draft service contract€¦ · arbitration by filing a written request with the secretariat of the...
TRANSCRIPT
![Page 1: DRAFT SERVICE CONTRACT€¦ · Arbitration by filing a written request with the Secretariat of the Milan Chamber of Arbitration. I.7.3 If for any reason the dispute remains unsettled](https://reader034.vdocuments.site/reader034/viewer/2022051918/600aec872d240126042f5166/html5/thumbnails/1.jpg)
Annex D - Draft Service Contract
Initialled by the Legal Representative for acceptance
__________________________________
1/30
DRAFTSERVICECONTRACT
OpenCallforTendersfortheSupplyofaWebContentManagementSystem
undertheSoftwareasaServicemodel
Ref:CFT-EUI-CS-2017-001
The European University Institute (hereinafter referred to as “the Institute”, “the EUI” or “the
contractingauthority”),establishedinSanDomenicodiFiesole,viadeiRoccettini9,Firenze,Italy,
CF80020410488,representedby itsPresident,Prof.RenaudDehousse/forthepurposesofthe
signature of this contract by [insert name of the Secretary General or authorising officer by
delegationorsubdelegation]1,
ontheonepart,
and
[Fullofficialname]
[Officiallegalform]2
[Statutoryregistrationnumber]3
[Fullofficialaddress]
[VATregistrationnumber]
(Hereinafterreferredtoas“theContractor”or“theCompany”),representedforthepurposesof
thesignatureofthiscontractbyMr/Ms[forename,surnameandfunction]
[Thepartiesidentifiedaboveandhereinaftercollectivelyreferredtoas“thecontractor”shallbe
jointlyandseverallyliablevis-à-visthecontractingauthorityfortheperformanceofthiscontract].
ontheotherpart,
1Signatorymustbeanauthorisingofficer(bydelegationorsub-delegation)designatedinaccordancewitharelevantDelegationDecision,e.g.President’sDecisionNo.69/70of18.12.2013orSecretaryGeneral’sDecisionNo.1/2014of06.02.2014.2Deleteifcontractorisanaturalpersonorabodygovernedbypubliclaw.3Delete if contractor isabodygovernedbypublic law.Fornaturalpersons, indicate thenumberof their identitycard,or failingthat,oftheirpassportorequivalent.
![Page 2: DRAFT SERVICE CONTRACT€¦ · Arbitration by filing a written request with the Secretariat of the Milan Chamber of Arbitration. I.7.3 If for any reason the dispute remains unsettled](https://reader034.vdocuments.site/reader034/viewer/2022051918/600aec872d240126042f5166/html5/thumbnails/2.jpg)
Annex D - Draft Service Contract
Initialled by the Legal Representative for acceptance
__________________________________
2/30
HAVEAGREED
tothespecialconditions,thegeneralconditionsforservicecontractaswellastothefollowing
Annexes:
AnnexI SpecialTenderSpecificationsCFT-EUI-CS-2017-001of03/04/2017
AnnexII Contractor'stender(referenceNo[complete]of[insertdate])including
o Technicaloffer(date)
o Economicoffer(date)
o Supportingdocuments:
o DeclarationonHonourconcerninglegalstatus;
o PerformanceBond(equalto10%ofthemeanannualcontractvaluebased
ontheEconomicoffer);
o Certificateofenrolmentincommercialregister;
o Insurances(asperArt.I.11.2),
whichformanintegralpartofthiscontract(hereinafterreferredtoas“thecontract”).
Intheeventofanyconflictherein,
• ThetermssetoutintheSpecialConditionsshalltakeprecedenceoverthoseintheotherparts
oftheContract.
• ThetermssetoutintheGeneralConditionsshalltakeprecedenceoverthoseintheAnnexes.
• The terms setout in theSpecial Tender Specifications (Annex I) shall takeprecedenceover
thoseinthetender(AnnexII).
For the avoidance of doubt, the Contractor acknowledges and agrees that the terms of the
ContractshallapplytotheexclusionoftheContractor’sstandardtermsandconditionsand/orany
conditionswhichmightbeimpliedbytradecustom,practiceorothercourseofdealing.
Subject to the above, the several instruments forming part of the Contract are to be taken as
mutually explanatory. Ambiguities or discrepancies within or between such parts shall be
![Page 3: DRAFT SERVICE CONTRACT€¦ · Arbitration by filing a written request with the Secretariat of the Milan Chamber of Arbitration. I.7.3 If for any reason the dispute remains unsettled](https://reader034.vdocuments.site/reader034/viewer/2022051918/600aec872d240126042f5166/html5/thumbnails/3.jpg)
Annex D - Draft Service Contract
Initialled by the Legal Representative for acceptance
__________________________________
3/30
explainedorrectifiedbyawritteninstructionissuedbytheInstitute;subjecttotherightsofthe
ContractorunderArticleI.7shoulditdisputeanysuchinstruction.
I-SPECIALCONDITIONS
ARTICLEI.1–SUBJECTMATTER
I.1.1The subject matter of the Contract isthe supply of a Web Content Management System
under the Software as a Service model, and all related activities of training, consultancy and
collaboration.
I.1.2N.A.
I.1.3Thecontractorshallexecutethetasksassignedto it inaccordancewiththeSpecialTender
Specificationsannexedtothecontract(AnnexI).
ARTICLEI.2-ENTRYINTOFORCEANDDURATION
I.2.1Thecontractshallenter intoforce[onthedateonwhich it issignedbythe lastparty]4 [on
[insertdate]ifithasalreadybeensignedbybothparties].
I.2.2Undernocircumstancesmayperformancecommencebeforethedateonwhichthecontract
entersintoforce.
I.2.3 The duration of the execution of the tasks shall not exceed 12months. Unless otherwise
specified,allperiodsoutlinedinthecontractarecalculatedincalendardays.
Executionofthetasksshallstartfrom[thedateofentryintoforceofthecontract][insertdate].
Theperiodofexecutionofthetasksmaybeextendedonlywiththeexpresswrittenagreementof
thepartiesbeforetheexpirationofsuchperiod.
I.2.4TheContractorissubjecttoaprobationaryperiodofthreemonths.If,duringthisperiod,the
execution of the service does not correspond to the requirements of the Special Tender
Specifications,ortoanyimprovementsofferedinthetenderbytheContractor,theInstituteshall
4 Asarulethecontractingauthoritysignslast. Inthiscase,thecontractorshouldbedulyinformedofthedateon
whichthecontractentersintoforce(dateofsignaturebythecontractingauthority).
![Page 4: DRAFT SERVICE CONTRACT€¦ · Arbitration by filing a written request with the Secretariat of the Milan Chamber of Arbitration. I.7.3 If for any reason the dispute remains unsettled](https://reader034.vdocuments.site/reader034/viewer/2022051918/600aec872d240126042f5166/html5/thumbnails/4.jpg)
Annex D - Draft Service Contract
Initialled by the Legal Representative for acceptance
__________________________________
4/30
be entitled to terminate the Contract by serving a notice of thirty (30) days by registered
mail.
I.2.5Where,attheendofthenaturaltermoftheContract,theContractingAuthorityhasnotyet
awardedacontractfortheservicecoveringtheimmediatelyfollowingperiod,theContractorshall
beobligedtocontinueprovidingtheservice(s)foraperiodnotexceedingsix(6)monthsunderthe
sametermsandconditionsinforceattheexpirationdate.
I.2.6 Contractrenewal
Optional Renewal: The contract may be renewed up to 6 times, each time for a period of
executionoftasksof12months,onlythreemonthsbeforepaymentofthebalanceandwiththe
expresswrittenagreementoftheparties,indicatingthedateonwhichexecutionofthetasksshall
start.Renewaldoesnotimplyanymodificationordefermentofexistingobligations.
ARTICLEI.3-PRICES
I.3.1The[maximum]totalamounttobepaidbythecontractingauthorityunderthecontractshall
be[amountinfiguresandinwords]5excludingVAT,coveringallservices/tasksexecuted(including
charges).
The Institute is exempt frompaymentof value added tax for services andpurchasesunder the
normalcourseofbusinessforamountsexceeding€300.00(pursuanttoArticle72-paragraph1-e)
andparagraph2ofPresidentialDecree633of26/10/1972andsubsequentamendments).
TheeconomicofferoftheContractorisprovidedinAnnexII.
I.3.2Pricerevision
Thetotalamountreferredto inArticle I.3.1shallbefixedandnotsubjecttorevisionduringthe
firstyearofperformanceofthecontract.
At thebeginningof thesecondandevery followingyearof thecontract, theamount(s)maybe
revisedupwardsordownwards, if suchrevision is requestedbyoneof theparties inwritingno
laterthanthreemonthsbeforetheanniversaryofthedateonwhichtheContractwassigned.The
5Thetotalamountwillbedeterminedbytheofferofthesuccessfultenderer.
![Page 5: DRAFT SERVICE CONTRACT€¦ · Arbitration by filing a written request with the Secretariat of the Milan Chamber of Arbitration. I.7.3 If for any reason the dispute remains unsettled](https://reader034.vdocuments.site/reader034/viewer/2022051918/600aec872d240126042f5166/html5/thumbnails/5.jpg)
Annex D - Draft Service Contract
Initialled by the Legal Representative for acceptance
__________________________________
5/30
otherpartyshallacknowledgereceiptwithin15daysofreceptionoftherequestforpricerevision.
Thenewpricesshallbecommunicatedinwritingassoonasthefinalindexisavailable.
The revision shall be determined by any change resulting from the “EUROSTAT” index of
reference.
The EUROSTAT index of reference for the revision is the “Harmonised index of consumer
prices”.Themost recent “Harmonised index of consumer prices” published before the request
shallbeusedforthere-evaluation.Inthecasewherethere-evaluationrequest isreceivedafter
theannualexpirationdate, thesamewillbegrantedwitheffect fromthedateofreceiptofthe
request.
ARTICLEI.4-PAYMENTARRANGEMENTS
I.4.1Payment
PaymentoftheamountsdueandchargesundertheContractshallbemadeonlyiftheContractor
has fulfilledall itscontractualand legalobligationsbythedateonwhichthe invoice iscorrectly
submitted.
PaymentoftheamountsdueandchargesundertheContractshallbemadeonamonthlybasis.
Toobtainpayment,theContractorwillfollowtheanalyticalproceduresrequiredbytheInstitute
intermsofbilling,issuinguponrequestspecificinvoicesforeachcost/activityreported.
TheContractingAuthorityshallmakepaymentwithinsixty(60)daysofreceiptofinvoice.
ThespecificrulesareoutlinedinArticleII.15–Reportingandpayments,clauseII.15.3-Invoices
andVAToftheGeneralConditions.
Deductions resulting fromeconomicpenalties fornon-compliancereferred to inArticle8of the
Special Tender Specificationswill be compensated simultaneouslywith thepaymentof invoices
fortheperiodofreference.
![Page 6: DRAFT SERVICE CONTRACT€¦ · Arbitration by filing a written request with the Secretariat of the Milan Chamber of Arbitration. I.7.3 If for any reason the dispute remains unsettled](https://reader034.vdocuments.site/reader034/viewer/2022051918/600aec872d240126042f5166/html5/thumbnails/6.jpg)
Annex D - Draft Service Contract
Initialled by the Legal Representative for acceptance
__________________________________
6/30
I.4.2Performanceguarantee6
Performanceguaranteebyfinancialguarantee
AperformanceguaranteeforanamountofEURequalto10%ofthemeanannualcontractvalue
basedontheContractor’sownEconomicOffershallbeissuednolaterthan[insertdate][thedate
ofdispatchofthe invoiceforpaymentofthebalance]7accordingtotheconditions laiddownin
ArticleII.15.5.
ARTICLEI.5-BANKACCOUNT
PaymentsshallbemadetotheContractor'sbankaccountdenominatedinEuro(€),orinthelocal
currencyifthereceivingpartyhasitslegalseatoutsideEuro-area,andidentifiedasfollows:
Nameofbank: Branchaddressinfull: Exactdesignationofaccountholder: IBANcode: SWIFTcode:
ARTICLEI.6–COMMUNICATIONDETAILSANDDATACONTROLLER
For the purposes of Article II.6, the data controller shall be the Communications Service,
representedbyitsDirector.
AnynoticeorothercommunicationrelatingtotheContractshallbemadeinwriting,shallbearthe
Contractnumberandshallbesenttotheappropriateaddressoremailaddresssetoutbelow(or
suchotheraddressorpersonastherelevantpartymaynotifytotheother):
ContractingAuthority:EuropeanUniversityInstituteCommunicationsServiceViadeiRoccettini,9-50014SanDomenicodiFiesole(FI)Emailaddress: [email protected]
Contractor:
Nameandsurname: 6 Ifthetenderspecificationsprovideforcomplexservices,theprovisionalapprovalofproductscanleadtopaymentofthe
balanceandfinalapprovaloftheproductswithfullsatisfactiononexecutioncantakeplacesometime(uptoseveralmonths)afterpaymentofthebalance.Thenaperformanceguaranteeisnecessarytocoverthisperioduntilfinalacceptance.
7 Thisbankguaranteecanberequestedlaterintheexecutionofthecontract,notnecessarilyatthebeginning,sinceitcoversex-postperformanceandthelongeraguaranteeis,themoreexpensiveitis.
![Page 7: DRAFT SERVICE CONTRACT€¦ · Arbitration by filing a written request with the Secretariat of the Milan Chamber of Arbitration. I.7.3 If for any reason the dispute remains unsettled](https://reader034.vdocuments.site/reader034/viewer/2022051918/600aec872d240126042f5166/html5/thumbnails/7.jpg)
Annex D - Draft Service Contract
Initialled by the Legal Representative for acceptance
__________________________________
7/30
Function: Companyname: Fullofficialaddress: Email:
ARTICLEI.7-APPLICABLELAWANDSETTLEMENTOFDISPUTES
I.7.1ThecontractshallbegovernedbytheEUI’srelevantregulatoryacts(e.g.theEUI’sregulation
onPublicProcurement&theEUI’sFinancialRules),complementedwherenecessarybythelawof
Italy.
I.7.2Any dispute arising in relation to the present contract shall be submitted in good faith by
either party to mediation under the International Mediation Rules of the Milan Chamber of
ArbitrationbyfilingawrittenrequestwiththeSecretariatoftheMilanChamberofArbitration.
I.7.3If for any reason thedispute remainsunsettled60daysafter the request formediation, it
shallbesubjecttoarbitrationundertheRulesoftheMilanChamberofArbitration.Theseatofthe
arbitrationshallbeMilanandthelanguageofthearbitrationshallbeEnglish.Theawardshallbe
finalandbinding.
ThearbitraltribunalshallapplytheEUI’srelevantregulatoryacts,includingtheEUI’sregulationon
PublicProcurementandtheEUI’sFinancialRules,complemented,wherenecessary,bythelawof
Italy.
ARTICLEI.8-EXPLOITATIONOFTHERESULTSOFTHECONTRACT
SeeARTICLEII.10.-OWNERSHIPOFTHERESULTS-INTELLECTUALANDINDUSTRIALPROPERTYRIGHTS
ARTICLEI.9-TERMINATIONBYEITHERPARTY
Either party may, unilaterally and without being required to pay compensation, terminate the
contract by formally notifying the other party by giving twelve weeks’ notice. Should the
contracting authority terminate the contract, the contractor shall only be entitled to payment
corresponding to part-performance of the contract before the termination date (e.g. payment
corresponding to the services which are the subject of valid Purchase Orders before the date
termination is notified to become effective (“TerminationDate”). The first paragraph of Article
II.14.3shallapply.
![Page 8: DRAFT SERVICE CONTRACT€¦ · Arbitration by filing a written request with the Secretariat of the Milan Chamber of Arbitration. I.7.3 If for any reason the dispute remains unsettled](https://reader034.vdocuments.site/reader034/viewer/2022051918/600aec872d240126042f5166/html5/thumbnails/8.jpg)
Annex D - Draft Service Contract
Initialled by the Legal Representative for acceptance
__________________________________
8/30
OnreceiptofsuchnoticefromtheInstitute,theContractorshalltakeallappropriatemeasuresto
minimisecosts,preventdamage,andcancelorreduceitscommitmentsinrelationtotheInstitute.
ItshalldrawupanydocumentsrequiredbytheContractanditsAnnexesfortheservicesprovided
uptotheTerminationDate,withinaperiodnotexceedingsixtydaysfromtheTerminationDate.
ARTICLEI.10-MECHANISMOFSANCTIONSANDPENALTIES
The carrying out of the service by non-regular or unsatisfactory means in the opinion of the
ContractingAuthority,shall incurtheapplicationofpenaltiespursuanttoArticle8oftheSpecial
TenderSpecifications.
The non-regular and unsatisfactory provision of the service will be notified in writing to the
Contractorwhoshall respond inanycasewith itscomments inwritingwithin5 (five)days from
the dispute.If said response is not acceptable according to the appreciation of the Contracting
Authority or if there is no answer or the same is not received within the time specified, the
Contracting Authority will apply the penalties referred to in Article 8 of the Special Tender
Specifications,fromthedateofthecommencementofthepoorperformance.
The request and/or payment of penalties shall not discharge the Contractor under any
circumstancesfromperformanceoftheobligationsforwhichitiscurrentlyresponsible.
ARTICLEI.11-PROVISIONSRELATINGTOSAFETY
NotApplicable.
ARTICLEI.12–CONTRACTUALFEES
If applicable, any consequential contract costs (fixed-fee registration) will be paid by the
Contractorwithouttherightofrecourseagainstthecontractingauthority.
ARTICLEI.13-OTHERSPECIALCONDITIONS
Duetothespecificcharacteristicsoftheservicesprovidedwithinthiscontract:
• ARTICLEII.16–REIMBURSEMENTS
isnotapplicable.
![Page 9: DRAFT SERVICE CONTRACT€¦ · Arbitration by filing a written request with the Secretariat of the Milan Chamber of Arbitration. I.7.3 If for any reason the dispute remains unsettled](https://reader034.vdocuments.site/reader034/viewer/2022051918/600aec872d240126042f5166/html5/thumbnails/9.jpg)
Annex D - Draft Service Contract
Initialled by the Legal Representative for acceptance
__________________________________
9/30
SIGNATURES
FortheContractor,
CompanyName/name&surnameof
representative/function
Signature/s:_____________________________
SignedinFlorence,on______________
FortheInstitute,
Name/surname/function
Signature/s:_______________________
SignedinFlorence,on______________
InduplicateinEnglish
![Page 10: DRAFT SERVICE CONTRACT€¦ · Arbitration by filing a written request with the Secretariat of the Milan Chamber of Arbitration. I.7.3 If for any reason the dispute remains unsettled](https://reader034.vdocuments.site/reader034/viewer/2022051918/600aec872d240126042f5166/html5/thumbnails/10.jpg)
Annex D - Draft Service Contract
Initialled by the Legal Representative for acceptance
__________________________________
10/30
II–GENERALCONDITIONSFORSERVICECONTRACTS
ARTICLEII.1–PERFORMANCEOFTHECONTRACT
II.1.1Thecontractorshallperformthecontractaccordingtothehighestprofessionalstandards.
II.1.2Thecontractorshallbesolelyresponsiblefortakingthenecessarystepstoobtainanypermit
orlicencerequiredforperformanceofthecontractunderthelawsandregulationsinforceatthe
placewheretheassignedtasksaretobeexecuted.
II.1.3Withoutprejudice toArticle II.4, any referencemade to the contractor’spersonnel in the
contractshallrelateexclusivelytoindividualsinvolvedintheperformanceofthecontract.
II.1.4 The contractor must ensure that the personnel performing the contract possess the
professionalqualificationsandexperiencerequiredfortheexecutionofthetasksassignedtoit.
II.1.5Thecontractorshallneitherrepresentthecontractingauthoritynorbehaveinanywaythat
wouldgivesuchanimpression.
II.1.6Thecontractorshallbesolelyresponsibleforthepersonnelwhoexecutethetasksassigned
tothecontractor.Thecontractorshallstipulatethefollowingemploymentorservicerelationships
withitspersonnel:
a. personnelexecutingthetasksassignedtothecontractormaynotbegivenordersdirectly
bythecontractingauthority;
b. thecontractingauthoritymaynotunderanycircumstancesbeconsideredtobethe
employerofthepersonnelreferredtoinpoint(a)andthepersonnelshallundertakenotto
invokeagainstthecontractingauthorityanyrightarisingfromthecontractualrelationship
betweenthecontractingauthorityandthecontractor.
II.1.7 In the event of disruption resulting from the action of one of the contractor's personnel
workingonthecontractingauthority’spremisesorintheeventthattheexpertiseofamemberof
the contractor's personnel fails to correspond to the profile required by the contract, the
contractorshallreplacehimorherwithoutdelay.Thecontractingauthorityshallhavetherightto
makeareasonedrequestforthereplacementofanysuchpersonnel.Thereplacementpersonnel
musthavethenecessaryqualificationsandbecapableofperformingthecontractunderthesame
![Page 11: DRAFT SERVICE CONTRACT€¦ · Arbitration by filing a written request with the Secretariat of the Milan Chamber of Arbitration. I.7.3 If for any reason the dispute remains unsettled](https://reader034.vdocuments.site/reader034/viewer/2022051918/600aec872d240126042f5166/html5/thumbnails/11.jpg)
Annex D - Draft Service Contract
Initialled by the Legal Representative for acceptance
__________________________________
11/30
contractualconditions.Thecontractorshallberesponsible foranydelay in theexecutionof the
tasksassignedtoitresultingfromthereplacementofpersonnel.
II.1.8 Should the execution of the tasks be directly or indirectly hampered, either partially or
totally,byanyunforeseenevent,actionoromission,thecontractorshall immediatelyandonits
own initiative record it and report it to the contracting authority. The report shall include a
descriptionoftheproblemandanindicationofthedateonwhichitstartedandoftheremedial
actiontakenbythecontractortoensurefullcompliancewithitsobligationsunderthiscontract.In
such an event the contractor shall givepriority to solving theproblem rather thandetermining
liability.
II.1.9Thecontractorshallobservetherulesstemmingfromexistinglawsandagreementsonthe
employment of labour, disability, age, workplace accidents, involuntary unemployment and all
otherprovisionsgoverningtheexecutionphaseofthecontract.
II.1.10 For workers employed in the execution of the service, whether they are Contractor
employees (or working partners in the case of cooperatives) and/or subcontractors, the
Contractor undertakes to complywith regulatory conditions andwages that are not to be less
thanthoseresulting fromcollectiveagreementsandfromnational territorial labouragreements
applicable on the date of the Contract as well as with conditions resulting from subsequent
amendments and additions, and generally, from any other collective agreement subsequently
entered intoby categoryas applicable to theContractor.Theobligation remainsevenafter the
expiryofsuchcontractsandcollectiveagreementsuntiltheyarereplaced.
TheseobligationsshallbindtheContractorthroughouttheperiodofvalidityofthecontracteven
if it is not adhering to the signatory associations or withdraws from them, and whatever the
natureoftradeorindustrialapplications,thestructureorsizeoftheCompanyaswellasitslegal
statusoreconomicunion,includingthecooperativeform.
ItshallbepossiblefortheContractingAuthoritytoasktheContractoratanytimetosubstantiate
the application of the regulations provided for in the collective salary category contracts and
supplementalagreements forworkersemployed intheservice.If theContractor is foundtonot
![Page 12: DRAFT SERVICE CONTRACT€¦ · Arbitration by filing a written request with the Secretariat of the Milan Chamber of Arbitration. I.7.3 If for any reason the dispute remains unsettled](https://reader034.vdocuments.site/reader034/viewer/2022051918/600aec872d240126042f5166/html5/thumbnails/12.jpg)
Annex D - Draft Service Contract
Initialled by the Legal Representative for acceptance
__________________________________
12/30
beincompliancewiththeseobligations,theContractingAuthoritywillapplyawithholdingtaxof
upto20%oftheamountdue.
Thedeductionwillbe releasedonlyuponpresentationby theContractorof thedocumentation
certifying the payment of social security contributions and compulsoryworkplace accident and
occupational illness insurance,without theContractor itselfbeingable to layanyclaim towards
non-ordelayedpayment.
II.1.11 Should the contractor fail to perform its obligations under the contract, the contracting
authority may -without prejudice to its right to terminate the contract- reduce or recover
paymentsinproportiontothescaleoftheunperformedobligations.Inaddition,theContracting
Authoritymay claim compensation or impose liquidated damages in accordancewith Art. II.12
and/oranypenaltiesindicatedintheSpecialTenderSpecifications.
ARTICLEII.2–MEANSOFCOMMUNICATION
II.2.1 Anycommunicationrelatingtothecontractortoitsperformanceshallbemadeinwriting
andshallbearthecontractnumber.Anycommunicationisdeemedtohavebeenmadewhenitis
receivedbythereceivingpartyunlessotherwiseprovidedforinthiscontract.
II.2.2 Electroniccommunicationshallbedeemedtohavebeenreceivedbythepartiesontheday
of dispatch of that communication provided it is sent to the addressees listed in ArticleI.6.
Withoutprejudicetothepreceding,ifthesendingpartyreceivesamessageofnon-deliverytoor
of absence of the addressee, it shall make every effort to ensure the actual receipt of such
communicationbytheotherparty.
Electronic communication shall be confirmed by an original signed paper version of that
communicationifrequestedbyanyofthepartiesprovidedthatthisrequestissubmittedwithout
unjustified delay. The sender shall send the original signed paper version without unjustified
delay.
II.2.3 Mail sent using the postal services is deemed to have been received by the contracting
authorityonthedateonwhichitisregisteredbytheresponsibleservicereferredtoinArticleI.6.
Anyformalnotificationshallbemadebyregisteredmailwithreturnreceiptorequivalent,orby
equivalentelectronicmeans.
![Page 13: DRAFT SERVICE CONTRACT€¦ · Arbitration by filing a written request with the Secretariat of the Milan Chamber of Arbitration. I.7.3 If for any reason the dispute remains unsettled](https://reader034.vdocuments.site/reader034/viewer/2022051918/600aec872d240126042f5166/html5/thumbnails/13.jpg)
Annex D - Draft Service Contract
Initialled by the Legal Representative for acceptance
__________________________________
13/30
ARTICLEII.3-LIABILITY
II.3.1Thecontractorshallbesolelyresponsibleforcomplyingwithanylegalobligationsincumbent
onit.
II.3.2Thecontractingauthorityshallnotbeheldliableforanyclaim,loss,costorexpenseorany
damagecausedorsustainedbythecontractor,includinganydamagecausedbythecontractorto
thirdpartiesduringorasaconsequenceofperformanceof thecontract,except in theeventof
wilfulmisconductorgrossnegligenceonthepartofthecontractingauthority.
II.3.3The contractor shall beheld liable for any lossordamage, cost (including legal andother
professionalfees)orexpensessustainedbythecontractingauthoritybutcausedbythecontractor
inperformanceof the contract, including in theeventof subcontractingand forany claimbya
thirdpartybutonlytoanamountnotexceedingthreetimesthetotalamountofthecontract.The
Contractor shall remain liablewithout any limitation as to the amount if the damage or loss is
causedbythegrossnegligenceorwilfulmisconductoftheContractororbyitsemployees,andfor
deathcausedbynegligenceorwilfulmisconductofitsemployees.
II.3.4Inaddition,thecontractorshall,intheexecutionofservice,complywithallproceduresand
precautions that apply to prevent the possibility of damage to property of the contracting
authority and thirdparties, andespeciallyof injury topersonsengaged in the serviceand third
parties,incompliancewiththeprovisionsofapplicablelaw.Anyliability,intheeventofaccidents,
for damages caused by the contractor’s staff will fall, therefore, upon the contractor, thus
relievingthecontractingauthority.
II.3.5 The contractor shall indemnify and hold the Institute harmless for all damages and costs
incurredduetoanyclaim.Thecontractorshallprovidecompensationintheeventofanyaction,
claim or proceeding brought against the contracting authority by a third party as a result of
damage caused by the contractor during the performance of the contract. In the event of any
action brought by a third party against the contracting authority in connection with the
performanceofthecontract,thecontractorshallassistthecontractingauthority.
II.3.6 Thecontractor shall takeoutan insurancepolicyagainst risksanddamage relating to the
performance of the contract, if required by the relevant applicable legislation. It shall take out
![Page 14: DRAFT SERVICE CONTRACT€¦ · Arbitration by filing a written request with the Secretariat of the Milan Chamber of Arbitration. I.7.3 If for any reason the dispute remains unsettled](https://reader034.vdocuments.site/reader034/viewer/2022051918/600aec872d240126042f5166/html5/thumbnails/14.jpg)
Annex D - Draft Service Contract
Initialled by the Legal Representative for acceptance
__________________________________
14/30
supplementaryinsuranceasreasonablyrequiredbystandardpracticeintheindustry.Acopyofall
therelevantinsurancecontractsshallbesenttothecontractingauthorityshoulditsorequest.
ARTICLEII.4-CONFLICTOFINTEREST
II.4.1TheContractorshalltakeallthenecessarymeasurestopreventanysituationofconflictof
interest. Such situationariseswhere the impartial andobjectiveperformanceof the contract is
compromised for reasons involving economic interest, political or national affinity, family or
emotionalties,oranyothersharedinterest.
II.4.2Anysituationconstitutingorlikelytoleadtoaconflictofinterestduringtheperformanceof
thecontractshallbenotifiedtothecontractingauthorityinwritingwithoutdelay.Intheeventof
any such conflict, the contractor shall immediately take all the necessary steps to rectify the
situation. The contracting authority reserves the right to verify that the steps taken are
appropriateandmayrequirethatadditionalstepsbetakenwithinaspecifieddeadline.
II.4.3Thecontractordeclaresthat ithasnotgrantedandwillnotgrant,hasnotsoughtandwill
not seek, has not attempted andwill not attempt to obtain andhas not accepted andwill not
accept,anyadvantage,financialorinkind,toorfromanypartywhatsoever,whensuchadvantage
constitutes an illegal practice or involves corruption, either directly or indirectly, in so far as it
servesasanincentiveorrewardrelatingtotheperformanceofthecontract.
II.4.4IncompliancewiththeEUI’sStaffRegulations,inparticularArt.11,EUI’sstaffmembersshall
not, without the permission of the Appointing Authority, accept any gift, directly or indirectly
connectedwiththeirownworkactivities.TheContractorconfirmsacknowledgementofthisrule
andtheconsequentterminationofthecontractincaseofnon-conformity.
II.4.5Thecontractorshallpassonalltherelevantobligationsinwritingtoitspersonnelandtoany
naturalpersonwiththepowertorepresentitortakedecisionsonitsbehalfandensurethatitis
notplacedinasituationwhichcouldgiverisetoconflictsofinterest.Thecontractorshallalsopass
on all the relevant obligations in writing to third parties involved in the performance of the
contractincludingsubcontractors.
![Page 15: DRAFT SERVICE CONTRACT€¦ · Arbitration by filing a written request with the Secretariat of the Milan Chamber of Arbitration. I.7.3 If for any reason the dispute remains unsettled](https://reader034.vdocuments.site/reader034/viewer/2022051918/600aec872d240126042f5166/html5/thumbnails/15.jpg)
Annex D - Draft Service Contract
Initialled by the Legal Representative for acceptance
__________________________________
15/30
Without prejudice to Article II.1 the Contractor shall replace, immediately and without
compensationfromtheInstitute,anymemberoftheContractor’sStafffacedwithorbroughtinto
suchasituation.
ARTICLEII.5-CONFIDENTIALITY
II.5.1Thecontractingauthorityandthecontractorshalltreatwithconfidentialityanyinformation
anddocuments, inany form,disclosed inwritingororally in relation to theperformanceof the
contractandidentifiedinwritingasconfidential.
II.5.2TheContractorshall:
a. notuseconfidentialinformationanddocumentationforanypurposeotherthanfulfilling
itsobligationsunderthecontractwithoutpriorwrittenagreementofthecontracting
authority;
b. ensuretheprotectionofsuchconfidentialinformationanddocumentationwiththesame
levelofprotectionitusestoprotectitsownconfidentialinformation,butinnocaseany
lessthanreasonablecare;
c. notdisclosedirectlyorindirectlyconfidentialinformationanddocumentationtothird
partieswithoutpriorwrittenagreementofthecontractingauthority.
II.5.3 The confidentiality obligation set out in Article II.5.1 shall be binding on the contracting
authority and the contractorduring theperformanceof the contract and for five years starting
fromthedateofthepaymentofthebalanceunless:
a. thedisclosingpartyagreestoreleasetheotherpartyfromtheconfidentialityobligation
earlier;
b. theconfidentialinformationbecomespublicthroughothermeansthanviabreachofthe
confidentialityobligationsthroughdisclosurebythepartyboundbythatobligation;
c. thedisclosureoftheconfidentialinformationisrequiredbylaw.
II.5.4TheContractorshallobtainfromanypersonwiththepowertorepresentitortakedecisions
on its behalf, as well as from third parties involved in the performance of the contract, an
undertakingthattheywillcomplywiththeconfidentialityobligationssetoutinArticleII.5.1.
![Page 16: DRAFT SERVICE CONTRACT€¦ · Arbitration by filing a written request with the Secretariat of the Milan Chamber of Arbitration. I.7.3 If for any reason the dispute remains unsettled](https://reader034.vdocuments.site/reader034/viewer/2022051918/600aec872d240126042f5166/html5/thumbnails/16.jpg)
Annex D - Draft Service Contract
Initialled by the Legal Representative for acceptance
__________________________________
16/30
ARTICLEII.6-PROCESSINGOFPERSONALDATA
II.6.1AnypersonaldataincludedinthecontractshallbeprocessedbytheInstituteinaccordance
with the EUI’s Data Protection policy pursuant to the EUI President’s Decision No. 40/2013
regardingDataProtectionattheEUI.Suchdatashallbeprocessedbythedatacontrollersolelyfor
thepurposesoftheperformance,managementandmonitoringofthecontractwithoutprejudice
to its possible transmission to the bodies charged with monitoring or inspection tasks in
applicationofrelevantEUandnationallaw.
II.6.2Thecontractorshallhavetherightofaccesstoitspersonaldataandtherighttorectifyany
suchdata.Thecontractor shouldaddressanyconcerns related to theprocessingof itspersonal
datatotheDataControllerindicatedinArt.I.6.
II.6.3 The contractor shall have the right of recourse at any time to the Director of the
Communications Service by simultaneous notification to the Data Protection Officer
II.6.4Wherethecontractrequirestheprocessingofpersonaldatabythecontractororanyofits
subcontractors, the contractor may act only under the supervision of the data controller, in
particularwith regard to the purposes of the processing, the categories of datawhichmay be
processed, the recipientsof thedataand themeansbywhich thedatasubjectmayexercise its
rights. In that respect, the contractor shall be bound by the relevant provisions of the EUI
President’sDecisionNo. 40/2013aswell asby theDataProtectionDirective (95/46/EC) andall
applicable national laws and regulations of the country where it is established regarding the
processingofpersonaldataandprivacy.
II.6.5Thecontractorshallgrantitspersonnelaccesstothedataonlytotheextentstrictly
necessaryfortheperformance,managementandmonitoringofthecontract.
II.6.6Thecontractorundertakestoadoptappropriatetechnicalandorganisationalsecurity
measureshavingregardtotherisksinherentintheprocessingandtothenatureofthepersonal
dataconcernedinorderto:
a. preventanyunauthorisedpersonfromgainingaccesstocomputersystemsprocessing
personaldata,andespecially:
![Page 17: DRAFT SERVICE CONTRACT€¦ · Arbitration by filing a written request with the Secretariat of the Milan Chamber of Arbitration. I.7.3 If for any reason the dispute remains unsettled](https://reader034.vdocuments.site/reader034/viewer/2022051918/600aec872d240126042f5166/html5/thumbnails/17.jpg)
Annex D - Draft Service Contract
Initialled by the Legal Representative for acceptance
__________________________________
17/30
i. unauthorisedreading,copying,alterationorremovalofstoragemedia;
ii. unauthoriseddatainput,aswellasanyunauthoriseddisclosure,alterationor
erasureofstoredpersonaldata;
iii. unauthoriseduseofdata-processingsystemsbymeansofdatatransmission
facilities;
b. ensurethatauthorisedusersofadata-processingsystemcanaccessonlythepersonaldata
towhichtheiraccessrightrefers;
c. recordwhichpersonaldatahavebeencommunicated,whenandtowhom;
d. ensurethatpersonaldatabeingprocessedonbehalfofthirdpartiescanbeprocessedonly
inthemannerprescribedbytheContractingAuthority;
e. ensure that,duringcommunicationofpersonaldataandtransportofstoragemedia, the
datacannotberead,copiedorerasedwithoutauthorisation;
f. design its organisational structure in such a way that it meets data protection
requirements.
ARTICLEII.7-SUBCONTRACTING
II.7.1 The contractor shall not subcontract without prior written authorisation from the
contractingauthoritynorcausethecontracttobedefactoperformedbythirdparties.
II.7.2Therequest forsubcontractingmustbeaccompaniedbyaclear indicationof theactivities
thatwillbesubcontracted,andmustnecessarilysatisfytherequirementsofthecurrentcontract
andanyapplicableItalianregulations.Inthecaseofsubcontractingoccurringduringtheperiodof
validity of the contract resulting from this procedure, the contractor must submit all required
documentation to the Instituteandawait itspriorauthorisationbeforemaking it indispensable,
effectiveandoperational.
II.7.3 Even where the contracting authority authorises the Contractor to subcontract to third
parties, theContractorshall remainboundby itsobligationstothe InstituteunderthisContract
andshallguaranteetheprovisionoftheServicesandbesolelyliablefortheproperperformance
oftheContractasifitwasperformingtheServicesitself.
![Page 18: DRAFT SERVICE CONTRACT€¦ · Arbitration by filing a written request with the Secretariat of the Milan Chamber of Arbitration. I.7.3 If for any reason the dispute remains unsettled](https://reader034.vdocuments.site/reader034/viewer/2022051918/600aec872d240126042f5166/html5/thumbnails/18.jpg)
Annex D - Draft Service Contract
Initialled by the Legal Representative for acceptance
__________________________________
18/30
II.7.4TheContractorshallensurethatthesubcontractdoesnotaffectrightsandguaranteeswhich
thecontractingauthorityhasbyvirtueof thisContractandagrees to indemnify thecontracting
authorityagainstanyclaim,loss,costorexpensesawardedagainst,suffered,incurred,oragreed
tobepaidbythecontractingauthorityasaconsequencethereof.
ARTICLEII.8-AMENDMENTS
II.8.1Any amendment to the contract shall be made in writing before fulfilment of any new
contractualobligationsandinanycasebeforethedateofpaymentofthebalance.
II.8.2Theamendmentmaynothavethepurposeortheeffectofmakingchangestothecontract
whichmightcallintoquestionthedecisionawardingthecontractorresultinunequaltreatment
oftenderers.
ARTICLEII.9–ASSIGNMENT
II.9.1 Thecontractor shallnotassign the rights, including claims forpayments, andobligations
arisingfromthecontract,inwholeorinpart,withoutpriorwrittenauthorisationfromthe
contractingauthority.
II.9.2 In the absence of such authorisation, or in the event of failure to observe the terms
thereof,theassignmentofrightsorobligationsbythecontractorshallnotbeenforceable
againstthecontractingauthorityandshallhavenoeffectonit.
ARTICLEII.10–OWNERSHIPOFTHERESULTS-INTELLECTUALANDINDUSTRIALPROPERTYRIGHTS
II.10.1 Intellectual PropertyRights (“IPR”)means all patents and patent rights, trademarks and
trademark rights, trade names and trade name rights, service marks and service mark rights,
servicenamesandservicenamerights,brandnames,copyrightsandcopyrightrights,tradedress,
businessandproductnames,logos,slogans,tradesecrets,industrialmodels,utilitymodels,design
models, designs, rights in confidential information, know-how, rights in the nature of unfair
competition rights and rights to sue for passing off, and all pending applications for and
registrationsofpatents,trademarks,servicemarks,andcopyrightstogetherwithallconnectedand
similaroranalogousrightsinanycountryorjurisdictionforthefulltermthereof.
![Page 19: DRAFT SERVICE CONTRACT€¦ · Arbitration by filing a written request with the Secretariat of the Milan Chamber of Arbitration. I.7.3 If for any reason the dispute remains unsettled](https://reader034.vdocuments.site/reader034/viewer/2022051918/600aec872d240126042f5166/html5/thumbnails/19.jpg)
Annex D - Draft Service Contract
Initialled by the Legal Representative for acceptance
__________________________________
19/30
II.10.2Pre-existingIPRmeansallIPRexistingpriortothedateofthisServiceContractandallIPR
in any materials, acquired or developed by or for Contractor or Contracting Authority
independently of this Service Contract, and any IPR in Contractor’s standard hardware and
softwareproductsormodificationsorupdatestosuchproducts.
II.10.3 All IPR title and interest in all reports, datamanuals and/or othermaterials (other than
software) (includingwithout limitationall and anyaudio or audio visual recordings, transcripts,
books,papers,records,notes,illustrations,photographs,diagrams)producedforthepurposesof
thisServiceContract (collectively“theMaterials”)(oranypartorpartsthereof)shallvest inthe
Contracting Authority and the Contractor so acknowledges and confirms. For the avoidanceof
doubttheContractorherebyassignsallIPRtitleandinterestintheMaterials(includingbywayof
present assignmentof futurecopyright)to theextent thatanysuch IPRtitleor interestmaybe
deemedbylawtoresideintheMaterialstotheContractingAuthorityabsolutely.
II.10.4TheContractingAuthoritygrantstotheContractoraroyalty-freenon-exclusivelicenceto
usetheContractingAuthority’sPre-existingIPRfortheTermtotheextentnecessarytoenablethe
Contractor to fulfil its obligationsunder this Service Contract. Save as expressly set out in this
clause all Pre-Existing IPR shall remain the sole propertyof the partywho owned, acquired or
developedsuchintellectualproperty.
II.10.5TheContractorshallwaiveorprocureawaiverofanymoralrightssubsistingincopyright
producedunderorinperformanceofthisContract.
II.10.6NothinginthisServiceContractshallprohibitorbedeemedtoprohibittheContractorfrom
providingservicessimilartotheServicestoanypartyotherthanthePartieshereto. Innoevent
shalltheContractorbeprecludedfromindependentlydevelopingforitself,orforothers,materials
whicharecompetitivewith,orsimilarto,theServicesandtouseitsgeneralknowledge,skillsand
experience, and any ideas, concepts, know-how, formats, templates, methodologies and
techniquesthatareacquiredorusedinthecourseofprovidingtheServices.
II.10.7 TheContractor shall ensure that all and any necessary consents and/or licences for any
software, instrument, modality or methodology are obtained and in place before use for the
purposesofthisServiceContract(to includebutnotbelimitedtoensuringthattheContracting
Authority shall be vestedwith all necessary rights so as to enable theContractingAuthority to
![Page 20: DRAFT SERVICE CONTRACT€¦ · Arbitration by filing a written request with the Secretariat of the Milan Chamber of Arbitration. I.7.3 If for any reason the dispute remains unsettled](https://reader034.vdocuments.site/reader034/viewer/2022051918/600aec872d240126042f5166/html5/thumbnails/20.jpg)
Annex D - Draft Service Contract
Initialled by the Legal Representative for acceptance
__________________________________
20/30
enjoythebenefitoftheServicesforitsbusinesspurposes).TheContractorherebyindemnifiesthe
Contracting Authority and shall keep and hold the Contracting Authorityharmless from and in
respectofallandanyliability,loss,damages,claims,costs,orexpenseswhicharisebyreasonof
anybreachofthirdpartyIPRinsofarasanysuchrightsareusedforthepurposesofthisService
Contract.
II.10.8 At the option of the Contracting Authority for and in respect of any such breach, the
Contractorshallatitsexpenseandoption:
1. procurethenecessaryrightsfortheContractingAuthoritytocontinueuse;
2. replacetherelevantdeliverablewithanon-infringingequivalent;
3. replace the relevant deliverable to make it non-infringing while giving equivalent
performance;or
4. iftheContractorcannotobtaintheremediesin1),2)or3)above,itmaydirectthereturnof
thedeliverableandrefundtotheContractingAuthoritychargespaidforsuchdeliverable
lessareasonableamountfortheContractingAuthority‘suseofthedeliverableuptothe
time of return, provided such reasonable amount is due to the owner of the said
deliverable,TOGETHERwithalldirectlossestherebyaccruingtotheContractingAuthority
asaresultofthebreach.
II.10.9 Upon the terminationof this Service Contract forwhatever reason, the Contractor shall
immediatelydeliveruptotheContractingAuthorityall theMaterialsprepareduptothedateof
termination.AsanexceptiontoitsobligationsunderthisclausetheContractormayretainonecopy
of theMaterials, inpaper form, in theContractor’s legal files for thepurposeofandonly to the
extent necessary for ensuring compliance with its obligations under this Service Contract. The
provisionsofthisclausewillsurvivetheexpirationorterminationofthisServiceContractforany
reason.
ARTICLEII.11-FORCEMAJEURE
II.11.1 'Forcemajeure'meansanyunforeseeableandexceptional situationoreventbeyond the
parties' controlwhich prevents either of them from fulfilling any of their obligations under the
contract, which was not attributable to error or negligence on their part or on the part of
![Page 21: DRAFT SERVICE CONTRACT€¦ · Arbitration by filing a written request with the Secretariat of the Milan Chamber of Arbitration. I.7.3 If for any reason the dispute remains unsettled](https://reader034.vdocuments.site/reader034/viewer/2022051918/600aec872d240126042f5166/html5/thumbnails/21.jpg)
Annex D - Draft Service Contract
Initialled by the Legal Representative for acceptance
__________________________________
21/30
subcontractorsandwhichprovestobeinevitableinspiteofexercisingduediligence.Anydefault
ofaservice,defectinequipmentormaterialordelaysinmakingthemavailable,unlesstheystem
directly from a relevant case of force majeure, as well as labour disputes, strikes or financial
difficulties,cannotbeinvokedasforcemajeure.
II.11.2 Apartyfacedwithforcemajeureshallformallynotifytheotherpartywithoutdelay,stating
thenature,likelydurationandforeseeableeffects.
II.11.3Thepartyfacedwithforcemajeureshallnotbeheldinbreachofitscontractualobligations
ifithasbeenpreventedfromfulfillingthembyforcemajeure.Wherethecontractorisunableto
fulfil its contractual obligations owing to forcemajeure, it shall have the right to remuneration
onlyforthetasksactuallyexecuted.
II.11.4 Thepartiesshalltakeallthenecessarymeasurestolimitanydamageduetoforcemajeure.
ARTICLEII.12–LIQUIDATEDDAMAGES
Thecontractingauthoritymayimposeliquidateddamagesshouldthecontractorfailtocomplete
itscontractualobligations,alsowithregardtotherequiredqualitylevel,accordingtotheSpecial
TenderSpecifications.
Shouldthecontractorfailtoperformitscontractualobligationswithinthetime-limitssetbythe
contract, then, without prejudice to the contractor's actual or potential liability or to the
contracting authority's right to terminate the contract, the contracting authority may impose
liquidateddamagesforeachandeverycalendardayofdelay.
Thecontractormaysubmitargumentsagainstthisdecisionwithin30daysofreceiptoftheformal
notification. Intheabsenceofareactionon itspartorofwrittenwithdrawalbythecontracting
authoritywithin30daysof the receiptof sucharguments, thedecision imposing the liquidated
damagesshallbecomeenforceable.
Thepartiesexpresslyacknowledgeandagreethatanysumspayableunderthisarticleareinthe
nature of liquidated damages and not penalties, and represent a reasonable estimate of fair
compensationforthelossesincurredduetofailuretofulfilobligationswhichmaybereasonably
anticipated.
![Page 22: DRAFT SERVICE CONTRACT€¦ · Arbitration by filing a written request with the Secretariat of the Milan Chamber of Arbitration. I.7.3 If for any reason the dispute remains unsettled](https://reader034.vdocuments.site/reader034/viewer/2022051918/600aec872d240126042f5166/html5/thumbnails/22.jpg)
Annex D - Draft Service Contract
Initialled by the Legal Representative for acceptance
__________________________________
22/30
ARTICLEII.13–SUSPENSIONOFTHEPERFORMANCEOFTHECONTRACT
II.13.1Suspensionbythecontractor
Thecontractormaysuspendtheperformanceofthecontractoranypartthereofifacaseofforce
majeuremakessuchperformance impossibleorexcessivelydifficult.Thecontractorshall inform
thecontractingauthorityaboutthesuspensionwithoutdelay,givingallthenecessaryreasonsand
detailsandtheenvisageddateforresumingtheperformanceofthecontract.
Oncethecircumstancesallowresumingperformance,thecontractorshallinformthecontracting
authorityimmediately,unlessthecontractingauthorityhasalreadyterminatedthecontract.
II.13.2Suspensionbythecontractingauthority
Thecontractingauthoritymaysuspendtheperformanceofthecontractoranypartthereof:
(a) if the contract awardprocedureor theperformanceof the contractprove tohavebeen
subjecttosubstantialerrors,irregularitiesorfraud;
(b) inordertoverifywhetherpresumedsubstantialerrors,irregularitiesorfraudhaveactually
occurred.
Suspensionshall takeeffecton theday thecontractor receives formalnotification,orata later
dateprovidedinthenotification.Thecontractingauthorityshallgivenoticeassoonaspossibleto
thecontractortoresumetheservicesuspendedorinformthecontractorthatitisproceedingwith
the termination of the contract. The contractor shall not be entitled to claim compensation on
accountofsuspensionofthecontractorofpartthereof.
ARTICLEII.14-TERMINATIONOFTHECONTRACT
II.14.1Groundsfortermination
Notwithstanding any other term of this Contract, the Contracting Authoritymay terminate the
Contract,apurchaseorderorspecificcontractinthefollowingcircumstances:
a. if a change to the Contractor’s legal, financial, technical or organisational or ownership
situation is likely to affect the performance of the contract substantially or calls into
questionthedecisiontoawardthecontract;
![Page 23: DRAFT SERVICE CONTRACT€¦ · Arbitration by filing a written request with the Secretariat of the Milan Chamber of Arbitration. I.7.3 If for any reason the dispute remains unsettled](https://reader034.vdocuments.site/reader034/viewer/2022051918/600aec872d240126042f5166/html5/thumbnails/23.jpg)
Annex D - Draft Service Contract
Initialled by the Legal Representative for acceptance
__________________________________
23/30
b. iftheexecutionofthetasksofthecontractorapurchaseorderoraspecificcontracthas
not actually commenced within three months of the date foreseen, and the new date
proposed,ifany,isconsideredunacceptablebythecontractingauthority;
c. ifthecontractordoesnotperformthecontractorapurchaseorderorspecificcontractas
established in the Special Tender Specifications, the request for services, or fails to fulfil
anyothersubstantialcontractualobligation;
d. intheeventofforcemajeurenotifiedinaccordancewithArticleII.11oriftheperformance
ofthecontracthasbeensuspendedbythecontractorasaresultofforcemajeure,notified
inaccordancewithArticle II.11,whereeither resumingperformance is impossibleor the
modificationstothecontractmightcallintoquestionthedecisionawardingthecontractor
resultinunequaltreatmentoftenderers;
e. ifthecontractorisdeclaredbankrupt,isbeingwoundup,ishavingitsaffairsadministered
by the courts, has entered into an arrangementwith creditors, has suspended business
activities, is the subjectofproceedings concerning thosematters, or is in anyanalogous
situationarisingfromasimilarprocedureprovidedforinnationallegislationorregulations;
f. ifthecontractororanynaturalpersonwiththepowertorepresentitortakedecisionson
itsbehalfhasbeenfoundguiltyofprofessionalmisconductprovenbyanymeans;
g. ifthecontractorisnotincompliancewithitsobligationsrelatingtothepaymentofsocial
securitycontributionsor thepaymentof taxes inaccordancewiththe legalprovisionsof
thecountryinwhichitisestablishedorwiththoseofthecountryoftheapplicablelawof
thiscontractorthoseofthecountrywherethecontractistobeperformed;
h. if thecontractingauthorityhasevidence that thecontractorornaturalpersonswith the
powertorepresentitortakedecisionsonitsbehalfhavecommittedfraud,corruptionor
anyotherillegalactivitydetrimentaltothefinancialinterestsoftheEUI,orhasevidenceor
seriouslysuspectsthattheyareinvolvedinacriminalorganisationormoneylaundering;
i. if the Contracting Authority has evidence that the Contractor or natural persons with
power to represent or take decisions on its behalf have committed substantial errors,
irregularities or fraud in the award procedure or the performance of the Contract,
includingthecaseofsubmissionoffalseinformation;
![Page 24: DRAFT SERVICE CONTRACT€¦ · Arbitration by filing a written request with the Secretariat of the Milan Chamber of Arbitration. I.7.3 If for any reason the dispute remains unsettled](https://reader034.vdocuments.site/reader034/viewer/2022051918/600aec872d240126042f5166/html5/thumbnails/24.jpg)
Annex D - Draft Service Contract
Initialled by the Legal Representative for acceptance
__________________________________
24/30
j. iftheContractorisunable,throughitsownfault,toobtainanypermitorlicencerequired
fortheperformanceoftheContract,purchaseordersorspecificcontracts;
k. in the presence of serious misconduct by employees, duly reported in writing by the
contractingauthorityandwhich isnotpromptlyhandledby replacementofpersonnel in
question.
II.14.2Procedurefortermination
Where thecontractingauthority intends to terminate thecontract,apurchaseorderor specific
contract,itshallformallynotifythecontractorofitsintention,specifyingthegroundsthereof.The
Contracting Authority shall invite the Contractor tomake any observations and, in the case of
point II.14.1,pointc) to informthecontractingauthorityabout themeasures takentocontinue
thefulfilmentofitscontractualobligations,within30daysfromreceiptofthenotification.
IftheContractingAuthoritydoesnotconfirmacceptanceoftheseobservationsbygivingwritten
approval within 30 days of receipt, the termination procedure shall proceed. In any case of
termination, the contracting authority shall formally notify the contractor about its decision to
terminatethecontract.
In the cases referred to in points in letters a), b), c), e), g) and j) of Article II.14.1, the formal
notificationshallspecifythedateonwhichtheterminationtakeseffect.
Inthecasesreferredtoinpointsd),f),h)andi)andk)ofArticleII.14.1theterminationshalltake
effectonthedayfollowingthedateonwhichnotificationisreceivedbythecontractor.
II.14.3Effectsoftermination
In the event of termination, the Contractor shall waive any claim for consequential damages,
includingany lossofanticipatedprofits foruncompletedwork.On receiptof thenotificationof
termination, the Contractor shall take all the appropriatemeasures tominimise costs, prevent
damages,andcancelorreduceitscommitments.TheContractorshallhave60daysfromthedate
ofterminationtodrawupthedocumentsrequiredbythespecialconditionsforthetasksalready
executed on the date of termination and produce an invoice if necessary. The Contracting
Authoritymayrecoveranyamountspaidunderthecontract.
![Page 25: DRAFT SERVICE CONTRACT€¦ · Arbitration by filing a written request with the Secretariat of the Milan Chamber of Arbitration. I.7.3 If for any reason the dispute remains unsettled](https://reader034.vdocuments.site/reader034/viewer/2022051918/600aec872d240126042f5166/html5/thumbnails/25.jpg)
Annex D - Draft Service Contract
Initialled by the Legal Representative for acceptance
__________________________________
25/30
The Contracting Authority may claim compensation for any damage suffered in the event of
termination.
On termination the Contracting Authority may engage any other Contractor to execute or
completetheservices.TheContractingAuthorityshallbeentitledtoclaimfromtheContractorall
extracostsincurredinthisregard,withoutprejudicetoanyotherrightsorguaranteesitmayhave
undertheContract.
ARTICLEII.15-REPORTINGANDPAYMENTS
II.15.1Dateofpayment
PaymentsshallbedeemedtobeeffectedonthedatewhentheyaredebitedtotheContracting
Authority'saccount.
II.15.2Currency
Thecontractshallbeineuros.
Paymentsshallbeexecutedineuro(€)orinthelocalcurrency,ifthereceivingpartyhasitslegal
seatoutsideEuro-area.
II.15.3InvoicesandVAT
TheInstituteisateachingandresearchcentrewhichusesadecentralisedadministrativestructure
and which manages, in addition to the different internal projects, several activities which are
externallyfinancedbybothpublicandprivatesponsors.TheContractorundertakestofollowthe
analyticalinvoicingproceduresrequestedbytheInstitute,issuingondemandspecificinvoicesfor
eachcostcentre/activityidentified.
InvoicesshallshowtheidentificationdetailsoftheContractor,theamount,currencyanddate,as
wellasthereferencetotheContract,purchaseorderorspecificcontract.
TheEUIis,asarule,exemptfrompaymentofValueAddedTax(VAT)pursuanttoArt.151,para1
(b) and para 2 of Council Directive 2006/112/EC, as last amended by Council Directive
2009/162/UE.
This exemption applies to goods imported and services provided for the Institute’s official
activitiesforamountsexceeding€300.00(threehundred/00).
![Page 26: DRAFT SERVICE CONTRACT€¦ · Arbitration by filing a written request with the Secretariat of the Milan Chamber of Arbitration. I.7.3 If for any reason the dispute remains unsettled](https://reader034.vdocuments.site/reader034/viewer/2022051918/600aec872d240126042f5166/html5/thumbnails/26.jpg)
Annex D - Draft Service Contract
Initialled by the Legal Representative for acceptance
__________________________________
26/30
TheEUIisexemptfromcustomsdutiesanddirecttaxeswithinthetermsofArticles4and5ofthe
"ProtocolonthePrivilegesandImmunitiesoftheEuropeanUniversityInstitute".
TheContractorshallaccordinglycompletethenecessaryformalitieswiththerelevantauthorities
toensurethatsuppliesandservicesrequiredfortheperformanceofthecontractareexemptfrom
taxesandduties,includingVATexemption.
II.15.4 Suspensionofthetimeallowedforpayment
The contracting authority may suspend the payment periods at any time by notifying the
contractor that its invoice cannot be processed, either because it does not comply with the
provisionsofthecontract,orbecausetheappropriatedocumentshavenotbeenproduced.
The contracting authority shall inform the contractor inwriting as soonaspossibleof any such
suspension,givingthereasonsforit.
Suspensionshalltakeeffectonthedatethenotificationissentbythecontractingauthority.The
remaining payment period shall start to run again from the date on which the requested
informationorreviseddocumentsarereceivedorthenecessaryfurtherverification,includingon-
the-spotchecks,iscarriedout.Wherethesuspensionperiodexceedstwomonths,thecontractor
mayrequestthecontractingauthoritytojustifythecontinuedsuspension.
Wherethepaymentperiodshavebeensuspendedfollowingrejectionofadocumentandthenew
documentproducedisalsorejected,thecontractingauthorityreservestherighttoterminatethe
contractinaccordancewithArticleII.14.1(c).
II.15.5 Performanceguarantees
Performanceguaranteesshallcoverperformanceoftheserviceinaccordancewiththetermsset
outintheSpecialTenderSpecificationsuntilitsfinalacceptancebythecontractingauthority.The
amount of a performance guarantee shall not exceed the total price of the contract. The
guaranteeshallprovide that it remains in forceuntil finalacceptance.Thecontractingauthority
shallreleasetheguaranteewithinamonthfollowingthedateoffinalacceptance.
InaccordancewithArticleI.4,theperformanceguaranteeshallfulfilthefollowingconditions:
![Page 27: DRAFT SERVICE CONTRACT€¦ · Arbitration by filing a written request with the Secretariat of the Milan Chamber of Arbitration. I.7.3 If for any reason the dispute remains unsettled](https://reader034.vdocuments.site/reader034/viewer/2022051918/600aec872d240126042f5166/html5/thumbnails/27.jpg)
Annex D - Draft Service Contract
Initialled by the Legal Representative for acceptance
__________________________________
27/30
a. thefinancialguaranteeisprovidedbyabankoranapprovedfinancialinstitutionor,atthe
requestofthecontractorandagreementbythecontractingauthority,byathirdparty;
b. theguarantorstandsasfirst-callguarantoranddoesnotrequirethecontractingauthority
tohaverecourseagainsttheprincipaldebtor(thecontractor).
Thecostofprovidingsuchguaranteeshallbebornebythecontractor.
ARTICLEII.16-REIMBURSEMENTS
II.16.1Whereprovidedbythespecialconditionsorbythetenderspecifications,thecontracting
authorityshall reimbursetheexpenseswhicharedirectlyconnectedwithexecutionofthetasks
on production of original supporting documents, including receipts and used tickets, or failing
that,onproductionofcopiesorscannedoriginals,oronthebasisofflatrates.
II.16.2 Travelandsubsistenceexpensesshallbereimbursed,whereappropriate,onthebasisof
the shortest itinerary and the minimum number of nights necessary for overnight stay at the
destination.
II.16.3 Travelexpensesshallbereimbursedasfollows:
a. travelbyairshallbereimburseduptothemaximumcostofaneconomyclassticketat
thetimeofthereservation;
b. travelbyboatorrailshallbereimburseduptothemaximumcostofafirstclassticket;
c. travelbycarmustbeauthorisedbythecontractingauthorityandshallbereimbursed
onthebasisofakilometreallowance,currentlyfixedatEuro0,22perkilometre.Other
expenses(motorwaytolls,ferrycrossings,etc.)canalsobereimbursedonpresentation
ofthecorrespondingsupportingdocuments.
II.16.4 SubsistenceexpensesshallbereimburseduptoEuro175perdayasfollows:
d. for journeys of less than 80 km for a return trip, no subsistence allowance shall be
payable;
e. dailysubsistenceallowanceshallbepayableonlyonreceiptofsupportingdocuments
provingthatthepersonconcernedwaspresentatthedestination;
![Page 28: DRAFT SERVICE CONTRACT€¦ · Arbitration by filing a written request with the Secretariat of the Milan Chamber of Arbitration. I.7.3 If for any reason the dispute remains unsettled](https://reader034.vdocuments.site/reader034/viewer/2022051918/600aec872d240126042f5166/html5/thumbnails/28.jpg)
Annex D - Draft Service Contract
Initialled by the Legal Representative for acceptance
__________________________________
28/30
f. dailysubsistenceallowanceispaidasaflat-rateandisconsideredtocoverthehotelor
other related cost (if applicable), breakfast and the twomainmeals, local travel, the
costoftelecommunications,includingfaxandinternet,andallothersundries;
g. taxiexpensesarereimburseduptoamaximumof€70pervisit.
Parkingexpenses(airportsonly)arereimburseduptoamaximumof4dayspervisit.
All supporting documents (duly completed) must always be attached to the statement of
expenses.
II.16.6 Conversionbetweentheeuroandanothercurrencyshallbemademonthlyapplyingthe
marketratesforthepenultimatedayofthepreviousmonthquotedbytheEuropeanCentralBank
or,dependingonavailability,providedby thedelegationsorotherappropriate sourcesclose to
thatdate.
ARTICLEII.17–RECOVERY
II.17.1 Ifanamountistoberecoveredunderthetermsofthecontract,thecontractorshallrepay
thecontractingauthoritytheamountinquestionaccordingtothetermsandbythedatespecified
inthedebitnote.
II.17.2 Iftheobligationtopaytheamountdueisnothonouredbythedatesetbythecontracting
authorityinthedebitnote,theamountdueshallbearinterestattherateappliedbytheEuropean
Central Bank for its main refinancing operations in Euros (the reference rate) plus 3.5%. The
referencerateshallbetherateinforceonthefirstdayofthemonthinwhichthepaymentperiod
ends,aspublishedintheCseriesoftheOfficialJournaloftheEuropeanUnion.
Interestonlatepaymentsshallcovertheperiodfromthedayfollowingtheduedateforpayment,
uptoandincludingthedatewhenthecontractingauthorityreceivesfullpaymentoftheamount
owed.
Anypartialpaymentshallfirstbeenteredagainstchargesandinterestonlatepaymentandthen
againsttheprincipalamount.
![Page 29: DRAFT SERVICE CONTRACT€¦ · Arbitration by filing a written request with the Secretariat of the Milan Chamber of Arbitration. I.7.3 If for any reason the dispute remains unsettled](https://reader034.vdocuments.site/reader034/viewer/2022051918/600aec872d240126042f5166/html5/thumbnails/29.jpg)
Annex D - Draft Service Contract
Initialled by the Legal Representative for acceptance
__________________________________
29/30
II.17.3 If payment has not been made by the due date, the contracting authority may, after
informing the contractor in writing, recover the amounts due by offsetting them against any
amountsowedtothecontractorbytheInstitute.
ARTICLEII.18–CHECKSANDAUDITS
II.18.1 Thecontractingauthoritymaycheckorhaveanauditontheperformanceofthecontract.
Itmaybecarriedouteitherdirectlybyitsownstafforbyanyotheroutsidebodyauthorisedtodo
soonitsbehalf.
Such checks and auditsmay be initiated during the performance of the contract and during a
periodoffiveyearswhichstartsrunningfromthedateofthepaymentofthebalance.
Theauditprocedureshallbedeemedtobeinitiatedonthedateofreceiptoftherelevantletter
sentbythecontractingauthority.Auditsshallbecarriedoutonaconfidentialbasis.
II.18.2 The Contractor, during the lifetime of the Contract, shall or shall procure that its
subcontractors shall gather, compile, correlate, collect and otherwise maintain all relevant
accounts, records, books and other information in documentary form or on easily accessible
electronicmedia(“Records”),arisinginconnectionwiththeperformanceoftheContract.
The contractor shall keep all original documents stored on any appropriatemedium, including
digitisedoriginalswhentheyareauthorisedbynational lawandundertheconditions laiddown
therein,foraperiodoffiveyearswhichstartsrunningfromthedateofpaymentofthebalance.
II.18.3 The contractor shall allow the contracting authority's staff and outside personnel
authorised by the contracting authority the appropriate right of access to sites and premises
where the contract is performed and to all the information, including information in electronic
format,neededinordertoconductsuchchecksandaudits.Thecontractorshallensurethatthe
information is readily available at themoment of the check or audit and, if so requested, that
informationbehandedoverinanappropriateform.
II.18.4 Onthebasisofthefindingsmadeduringtheaudit,aprovisionalreportshallbedrawnup.
Itshallbesenttothecontractor,whichshallhave30daysfollowingthedateofreceipttosubmit
observations.Thefinalreportshallbesenttothecontractorwithin60daysfollowingtheexpiryof
thatdeadline.
![Page 30: DRAFT SERVICE CONTRACT€¦ · Arbitration by filing a written request with the Secretariat of the Milan Chamber of Arbitration. I.7.3 If for any reason the dispute remains unsettled](https://reader034.vdocuments.site/reader034/viewer/2022051918/600aec872d240126042f5166/html5/thumbnails/30.jpg)
Annex D - Draft Service Contract
Initialled by the Legal Representative for acceptance
__________________________________
30/30
On thebasisof the final audit findings, the contractingauthoritymay recoverallorpartof the
paymentsmadeandmaytakeanyothermeasurewhichitconsidersnecessary.