construction delay claims: proving and defending...
TRANSCRIPT
Presenting a live 90‐minute webinar with interactive Q&A
Construction Delay Claims: Construction Delay Claims: Proving and Defending DamagesLitigating Disputes Over Design Changes, Differing Site Conditions and Other Sources of Delay
T d ’ f l f
1pm Eastern | 12pm Central | 11am Mountain | 10am Pacific
TUESDAY, AUGUST 9, 2011
Today’s faculty features:
Robert A. Meynardie, Partner, Meynardie & Nanney, Raleigh, N.C.
Timothy L. Pierce, Partner, K&L Gates, Los Angeles
Stanley A. Martin, Partner, Duane Morris, Boston
The audio portion of the conference may be accessed via the telephone or by using your computer's speakers. Please refer to the instructions emailed to registrants for additional information. If you have any questions, please contact Customer Service at 1-800-926-7926 ext. 10.
Conference Materials
If you have not printed the conference materials for this program, please complete the following steps:
• Click on the + sign next to “Conference Materials” in the middle of the left-hand column on your screen hand column on your screen.
• Click on the tab labeled “Handouts” that appears, and there you will see a PDF of the slides for today's program.
• Double click on the PDF and a separate page will open. Double click on the PDF and a separate page will open.
• Print the slides by clicking on the printer icon.
Continuing Education Credits FOR LIVE EVENT ONLY
For CLE purposes, please let us know how many people are listening at your location by completing each of the following steps:
• Close the notification box
• In the chat box, type (1) your company name and (2) the number of attendees at your location
• Click the blue icon beside the box to send
Tips for Optimal Quality
S d Q litSound QualityIf you are listening via your computer speakers, please note that the quality of your sound will vary depending on the speed and quality of your internet connection.
If the sound quality is not satisfactory and you are listening via your computer speakers, you may listen via the phone: dial 1-866-871-8924 and enter your PIN when prompted Otherwise please send us a chat or e mail when prompted. Otherwise, please send us a chat or e-mail [email protected] immediately so we can address the problem.
If you dialed in and have any difficulties during the call, press *0 for assistance.
Viewing QualityTo maximize your screen, press the F11 key on your keyboard. To exit full screen, press the F11 key againpress the F11 key again.
C i D l Cl i Construction Delay Claims: Proving and Defending Damages
Bob MeynardieMeynardie & Nanney, PLLC333 Fayetteville Street Suite 500333 Fayetteville Street, Suite 500Raleigh, North Carolina 27601(919) 747‐7373bob@mnlaw‐nc.com
5
D l Delay AccelerationL f L b P d i i Loss of Labor Productivity Out of Season / Out of Sequence
Equipment or Material Price Escalation Equipment or Material Price Escalation
6
Site Access Site Access Unidentified Utilities and Utility Relocation Differing Site Conditions Governmental Approvals Payment Delays Inadequate/Inaccurate Designq / g Untimely Approval of Submittals Interference with M&M
O li d i d l Owner‐supplied equipment delays Scope Disputes Inspection Delaysp y
7
No delay should entitle the contractor to either an extension of the contract completion period an extension of the contract completion period or additional compensation unless the delay affects the critical path of the schedule.p
8
Must clearly define: The type of schedule required. The time for submission of original schedule and updates. Th l l f d il ( i ) i d The level of detail (time, resources, cost) required.
An enforcement mechanism to ensure periodic updates, construction that maintains the schedule and is built construction that maintains the schedule and is built according to the schedule.
Consistent with the requirements for a time extension.
9
Identification of all activities required to complete the project.Li ki h i i i id if h l i l Linking those activities to identify the logical and/or required sequence of activities and the logic connecting themlogic connecting them.
Computerized forward and backward passes through the activities to determine the longest through the activities to determine the longest sequence of activities.
10
D l f hi h th i k h t b ll t d t th Delays for which the risk has not been allocated to the contractor.
Acts of God Acts of God. Normal and Unusual Weather. Delays caused by omission or commission of the Delays caused by omission or commission of the Owner.
12
Under certain circumstances a contractor may be entitled to either excusable or compensable delay in entitled to either excusable or compensable delay in spite of a concurrent non‐excusable delay.
In the face of another delay, the contractor‐caused delay may be found to be a “pacing” delay. That is the contractor may have slowed production as a result of a known owner caused delay to avoid “hurry up result of a known owner‐caused delay to avoid hurry up and wait.”
15
Only delays that impact the critical path (by definition, these affect the end date of the entire project) are compensableproject) are compensable.
Delays to non‐critical path activities are not compensable.p
16
Technical definition: the difference between the early start yand the late start or the early finish and the late finish of an activity.L ’ d fi i i Th f i il bl Layman’s definition: The amount of excess time available to complete activities not on the critical path.
Bottom line: The amount of time by which an activity or a Bottom line: The amount of time by which an activity or a path of activities can be delayed without delaying the critical path of the whole project.
17
Consider a 30 day delay to a path that has 20 days of float. The delay consists of 10 days of contractor delay, 10 days of owner delay, and 10 days of excusable but noncompensable delay.delay.
Whether the contractor is entitled to an extension or an extension and compensation depends on which delay
f d d h doccurs first, second and third. The use of float is first come, first served.
18
Absent a contractual provision to the contrary, a contractor is entitled to complete the project in less p p jtime than allowed by the contract.
In this scenario, the contractor may be entitled to delay damages even where the project finishes early.
19
By definition, a cardinal change makes such a fundamental change in the scope of the work that fundamental change in the scope of the work that the contractor cannot be held to perform under the changes provisions of the contract.the changes provisions of the contract.
The question is a matter of degree and determination is subjective.j
Delays, when significant enough, can be cardinal changes.g
20
Cardinal change allows the contractor to recover Cardinal change allows the contractor to recover damages in excess of the contract measure. Reasonable value of the services.
Cardinal change may be considered a material breach by the Owner allowing the Contractor to terminate the contract.
21
Contact Information
B b M diBob MeynardieMeynardie & Nanney, PLLC
333 Fayetteville Street, Suite 500Raleigh, North Carolina 27601
(919) 747‐7373bob@mnlaw‐nc.com
22
C t ti D l Cl i P i dConstruction Delay Claims: Proving and Defending Damages
Timothy PiercePartner K&L Gates
Copyright © 2010 by K&L Gates LLP. All rights reserved.
A. Contractor Extended Site Overhead
1. State Claims Requires some form of schedule analysis Accounting for overhead costs Can only recover costs that are time related. Rent, utilities, personnel typically are time
related Is equipment on the job time related or task Is equipment on the job time related or task
specific? Insurance is typically not time related
24
A. Contractor Extended Site Overhead
2 Specific Issues on Federal Projects2. Specific Issues on Federal Projects
DCAA or OIG Audit generally required If over $100k, must be certified under
Contract Disputes Act and subject to False Claims ActClaims Act Must be approved at a settlement level Must exhaust administrative remedies prior p
to appeal CO Final Decision or Deemed Denial Full schedule and cost analysis
25
Full schedule and cost analysis
A. Contractor Extended Site Overhead
3 I t f N D f D l3. Impact of No Damage for Delay Clauses
Still viable in many jurisdictions Still viable in many jurisdictions Some states place limits on such clauses For example – Cal. Pub. Con. Code 7102For example Cal. Pub. Con. Code 7102
26
A. Contractor Extended Site Overhead
3. Impact of No Damage for Delay Clauses
Such clauses are generally strictly Such clauses are generally strictly construed. Typical exceptions courts apply:yp p pp y Delay not reasonably contemplated Bad faith, fraud, active interference or gross
negligence by the owner or its representativesnegligence by the owner or its representatives Unreasonable delay amounting to an
abandonment of the contract.
Labor inefficiency excluded by such
27
Labor inefficiency excluded by such clauses?
B. Contractor Labor Inefficiency
1 G l1. Generala. Proof Can Be Challenging
Proof is the challenge, making contemporaneous record keeping the key Measured Mile is the best if not only approach thatMeasured Mile is the best, if not only, approach that
will succeed; Comparing efficiency to the isometric may be required
MCAA Factors USACE CII Studies alone likely willMCAA Factors, USACE, CII Studies alone likely will not fly, but may be useful as a cross reference
“Sanity checking” results against cost report a must
Total cost approach nearly impossible
28
Total cost approach nearly impossible
C. Contractor Home Office Overhead
1 Home Office Overhead Eichleaya. Theory is “unabsorbed home office
overhead”
1. Home Office Overhead – Eichleay
Unearned profits on idle forces? Eichleay Corporation, ASBCA No. 5183, 60-2
BCA ¶2688 (1960), aff'd on recon., 61-1 BCA ¶2894 Recent case law restricting use of EichleayRecent case law restricting use of Eichleay Eichleay looks at the amount of overhead
covered by specific project and amount that is
29
not covered due to delays.
C. Contractor Home Office Overhead
1 Home Office Overhead Eichleaya. Federal Federal law is clear
1. Home Office Overhead – Eichleay
Federal law is clear Eichleay Corporation, ASBCA No. 5183, 60-2
BCA ¶2688 (1960), aff'd on recon., 61-1 BCA ¶ ( )¶2894 Recent Case law restricting use of Eichleay
b St tb. State Not much different – Maryland, Virginia,
Ohio Texas others follow Eichleay
30
Ohio, Texas, others follow Eichleay
D. Owner Damages1. Scope of Recoverable Damages
a. Direct Damages Site costs
CM d A/E t CM and A/E costs b. Home Office Costs
Recoverable if not direct? Recoverable if not direct? No equivalent Eichleay theory.
c. Liquidated Damagesq g Rather than actual damages?
d. Consequential Damages
31
The big unknown
E. Owner Liquidated Damages1. General
a. State and Federal Now in virtually all contracts Unenforceable if considered a penalty Only assessable on inexcusable,
contractor-caused delaycontractor-caused delay Will “no harm no foul” apply?
b. Are liquidated damages good for the owner and/or contractor.
32
F. Consequential Damage1. Basic Principles
a Statea. State Are limitations in contracts enforceable? Are consequential damages defined?Are consequential damages defined?
b. Federal No consequential damages Argue over what constitutes consequential
damagesP ti l S l ti t C ti lc. Practical Solutions to Consequential Damage Exposure Complete waiver
33
Co p ete a e Reasonable limitations
Construction Delay Claims:yProving and Defending Damages
Stan MartinTuesday, August 9, 2011
1:00-2:30 – Webinar
www.duanemorris.com
©2011 Duane Morris LLP. All Rights Reserved. Duane Morris is a registered service mark of Duane Morris LLP. Duane Morris – Firm and Affiliate Offices | New York | London | Singapore | Los Angeles | Chicago | Houston | Hanoi | Philadelphia | San Diego | San Francisco | Baltimore | Boston | Washington, D.C.
Las Vegas | Atlanta | Miami | Pittsburgh | Newark | Boca Raton | Wilmington | Cherry Hill | Princeton | Lake Tahoe | Ho Chi Minh City | Duane Morris LLP – A Delaware limited liability partnership
DM1/2764827
Best Practices to Minimize Construction Delay Claims – Contract Termsy
• Notice Be fair Avoid “forfeiture” clauses
Li id ti d l t• Liquidating delay costs Consider specifying per diem amount
• No damages for delay clause• No damages for delay clause Polarizing clause Per diem on general conditions is often acceptable
www.duanemorris.com
Or carve out owner-caused delay
35
Best Practices – Contract Terms
• Define nature of schedule info and data required Include periodic updates, plus updates in the event of a major
t hevent or change Schedule obligations should match the project size, scope and
complexity
• Define rights of the parties on schedule issues Identify allocation or use of float Identify whether owner can insist on acceleration in the event Identify whether owner can insist on acceleration in the event
of an otherwise excusable delay Specify contractor’s obligations for work-around if there is
contractor caused delay
www.duanemorris.com
contractor-caused delay
36
Best Practices – Claims Avoidance
• Communication is key• Team spirit really worksp y• Culture of problem-solving works• If you can’t avoid the claim:If you can t avoid the claim:
Be factual Support position with facts, including schedule updates Miti t d l Mitigate delays Keep an open mind
www.duanemorris.com37
Best Practices – Real-Time Claim Resolution
• Multi-step dispute resolution processp p p Project-level personnel given 48 hours Escalate to project-management level, for 48 hours Then escalate to upper management Then escalate to upper management Include next step if still no resolution (e.g., mediation)
• Claims don’t go away on their owng y Usually become more protracted Project personnel become wedded to positions Upper management sometimes does not hear the truth
www.duanemorris.com
Upper management sometimes does not hear the truth
38
Best Practices – Real-Time Claim Resolution (cont’d)( )
• Consider use of schedule expert/consultant for pinterim assessment
Shared by the parties?
• Bring all involved parties to the table e.g., subs, vendors, designers who played a role in the
delay eventsdelay events
• Make sure all associated aspects of the schedule claim are resolved, with no loose ends
www.duanemorris.com
claim are resolved, with no loose ends
39
Best Practices – Post-Project Dispute Resolution
• Direct negotiationg• Facilitated negotiation (mediation)• Joint expertJoint expert• Arbitration• LitigationLitigation
www.duanemorris.com40
Use of Schedule Experts
• Considerations:– In-house versus independent– Approach to schedule analysis
What schedule delay technique will the expert employ? (see slides 9 and 10)slides 9 and 10)
Is this technique consistent with administration of the schedule during the project?
Testif ing e perience req ired or not– Testifying experience required or not What is the overall strategy for resolution?
www.duanemorris.com41
Use of Schedule Experts (cont’d)
• Credibility arises out of the detail• Facts can’t be rearranged afterwards to suit the g
analytical approach• Reality checks are required• Conceding one’s own problems will buttress the
overall analysis
www.duanemorris.com42
Schedule Delay Methodologies
• As-planned versus as-built Simple, but fails to include causative factors.
• Impacted as-planned Assumes original logic was fine; fails to incorporate actual
eventsevents.
• Collapsed as-built Removes excusable delays in order to gauge actual
completion in absence of such delays; may fail to account for logic or other changes.
www.duanemorris.com43
Schedule Delay Methodologies (cont’d)
• Phase analysis (“windows” or “time slice”) Breaks project down into phases or “windows” and looks at
th i t f h ti R i t i fthe impact of each portion. Requires accurate info.
• As-built Often the only option if the original schedule was lacking in Often the only option if the original schedule was lacking in
substance or detail.
• Contemporaneous Considered to be most accurate, since logic changes and
other current factors are treated appropriately.
www.duanemorris.com44
Contact Information
Stan MartinDuane Morris LLP
Boston, MA857-488-4278
www.duanemorris.com45