tender document · 2019-06-01 · at stc building, rohini. contractor’s signature section –...
Post on 01-Mar-2020
1 Views
Preview:
TRANSCRIPT
`1
Civil, Interior-Furnishing & AC Works of PSB BO
at STC Building, Rohini. Contractor’s Signature
PUNJAB & SIND BANK
TENDER DOCUMENT
OF
CIVIL, INTERIOR-FURNISHING, ELECTRICAL &AIR-CONDITIONING
WORKS FOR BO at STC BUILDING, ROHINI, SEC-3, DELHI.
TECHNICAL BID
Architects M/s SPACE ACE
PLANNERS& INTERIOR DESIGNERS V-20A/05 DLF CITY-III, GURUGRAM,
HARYANA - 122002 TEL. PH. No. :- 0124-4106618
Email: spaceace.india@gmail.com
`2
Civil, Interior-Furnishing & AC Works of PSB BO
at STC Building, Rohini. Contractor’s Signature
SECTION- I: DETAILS OF TENDER
DETAILS OF TENDER
1. Details of work to
be done
Civil, Interior-Furnishing, Electrical & air-conditioning works for
B/O at STC Building Sec -3, Rohini, Delhi
2. Form of tender Limited tender from empanelled Interior Furnishers under ZO
Delhi-II
3. Approximate
estimate cost of
tender
Rs.16.65 lakhs.
4. Earnest Money
Deposit
Rs.33,300/- in the form of Demand draft in favour of Punjab &
Sind Bank payable at Delhi (to be enclosed in a separate cover).
EMD of the successful bidder shall be release on receipt of
Performance Guarantee.
5. Date of issue of
tender
01/06/2019
6. Last date of receipt
of tender
11/06/2019 at 11.00 a.m
Zonal Office - II
Punjab & Sind Bank,
B-38, 3rd
floor,
Naraina Industrial Area, Phase-I,
New Delhi-110028.
7. Date & Place of
Bid opening
11/06/2019 at 12.00 p.m
Zonal Office - II
Punjab & Sind Bank,
B-38, 3rd
floor,
Naraina Industrial Area, Phase-I,
New Delhi-110028.
8. Date of
commencement of
work
Within 3 days from the date of issue of LOI
9. Performance
Guarantee
The successful bidder is required to deposit an amount @5% of
total contract value as performance guarantee. This P.G shall be
released within 15 days from the date of virtual completion of
work.
Signature of contractor
with date and seal
`3
Civil, Interior-Furnishing & AC Works of PSB BO
at STC Building, Rohini. Contractor’s Signature
SECTION- II:SUMMARY OF SALIENT FEATURES 1. Type of Contract Item rate contract
2. Validity of offer 45 days from the last date of submission
of bid.
3. Earnest Money Deposit (Refundable)
Rs. 33,300/- by demand draft only drawn
in favor of the Punjab & Sind Bank
Payable at New Delhi in a Separate
Sealed Envelope.
EMD of the successful bidder shall be
release on receipt of the performance
security.
4. Date of commencement of work at site Within 3 days from the date of issue of
letter of Intent.
5. Performance Security
5% of the total contract value to be
submitted within 7 days from the date of
issue of letter of Intent.
Performance security shall be released
after payment of final bill/deduction of
security deposit.
6. Mobilization advance No mobilization advance will be paid.
7. Secured Advance against Material No Secured Advance against Material
shall be paid
8. Period of completion 15 days from the 3
rdday of issue of letter
of Intent.
9. Interim / Final Payments On final completion of work.
10. Retention Money 10% to be retained from each R/A bill.
11. Defect Liability period
12 months from the date of issue of
virtual Completion certificate by the
Architect.
12. Liquidated Damages
2% per week or part there of subject to
the max of 10% of accepted contract
price.
13. Language for communication English
14. Insurance, Custom Duties & taxes, work
contract tax, sales tax, GST
To be provided and paid by contractor
(price quoted to include all taxes)
15. Assignment &Subletting Not allowed
16. Rates of B.O.Q's items
To be quoted all inclusive and including
all taxes, charges, surcharges, cess etc.
i.e., net to the Bank.
17. Period of submitting final bill by
contractor
07 days from the date of virtual
completion
18. Labour Cess
1% of contract value will be deducted by
PSB as labor Cess payable to Delhi
Government.
19. Water and electricity charges
Electricity & water connection will be
provided by the bank at one point.
Contractor shall make his own
arrangements to supply it further.
20. Signing of Agreement Within three days of the issue of letter of
intent/work order.
`4
Civil, Interior-Furnishing & AC Works of PSB BO
at STC Building, Rohini. Contractor’s Signature
SECTION – III: NOTICE TO CONTRACTORS
Tender for Civil, Interior-Furnishing, Electrical &Air-conditioning works for B/O at
STC Building, Sec-3, Rohini, Delhi
1) Sealed item rates tenders are invited from Interior Furnishers empanelled under Bank’s
ZO Delhi –ii.
2) Tenders should be addressed to the Zonal Manager, Punjab and Sind Bank, Zonal
office Delhi-II, B-38, 3rd
floor, Naraina Industrial Area, Phase-I, New Delhi-110028.
3) The tenderers are required to submit their offer in sealed packets and super scribed as “
Civil, Interior-Furnishing, Electrical &Air-conditioning works for B/O at STC
Building, Sec-3, Rohini, Delhi”
4) All the pages of the tender document is required to be signed and stamped by the person
or persons submitting the tender in token of his/their having acquainted
himself/themselves with all the conditions/specifications, as laid down. Any tender with
any of the document not so signed may be rejected.
5) Clarification if any, may be obtained from the Bank or the Architect, M/s SPACE ACE,
V 20A/5, D.L.F. CITY III, GURUGRAM, HARYANA -122002 (Tel: 0124-4106618,
Email: spaceace.india@gmail.com) on any working day during from 10.00 a.m to 5.00
p.m.
6) The tender must obtain for himself on his own responsibility and at his own expenses all
the information which may be necessary for the purpose of filling this tender and for
entering into contract for the execution of the same and must examine the drawings and
inspect the site of the work acquaint himself with all local conditions and matters
pertaining thereto.
7) Any additions and alternations made filling the tender must be attested be initial of the
tenderer. Over-writing of figures is not permitted. Failure to comply with either of these
conditions will render the tender void. No request, advice or any change in rates or
conditions after submission of the tender will be entertained.
8) The tenderers shall deposit with PSB payable at Delhi Rs33,300/- by Demand Draft only
from any of the scheduled bank in favor of the PSB as the Earnest Money. The EMD of
the unsuccessful tenderers will be returned without any interest within 15 days, after a
decision is taken regarding the award of the Contract. Any tender not accompanied by
the requisite Earnest Money in Demand Draft will not be considered and shall stand
rejected. It may' be noted that conditional Tender may be liable to be rejected. The EMD
of the Tenderer shall be forfeited in the following circumstances:-
(i) the Tenderer withdraws his bid;
(ii) the tenderer either fails to start the work within a period of 3 calendar days or fails
to execute the agreement within 3 days after the receipt of letter of acceptance of
tender or the Letter of intent;
(iii) The Tenderer fails to supply goods / services as per the terms of the Tender and
Purchase / Work Order.
(iv) Any other justified reasons e.g. misleading or wrong information in the Bid,
violation of the terms and conditions of the Tender, involvement in forming ring /
cartel, submission of multiple bids in different names etc.
`5
Civil, Interior-Furnishing & AC Works of PSB BO
at STC Building, Rohini. Contractor’s Signature
9) EMD of successful tenderer(s) shall be refunded to the successful Tenderer on receipt of
Performance Security.
10) Within 3 (working) days of the receipt of intimation from the PSB of the acceptance of
his/their tender, the successful tenderers shall be bound to implement the Contract by
signing agreement in accordance with the terms and conditions of the contract attaching
herewith, but the work order or the written acceptance by the PSB of tender will
constitute a binding agreement between the PSB and the Contractors so tendering
whether such formal contract is or not subsequently entered into.
11) All compensations or other monies payable by the Contractor to PSB under the terms of
this contract may be deducted from the retention money or from any sum that may be or
may become due to the Contractor on any account whatsoever and in the event of the
retention money being reduced by reason of- any such deductions the Contractor shall
within 5 days of being asked to do so make good in cash or cheque any sum or sums
which have been deducted from his retention money.
12) In case, where the same item of work is mentioned at more than one place in the
Schedule of quantities the lowest of the rates quoted by the Contractor for the item shall
be taken for the payment of that item.
13) Time is the essence of the Contract. The work should be completed in 15 days to the
Contractor from 3rd
day of issue of letter of Intent to commence the work. Tenders shall
not claim any extension of time. However, the PSB to its sole discretion may
extend the time for completion of work.
14) The contractor fails to complete the work by the schedule date of completion or within
any sanctioned extended time, he will have to pay liquidated damages for the period that
work remains incomplete maximum up to 10% of the agreed sum of contract.
15) The quantities contained in the Schedule are only approximate. The work as actually
carried out and done will be measure up from time to time, for which payment will be
made subject to the terms and conditions of the Contract.
16) The Tenderers are advised to note that NO MOBILISATION ADVANCE shall be
released to the contractor for commencing the work.
17) Tender shall be valid for period of thirty days (30 days) from the last date of submission
of bid to the PSB. However, PSB is not bound to accept the lowest or any tender and
reserves the right to accept or reject any or all tenders either in whole or in part, without
assigning any reason for doing so. The along with their tender.
Zonal Manager
`6
Civil, Interior-Furnishing & AC Works of PSB BO
at STC Building, Rohini. Contractor’s Signature
SECTION IV - GENERAL CONDITIONS OF THE CONTRACT
DIRECTIONS REGARDING PROCEDURES
In construing these conditions, specifications and Contract Agreement, the following words
shall have the meaning here in assigned to them except where the subject or context
otherwise requires:
(a) "Bank" Shall mean Zonal office, Punjab & Sind Bank, Delhi-II, B-
38, 3rd floor, Naraina Industrial Area, Phase-I, New Delhi-
110028 and shall include his (their) legal representative/s
assign/s or authorized officer.
(b) "Contractor/Builder” Shall mean the individual or firm or company, whether
incorporated or not, undertaking the work and shall include
legal personal representatives of such individual or the persons
comprising such firm or company or the successors of such
individual or firm or company and the permitted assignee of
such individual or such individual or firm or company.
(c) "Architect" Shall mean SPACE ACE whose registered office is situated at
V-20 A/05, DLF Phase-III, Gurgaon, Haryana-122002. (and
shall include his authorized representative) or in the event of
his death or termination of his services by the Bank in his sole
and unqualified discretion, such other person/persons as shall
be provided always that no person subsequently appointed to
be Architect under this contract shall be entitled to disregard
or over rule any previous decision or direction given or
expressed by the Architect specified here in unless otherwise
approved by the Bank.
(d) “Contract” Means the documents forming the tender and acceptance
thereof and the formal agreement executed between the
competent authority on behalf of The Zonal Manager,
Punjab & Sind Bank, Zonal office Delhi-II, B-38, 3rd floor,
Naraina Industrial Area, Phase-I, New Delhi-110028and
the Contractor, together with the documents referred to there
in including these conditions, the specifications, designs,
drawings and instructions issued from time to time by the
Engineer-in-Charge and all these documents taken together,
shall be deemed to form one contract and shall be
complementary to one another.
`7
Civil, Interior-Furnishing & AC Works of PSB BO
at STC Building, Rohini. Contractor’s Signature
In the contract, the following expressions shall, unless the
context otherwise requires have the meanings, hereby
respectively assigned to them:
(i) The expression works or work shall, unless there be
something either in the subject or context repugnant to
such construction, be construed and taken to mean the
works by or by virtue of the contract contracted to be
executed whether temporary or permanent, and
whether original, altered, substituted or additional.
(ii) The site shall mean the land/or other places on, into or
through which work is to be executed under the
contract or any adjacent land, path or street through
which work is to be executed under the contract or any
adjacent land, path or street which may be allotted or
used for the purpose of carrying out the contract.
(iii) Schedule(s) referred to in these conditions shall mean
the relevant schedule(s).
(iv) Tendered Value means the value of the entire work as
stipulated in the letter of award of work.
1. GENERAL
The work shall be carried out strictly in accordance with the drawings amplified by the
specifications of materials and workmanship given hereunder. The drawings and
specifications shall be taken together and shall complement each other. In case of any
discrepancy, the following order of preference shall be followed:
(a) Particular Specifications.
(b) Drawings.
(c) CPWD Specifications & DSR 2016.
(d) National Building Code and Relevant IS Provisions.
In case there are no specifications for items shown on the drawings or where items are not
exhaustively described, the general specifications of CPWD shall be followed for which
nothing extra shall be paid. However the specification should be got approved from the
Architect before commencement of work.
2. DRAWINGS AND SPECIFICATIONS
(a) After signing the Contract, the contractor will be given free of charge three prints of all
working drawings. The contractor shall make at his own expense any additional copies
he requires. One copy of the drawing furnished to the contractor as aforesaid shall be
kept by the contractor at site and the same shall, at all reasonable times be available for
inspection and use by the Architect and his representatives any by any other person
authorized by him in writing.
`8
Civil, Interior-Furnishing & AC Works of PSB BO
at STC Building, Rohini. Contractor’s Signature
(b) Such further drawings and instructions including revisions, as the Architect may
furnish to the Contractor shall form part of this contract.
(c) Only figured dimensions and detailed drawings shall be followed. The Contractor
shall verify all dimensions in the field before any work is started and obtain
instructions of the Architect in case of any discrepancy.
(d) The Architect with approval of the The Zonal Manager, Zonal office Delhi-II, B-38,
3rd floor, Naraina Industrial Area, Phase-I, New Delhi-110028shall have power
and authority to supply to the Contractor from time to time during the progress of the
work, such further drawings and instructions as shall be necessary for the purpose of
proper and adequate execution and maintenance of work and the Contractor shall carry
out and be bound by the same.
3. ARCHITECTS STATUS AND DECISIONS
(a) Status:
The Architects shall have general supervision and direction of the work. He has
authority on behalf of the Bank to stop the work whenever such stoppage may be
necessary to ensure the proper execution of the work. The architect shall be the
interpreter of the conditions of contract and the judge of its performance.
(b) Decisions:
The Architect shall, within a reasonable time, make decisions on all claims of the
contractor and on all other matter relating to the execution & progress of the work or
the interpretation of the contract documents. The decisions, opinion or direction of the
Architects with respect to all or any of the following matters shall be referred to the
The Zonal Manager &PSB and decision so taken shall be final & binding to the
contractor.
1. Variation or modifications of the design.
2. The quality or quantity of works or the additions/alterations or omissions or
substitutions of any work.
3. Any discrepancy in the drawings or between the drawings and or specifications.
4. The removal and / or re-execution of any work by the contractor.
5. The dismissal from the work of any persons employed therein.
6. The opening up for inspection of any work covered up.
7. The amending the making good of any defects under defects liability period.
8. Approval of materials and workmanship.
9. The contractor to provide everything necessary for the proper execution of the
work.
(c) Dismissal:
The contractor shall on the report of the architects immediately dismiss from the works
within 24 hours any person employed by him for the above work, who may, in the opinion
of Architects be incompetent or misconducts himself and such person shall not be re-
employed on the works without the permission of the Architects.
`9
Civil, Interior-Furnishing & AC Works of PSB BO
at STC Building, Rohini. Contractor’s Signature
4. EXTENT OF CONTRACT
The contractor shall supply at his own cost all material implements, ladders, cordage, tackle,
scaffolding and temporary works required for the proper execution of the work whether
original, altered or substituted and whether included in the specifications or other documents
forming part of the contractor of the contract or referred to in these conditions or not and
which may be necessary for the purpose of satisfying of conditions he is entitled to be
satisfied which he is entitled to require together with carriage therefore to and from the
work. The contractor shall also supply survey instruments and other materials necessary for
the purpose of setting out works, and counting weighing and assisting to the measurement or
examinations at the any time and from time to time of the work material, failing his so doing
the same may be provided by the engineer-in-charge at the expense of the contractor and the
expenses may be deducted from any money due to the contractor under the contract from his
security deposit or the proceeds of sale thereof. The contractor shall also provide a sufficient
portion of fencing and lights required to protect the public from accident, and shall be bound
to bear the expenses of defense brought by any person for injury sustained owing to neglect
of the above precautions and to pay any damage and costs which may be awarded in any
such suit, action or proceedings to any such person or which may with the consent of the
contractor be paid to compromise any claim by any such person. In no case, the Bank shall
be a party to any such claim/claims and the contractor shall indemnify the Bank against any
claim for any person on this account.
5. ASSIGNMENT OR SUB LETTING OF CONTRACT
The contractor shall not assign the contract or any part thereof or any benefit or interest
therein or there under or any claim arising out of the contract to any other party without the
prior written consent of the Bank.
6. CONTRACTORS OFFICE AND STORES
All offices, sheds and stores required by the contractor shall be enacted at his own cost with
the prior approval of the Bank or its representative and shall be dismantled and removed
upon the completion of the work if so directed within 7 (seven) days of the issue of such
intimation.
7. DIRECTION FOR EXECUTION OF WORK
7.1 Setting outs
The contractor shall be responsible for the true and proper setting out of the works in
relation to the original points, lines and levels of reference given by the architect in writing
and for correctness subject as above mentioned of all the positions, levels dimensions and
alignments of all parts of the work and for the provision of all necessary instruments,
appliances and labor in connection therewith. If at any time during the progress of the work
any error shall appear or arises in any part of the work, the contractor on being required to
do so by The Zonal Manager, (PSB) shall at once inform the architect or their
`10
Civil, Interior-Furnishing & AC Works of PSB BO
at STC Building, Rohini. Contractor’s Signature
representatives. The checking of the work by the architect/representative shall not in any
way relieve the contractor from his responsibilities of carrying out the work as per the best
practices of construction.
7.2 Engagement of Labor
The contractor shall be solely responsible for the labor/ personnel employed and that the
personnel provided by the contractor shall and will not make any claim to become
employees of the Bank and that there will be no Employee and Bank relationship between
the personnel engaged by the Contractor and the Bank.
The contractor shall employ labor in sufficient numbers either directly or through
subcontractors, where such sub letting is permitted to maintain the required rate of specified
in the contract and to the satisfaction of the architect. The contractor shall not employ in
connection with the works any person who has not completed his fifteen years of age.
The contractor shall comply with the provisions of the payment of Wages Act, 1936;
Minimum Wages Act, 1948; Act, 1947; Maternity Benefit Act, 1961 and Mines Act, 1938,
Labor Contract (Regulations & Abolishing) Act or Rules, or any modifications thereof and
any other law relating thereto and rules made there under time to time.
The Contractor shall be fully responsible for timely monthly payment of wages and any
other dues to the personnel deployed by the Contractor. Further the Contractor shall solely
be responsible for having made the payments towards ESI and EPF amount (both Banks and
employee’s contribution) in the respective account of the worker for the period for which
bill is raised.
The contractor shall indemnify the Bank against any payment to be made under and for
observance of the Regulation aforesaid without prejudice to his right to claim indemnity
from his sub-contractors.
The contractor shall provide and maintain at his own expenses all rights, guards, fencing and
watching when and where necessary or required by the Resident Engineer for the protection
of the works or for the safety and convenience of those employed on works or the public.
7.3 Sampling
The contractor shall submit the samples of various materials for the approval of the
Architect &Bank. The contractor shall use the material only after the approval of the
Architect/ Bank. The verification of the material shall be done on random base during the
progress of the work in either the following manner:
(a) Random samples would be picked up during execution of work from site & if decided
by the Architect/ Bank, it would be sent to one of the approved laboratories for test &
quality check. The cost of such tests would be borne by the client.
(b) The Architect/Bank may direct the contractor to submit the challan of delivery of the
material brought at site. It would be on Random based. The Architect may also direct the
contractor to submit the copy of the test/verification certificate provided by the
manufacturer of that particular material.
`11
Civil, Interior-Furnishing & AC Works of PSB BO
at STC Building, Rohini. Contractor’s Signature
7.4 Inspection of work
All work under or in course of execution or executed in pursuance of the contract shall at all
times be open to inspection and supervision of the Architect or his representative and to the
personnel and the representatives of the Bank and the contractor shall at all times with
reasonable notice or the intention of the Architect or his representatives to visit work shall
have been given to the contractor, either himself be present to receive orders and
instructions, or have responsible agent duly accredited in writing present for that purpose.
Orders to the contractor's agent shall be deemed to have been given to the contractor
himself.
7.5 Suspension of Work
The contractor shall on the written order of the Architect/Bank suspend the progress of the
work or any part thereof for such time or time and in such a manner as the Architect/ Bank
may consider necessary and shall during such suspension properly protect and secure the
work as considered necessary in the opinion of the Architect/ Bankor their representative-in-
charge of the work. No compensation shall be payable to the contractor on what so ever
account for the suspension of work.
7.6 Extension of time for completion
Time is the essence of the contract. The owner and the contractor in consultation with the the
Architects shall agree upon the work progress chart. The chart shall be prepared in direct
relation to the time stated in the contract or the works order for completion of the individual
items thereof and/or the contract or works order as a whole. It shall indicate the forecast of
the dates of commencement and completion of the various trade processes or sections of the
work and shall be amended as may be required by agreement between the architects and the
Contractor within the limitations of time imposed in the contract.
If the works be delayed:
i.) By force majeure, or
ii.) By reasons of abnormally and bad weather
iii.) By reason of serious loss or damage by fire or
iv.) By reason of civil accommodation local combination of workmen or
strike or lockout effecting any of the trades employed on the work or
v.) By reason of delay on the part of contractor or trademen engaged by
the owner in executing works not forming part of the contract or
vi.) By reason of proceeding taken threatened by or dispute with adjoining
or neighboring owners or public authorities arising otherwise, than
through the Contractor’s own default, or
vii.) By reason of any other cause which in the absolute discretion of Owner is
beyond contractor’s control then in any such case the owner may make fair and
reasonable extension after obtaining Architect’s advice in the completion dates
of individual items or groups of items of work for which separate periods of
completion are mentioned in the contractor or works order as applicable.
`12
Civil, Interior-Furnishing & AC Works of PSB BO
at STC Building, Rohini. Contractor’s Signature
viii.) Upon the happening of any such event causing delay, the contractor shall
immediately give the notice thereof in writing to the architects with a copy to
Bank but shall nevertheless use constantly his best Endeavour to prevent or
make good the delay and shall do all that may reasonably be required to the
satisfaction of the Architect/Bank to proceed with the works Extension of time
shall be granted.
7.7 Defacement
If the contractor or his work people, or servants shall break, deface, injure, or destroy any
part of a building, or interiors, then the contractor has to rectify the same part at his own
expenses to the satisfaction of the Architect.
7.8 Approval of Materials
The contractor would bring samples of necessary materials as per the directions & would get
them approved prior to execution of work from Architect.
8. LIQUIDATED DAMAGES FOR DELAY
The times and date stipulated in the contract for the completion of the work or any part or
stage thereof shall be deemed to be the essence of the contract. The work shall, throughout
the stipulated period of the contract, be carried out with all diligence. If the contractor fails
to complete the work within the time prescribed or within the extended time under the
contract, he shall pay to the Bank on demand amount without prejudice to other rights and
remedies the Bank may have against the contractor, 2% of contract price per week or part
there of as liquidated damages for such fault, if the work remain unfinished after the
stipulated date of completion provided that the total liquidated damages payable shall not
exceed 10% of the accepted contract price. The Bank may, without prejudice to any other
method of recovery, deduct the amount of such damages from any money due or which
become due to the contractor. The recovery or deduction of such damages shall not relieve
the contractor from any obligations and liabilities under the contract.
9. DEFECTS LIABILITY PERIOD
The contractor shall be responsible to make good and remedy at his own expense within
such period as may be stipulated by the Bank any defect which may develop or may be
noticed before the expiry of 12 (twelve) calendar months from the date of completion and
intimation of which has been sent to the contractor within seven days of the expiry of the
said period.
10. SECURITY DEPOSIT
a) The Bank will, at the time of making any payment to the contractor for work
done or supply made under the contract deduct 10% of Gross value of each
bill.
b) All compensations or other sums of money payable by the contractor to the
Bank in terms of this contract may be deducted from, or paid by, the sale of a
`13
Civil, Interior-Furnishing & AC Works of PSB BO
at STC Building, Rohini. Contractor’s Signature
sufficient part of his security deposit, or from any sums which may become
due to the contractor by the Bank on any account whatsoever, and in the event
of his security deposit being reduced by reason of any such deduction or sale
as aforesaid, the contractor shall within ten days. Thereafter make good in
demand draft, endorsed in favor of the Bank as aforesaid any sum or sums
which may have been deducted from, or raised by sale of his security deposit
or any part thereof.
c) The above said security deposit shall be liable to forfeiture wholly or in part at
the sole discretion of the Architect if the contractor fails to carry out the work
or perform or observe any of the conditions of the contract.
d) No interest would be payable by the Bank to the contractor on the security held
in deposit.
11. BILL PAYMENT
a) Final bill supported with consolidated measurement of the full work executed
shall be submitted by the contractor within 07 days from the date of issue of
certificate of virtual completion.
b) Architect/Bank or his representative shall verify the requisite measurement for
the purpose of having the same verified for the claim as far as admissible
c) All measurements to be taken in duplicate and all bills shall be submitted in
triplicate along with a contractor’s copy of each.
d) When the final bill has been verified and corrected, the architect will give
seven days notice to the contractor to countersign the bill in token of
acceptance, the contractor shall countersign the bill within the above seven
days or intimate in writing his intention to dispute.
e) If the contractor fails to take appropriate action as above within the period
prescribed, the bill finalized by the architect or his representative shall be final
and binding on the contractor and the contractor shall have no right to dispute
the same.
12. CLAIM FOR INTEREST
No claim for interest will be entertained by the Bank with respect to any moneys
or balances which may be in its hands owing to a dispute between itself and the
contractor or with respect of any delay on the part of the Bank in making interim
or final payments or otherwise.
13. RATES FOR EXTRA ADDITIONAL, ALTERED OR SUBSTITUTED
WORK
The rates for additional, altered or substituted work shall be worked out in
accordance with the following provisions in their respective order.
i) If the rates for similar additional, altered or substituted work and directly
available in the contract for the work, the contractor is bound to carry out the
work at the same rates as are available in the contract for the work.
`14
Civil, Interior-Furnishing & AC Works of PSB BO
at STC Building, Rohini. Contractor’s Signature
ii) If the rates for additional, altered or substituted work are not directly
available in the contract for the work the rates will be derived from the rates
for a similar class of work as are specified in the contract for the work.
iii) If the rates for the altered, additional or substituted work cannot be
determined in the manner specified in sub-clause (i) to (ii) above, then the
contractor shall within three days of the date of receipt of order to carry out
the work, inform the Architect of the rate which it is intending to charge for
such works supported by analysis of the rate or rates claimed (CPWD
analysis). Rates finalized and approved by the Architect on the basis of these
details will be final and binding. However, the architect by notice in writing
will be at liberty to cancel his order to execute such work and arrange to carry
it out in such a manner as he may deem advisable, but under no circumstances
shall the contractor suspend the work once ordered in writing o n the plea of
non-settlement of rate.
iv) In case of furniture items, the minor changes I modifications in the design
shall not be considered as deviation, and no price adjustment shall be made
against the rates agreed to as per the Schedule of Quantities of t he contract.
For major change in the design of any item of the furniture, the deviation shall
be priced by the Architects as Extra, as per above however the decision of the
Architects whether the charge / modification in the design of furniture items is
minor or major, shall be final and binding on the contractor.
13.1REIMBURSEMENT OF VARIATION IN PRICE
Prices and rates quoted by the Tenderers shall be considered as firm for the
complete work and entire duration of the contract. No claim for extra payment due
to any rise in rates of raw material and labour or due to whatsoever reasons shall
be considered, not even for extended period of completion.
14. GUARANTEES
14.1 Quality of Work
The contractor shall guarantee that the materials and workmanship are the best of
their respective kinds for the service intended and that all items of work will be
free from all inherent defects in workmanship and materials. He shall also
guarantee that the works will not fail in any respect due to quality of materials,
workmanship and methods of construction.
The specifications assume a proper degree of skill on the part of contractor and
workmen employed. The contractor shall consult the Architect or his
representative, whenever in his judgment variation in the methods of construction
or in the quality of material would be beneficial or necessary to fulfill the
guarantee is called for. Such variations may be made by the contractor only when
authorized by the architect.
`15
Civil, Interior-Furnishing & AC Works of PSB BO
at STC Building, Rohini. Contractor’s Signature
14.2 Rejection
If during the “Period of Guarantee”, any work or material shall fail in any respect
to meet the above guarantee, the contractor shall replace such work or material in
a condition which will meet the above guarantee, immediately.
14.3 Cost of Execution of work or repair etc.
All work of repair shall be carried out by the contractor at his own expense if the
necessity thereof shall in the opinion of the Architect be due to the use of
materials or workmanship not in accordance with the contract or on account of
neglect or failure on the part of the contractor to comply with any obligation
expressed or complied on the contractor’s part under the contract.
14.4 Remedy on Contractor’s failure to carry out the work required
If the contractor shall fail to do any such work as aforesaid required by the
architect the Bank shall be entitled to carry out such work from/through other
person, at the contractor’s own cost. The Bank shall be entitled to recover from
the contractor the cost thereof or may deduct the same from any money due or that
may be come due to the contractor.
15. CERTIFICATE OF COMPLETION OF WORKS
On completion of the work, the Contractor shall be furnished with a certificate,
but no such certificate be given nor shall the work be considered to have been
completed until the contractor shall have removed from the area of the premises
(to be distinctly marked by the Architect) in the site plan which, the work shall be
executed) all scaffolding, surplus materials and rubbish and clean the dirt from all
wood work, doors, windows, walls, floors or other parts of any building, in or
upon which the work is to be executed, or of which he may have had in possession
for the purpose of the execution hereof. If the contractor shall fail to comply with
the requirements of the clause as to the removal of scaffolding, surplus materials
and rubbish and cleaning off dirt on or before the date fixed for the completion of
the work, the architect may at the expense of the contractor remove such
scaffolding, surplus materials, and the contractor shall forthwith pay th e amount
of all expense so incurred, and shall have no claim in respect of any such
scaffolding or surplus materials aforesaid, except for any sum actually realized by
the sale thereof.
16. TERMINATION OF THE CONTRACT
If at any time after the commencement of the work the Bank for any reason
whatsoever does not require the whole or part thereof as specified in the tender to
be carried out, the Bank shall have the right to terminate this Agreement and The
PSB shall communicate the termination by giving a notice in writing to the
contractor.
The contractor shall have no claim to any payment or compensation whatsoever on
account of any profit or advantage, which would have derived from the execution
`16
Civil, Interior-Furnishing & AC Works of PSB BO
at STC Building, Rohini. Contractor’s Signature
of the work in full, but which he did not derive in consequences the full amount of
the work not having been carried out.
The Contractor shall not have any claim or compensation by reason of any
alterations having been made in the original specification, or the designs and
instruction on which shall involve any containment of the work originally
contemplated. However, in case of part cancellation, the Contractor shall be paid
such amount as is commensurate to the actual work done by him till such
termination notice is received.
17. JURISDICTION
The contractor and its operation shall be governed by the law of India for the time
being in force, irrespective of the place of delivery of materials the place of
execution of work or place of payment under this contract shall be deemed to have
been entered into at New Delhi.
18. BYE LAWS OF LOCAL AUTHORITIES
The contractor shall conform to the provisions of all applicable Government Acts
which relate to works and to the regulations and bye laws of any local authorities.
The Contractor shall give all such notices required by the said Act or Laws, etc.,
and pay all fees payable to such authorities and allow for these contingencies in
his tendered rates including fees for encroachment, stacking charges, costs of
restorations, etc., and all other fees payable to the local authorities. The
Contractor shall keep the Bank indemnified against all penalties and liabilities for
every breach of any such Act, Rules, Regulations or Bye-laws.
Further the Contractor shall specifically ensure compliance of various Labor
Laws/Acts including but not limited to with the following and their re -
enactments/amendments/modifications while dealing with the employment of
labor such as:
a. The Payment of Wages Act, 1936
b. The Minimum Wages Act, 1938
c. The Workmen Compensation Act, 1923
d. The Contract Labor (Regulations & Abolishing) Act.
e. The Bank’s Liabilities Act, 1938
f. Industrial Dispute Act, 1938
g. Maternity Benefit Act, 1961
h. The Employees State Insurance Act, 1948
Safety code, labor welfare Act or rules or any modificat ion thereof any other laws
and regulations framed by the Competent Legislative Authorities from time to
time.
`17
Civil, Interior-Furnishing & AC Works of PSB BO
at STC Building, Rohini. Contractor’s Signature
19. LIASONING & CO- ORDINATION WITH LOCAL MUNICIPAL
AUTHORITIES
The contractor has to liason and takes any clearance from local authorities
like Delhi / other authorities for approval to start renovation and during
renovation of work including Defect Liability Period if needed. Only statuary
fees will be reimbursed by PSB.
`18
Civil, Interior-Furnishing & AC Works of PSB BO
at STC Building, Rohini. Contractor’s Signature
SECTION V– SPECIAL CONDITIONS OF THE CONTRACT
1. INSURANCE FOR WORKS
The contractor at the time of signing the contract or before commencing the
execution of work, without limiting his obligations and responsibilities shall
insure the works at his own cost and keep them insured until the virtual
completion of the contract against all acts of God including Fire, Theft, Riots,
War, Floods etc. with a Nationalized Insurance company in the joint names of the
Bank and the contractor (the name of the former being placed first in the policy)
for the full amount of the contract. Such policy shall cover the property of the
Bank and fees for assessing the claim and in connection with is services generally
therein and shall not cover any property of the Contractor or of any sub contractor
or employee.
The contractor shall deposit the policy and receipt for the premiums with the Bank
within seven (7) days, from the date of signing of the contract/commencement of
the execution of the work or unless otherwise instructed by the Bank. In default of
the contractor insuring as provided above, the Bank on his behalf may so insure
and may deduct the premiums paid from any moneys due on which may become
due to the contractor. The contractor shall as soon any claim under the policy is
settled on the work reinstated by the Insurance office should e lect to do so,
proceed with all due diligence with, the completion of the works in the same
manner as through the misfortune/accident had not occurred and in all respects
under the same conditions of the contract. The contractor in case of rebuilding or
reimbursement after accident shall be entitled to such extension of time for
completion, as the Bank deems fit.
2. INSURANCE IN RESPECT OF DAMAGE TO PERSONS AND
PROPERTY
a. The contractor shall be responsible for all injury to persons, animals or things
and for all structural and decorative damage to property which may arise from
the operation or neglect of himself or of any approved sub-contractor’s or
employees, whether such injury or damage arise from carelessness, accident or
any other cause whatsoever in any way connected with the carrying out of this
contract. The clause shall be held to include any damage to buildings, whether
immediately adjacent or otherwise, and any damage to roads, streets, foot
paths, bridges and works forming the subject of this cont ract by frost or other
inclemency of the weather. The contractor shall indemnify the Bank and hold
him harmless damage to persons or property as aforesaid and also respect of
any claims made in respect of injury or damage under any Acts of Government
or otherwise and also in respect of any award of compensation of damages
consequent upon such claims.
`19
Civil, Interior-Furnishing & AC Works of PSB BO
at STC Building, Rohini. Contractor’s Signature
b. The contractor shall reinstate all damages of every sort mentioned in this
clause, so as to deliver up the whole of the contract works complete and
perfect in every respect and so as to make good or otherwise satisfy all claims
for damage to the property of third parties.
c. The contractor shall indemnify the Bank against all claims which may be made
against the Bank by any member of the public or other third party in respect of
works in consequence thereof and shall at his own expense arrange to effect
and maintain, until the virtual completion of the contract, with any
Nationalized Insurance company in the joint name of the Bank and the
contractor against such risks and deposit such policy or policies with the Bank
from time to time during the currency of this contract. The contractor shall
similarly indemnify the Bank against all claims which may be made upon the
Bank whether under the Workman’s Compensation Act or any other statute in
force during the currency of this contract or at common law in respect of any
employee of the contractor or any sub-contractor and shall at his own expenses
effect and maintain with an approved office a policy of Insurance in the j oint
names of the Bank and the contractor against such risks and deposit such
policy of policies with the Bank and the contractor against such risks and
deposit such policy or policies with the Bank from time to time during the
currency of the contract. The contractor shall be responsible for anything
which may be excluded from the insurance policies above referred to and also
for all other damages to any property arising out of and incidental to the
negligent or defective carrying out of this contract. He shall also indemnify the
Bank in respect of any costs, charges or expenses arising out of any claim or
proceedings and also in respect of any award of or compensation of damages
arising there from.
d. The Bank shall be at liberty and is empowered to deduct the amount of any
damages, compensation costs, charges and expenses arising or occurring from
or in respect of any such claim or damage from any sum or sums due to or
become due to the contractor including the security deposit.
e. If the contractor fails to comply with the terms of these conditions, the Bank
may insure the works and may deduct the amount of the premiums paid from
any moneys that may be or become payable to the contractor or may at the
option, not release running payment to the contractor until the contractor shall
have complied with the terms of this condition.
f. Such insurance whether affected by the Bank or the contractor will not limit or
bar the liability and obligation of the contractor to deliver the works to the
Bank completed in all respects according to the contract. In case of loss or
damage due to any of the aforesaid clause, the moneys payable under any such
insurance shall be received and retained by the Bank until the works are finally
completed and such moneys shall then be credited to the contractor in final
settlement of accounts.
`20
Civil, Interior-Furnishing & AC Works of PSB BO
at STC Building, Rohini. Contractor’s Signature
g. The works shall be executed in close co-ordination with the progress of other work. This
being absence of the contract, no claim for idles labor will be entertained.
3. TYPOGRAPHIC OR CLERICAL ERRORS:
The Architect’s/Engineer-in-Charge's clarifications regarding partially omitted particulars or
typographical or clerical errors shall be final and binding on the Contractor.
4. SCOPE OF CONTRACT:
The Contractor shall carry out and complete the said furnishing works comprising of
wooden partition, paneling false ceiling including miscellaneous, electrical works and
modification / addition to existing provision. Provision and Furniture, furnishing etc.
complete in every respect in accordance with Contract and with the directions of and to the
satisfaction of the Architects and the Bank. The Architects may in their absolute discretion
and from time to time, issue further drawings and/or written instructions, details, directions
and explanations which are hereafter collectively referred to as "Architect's Instructions" in
regard to:
a. The variations or modifications of the design quality or quantity of works or the
addition or omission or substitute of any work.
b. Any discrepancy in the drawings or between the Schedule of Quantities and/or
drawings and/or Specifications.
c. The removal and / or re-execution or any works executed by the Contractor.
d. The removal from the site of any material brought there on by the contractor and the
e. Substitution of any other material there from.
f. The dismissal from the works of any person / persons employed thereupon.
g. The opening up for inspection of any work covered up.
h. The amending and making good of any defects under clause "Removal of Improper
Work and Material".
The Contractor shall forthwith comply and fully execute any work comprised in such
Architect's Instructions provided always that verbal instruction. Directions and explanations
given to the Contractor or his representative upon the works by the Architects shall, if
involving a variation, be confirmed in writing by the Contractor within 3 days and if not
dissented from in writing within further 3 days by the Architect. Such shall be deemed to be
the Architect's instructions within the scope of the contract.
If compliance with the Architect's instructions as aforesaid involved work and/or expense
and/or loss beyond that contemplated by the Contract. Then unless the same were issued
owing to some breach of this contract by the Contractors. The Bank shall pay to the
Contractor on the Architect's Certificate, the price of the said work (as an extra to be valued
as herein after provided) and/or expense and/or loss.
5. SCHEDULE OF QUANTITIES:
The Schedule of Quantities unless otherwise stated shall be deemed to have been prepared in
accordance with the method of measurements specified in the particular specifications and
`21
Civil, Interior-Furnishing & AC Works of PSB BO
at STC Building, Rohini. Contractor’s Signature
shall be considered to be approximate. The Bank does not undertake to carry out the whole
of work as shown in the drawings and taken in the schedule of quantities and reserves the
right to modify the same or any part thereof. The Contractor shall not be allowed any
compensations or damages for the work so omitted or cancelled by the Bank. Each tender
item should be filled in with the rates and amounts in separate columns and all the sections
should be totalled up in order to show the aggregate value of the entire tender. The rates
should be filled both in figures and words for each item and in case of discrepancy the rates
filled in words shall be considered as correct for the evaluation of tender amount. The
initials of the tenderers shall duly attest all corrections in the tender Schedule. Corrections,
which are not attested, may entail the rejection of tender.
`22
Civil, Interior-Furnishing & AC Works of PSB BO
at STC Building, Rohini. Contractor’s Signature
LIST OF APPROVED MATERIALS:
Material
Approved Make/Brand
CIVIL INTERIOR WORKS
Laminated sheet (1.0 mm thick) Premium
Formica /Greenlam / Merino /
Archidply
Comm. Board /Flush door shutter Duro/ century / Green / Archidply
Commercial Ply wood Duro/ century / Green / Archidply
MR grade ply Conforming to IS 303 Duro/ century / Green / Archidply
Marine grade Ply wood Conforming IS 710 Greenply /Duro /Century / Archidply
BWP grade Block Board /ply Duro / Merino /Century / Archidply
Melamine /PU Finish MRF/Asian Paints /Nerolac
Ceramic Tiles/vitrified homogeneous glazed tiles.
Kajaria/Nitco / HR Johnson / Somany /
Marbonite
Glazing (Clear) St. Gobain / Indo Asahi /Modi float / Glaverbel
HYDRAULIC DOOR CLOSER DORMA/ DOORSET
FLOOR SPRING, FRAMELESS GLASS
FITTINGS, HANDLES
DORMA / TRIUM / KICH
Glue Fevicol
Paints/Distemper/Arcylic/Enamel/Plastic paint Asian / Shalimar / ICI / Nerolac / Berger
Door locks Godrej,goldenlocks,dorset
Door closer Dorma /Dorset
Anti termite/fire retardant paint Viper FirestarFr – 881 paint
GREY CEMENT (OPC) ACC/ L&T
WHITE CEMENT JK/ BIRLA
ELECTRICAL WORKS
Distribution Boards withMiniature Circuit
Breakers, ELCB
Legrand, Schneider, Hagger
CableTray/ Raceway CTM Engineers, KME, MEM
Telephone Cable Delton, KEI, Polycab
Co-axial cable for TV KEI, D Link, Polycab
Telephone Tag Block Krone, TVS R&M
M.S. Conduit BEC, RMCON, AKG
PVC Conduit BEC, AKG, Polycab
Modular Switches & Sockets CrabtreeAthena, MK WraproundPlus,
ScheniderOpale
LV System Wire (Cat 6) Amp, Systemax
Telephone/ DataOutlet Amp, Systemax
Exhaust Fan / Wall Fan
GEC, Crompton, Orient
`23
Civil, Interior-Furnishing & AC Works of PSB BO
at STC Building, Rohini. Contractor’s Signature
AC WORKS
Copper Pipe Mandev Tubes/ Merchant/ Met Tube
wall mounted automatic stabilizer bluebird/ logictech/ carrier/ micel
Power Cables Phenolex/Kalinga
Control Cable Phenolex / Kalinga
CONDUIT for Elect. Wires AKG / Marshal / Plaza
Voltmeter / Ammeter A. E. / IMP
Overload Relays LT / LK / Siemens / BCH./GE
Time Delay Device Siemens / LT / LK / Concord
Single phase Preventer LT/LK/Minilec/GE
Paints ICI / Asian / Johnson & Nicholson
M.C.B. MDS/L&T / Indo Kopp/Standard
`24
Civil, Interior-Furnishing & AC Works of PSB BO
at STC Building, Rohini. Contractor’s Signature
DRAWINGS
`25
Civil, Interior-Furnishing & AC Works of PSB BO
at STC Building, Rohini. Contractor’s Signature
`26
Civil, Interior-Furnishing & AC Works of PSB BO
at STC Building, Rohini. Contractor’s Signature
`27
Civil, Interior-Furnishing & AC Works of PSB BO
at STC Building, Rohini. Contractor’s Signature
`28
Civil, Interior-Furnishing & AC Works of PSB BO
at STC Building, Rohini. Contractor’s Signature
`29
Civil, Interior-Furnishing & AC Works of PSB BO
at STC Building, Rohini. Contractor’s Signature
`30
Civil, Interior-Furnishing & AC Works of PSB BO
at STC Building, Rohini. Contractor’s Signature
`31
Civil, Interior-Furnishing & AC Works of PSB BO
at STC Building, Rohini. Contractor’s Signature
PUNJAB & SIND BANK
TENDER DOCUMENT
OF
CIVIL, INTERIOR-FURNISHING, ELECTRICAL &AIR-CONDITIONING
WORKS FOR BO at STC BUILDING, ROHINI, SEC-3, DELHI.
FINANCIAL BID
Architects M/s SPACE ACE
PLANNERS& INTERIOR DESIGNERS V-20A/05 DLF CITY-III, GURUGRAM,
HARYANA - 122002 TEL. PH. No. :- 0124-4106618
Email: spaceace.india@gmail.com
32
S. No. Description Unit Qty. Rate Amount
I
1.0 CIVIL WORKS
1.1 BRICK WORK
A Half brick masonry with common burnt clay F.P.S. (non modular) bricks of
class designation 7.5 in superstructure above plinth level up to floor V
level.
Cement mortar 1:3 (1 cement :3 coarse sand) Sqm 15
1.2 PLASTERPlastering of walls in 12mm th. smooth cement plaster on existing block masonary,
RCC columns, RCC Walls, of any profile, in 1:4 cement mortar, (1unit- cement, 4unit-
fine screened sand), incl. of hacking on column/wall, making surface wet before
applying plaster and proper curing after plaster etc complete. all plaster works will
have provision of chicken mesh with more than 2" overlap between RCC member
and wall so as to avoid cracks due to thermal expansion, chicken mesh to be also
provided on all chased surfaces such as ,conduit chasing , pipe line chasing etc. and
then chased area to be replastered . Cost to be inclusive of all including scafolding at
all heights .
Sqm 25
1.3 P.C.CProviding and laying plain cement concrete 1:2:4 mix (1 cement :2 coarse sand :4
hard stone aggregate 20 mm nominal size) under floors. For raceways, electrical
conduits in floors etc. over existing R.C.C Slab, necessary shuttering, curing,
compacting, etc Complete & all to be included in cost & quoted rate shall for all levels
of floor & height.
Cum 5.00
For raceways, electrical conduits in floors etc.
Total to be carried over the summary
2 FALSE CEILING WORKS
Note: Quoted Rates are for all heights , scaffolding, depths, levels, leads and lifts and
for all design and pattern shown in drawings
Contractor to include the cost of members & all required accessories for
installation compelet finished ceiling in his quoted rate
Actual finished area to be measured and paid for
Vendor Shall submit & get approved all type of board/Tiles /plank sample by
Architect before execution.
FINANCIAL BID FOR INTERIOR-FURNISHING, ELECTRICAL & AIR-CONDITIONING WORKS FOR PUNJAB & SIND BANK
BO at STC BUILDING, ROHINI, SEC-3 NEW DELHI.
BOQ - Civil, Interior-Furnishing, Electrical AC Works of BO at STC Building, Sec-3, Rohini. Contractor's Signature
33 S. No. Description Unit Qty. Rate Amount
2.1 Modular Grid Ceiling
Providing and Fixing of false ceilings at all heights of 600mm x 600mm Grid
ceiling tiles with Microlook Edge laid on prelude XL exposed silouette grid
systems with 15mm wide T- section flanges colour white. The framework
comprise of main runner spaced at 1200mm centers securely fixed to the
structural soffit by approved hangers at 1200mm maximum centers. Hangers
(GI wire of 4.0mm dia) to be fixed by approved roof plug/ fastener, level
adjusters and screws etc. The last hanger at the end of each main runner
should not be greater than 450mm from the adjacent wall. Flush fitting
1200mm long cross tees (with double stitching) to be interlocked between
main runners at 600mm centers to form 1200 x 600 modules. Cut cross tees
longer than 600mm to be supported independently.
600mm x 600mm modules to be formed by fitting 600mm long flush fitting
corss tees centrally between the 1200mm cross tees. Perimeter trim to be
Armstrong wall angle secured to walls at 450mm maximum centrers. The
quoted rate shall be inclusive for making opening for light fixtures, diffusers &
AC fittings. The quoted rate shall be inclusive of suspenders at all heihgt &
extra member required for all openings. (Basic rate of only ceiling tile Rs
800/- per Sqm. including taxes)(Contractor to include the cost of
members & all other accessories mentioned above in his quoted rate)
ARMSTRONG silhouette grid system of size 600x600 Sqm 68
2.2 Gypsum False ceiling
Providing and fixing false ceiling at all height including providing and fixing of frame
work made of special sections, power pressed from M.S. sheets and galvanized with zinc
coating of 120 gms/sqm (both side inclusive) as per IS : 277 and consisting of angle cleats
of size 25 mm wide x 1.6 mm thick with flanges of 27 mm and 37mm, at 1200 mm centre
to centre, one flange fixed to the ceiling with dash fastener 12.5 mm dia x 50mm long
with 6mm dia bolts, other flange of cleat fixed to the angle hangers of 25x10x0.50 mm of
required length with nuts & bolts of required size and other end of angle hanger fixed with
intermediate G.I. channels 45x15x0.9 mm running at the spacing of 1200 mm centre to
centre, to which the ceiling section 0.5 mm thick bottom wedge of 80 mm with tapered
flanges of 26 mm each having lips of 10.5 mm, at 450 mm centre to centre, shall be fixed
in a direction perpendicular to G.I. intermediate channel with connecting clips made out
of 2.64 mm dia x 230 mm long G.I. wire at every junction, including fixing perimeter
channels 0.5 mm thick 27 mm high having flanges of 20 mm and 30 mm long, the
perimeter of ceiling fixed to wall/partition with the help of rawl plugs at 450 mm centre,
with 25mm long dry wall screws @230 mm interval, including fixing of gypsum board to
ceiling section and perimeter channel with the help of dry wall screws of size 3.5 x 25 mm
at 230 mm c/c, including jointing and finishing to a flush finish of tapered and square
edges of the board with recomme-nded jointing compound, jointing tapes, finishing with
jointing compound in 3 layers covering upto 150 mm on both sides of joint and two coats
of primer suitable for board, all as per manufacturer’s specification and also including the
cost of making openings for light fittings, grills, diffusers, cutouts made with frame of
perimeter channels suitably fixed, all complete as per drawings, specification and
direction of the Engineer in Charge including the cost of making trap door made of 12
mm thick prelaminated partical board resting/ fixed including all hardware, hard wood
lipping etc. complete as per drawing : Knuff Size: 600x600
a 12.5 mm thick tapered edge gypsum fire resistant board
conforming to IS: 2095- Part I
sqm. 76.0
Total to be carried over the summary
BOQ - Civil, Interior-Furnishing, Electrical AC Works of BO at STC Building, Sec-3, Rohini. Contractor's Signature
34 S. No. Description Unit Qty. Rate Amount
3.0 FLOORING / CLADDING WORKS
Note: (Quoted Rates are for all heights, depths, levels, leads and lifts and for all design and
pattern shown in drawings)
Note: Actual finished area to be measured and paid for.
Note :- Vendor Shall submit & get approved all type of stone/Tiles sample by
Architect before execution.
Make Vitrified Tiles: Kajaria / Somany / Johnson / Nitco
3.1 Tile Flooring
Providing and laying 10-12mm thick Vitrified tiles of Kajaria / Somany / Johnson /
Nitco make of approved shade of size as per drawing in floors over 20mm (average)
base of cement mortar 1:4 ( 1 cement :4 coarse sand) required thickness to match
finished floor level mentioned and to match the neighboring floor finish and jointed
with epoxy grout of approved shade from Bal Endure or equivalent brand all complete
as directed complete. Rate to include forming pattern in the flooring like border,
skirting, cut tiles, Protecting of the tile till hand over date by POP., etc all complete as
per detailed architectural drawing.
a same as above With Vitrified Tiles of Base rate of Vitrified tiles Rs. 800/- per
Sqm. leaving taxes and freight and loading un loading charges )
sqm. 136.00
Total to be carried over the summary
4.0 DOOR / WINDOW WORKS
Note: Providing and fixing phenol bonded solid core flush door shutters of approved quality
and make non decorative type core of block board construction with internal frame of
red marandi wood.
Door Frame: Made overall size 60 x 150 mm finished with polish finish as shown in
drawing . Note:- for partition frame size - 50 x 100 or as per partitions width.
Architraves of overall size 40 x 12 mm fixed to wooden frame both side as shown in
drawing.
Including providing & fixing of all hardware & accessaries, hinges, door handle,
door closer, door stopper, lock, tower bolt, door buffer, making of grooves, providing
& applying wood preservative, antitermite proof paint, polish, screws, nails,
wooden studs, wooden beading, all necessary fixing arrangement etc complete as per
design and drawing. all hardware to be dorma/Hettich or equivalant Make
Make for Doors & Fittings
Hardware/Locks: Dorma XLC, Kitch, Geze, Hettich, Dorset, Halflae
Hardware: Dorset, Ingersoll Rand, Hettich, Kitch,
Door Closers : Dorma
Door Locks: DORSET,Golden
Door Seals: Enviroseals
4.1 Laminate Doors : Same as above Description with 30-35 mm thick shutter finish with
1 mm thick laminate (Forica, Merino, Durian, Green Lam) in both side of the shutter
of approved make & shade and edge polishing / enamel painting, including
200x1800mm vision panel made of 6mm thick non toughened clear Glass with
wooden frame duly polished on each shutter complete with all necessary fixing
arrangement complete as per shown in drawing and directed by the Architect.
Flush Doors: Merino, Green ply industries, Century, Sonear, Alpro, Durian
Each door to have 4 Nos of 6" railway barring hinges in SS finish
door shall be with the dorma heavy duty door closer code no ITS96GSR with
necessary tower bolts and pivots
Doors to have cylindrical locks
Door to have 400mm long 30mm dia SS buff finish handles on both sides. etc all
complete as per detailed architectural drawing.
a Item same as above but with overall size of shutter is 750 to 900 x 2100mm with or
without vision panel (as per requirement).
Each 2
BOQ - Civil, Interior-Furnishing, Electrical AC Works of BO at STC Building, Sec-3, Rohini. Contractor's Signature
35 S. No. Description Unit Qty. Rate Amount
4.2 GLASS DOORS
Providing and fixing Single/Double leaf frameless glass door made of 12 mm thick
toughened glass including floor spring, patch fittings, SS top pivot, door handle,
lock of approved make (sample approved by the Architect/ Client) and all necessary
hardwares and fixing arrangement complete as shown in drawing and directed by the
Architect. make of Fitting as approved: Kich/Ozone/Neki/Dorma. & Glass Make :
Modiguard/Asahi float/ Saint-Gobain/Asahi India
sq.m. 8
with cylinderical locks and kitch handles both sides 30mm dia and 600mm long in
buffed SS 304 finish.
Total to be carried over the summary
5.0 PARTITION/PANELLING WORKS
5.1 Providing and fixing G.I Frame for Partitions consisting of G.I vertical studs of size
50mm & horizontal members @ 600 x 600 or where ever required as per
manufacturer, specs, using Gypsteel sections, hardwood will be inserted as may be
required to fix door frames skirting etc. with all necessary fixing arrangement
complete as per shown in drawing and directed by the Architect. Quote only for
framework. All components to be of India Gypsum or LA gyp (la farge)
The cost to be included of 50 mm thick 24 kg/m3 density glass wool insulation inside
the partition frame work including jointing and finishing. and To facilitate the skriting
bottom channel to be cladded with 6mm marine plywood on both sides resist by 5-
10mm groove on both sides. includning Providing and fixing of prefabricated
alumnium skirting as per product details, 50-75mm high of jeb/bottomline or
equivalant make. all inclusive as per architects instruction.
a FRAME WORK FOR FULL HEIGHT PARITION: Frame work of Partition in
G.I
sqm 60.00
b FRAME WORK FOR WALL PANELLING WORKS: Frame work of Partition
in G.I consisting of G.I vertical studs of size 50mm & horizontal members @ 900 x
900 or where ever required as per manufacturer, specs, using Gypsteel sections,
hardwood will be inserted as may be required to fix door frames skirting etc. with all
necessary fixing arrangement complete as per shown in drawing and directed by the
Architect. Quote only for framework. All components to be of India Gypsum or LA
gyp (la farge)
sqm 72.00
5.2 Providing and applying the claddings on the G.I framework erected for Solid
partitions.
Cladding under this section shall be considered to be applied only to one side.
Cost for fixing plywood/ MDF etc. and fixing/cladding laminate/ veneer to be quoted
as per case. Each side of the partition finishes will be measured as per the case.
Contractor to make provision for all electrical/ networking boxes and to provide
30mm dia cut-outs as required. Electrical/ Network boxes/ other services to be
provided at desired height and location as indicated in the drawing or as instructed at
site.
All junctions between materials, columns, walls, etc to have a 6mm groove with
Aluminium `L'/ 'U' sections as per details. And all grooves joint and design pattern
shall be included in quoted cost.
All exposed edges/ corners/ grooves to have proprietary corner/ edge bead sections/
channels as per Architect's instructions.
All exposed gyp board edges to be fixed with BeadEx self adhesive.
At all locations where services are penetrating the partition above false ceiling to have
additional GI frame work around the duct/ cable tray/ pipe and the gaps between the
frame work and service to be filled with appropriate acoustic sealant or with fire stop
material as directed.
Approved make
Laminates: Formica / Greenlam / Durian / Merino
Veneer: Duro group B
Commercial/Flexible Ply: Century/ Green/ Garnet/ Alpro/Durian/ merino/ Duro
BOQ - Civil, Interior-Furnishing, Electrical AC Works of BO at STC Building, Sec-3, Rohini. Contractor's Signature
36 S. No. Description Unit Qty. Rate Amount
a SKIN TYPE-1 OVER G.I FRAMING: 6 mm PLY/MDF + 6mm PLY/MDF +
1mm Laminate on both sides of Partition. The PLY should be Leed certified Green
Products, FSC certified and CE certification. which insure the quality of the products
to the international standards.
sqm 60.00
b SKIN TYPE-1 OVER G.I FRAMING: 6 mm PLY + 6mm PLY + 1mm
Laminate on single sides of Paneling. The PLY should be Leed certified Green
Products, FSC certified and CE certification. which insure the quality of the products
to the international standards.
sqm 72.00
5.3 Laser Cut Graphic / pattern in 19mm+19mm thk MDF For column clading
P/F laser cut shapes out of 19mm+19mm MDF. This will be installed on panel with
3m tape as located in plan. The quoted cost to include making arrangement for fixing
the designer panel in floor and same to be fixed in ceiling with G.I support above false
ceiling lvl
sqm 3.00
5.4 FULL HEIGHT GLASS PARTITION (12mm Thk Toughfened Glass
Partition)
Providing & fixing 12 mm thk toughfened glass partition finished with machine
polish at all exposed sides as per site requirement fixed with L-connectors complete as
per detail drawing & instructions of Architect including Etching Film ( garware ) as
per design on above item as per instructions of Architect in required pattern.
sqm 23.00
Total to be carried over the summary
6.0 FINISHING WORKS
Notes: Painting rates to include cost of covering/ protecting all finishing materials including
switches, lighting fixtures, AC equipment etc.
Applying painters putty & scrapping the surface and repeating the process as many
times as is required to achieve a thoroughly smooth surface for partitions paneling and
walls
6.1 POP punning
Providing and applying plaster of paris (super fine quality) punning with minimum
thickness of 6mm and finish the surface smooth in line and also making groove, level
to the entire satisfaction of Architect including scraping and hacking the existing
finished surfaces, scaffolding etc. complete as per drawing.
sqm 70.00
6.2 Acrylic Emulsion paint
Wall painting with acrylic emulsion paint of approved brand and
manufacture to give an even shade :
Two or more coats on new work sqm. 76
6.3 SYNTHETIC ENAMEL PAINT
Painting with synthetic enamel paint of approved brand and manufacture
to give an even shade :Make: Asian (Apcolite)/ICI Dulux (Gloss)/Nerolac (Full Glass
Hard Drying)
Two or more coats on new work Sqm 40.00
Total to be carried over the summary
BOQ - Civil, Interior-Furnishing, Electrical AC Works of BO at STC Building, Sec-3, Rohini. Contractor's Signature
37 S. No. Description Unit Qty. Rate Amount
7.0 FURNITURE
Important Notes:
all veneer (Duro group B ) are of Base Rate 175 Rs./Sq.ft unless or otherwise
specified.
all furniture in veneer are with melamine polish included in desire color shade as to be
approved by architect's
all necessary hardware such as handle, drawer channels, hinges shall be inclusive in
the quoted cost.
Every invidual table to be considered with drawer' and shelf built in as per design and
quoted cost shall include this also.
all Laminates make Merino/Green Lam/Durian/Formica
7.1 TABLES
A P/F Tables of 2'-6" height made ¾ “ th comm board for tables made out of
19mm comm block board for tables/12 mm thk. flexible ply in designs
wherever required as per design, with modesty panel, file drawers, all visible
areas to be finished with 1mm premium laminate / veneer, top side finished
with 6mm thick solid arcylic top (Corian Top) of make Dupont / Samsung
/ Aspiron / Duralax etc. (basic rate of Rs. 550/- per sq.ft. excluding taxes
and transportation) in approved color as per drg/detail with pencil drawer,
file drawer ,3”,6” drawer etc , 3”x 2” steam beech wood leg rest,
european/german steemed beech ¾”x ½” mouldings on margin and 11/2”x
1½”European/German Steemed Beech moulding on all edges sides and 3/4" X
3/4" Ex Steam beech moulding melamine polish at 2” high skirting level with
all necessary hettich/ haffle channels, Keyboard and channel ,handles
,hardware, all drawers with telescopic channels and all handles to be stainless
steel. as per drgs per design /architect's instructions, (Includes the cost of 3/4"
X 3/4" ex steam beech moulding melamine polish at bottom bands) Godrej
locks & SS handles as per approved sample.
I Table of size 7'0" x 3'-0" x 2-'6" high with side credenza / table of size 3'6" to 3'10" x
1'-6" x 2-'4" to 2'-6". (For BM cabin).
Nos. 1
II Table of size 5'-0" x 2'-3" x 2-'6" high with side credenza / table of size 3'6 to 3'10" x
1'-6" x 2-'4" to 2'-6". (For Workstations)
Nos. 6
III Cash counter tables Size: 5'9" x 2'6" to 2'3" x 2'6" with corian only on top face of
counter
Nos. 1
7.3 STORAGE FULL / LOW HEIGHT / CREDENZA
7.3.1
P/F low height 1’-6” to 2'0" deep(area calculated as length x breadth ) storage in
cabins as / dwg.made up of 19mm commercial block board shutters,sides & shelves
with melamine polished european/german steemed beech ¾”x ½” mouldings on
margin and 11/2”x 1” European/German Steemed Beech moulding on all edges sides
and 3/4" X 3/4"Ex Steam beech moulding melamine polish at 2” high skirting level .
6mm plywood back,with 1mm thick laminate on all visible surfaces leaving storage
table top. The low heighted storage top side finished with 6mm thick solid
arcylic top (Corian Top) (basic rate of Rs. 550/- per sq.ft. including taxes and
transportation) in approved color as per drg/detail with enamel/plastic base on inner
surfaces, mounted on powdercoated hinges, including efficent gadgets locks. C 4”
stainles steel handles, and magnetic ball catchers with necessary hettich/haffle
hardware, SS tower bolts (300x10 mm), hinges, godrej locks and SS handles as per
architects instructions including shelves as per design .
Sq.mt 10
7.3.2
P/F full height 1’-6” to 2'0" deep(area calculated as length x breadth ) storage in
cabins/working hall area as / dwg.made up of 19mm commercial block board
shutters, sides & shelves with melamine polished european/german steemed beech
¾”x ½” mouldings on margin and 11/2”x 1” European/German Steemed Beech
moulding on all edges sides and 3/4" X 3/4"Ex Steam beech moulding melamine
polish at 2” high skirting level . 6mm plywood back, with 1mm thick premium
laminate on all visible surfaces in approved color as per drg/detail with enamel/
plastic base on inner surfaces, mounted on powdercoated hinges, including efficent
gadgets locks. C 4” stainles steel handles , and magnetic ball catchers with necessary
hettich/haffle hardware,hinges, godrej locks, SS tower bolts (300x10 MM) and SS
handles as per architects instructions including shelves as per design .
Sq.mt 23
BOQ - Civil, Interior-Furnishing, Electrical AC Works of BO at STC Building, Sec-3, Rohini. Contractor's Signature
38 S. No. Description Unit Qty. Rate Amount
Total to be carried over the summary
8.0 MISCELLANEOUS
8.1 Fabric Board
Providing and fixing Fabric Board. Rates of the Fabric board to be inclusive of
accessory kit like pen stand, duster, magnets etc.
Sqm 20
Base Rate of Fabric : 350 Rs. Rmt (Leaving all taxes and Transportation charges)
8.2 BLINDS
8.2.1 Roller Blinds- Normal
Providing & fixing roller blinds comprising of polymer coated fibre fabric with
minimum openness factor of 3% as per AS standards. The fabric shall be fire retardant
and have high heat reflection ratios. The roller mechanism shall be a moulded unit
made from engineering grade plastic polymer with steel spring support. The fabric
shall be finished on the sides with edge tape duly welded for waviness control. The
fabric shall be attached to the roller tube with high quality self adhesive tape. Average
width of blinds shall be 2000mm and fall of 3000mm with manual operation.
Headrail: shall be .812" high x 2" deep extruded aluminum headrail with a wall
thickness of 0.045” and painted to coordinate with fabric color.
Cord lock: shall be a snap-in design of injection-molded thermoplastic incorporating
a metal, free-floating, serrated cord-locking roller.
Lift cord: shall be 1.2mm polyester and concealed for a clean appearance. A snap
tassel and joiner ball connect to a single Danskord for raising and lowering the shade.
Cord, tassel and joiner ball are color coordinated with fabric.
Installation: Bracket shall be low profile, hidden snap-in design made of 0.025” zinc-
plated spring steel.
Bottomrail: shall be 0.375" high x 2" deep extruded aluminum with a wall thickness
of 0.045” and painted to coordinate with fabric color.
Fabrication Shades shall be fabricated according to specifications and accurate to
tolerance established by SWF engineering standards
a Basic Cost: Rs 1500 per sm + taxes
make: Vista / Hounter Douglas / Livin Sqm 9.00
8.3 MS GRILL IN BRANCH FRONT SIDE
8.3.1 Structural steel work in single section, fixed with or without connecting plate,
including cutting, hoisting, fixing in position and applying a priming coat of approved
steel primer all complete.
Kg 500.00
Total to be carried over the summary
S.No. ITEM DISCRIPTION AMOUNT
1.0 CIVIL WORKS
2 FALSE CEILING WORKS
3.0 FLOORING / CLADDING WORKS
4.0 DOOR / WINDOW WORKS
5.0 PARTITION / PANNELING WALL FINISHING WORKS
6.0 FINISHING WORKS
7.0 FURNITURE
8.0 MISCELLANEOUS
TOTAL AMOUNT FOR INTERIOR_FURNISHING WORKS
SUMMARY OF CIVIL, INTERIOR_FURNISHING WORKS
BOQ - Civil, Interior-Furnishing, Electrical AC Works of BO at STC Building, Sec-3, Rohini. Contractor's Signature
39 S. No. Description Unit Qty. Rate Amount
II
Note: Providing and fixing and commissining the below mentioned Light fixture with Open
construction low loss electronic / copper Ballasts, starter, HPF condenser, Low glare
and with High lumens output lamps. The installation shall be complete with all
hardwares like anchor fasteners, set of chain / drop rods with ball & sockets, check
nuts, flexible pipes with glands etc. complete.
The rate shall also include cutting open false ceiling and channels to the required sizes
and finishing with pop works.
1.0 Providing and fixing and commissining Philips /Insta power LED Linear/strip
lighting system of approved design, mounted on ceiling, columns as per required
designs.
mtr. 10
14.4W Linear led light strip
2.0 Supply & Installation including making hole for exhaust fan in the opening, including
making the hole to suit the size of the above fan, making good damages connection,
I/c fixing louvers / shutters complete with frame, mounting rings frame with four
fixing holes, testing and commissioning etc. as required.(Crompton Greaves / Orient
Heavy duty )
Nos. 1
450 sweep and RPM 1400
3.0 Fixing in gypsum/armstrong ceiling, connecting testing and commissioning of
dismantalled downlighters (provided by bank dismantalled at time of work
excution and stored in place provided by bank) including the cost of necessary
inter-connections required all complete.
Lumpsum 1
4.0 Supplying, installing, testing and commissioning of wall bracket fan of 400
mm, complete with moulded propeller type blades, and accessories suitable
for operation on 230 / 240 Volts,
50 Hz, single phase, A.C. supply. (Make: GEC/Crompton/Orient)
Nos. 10
5.0 Providing & fixing BELL POINTS on wall /Partition with 2x1.0 sqmm copper
conductor in PVC medium gauge conduit(IS:9537) with call bell switch(Push
Type) including call bell Multi Tune Bell etc. complete in BM Cabin.
Nos. 1
6.0 a) Providingand fixing in gypsum/armstrong ceiling, connecting testing and
commissioning of following luminaires including the cost of necessary inter-
connections required 2'X 2' Luminare all complete.in 42 W(a) Wipro Pure
LED/Phillips/GE Mapple.)
Nos. 18
ELECTRICAL & LIGHT FIXTURES
BOQ - Civil, Interior-Furnishing, Electrical AC Works of BO at STC Building, Sec-3, Rohini. Contractor's Signature
40 S. No. Description Unit Qty. Rate Amount
6.00 WIRING
6.1 Supply all materials, receiving, storing, handling, fixing, laying, wiring and
testing for light, fan, exhaust fan, 5 Amp. switch and socket, etc starting from
point control box to the outlet using ISI marked (IS:694) single core 1.5 sqmm
flexible, flame retardant low smoke (FRLS), stranded copper conductors
PVC insulated 1100 Volt grade wiring in concealed / exposed system using 25
mm ISI marked (IS:IS:9537-III & 3419) 2 mm thick, heavy duty PVC
conduit including all conduit accessories, such as bends, tees, draw boxes,
minimum 1.2 mm thick G.I. or MS point control boxes with zinc plating and
yellow passivation, together with wiring accessories such as white modular
plate type switches and sockets, cover plate, grid plate etc. including circuit
wiring from DB to switch board and switch board to switch board by 2x1.5
sq.mm. flexible flame retardant copper wire with 1.5 sqmm Cu earth
continuity wire.
The conduit being laid in recess (concealed) either in ceiling slab / wall,
chasing on surface or under false ceiling including required clamping
arrangement and required length of PVC flexible conduit or in wooden
partitions etc. complete as required at site. (The minimum size of conduit will
be 25 mm dia irrespective of number of wires drawn into it)
a One light point with 5 Amp. switch. 20 NOS
bEach additional light point controlled by same 5 amp switch 35 NOS
cExhaust fan point with 5 Amp. Switch 1 NOS
dOne 5 pin 5 amp shuttered socket outlet with 5 amp switch 10 NOS
eSet of three 5 pin 5 amp shuttered socket outlet with 1 no. 5 amp switch. 12 NOS
f Blank plate for modular plate type switch boards wherever required. 5 NOS
6.2 Supply all materials, receiving, storing, handling, fixing, laying, wiring and
testing for power outlets using ISI marked (IS:694) single core, flexible,
flame retardant low smoke (FRLS), stranded copper conductors PVC
insulated 1100 Volt grade wiring in concealed/ exposed system using 20
mm/25 mm ISI marked heavy duty PVC conduit (IS:IS:9537-III & 3419)
including all conduit accessories, such as bends, tees, draw boxes, minimum
1.2 mm thick G.I. or MS point control boxes with zinc plating and yellow
passivation, together with wiring accessories such as white modular plate
type switches and sockets, cover plate, grid plate etc. including submain
wiring from DB to outlet with Cu earth continuity wire, conduit being laid in
recess (concealed) either in ceiling slab / wall, chasing on surface or under
false ceiling including required clamping arrangement and required length of
PVC flexible conduit or in wooden partitions etc. complete as required at site.
aOne 6 pin 15 amp shuttered socket outlet with 15 amp switch by 2x4 + 2.5 sq
mm copper wires. (Primary Power)
10 NOS
b
32 amp TPN industrial metal clad outlet in MS box with 32 amp C series FP
MCB and metal plug top instead of modular switch & sockets by 4x6 + 4 sq
mm copper wires.
1 NOS
c
20 amp SPN industrial metal clad outlet in MS box with 20 amp C series DP
MCB and metal plug top instead of modular switch & sockets by 2x4 + 2.5 sq
mm copper wires.
1 NOS
BOQ - Civil, Interior-Furnishing, Electrical AC Works of BO at STC Building, Sec-3, Rohini. Contractor's Signature
41 S. No. Description Unit Qty. Rate Amount
7.0 DISTRIBUTION BOARDS AND CIRCUIT BREAKERS
7.1 Supplying, receiving, storing, handling, erecting, testing and commissioning of
Single Pole and Neutral MCB distribution board, IP 43 protection, sheet
steel, double door, powder coated, 240 volts, in recess/surface, complete with
100 amp tinned copper bus bar, neutral bar, earth bar, top and bottom
removable gland plates with knockouts, interconnections, earthing etc. as
required. DB's shall be original factory fabricated of approved make.
Make : Legrand-Lexic / L&T / Hager / ABB / Schneider-Acti 9 / Havells
a 16 WAYS SPN 1 NOS
b 12 WAYS SPN 2 NOS
7.2 Supplying, fixing, connecting, testing and commissioning of following rating,
ISI marked (IS 8828) 240 / 415 volts, 10 KA, Miniature Circuit Breaker
(MCB) of single / double / three / four poles in the existing MCB DB or in
existing MS enclosure complete in all respects.
Make : Legrand-Lexic / L&T / Hager / ABB / Schneider-Acti 9/ Havells
a 6 to 32 Amp. SP MCB 30 NOS
b 6 to 32 Amp. DP MCB 10 NOS
c 40 Amp. DP MCB 2 NOS
d 50/63 Amp. DP MCB 2 NOS
e 32 Amp. FP MCB 1 NOS
f 40 Amp. FP MCB 2 NOS
g 50/63 Amp. FP MCB 1 NOS
8.0 TELEPHONE, DATA & TV
8.1 Supply and fixing of ISI marked (IS:9537-part 3 & 3419) 2 mm thick heavy
duty PVC conduit in concealed / exposed system in wall, ceiling or on floor
including cutting of brick work, laying of conduit and fixing it with M.S.
hooks and then plastering with cement, sand motar finished to the level,
providing necessary sockets, bends, tees, junction boxes of required sizes etc
as directed at site by the engineer-in-charge with supply of all material labour
and T & P required for proper completion of work. conduit being laid either in
concealed system in ceiling slab or wall or on surface or under the frame of
false ceiling including flexible conduits or through wooden partition including
clamping arrangements as required.
25 mm dia. conduit 150 M
8.2 Providing & Fixing of modular plate type telephone outlet on 1.0 mm tk G. I.
Switch control boxes, with cover plate, grid plate, screws, etc with
connections as required.
a Single RJ 45 Tel. Jack 8 set
b Twin RJ 45 Tel. Jack 3 set
BOQ - Civil, Interior-Furnishing, Electrical AC Works of BO at STC Building, Sec-3, Rohini. Contractor's Signature
42 S. No. Description Unit Qty. Rate Amount
8.3 Providing, fixing, connecting & testing of Krone box (Telephone Tag Block)
in a thermoplastic, IP 65 (weather proof) enclosure, internally embedded
gasket, anti corrosive, insulated and shock proof with provision for cable
through IP 65 glands complete in all respects. (Make : Hensel)a Supply and fixing of cat6 patch cord for voices uses 10 nos.
b Supply and fixing of 100 MDF Box with krone module 1 nos.
8.4 Providing, drawing, connecting and testing of telephone wire of cat6 cable in
MS/PVC conduit from telephone outlet box to the junction box/tag block as
required.
50 M
8.5 Providing, drawing, connecting and testing of telephone wire 0.5 sqmm
tinned annealed high conductivity copper conductor with high density
Polyethylene insulation, paired, polyster taped and FR PVC sheathed in
existing MS/PVC conduit from telephone outlet box to the junction box/tag
block as required.
2 pair 0.51 sq. mm. 250 M
8.6 Providing & Fixing of modular plate type white RJ 45 CAT 6 Data outlet /
information outlets ETL verified to meet or exceed TIA / EIA category 6
requirements, universal wiring label permitting to either T568A or T568B, UL listed,
for computer networking complete in all respect with cover plate, grid plate, screws,
MS box, etc with connections as required.
1 nos. RJ 45 Data Outlet 15 nos.
8.7 Providing, drawing, connecting and testing of enhanced category 4 pair LAN
(local area network) cable, UL and CUL listed, in existing MS/PVC conduit
or floor raceways including connections etc as required complete in all
respects. (Make : AMP / Systemax)
CAT-6 network cable 450 M
8.8 Providing & Fixing of modular plate type white coaxial television outlet
complete in all respect with cover plate, grid plate, screws, 1.0 mm tk G. I.
Switch control boxes, etc with connections as required.
1 nos.
8.9 Providing, drawing, connecting and testing of Television cable, Electrolytic
grade solid annealed high conductivity copper conductor, gas injected physical
polyethylene foam insulated, wrapped with aluminium tape and aluminium
alloy wire braided, jelly flooded and PVC jacketing in black colour
(Compatible to DTH TV signal), in existing MS/PVC conduit from television
outlet box to the junction box / splitter / subscriber or dwelling unit / Dish
antenna as required. (Make : Finolex / RR / Polycab / Skytone)
RG - 6 50 M
9.0 RACEWAY: including cutting of the floor and fixing as and wherever
required.
9.1 Supply, fixing, laying, hanging and embedding in wall of Aluminium raceway
top cover openable with counter sunk screws, painted stove enamelled
approved colour the cover should be tight on channel with counter sunk
screws to avoid entry of vermins. It should be tightened in such a way to avoid
ingress of mosquito, moisture and dust. The Aluminium raceway / wire ways
shall be complete with all accessories required such as bends, tees, reducers,
offsets, cover, junction boxes etc. as reqd.
a Supply, laying, testing and commissioning of 100 MM wide x 50mm
raceway with all requirements.
35 RM
b Supply, laying, testing and commissioning of 150 MM wide x 50mm
raceway with all requirements.
25 RM
BOQ - Civil, Interior-Furnishing, Electrical AC Works of BO at STC Building, Sec-3, Rohini. Contractor's Signature
43 S. No. Description Unit Qty. Rate Amount
10.0 SUBMAINS/MV CABLES
10.1 Providing and laying of PVC insulated copper conductor/Cable 1100 volt
grade stranded flexible FRLS Wire in required size of pvc heavy duty conduit.
a 2 x 10 + 1 x 4 sq.mm PVC insulated stranded flexible copper wires in pvc
conduit
15 rmt.
b 2 x 16 + 1 x 6 sq.mm PVC insulated stranded flexible copper wires in pvc
conduit
10 rmt.
c 4 x 10 + 2 x 4 sq.mm PVC insulated stranded flexible copper wires in pvc
conduit
25 rmt.
d 4 x 16 + 2 x 6 sq.mm PVC insulated stranded flexible copper wires in pvc
conduit
20 rmt.
III
1 Providing and fixing of interconnected refrigerant piping circuit of required
sizes with imported copper tubes duly insulated with close cell elastrometric
foam, complete with supports and properly clamped along with Interconnected
electrical wiring between room and condensing units including power cables
from power supply switch/socket to condensing unit, conduit fittings etc. as
required complete as per design and specifications of the manufacturer and
approval/instruction of the consultant. items include chissiling of walls and
finishig the same upto complete satisfaction of the architect.
100 rmt.
2 Providing and fixing of PVC Drain piping-20 kg density with fittings and
valves, insulated with close cell Elastrometric foam complete as per design
and specifications of the manufacturer and approval/instruction of the
consultant. (For 4 No. AC's unit) items include chissiling of walls and
finishig the same upto complete satisfaction of the architect.
(a) 25MM
105 rmt.
3 Commissioning and installation of Air cooled HI-WALL MOUNTED SPLIT
AC's (supplied by the bank) complete with outdoor unit, cordless remote
control, safety feature as per the design and specifications and
approval/instruction of the consultant.
Nominal CAPACITY– 1.0 TR. 3 no.
Nominal CAPACITY– 1.5 TR. 1 no.
Nominal CAPACITY– 2.0 TR. 4 no.
4 Providing ,Fixing & Installation of MS Cages for split ac condesing unit to be
hanged outside, or kept on terrace with MS base frame, the cages may be
grouted in the ceiling or wall as the case may be.The cages to have shuttered
opening which are lockable all the cage to be painted in 2 coats of synthetic
enamel after preparing base with primer coating.
8 no.
5 Providing and fixing triple step 5 to 4 k.v.a automatic voltage stabilizer wall
mounted of bluebird/ logictech/ micel make.
8 no.
6 Providing fixing 3c x4sqmm circular wire connection complete,connection 250 rmt.
Total Amount for HVAC Works to be carried over the summary
DISCOUNT (IF ANY)
FINAL AMOUNT (INCLUDING GST)
TOTAL AMOUNT (Interior furnishing+Electrical works+AC Work)
HVAC WORKS (Make : Mitsubishi / Diakin / Voltas / O General / Carrier) of Minimum 5 star rating by BEE (HWS)
Total Amount for Electrical Works to be carried over the summary
BOQ - Civil, Interior-Furnishing, Electrical AC Works of BO at STC Building, Sec-3, Rohini. Contractor's Signature
top related