN NO. 2602, AUSAID G0187 Nippon Koei in association with JARTS
Environmental Monitoring Report 22, March 2013 Page 4
3. Results of Environmental Monitoring
3.1 Reviewing on Environmental Report of TSO
To date 30 March 2013, TSO/SPCC does not submit yet the Monthly Progress Report for
December 2012 and January-February 2013 for Southern Line (RRL1: Phnom Penh-
Sihanaoukville).
There is no TSO’s Monthly Progress Report for the Northern Line (RRL2: Phnom Penh-
Poipet) since July 2012, due to contractor has stopped all site activities at the end of July
2012.
3.1.1 Environmental Issues and Corrective Works
As mentioning above TSO/SPCC not submitted yet the Monthly Progress Report for
December 2012 and January-February 2013 for project Southern Line.
3.2 Field monitoring by CSC/Local Environmental Specialist
The task work includes follow up on the environmental issues and corrective action by the
contractor TSO in both project lines (SL and NL), and investigation on other environmental
items that had been occurred by the project construction activities.
The field observation had been done on 28-29 February, 2013 for Southern Line. There is
not activity in the Northern Line, TSO stopped all the activities and moved all project’s
equipment from the site since 21 July 2012.
The environmental issues and environmental mitigation measure were described in
following paragraph, and the field recorded is included environmental monitoring matrix
(Annex 1) and borrow pits matrix (Annex 2).
3.2.1 Southern Line
The field monitoring in Southern Line was carried out from Touk Meas station to
Sihanoukville station (as phase 2 of the RRL1). The result of environmental condition can
be described in following:
1. Leaks and spills of hazardous material: The fuel storage facilities at Kampot and
Sihanoukville station are very good installation (concrete platform and wall, and
security equipment and fence), see figure 3.2.1-1a. Both stations had an incharged
person for daily operation and maintain including security and safety.
The monitoring work in this month found that the fuel storage places in Sihanoukville
and Kampot stations are well managed of leakage fuel, no sign of spillage on the
ground and on the concrete floor.
GMS: REHABILITATION OF THE RAILWAY IN CAMBODIA ADB LOAN NO. 2288-CAM, OFID P1125, ADB LOAN NO. 2602, AUSAID G0187 Nippon Koei in association with JARTS
Environmental Monitoring Report 22, March 2013 Page 5
at Kampot station at Sihnoukvile station
Figure 3.2.1-1a: Fuel storage facilities
To date (29 March 2013), TSO not provide yet the spilling kit to both fuel storage
places. At the workshop and fuel storage areas the incharged person used absorbent
cloth/second-hand clothes to maintain spilling oil and grease in place.
2. Soil erosion: In generally no sign of soil erosion during the site monitoring in this
month, most of the embankment are covered by vegetation that naturally grew and
grass planted by contractor since July and August 2012. On the other hand there had
not earth work along the embankment at all, and this month is fully dry season and
very small rain.
3. Borrow pits/quarries:
To date 29 March 2013, the borrow pits PK140+600, PK140+650, PK140+780, and
PK141+000 are not yet improved or re-fenced. As well as the two borrow pits (right
hand site from Touk Meas to Kampot) at PK119+750 to PK119+800 (behind Touk
Meas high school) are not yet re-filled, see borrow pit matrix Annex 2. The two
borrow pits (left hand site from Kampot to Sihanoukville) at PK168+960 are not yet
re-filled too, see borrow pit matrix Annex 2.
It meant that TSO not yet implemented on environmental mitigation measure to the
borrow pits used for project RRL1 that list in the borrow pit matrix and instruct by
CSC/NK two months continuously. In figure 3.2.1-3a showed the present condition of
those borrow pits.
GMS: REHABILITATION OF THE RAILWAY IN CAMBODIA ADB LOAN NO. 2288-CAM, OFID P1125, ADB LOAN NO. 2602, AUSAID G0187 Nippon Koei in association with JARTS
Environmental Monitoring Report 22, March 2013 Page 6
Photo in February 2013 Photo in March 2013
Photo in February 2013 Photo in March 2013
Photo in February 2013 Photo in March 2013
Photo in January 2013 Photo in March 2013
Figure 3.2.1-3a: The borrow pits that the people requested to re-fill and keep as water supply pond or fish feeding pond
Borrow pit at PK168+950
Borrow pit at PK168+960
Borrow pit at PK119+800
Borrow pit at PK119+750
GMS: REHABILITATION OF THE RAILWAY IN CAMBODIA ADB LOAN NO. 2288-CAM, OFID P1125, ADB LOAN NO. 2602, AUSAID G0187 Nippon Koei in association with JARTS
Environmental Monitoring Report 22, March 2013 Page 7
4. Water quality
During field observation there was not signed of water laden into the rice field or
water body nearby the embankment of the railway, due to very small track work and
drainage system construction in the Sihanoukville station, no earth work activities at
all.
5. Air pollution
Based on the field observation can be noted that dust and emission air from
construction machineries and relaying ballast are main polluted sources. There were
very small activities of relay top ballast by train. So polluted air and dust come from
construction machineries and relay ballast are very small or minor.
The ballast pile at PK184 was closed, and TSO is cleaning the remaining ballast to
make place become as previous condition, figure 3.2.1-5a.
Figure 3.2.1-5a: Ballast pile at PK 184, photo 28 March 2013
6. Noise disturbance
Noise disturbance is happened from the construction machinery such as excavator,
bulldozer, ballast regulator, sleeper tamping machine, and transportation trucks of the
project. In this month, there are small amount of construction machineries on the
platform such as ballast transporting train, ballast regulator, and tamping machine in
side of Sihanoukville port. Moreover noise and vibration come from tamping machine
and ballast regulator were happened short time only in one place.
7. Waste management
The workshops and storage areas in Kampot and Sihanoukville station have been
improved and equipped with garbage bin, figure 3.2.1-7a. The platform space in
Sihanoukville is well cleaned after removing of the workers camps.
GMS: REHABILITATION OF THE RAILWAY IN CAMBODIA ADB LOAN NO. 2288-CAM, OFID P1125, ADB LOAN NO. 2602, AUSAID G0187 Nippon Koei in association with JARTS
Environmental Monitoring Report 22, March 2013 Page 8
Most of the construction sites are well managed of solid waste as well as spoil soil,
during site observation in March 2013, figure 3.2.1-7b.
However the solid waste at some workers is still poor managed and strewed on the
space around the camps, e.g workers camp at railway pile in Sihanoukville station and
at PK263+780 near level crossing have not garbage bin and camp representative. In
figure 3.2.1-7c shows the condition of poor solid waste management in workers
camps.
Sihanoukville workshop Kampot workshop
Storage area in Kampot station
Figure 3.2.1-7a: Clean of waste at workshop and storage areas
Figure 3.2.1-7b: Solid waste and spoil soil were cleaned in construction sites
GMS: REHABILITATION OF THE RAILWAY IN CAMBODIA ADB LOAN NO. 2288-CAM, OFID P1125, ADB LOAN NO. 2602, AUSAID G0187 Nippon Koei in association with JARTS
Environmental Monitoring Report 22, March 2013 Page 9
at workers camp at railway pile in
Sihanoukville station
at workers camp at PK263+780
Figure 3.2.1-7c: Poor solid waste management in workers camps
8. Liquid waste generation/Drainage
The liquid waste generation from the project is wastewater from the bathing and
flushing toilet. Generally, the workers camps shall be equipped with bathing room and
toilet. The bathing water shall be drained into the small channel nearby the camps or
connected to the public sewer or open ditch along the road ways, figure 3.2.1-8a. The
toilet is built with storage flushing water concrete ring (two concrete rings with
diameter 1meter).
Same as last month CSC found that the worker camps at rail storage/pile in
Sinaoukville station have not drainage system, figure 3.2.1-8b. All bathing waters are
flushed on the open space surround the water tank, so some muddy during bathing
was happened.
Most of the drainage system in Sihanoukville station is nearly completed construction
and it will have enough capacity to drain all waste water and runoff from the
Sihanoukville station.
at workers camp at railway pile in
Sihanoukville station
at workers camp at PK263+780
Figure 3.2.1-8a: Drainage condition at workers camps
GMS: REHABILITATION OF THE RAILWAY IN CAMBODIA ADB LOAN NO. 2288-CAM, OFID P1125, ADB LOAN NO. 2602, AUSAID G0187 Nippon Koei in association with JARTS
Environmental Monitoring Report 22, March 2013 Page 10
9. Traffic problem
On date of the field observation, the monitoring team did not see any traffic
congestion as well as accident that caused by the project activities. Most of the
construction activities are on the platform of railway from PK185 to PK195, in front of
Warehouse, and at level crossing in front of Sihanoukville port.
Anyway, in March 2nd, 2013, NK-Resident Engineer in Southern Line received a letter
from TSO enclosed with accident reports of the train accident on 23 Feb. and 26 Feb.
2013 (Annex 4). No body get an injuries in both accidents vents, but in second
accident on 26 Feb.2013 one fuel truck of Sokimex Gasoline company was small
damaged. Both accident have been solved by concerning party, see detail report in
Annex 4.
However, the level crossing sign and barrier are not yet put in implementation for the
phase 2 of RRL1 project (Touk Meas to Sihanoukville port). The contractor TSO&SPCC
just provide facilitator and traffic sign at advance and behind the construction site
where across the level crossing.
10. Damage road and bridge
Damaged culvert or bridge was not found on date of field environmental monitoring.
11. Adequacy of facilities/equipment for workers
During environmental monitoring this month, found that most of the workers of TSO
whom are working on track-worked and at level crossing construction were equipped
with boots and light jacket, but the workers of SPCC whom are working on culvert and
drainage canal construction are not wearing PPE at all. In figure 3.2.1-11a showed the
TSO’s workers equipped with PPE.
However the workers team of TSO (three persons) whom work for breaking rock for
building drainage channel at PK 0+250 (in front of Sihaoukville warehouse) had not
dust musk, goggles, and ear plug, and they complained that TSO did not provide
these kind of PPE to them, figure 3.2.1-11b.
For the workers whom are working on the track works they said that TSO had provide
very thick gloves to them and they complained that it was difficulty to carry out
construction tools when they wear very thick gloves, that why they decide not wear it.
However some workers they spent their own money and bought suitable gloves.
GMS: REHABILITATION OF THE RAILWAY IN CAMBODIA ADB LOAN NO. 2288-CAM, OFID P1125, ADB LOAN NO. 2602, AUSAID G0187 Nippon Koei in association with JARTS
Environmental Monitoring Report 22, March 2013 Page 11
Track works team Level crossing construction team
Figure 3.2.1-11a: TSO’s workers have reasonable PPE
Figure 3.2.1-11b: TSO’s workers work on breaking rock have not goggles and ear
plug
12. Safety
All the workshops and storage places have been equipped with extinguisher capacity
of 8kg (at least 2 bottles).
As normal provision, the workers camps shall be provided with wooden shelf/bed,
good plastic roof and wall, water tank, garbage bin, lighting (battery + lamp), and
toilet. However during the field monitoring in March 28-29, 2013, found that the
workers camps at rail pile in Sihanoukville station and workers camp at Trapeang
Rpov station (PK198+500) not yet provided latrine, garbage bin, and lighting facilities
(figure 3.2.1-12a). The workers camp at PK263+780 had one latrine but not function,
GMS: REHABILITATION OF THE RAILWAY IN CAMBODIA ADB LOAN NO. 2288-CAM, OFID P1125, ADB LOAN NO. 2602, AUSAID G0187 Nippon Koei in association with JARTS
Environmental Monitoring Report 22, March 2013 Page 12
had not garbage bin, and light facilities is broken. The plastic roof of workers camp at
Trapeang Rpov station (PK198+500) were tear, but contractor TSO not provide a new
once to change (Note that this camp just installed 4 days, but TSO not follows the
safety discipline as they wrote in the paper), figure 3.2.1-12b.
As previous month all the workers camp have not first aid kits, according site
observation and question to the leader of group worker.
All SPCC’s workers have not sufficient safety equipment or safety tools such as boots,
helmet for team work in culvert construction sites, e.g 6 of 8 SPCC’s workers are
working for culvert construction at level crossing at PK0+244 and 6 workers are
making wrap rock at culvert in Sihanoukville station had not equipped with PPE at all,
figure 3.2.1-12c.
at railway pile in Sihanoukville station
at Trapeang Rpov (PK198+500)
at PK263+780
Figure 3.2.1-12a: The workers camps without safety tools and equipments
GMS: REHABILITATION OF THE RAILWAY IN CAMBODIA ADB LOAN NO. 2288-CAM, OFID P1125, ADB LOAN NO. 2602, AUSAID G0187 Nippon Koei in association with JARTS
Environmental Monitoring Report 22, March 2013 Page 13
Figure 3.2.1-12b: The workers camp at Trapeang Rpov station (PK198+500)
PK0+244 In Sihanoukville station
Figure 3.2.1-12c: The SPCC’s workers had not PPE at all
13. Construction-related complaint
CSC had coordinate with TSO’s HSE manager (Mr. Gerardo Paderanga) and the
villagers living close to the borrow pits at PK168+960 and PK119+800 to prepare
complained letter (in Khmer language) to contractor (TSO) in delaying re-fill borrow
pit, Annex 3. The complained letter had agreed by village chief or leader group of the
community in place.
14. Other issues
During site monitoring, CSC got complained from workers in oral that TSO delay in
delivery of workers salary, they worked 4 weeks but TSO not yet deliver salary 2
weeks to them. It meant that similar to last month condition, TSO delay up to 5 weeks
worked and deliver only 2 weeks worked salary to workers.
From now on CSC know Mr. Gerardo Paderanga is HSE manager of TSO closely work
with him to deal with environmental issue that occurred by project construction
activities.
GMS: REHABILITATION OF THE RAILWAY IN CAMBODIA ADB LOAN NO. 2288-CAM, OFID P1125, ADB LOAN NO. 2602, AUSAID G0187 Nippon Koei in association with JARTS
Environmental Monitoring Report 22, March 2013 Page 14
3.2.2 Northern Line
There is not activity in the Northern Line, TSO stopped all the activities and moved all
project’s equipment from the site since 21 July 2012. The environmental condition is
same as September 2012.
4. Summary and recommendations
4.1 Summary
The result on environmental monitoring in February 2013 can be concluded as following:
(1) Good fuel storage facilities had been provided/installed (concrete platform and wall,
and security equipment and fence) with security fencing, and not sign of
leakage/spillage. But TSO did not provide cleanup equipment/spilling kit to both fuel
storage places.
(2) The borrow pits PK140+600, PK140+650, PK140+780, and PK141+000 are not yet
improved or re-fencing. The borrow pits (right hand site from Touk Meas to
Kampot) at PK119+800 (behind Touk Meas high school) are not yet re-filled,
anyway the borrow pit at PK119+750 got more requesting letter from people to
keep it as fish feeding pond. Similarly the two borrow pits (left hand site from
Kampot to Sihanoukville) at PK168+960 are not yet re-filled and the borrow pit at
PK168+950 got more requesting letter for keeping as water supply pond, as
enclosed in Annex 3.
(3) No sign of soil erosion during the site monitoring during this month and on the
other hand there had not earth work along the embankment at all.
(4) No sign of water laden into the rice field or water body nearby the embankment of
the railway.
(5) During field observation CSC not meet the workers work in tamping amchine and
ballast regulator, but expected that dust and noise from ballast regulator and
tamping machine cause polluted and affected to workers team in this machine,
according to the team worked in this machine have not mask, eye glass, and ear
plug, because TSO still not provide those tools to them yet.
(6) Solid waste were clean after camp removing, but in some new workers camps are
poor managed of solid waste, because no garbage bin had been provided and no
representative had been appointed.
(7) The drainage system in Sihanoukville station is ongoing improved, but some
workers camp have not provide drainage trench at all.
(8) It can be said that during February and March some workers camps have not
latrine, garbage bin, and lighting facilities. e.g workers camp at rail pile in
GMS: REHABILITATION OF THE RAILWAY IN CAMBODIA ADB LOAN NO. 2288-CAM, OFID P1125, ADB LOAN NO. 2602, AUSAID G0187 Nippon Koei in association with JARTS
Environmental Monitoring Report 22, March 2013 Page 15
Sihanoukville station, workers camp at PK263+780, and workers camp at
PK198+500 (next to Trapeang Rpov station). All three camps had not first aid kit.
(9) There is not traffic problem during site monitoring, however CSC received an
accident report from TSO and described the 2 accidental events in 23th and 26th
February 2013, as Annex 4.
(10) Some of the workers of TSO were not equipped with PPE, e.g 3 workers whom
worked for breaking rock for building drainage channel at PK 0+250 (in front of
Sihaoukville warehouse) had not dust musk, goggles, and ear plug. To date TSO
not provide properly PPE (ear plug, eye glass, and mask) to workers are working on
ballast regulator and tamping machine. All SPCC’s workers have not sufficient safety
equipment (PPE) for team work in culvert construction sites.
(11) CSC had coordinate with TSO’s HSE manager (Mr. Gerardo Paderanga) and the
villagers living close to the borrow pits at PK168+960 and PK119+800 to prepare
complained letter (in Khmer language) to Contractor (TSO/SPCC) in delaying re-fill
borrow pit, Annex 3.
(12) Similar like last month, TSO/SPCC delay payment the daily salary of the workers,
they are worked 4 weeks but to date they do not received the salary yet.
(13) CSC know Mr. Gerardo Paderanga is HSE manager of TSO closely work with him to
deal with environmental issue that occurred by project construction activities.
4.2 Recommendations
As requirement of the EMP in IEE report and missing environmental mitigation measure or environmental improvement of Contractor (TSO/SPCC) during construction stage as well as the comments from ADB on EMR January and February, the CSC’s environmental specialist recommends in following points:
1. Contractor must immediately submit the Monthly Progress Report (with environmental report) for December 2012 and January-February 2013 for Southern Line (RRL1: Phnom Penh-Sihanaoukville) to MPWT/NK project office. In case of Contractor missed submit the three progress reports within April 2013, CSC will recommend to MPWT to deduct cost value from Contractor’s interim payment certificate (IPC).
2. Contractor must immediately provide latrine, garbage bins, and lighting facilities to
all workers camps of the RRL1 project, and appoint a camp representative for keeping camp clean of solid waste and liquid waste. In case of Contractor fail to comply requirement measure as stated above within April 2013, then CSC will recommend to MPWT to engage third party to undertake requirement measure and the corresponding costs will be born from Contractor account.
3. Contractor must provide immediately eye glass, ear plug, and musk to
workers/teams are working with ballast regulator and tamping machine as well as the workers breaking rock.
4. Contractor must immediately provide adequate/sufficient PPEs/safety tools to all
project workers/staffs in appropriated working place/type, and ensure all the workers
GMS: REHABILITATION OF THE RAILWAY IN CAMBODIA ADB LOAN NO. 2288-CAM, OFID P1125, ADB LOAN NO. 2602, AUSAID G0187 Nippon Koei in association with JARTS
Environmental Monitoring Report 22, March 2013 Page 16
are properly use PPEs during working time. The workers no wearing properly PPE are not allowed to work in construction site.
5. Contractor must immediately provide first aid kits to each workers camp. 6. Contractor must immediately re-fill the borrow pits PK119+800 (behind the Touk
Meas high school), PK140+780, and PK168+960, see detail information in borrow pits matrix (Annex 2). In case of Contractor not take in action or miss implement by 25 April 2013 then CSC will write a letter to MPWT to engage the third party to re-fill those borrow pits and the cost will be born from Contractor account.
7. Contractor must immediately re-fence and put warning sign to the borrow pits at PK
140+650, PK140+700, PK141+000, and PK168+950 (as indicated in Annex2). In case of Contractor not take in action or miss implement by 25 April 2013 then CSC will write a letter to MPWT to engage the third party to re-fill those borrow pits and the corresponding cost will be born from Contractor account.
8. Contractor must immediately improve the schedule of delivering salary to workers,
the shorter the better (e.g worked 2 weeks, deliver salary 1 week).
9. Contractor must properly implement all environmental mitigation measure in construction stage as setting IEE report and other environmental safeguards that stated in construction contract. In following paragraph are some mitigation measures have been described in EMP (construction phase) in Appendix A of IEE report, November 2006, page 58-73.
ANNEX 1:
- Environmental Monitoring Matrix
Project name: GMS:REHABILITATION OF THE RAILWAY IN CAMBODIA
Environmental Monitoring Matrix (Construction Phase)
Location: Touk Meas station to Sihanoukville port
Inspection Date: 28-29 March 2013
Name of Inspector: Taing Sophanara
No. Description Impact Location Extent1
Mitigation Measures Degree2
Remarks3
Storage area is sited away from watercourse,
drains 3Storage area has concrete floor, bund/dike, wall;
pallets are used 4Hazardous wastes handling and management
training 3Safety signal, posters 3
Cleanup equipment and procedure are in place 3Key person incharge 3
Slope design 3
Compaction 3
re-vegetation 4
Slope 2
Depth (m) 2
Perimeter fences 1
Warning signs 1
Dust-generating activities away from waterways 4
Drain discharges have low (suspended) solid 4
Proper waste disposal 3
Waste management training 3
Cleanup 4
Water spray 3
Covers on trabsport materials, storage area 3
Mask for workers 2
Ear muffs for workers 1
Insulation/muffler for noisy equipment 3
Noisy activities at daytime only 3
Solid waste management training for workers 3
Garbage bins are in place 2
Disposal site/method identified 3
Signage, posters 3
Key person assigned 2
Liquid waste management training for workers 2
Sanitory toilets for workers 2
Functional drainage canals 3
N
No spilling kit in both fuel storage place
in Kampot and Sihanoukville station,
second-hand clothes have been used
to absorb spilling oil and grease in
workshops in Kasmpot and
Sihanoukville station
1
Construction sites; Borrow
pit/quary area No earth work any more
2N
Hazardous wastes
generation; possible
leakage and spillage of
hazardous material
Soil erosion
Fuel storage area;
Construction site;
Workers camps
3
E
Two depth (deep >2m) borrow pits
behind the Touk Meas high school
(PK119+800) and at PK 168+950 are
not yet re-filledWater quality;
sedimentation
4 Project siteN
Borrow pit/quarry hazards Borrow pit/quary areas
(see separate matrix for
all pits)
5 Project siteN
Air quality: dust generation6 Project site; Access road;
Community N
Water quality: floating
wastes
7 Noise Project site; nearest
settlement M
Tamping machine and top ballast
regulator machine team had not ear
pludgeProject site; Worker camp
N
Solid waste generation8
No garbage bin in some workers
camps
Project site; Worker campLiquid waste generation9
NSome workers camp did not have
drainage trentch and toilet
No. Description Impact Location Extent1
Mitigation Measures Degree2
Remarks3
Signage, posters 3
Key person assigned 3
Signage, directions
Traffic barrier
Traffic management plan
Proper planning/preparation 3
Immediate repair of damaged structures 3
Potable water supply 3
Washing/bathing water supply 3
Sanitory toilets 2
Comfortable sleep/rest quarters 4
Information/training 3
Signage, posters 3
Safety tools for workers 3
First aid kits 2
Coordination with communities/leaders 3
Key person assigned 3
Documentation and resolution of complaints 3
Note: 1 - Describes the magnitude of impact: write N-nominal/minimal; M- moderate; E- extensive
2 - Describes the quality of mitigating measure: write 5- excellence; 4- very good; 3- good; 2- poor; 1- very poor
Project site; Worker campLiquid waste generation9
NSome workers camp did not have
drainage trentch and toilet
10 Traffic problems Access road; Level
crossing N
The level crossing sign and barrier are
not implement for the phase 2 (Touk
Meas to Sihanoukville port)
Damage to roads, culverts,
bridges
11 Roads; culvert; bridgeN
12 Workers' camps; project
siteN
Some workers camp did not have toilet
Project site; camps;
workshop; borrow
pit/quary
13 Safety issues
N
First aid kit had not provided to workers
team/camp. Most workers have not
wearing gloves, and no ear plug for
team working with tamping machine.
Adequacy of
facilities/equipment for
workers
Possible conflict with
communities and
complaints from residents
14 Project site; camps;
workshop; borrow
pit/quaryN
3 - Provise specifics/details on problem identified (e.g., exact location, specific concern, etc.), additional necessary mitigation measures and corresponding
target date of implementation, and other observations.
ANNEX 2:
- Borrow Pits Matrix
Loan 2288-CAM (SF) GMS: Rehabilitation of the Railway in Cambodia Environmental Monitoring
Page 1 of 7
ANNEX 2: Matrix of Borrow Pits
Priority borrow pits in Southern Line need to be improved by Contractor (TSO), 3 pits must be re-filled and 4 pits must be re-fenced
Borrow pit location (specify
distance from nearest house,
school, and other sensitive
receptors)
Photograph Estimated
area, (m
2)
Estimated depth,
(m)
Start date of borrow
pit operation (month &
year)
Status (active or completed); If
active =indicate estimated
completion date; If completed=
indicate date of completion
Specific mitigation measures
implemented by the contractor and date(s) of
implementation
Required additional mitigation
measure and target date for
implementation
PK119+800
(Photo in May, 2011)
7x15= 105
2 April 2010
May 2010 Not yet
Immediately Re-Fill; TSO
must be done by April 2013.
In case TSO-
SPCC not take in action then CSC
will write a letter to MPWT to
recruit the third party to re-fill those borrow pits and the
budget will be born from TSO account in the
RRC (RRL1) project
(Photo in March
28, 2013)
Loan 2288-CAM (SF) GMS: Rehabilitation of the Railway in Cambodia Environmental Monitoring
Page 2 of 7
Borrow pit location (specify
distance from nearest house,
school, and other sensitive
receptors)
Photograph Estimated
area, (m
2)
Estimated depth,
(m)
Start date of borrow
pit operation (month &
year)
Status (active or completed); If
active =indicate estimated
completion date; If completed=
indicate date of completion
Specific mitigation measures
implemented by the contractor and date(s) of
implementation
Required additional mitigation
measure and target date for
implementation
PK140+780
Photo taken in August 2011
6x15=90 1.5
May 2010
June 2010
Fencing in July 2011, but it was
completely broken in Nov.
2012
Immediately Re-Fill;
TSO must be done by April
2013
In case TSO-SPCC not take in action then CSC
will write a letter to MPWT to
recruit the third party to re-fill those borrow pits and the
budget will be born from TSO account in the
RRC (RRL1) project
Photo taken in January 2013
Loan 2288-CAM (SF) GMS: Rehabilitation of the Railway in Cambodia Environmental Monitoring
Page 3 of 7
Borrow pit location (specify
distance from nearest house,
school, and other sensitive
receptors)
Photograph Estimated
area, (m
2)
Estimated depth,
(m)
Start date of borrow
pit operation (month &
year)
Status (active or completed); If
active =indicate estimated
completion date; If completed=
indicate date of completion
Specific mitigation measures
implemented by the contractor and date(s) of
implementation
Required additional mitigation
measure and target date for
implementation
PK168+960
(Photo in November,
2011)
5x15=75 2.5
March 2010
April 2010
Fencing in July 2011, but it was broken in Nov.
2012
Immediately Re-Fill;
TSO must be done by April
2013
In case TSO-SPCC not take in action then CSC
will write a letter to MPWT to
recruit the third party to re-fill those borrow pits and the
budget will be born from TSO account in the
RRC (RRL1) project
(Photo in March 28, 2013)
Loan 2288-CAM (SF) GMS: Rehabilitation of the Railway in Cambodia Environmental Monitoring
Page 4 of 7
Borrow pit location (specify
distance from nearest house,
school, and other sensitive
receptors)
Photograph Estimated
area, (m
2)
Estimated depth,
(m)
Start date of borrow
pit operation (month &
year)
Status (active or completed); If
active =indicate estimated
completion date; If completed=
indicate date of completion
Specific mitigation measures
implemented by the contractor and date(s) of
implementation
Required additional mitigation
measure and target date for
implementation
PK140+650
Photo taken in June 2011
8x50=400 1.7 May 2010
June 2010
Fencing in July 2011, but it was
completely broken in Nov.
2012
Immediately Re-fence and put warning
sign (as borrow pit at PK 372 in NL); TSO must
be done by April 2013
In case TSO-
SPCC not take in action then CSC
will write a letter to MPWT to
recruit the third party to build fence those
borrow pits and the budget will be born from
TSO account in the RRC (RRL1)
project
Photo taken in January 2013
Loan 2288-CAM (SF) GMS: Rehabilitation of the Railway in Cambodia Environmental Monitoring
Page 5 of 7
Borrow pit location (specify
distance from nearest house,
school, and other sensitive
receptors)
Photograph Estimated
area, (m
2)
Estimated depth,
(m)
Start date of borrow
pit operation (month &
year)
Status (active or completed); If
active =indicate estimated
completion date; If completed=
indicate date of completion
Specific mitigation measures
implemented by the contractor and date(s) of
implementation
Required additional mitigation
measure and target date for
implementation
PK140+700
Photo taken in April 2012
8x40=320 1.7 May 2010
June 2010
Fencing in July 2011, but it was
completely broken in Nov.
2012
Immediately Re-fence and put warning
sign; TSO must be done by April 2013
In case TSO-
SPCC not take in action then CSC
will write a letter to MPWT to
recruit the third party to build fence those
borrow pits and the budget will be born from
TSO account in the RRC (RRL1)
project
Photo taken in January 2013
Loan 2288-CAM (SF) GMS: Rehabilitation of the Railway in Cambodia Environmental Monitoring
Page 6 of 7
Borrow pit location (specify
distance from nearest house,
school, and other sensitive
receptors)
Photograph Estimated
area, (m
2)
Estimated depth,
(m)
Start date of borrow
pit operation (month &
year)
Status (active or completed); If
active =indicate estimated
completion date; If completed=
indicate date of completion
Specific mitigation measures
implemented by the contractor and date(s) of
implementation
Required additional mitigation
measure and target date for
implementation
PK141+000
Photo taken in August 2011
6x80=480 1.6
May 2010
June 2010
Fencing in July 2011, but it was
completely broken in Nov.
2012
Immediately Re-fence and put warning
sign; TSO must be done by April 2013
In case TSO-
SPCC not take in action then CSC
will write a letter to MPWT to
recruit the third party to build fence those
borrow pits and the budget will be born from
TSO account in the RRC (RRL1)
project
Photo taken in January 2013
Loan 2288-CAM (SF) GMS: Rehabilitation of the Railway in Cambodia Environmental Monitoring
Page 7 of 7
Borrow pit location (specify
distance from nearest house,
school, and other sensitive
receptors)
Photograph Estimated
area, (m
2)
Estimated depth,
(m)
Start date of borrow
pit operation (month &
year)
Status (active or completed); If
active =indicate estimated
completion date; If completed=
indicate date of completion
Specific mitigation measures
implemented by the contractor and date(s) of
implementation
Required additional mitigation
measure and target date for
implementation
PK168+950
(Photo in November,
2011)
5x12=60 3
March 2010
April 2010
Fencing in July 2011, but it was broken in Nov.
2011
Immediately Re-fence and put warning
sign; TSO must be done by April 2013
In case TSO-
SPCC not take in action then CSC
will write a letter to MPWT to
recruit the third party to build fence those
borrow pits and the budget will be born from
TSO account in the RRC (RRL1)
project
Photo in March 28, 2013)
Annex 3:
- Complaint letter from people living close to the
borrow pits
Annex 4:
- Accident report of TSO