additional conditions of contract accengineeringprojects.com/tender/uploadfiles/1582_vol--ii.pdf ·...

Additional Conditions of Contract ________________________________________________________________________Engineering Projects (India) Limited

_____________________________________________________________________________________________________ Signature of Contractor 1 EPI

ADDITIONAL CONDITIONS OF CONTRACT (ACC)

1.0 The following Additional Conditions of Contract shall be read in conjunction

with General Conditions of Contract. If there are any provisions in these Additional Conditions of Contract, which are at variance with the provisions of General Conditions of Contract, the provisions in these Additional Conditions of Contract shall take precedence.

2.0 INTRODUCTION

Construction of Non- Residential Building for Base Hospital at Chandak, Pithoragarh is the work of Uttarakhand State Infrastructure Development Corporation (USIDCL).

3.0 SCOPE OF WORK INCLUDED IN THE CONTRACT

The scope of work included in this tender shall include (but not be limited to) Site development, setting out and layout, excavation of foundation & Basement, laying base concrete, R.C.C. footing, brick work in foundation and up to plinth, fixing door and window frames. Brick work in superstructure, laying of R.C.C. slab, plaster work, laying of floors, fixing of door and window shutters, painting and varnishing work, white washing, cement paint, construction of drain etc of quality assurance of various components of the works. Rectification of the defects in the completed works during the defect liability period, submission of “As built” drawing. and any other related documents and other items of work as may be required to be carried out for completing the works, in accordance with the drawings and provisions of the contract to ensure safety.

Electrical works:- PVC conduit, wiring, fixing of switches & switch boards, sub main wiring, cabling, power points, fixing of distribution board, all internal & external electrification works etc. complete.

Water Supply & Sanitation works:- Open and concealed GI pipe works of all dia. including all fittings, fixing of gate valve, SCI/PVC pipes sanitation works including all fittings, construction of man hole chamber, soakage pit, septic tank, fitting of water supply and sanitary fixtures, under ground & roof water tanks, all internal & external water supply and sanitation works etc. complete.

4.0 QUALIFICATION OF TENDERERS

To be eligible for this tender the bidders should fulfill the requirements for eligibility as mentioned in the Notice Inviting Tender (NIT) and should submit

Additional Conditions of Contract ______________________________________________________________________ _Engineering Projects (India) Limited

Signature of Contractor 2 EPI

detailed data and credentials set out in Clause No. 19.0 of ITT (Vol-I), NIT (Vol-II) of the tender. The bidders are required to fulfill all the eligibility criteria as stipulated in NIT documents and elsewhere in the Tender documents. The price bid of bidders who fulfill the eligibility criteria as per evaluation of EPI shall only be opened. The decision of EPI in this regard shall be final & binding on the bidders

5.0 DISQUALIFICATION

The bidders may note that their bids are liable to be disqualified and not considered for the opening of Price Bid if;

a) Representation in the forms, statements and attachments submitted in

the pre-qualification document are proved to be incorrect, false and misleading.

b) They have record of poor performance during the past 10 years such as abandoning the work, rescinding of contract for which the reasons are attributable to the non-performance of the contractor, inordinate delay in completion, consistent history of litigation / arbitration awarded against the contractor or any of its constituents or financial failures due to bankruptcy etc. in their on going / past projects.

c) They have submitted incompletely filled in formats without attaching certified supporting documents and credentials to establish their eligibility to participate in the tender.

d) If the bidders attempt to influence any member of the selection committee.

e) These are in addition to conditions of GCC. EPI reserves its right to take appropriate action including disqualification of bidder (s) as may be deemed fit and proper by EPI at any time without giving any notice to the bidder in this regard. The decision of EPI in the matter of disqualification shall be final and binding on the bidders.

6.0 EPI reserves the right to independently verify the performance of the bidder

from the existing owners / users / owners’ Consultants. In case of non-receipt of such confirmation, EPI reserves the right to reject the tender and price bid of such bidder and bid shall not be considered, even if the bidder is meeting the technical and other qualifying requirements.

In such circumstances the bidder shall have no claim on EPI of whatsoever

nature.



7.0 Clause no 1.0 of Instructions to Tenders i.e. mode of submission shall also include the following paras:

(a) The Envelope-1 shall also contain the documents meeting the eligibility

criteria mentioned in “Notice Inviting Tender” Clause No. 1.0 (a) to (h), in addition to the documents mentioned in Clause No.1.0 (i) to (vi) given in Page No. (1) of “INSTRUCTIONS TO TENDERERS”.

(b) The tenderer who download the tender documents directly from EPI’s

website shall have to submit tender fees of Rs. 10,000/- (Rupees Ten Thousand only) (Non-Refundable) by Crossed Demand Draft favouring “Engineering Projects (India) Ltd.”, payable at Delhi along with their bid in Envelope-1.

8.0 CLAUSE NO.1.1 OF INSTRUCTIONS TO TENDERERS as given in Page (2)

of INSTRUCTIONS TO TENDERERS stands amended as below: First the Envelope-1 of the tenderer shall be opened. Tenderers who un-

conditionally accept the tender conditions, deposit the required Earnest Money, meet the eligibility criteria mentioned in clause no. 1.0 (a) to (h) of NIT, deposit the tender fees as defined above in Clause 7.0(b) and whose Techno-Commercial Bid is found suitable, shall be considered for the opening of their Price Bid and Envelope-2 of such tenderers shall only be opened. The Tenders not accompanied by requisite Earnest Money and/or not accompanied by the requisite tender fees and / or not conveying un-conditional acceptance of tender conditions and / or not meeting the eligibility criteria or whose Techno-Commercial Bid are not found acceptable, shall be rejected and such tenderer shall not be allowed to attend Price Bid opening i.e. opening of Envelope-2.

9.0 SPECIFICATIONS 9.1 The work in general shall be carried out as per latest CPWD specifications

New Delhi for Civil Works, Internal Electrical works and Fire fighting (updated with correction slips issued up to last date of submission of tender) unless otherwise specified in the nomenclature of the individual item or in the particular specifications of concerned items of works.

9.2 For items not covered under latest CPWD specification, for (Civil Works) /

latest CPWD specification for Electrical Works, Fire fighting works etc. and in particular specification or nomenclature of the individual item as above, the work shall be done as per latest relevant BIS codes of practice and DIN or IEC standards.

9.3 In case specifications are not covered under Para 11.1 & 11.2 above the work shall be carried out as per the provisions of technical specification.



9.4 In case of non availability of any specification in the above paras or any overlapping provisions, non-clarity on any issue, applicability of particular provision out of above, shall be decided by Engineer-in-Charge whose decision shall be final & binding on the contractor.

10.0 Payment Terms

Subject to deduction which EPI might be entitled to make under the contract, the contractor shall receive payment of contract value as per Clause 37.0 of GCC. Retention money as applicable shall be deducted from each bills. (Clause 10.0 of GCC).

11.0 For dispatch of materials to site, equipment manufacturer / supplier shall mark consignee as self A/c USIDCL through EPI.

12.0 ROAD PERMIT:

Road permit for transportation of goods across state border shall not be issued by USIDCL/ EPI and will have to be arranged by contractor on his own. Transit Insurance of the equipment shall be arranged by the contractor. Nothing extra shall be paid on this account.

13.0 Invoice should be raised by Contractor in the name of Engineering Projects

(India) Ltd., Pithoragarh, Uttarakhand with copy to EPI-PMD, NRO, New Delhi.

14.0 THE CLAUSE NO. 69.0 (IV) OF GCC STANDS MODIFIED AS UNDER:

If the rates for the altered, additional or substituted work cannot be determined in the manner specified in sub-clauses (i) to (iii) above, then the Contractor shall, within 7 days of the date of receipt of order to carry out the work, inform the Engineer-in-Charge the rates which he intends to charge for such class of work, supported by analysis of the rate or rates claimed, and the Engineer-in-Charge shall determine the rate or rates on the basis of prevailing market rates of the material, Labour, T&P etc. plus 15% (Fifteen percent) to cover the Contractors supervision, overheads and profit and pay the Contractor accordingly. The opinion of the Engineer-in- charge as to the current market rates of materials and quantum of labour involved per unit of measurements will be final and binding on the Contractor. However, the Engineer-in-Charge, by notice in writing, will be at liberty to cancel his order to carry out such class of work and arrange to carry it out in such manner, as he may consider advisable. But under no circumstances, the Contractor shall suspend the work on the plea of non-settlement of rates of items falling under the clause.



15.0 PLANT & MACHINERY All plant & machinery required for execution of work shall have to be

arranged by the contractor at his own cost as under:

Sl. No.

Item of Equipment

No. Owned/Leased

1 Water Tanker 2 Nos.2 C.C. Batching Mix Plant (4Bag Capacity) 1 No.3 Concrete Mixer with lift 1 No.4 Concrete Mixer with hopper/Transit mixer 1 No.5 JCB Machine 1 No.6 Pin/ Needle Vibrator/ Surface Vibrator 4 Nos. 7 Generator 25 KVA 1 No.8 Grinding/Polishing Machine 1 No.9 Concrete Pump. 1 No.10 Stone cutting machine 6 Nos.11 Shuttering 4500 m2

12 Level machine 1 No.13 Theodolite 1 No.14 Total Station machine 1 No.15 Site lab testing equipment i -Cube testing machine 1 No. ii- Cube mould 30 Nos. iii- Slump cone 2 Nos. iv- Vernier Callipers 1 No. v- Screw gauge 1 No. vi- Weighing machine 1 No. vii- Silt testing container 4 Nos. viii- Sieves as per IS Complete set

The contractor will not be allowed to take out equipments from the site without the written permission of Engineer-in-Charge.

16.0 The contractor shall comply with legal orders, directions and by laws of local

bodies / authorities. The contractor shall give to the Municipality, Police, Local Bodies and concerned Governmental authorities all necessary notices relating to works that may be required under the law and obtain all requisite licences, permissions for temporary obstructions, enclosures, collection and stacking of materials, etc. The contractor shall pay at his own cost all fees, taxes and charges that may be liable on account of these operations in executing the contract. Nothing extra shall be paid by EPI on this account.



The contractor shall be bound to follow the instructions and restrictions imposed by the administration / Police authorities on the working and / or movement of labour, materials etc. nothing extra shall be payable due to less / restricted working hours at site or any detours in movement of vehicles.

17.0 INSURANCE OF WORKS

The Insurance coverage as stipulated in General Conditions of Contract (GCC) clause no. 17, 18 and 19 shall be in the combined name of USIDCL/EPI and the Contractor for a period of 12 months after Successful completion / handling over of work. The Insurance coverage shall be on the total value of work awarded to contractor by EPI.

Clause 17.0 of GCC is modified as under:

EPI shall take, in the joint names of the EPI/USIDCL and contractor, "Contractor's All Risk Policy" insurance from the start Date to the end of the Defect Labiality period the amounts and deductibles stated in the contract data for the following events which are due to the contractor’s risks.

a) Loss of or damages to the works, plant and material.

b) Loss of or damages to equipments. c) Loss of or damages of property (except the works, plant materials and

equipment) in connection with the contract; and Personal injury or death.

All each insurance shall provide for compensation to be payable in the types and proportions of currencies required to rectify the loss or damage incurred.

Proportionate cost/premium of the policy shall be recovered from the

contractor corresponding to the contract value plus other premium on his equipment as mentioned above.

Alterations to the terms of insurance shall not be made without the approval

of the Engineer-in-Charge.

Both parties shall comply with conditions of the insurance policies. 18.0 INDEMNITY AGAINST PATENT RIGHTS The following Para shall be added to clause No. 20.0 of General Conditions of

Contract as under:

The Indemnity against Patent rights shall be in the Joint Name of USIDCL and EPI.



19.0 PERMITS AND INSPECTIONS The contractor shall obtain all necessary permits from local bodies, provincial

or central authorities and shall make arrangement for inspection and tests etc. as required at his own cost.

20.0 LICENCES The contractor shall arrange for obtaining the licence and clearances for the

operation. (If required) from the local authorities and statutory bodies at his own cost & nothing extra shall be payable. Certification of various equipments / installations from statutory bodies other agencies as required as per technical specifications, shall be arranged by contractor at his own cost before handing over.

21.0 The contractor shall have to make his own arrangements for getting the

permission for plying trucks or any plant & equipment for execution of works from the statutory authorities at his own cost. No excuse as to delay in work due to non-availability of permission shall be entertained.

22.0 The work shall be carried out in accordance with the drawings/documents

approved by the EPI / USIDCL. Before the commencement of any item of work, the contractor shall correlate all the relevant architectural and structural drawings issued for the work and satisfy himself that the information available there from is complete and unambiguous. The discrepancy, if any, shall be brought to the notice of Engineer-In-Charge before the execution of work. The contractor alone shall be responsible for any loss or damage occurring by the commencement of work on the basis of any erroneous and / or incomplete information. Nothing extra shall be paid on this account

23.0 The contractor shall give performance tests of the entire installation (s) as per

specifications and drawings before the work is finally accepted and nothing extra whatsoever shall be payable to the contractor for these performance tests.

24.0 The contractor shall be bound to sign the site order book as and when

required by Engineer-In-Charge at Site and carry out compliance of instruction promptly to the satisfaction of Engineer-In-Charge.

25.0 Bill of Quantities shall be read in conjunction with the specifications and

requirement described in tender documents, Instructions to tenderers, General conditions of contract, Additional conditions of contract, Technical specifications, Drawings, Schedules, and Annexure & Addendum etc. to tender document.



General directions and description of work and materials are not necessarily repeated or summarized in the Bill of quantities. Reference to the relevant sections of the contract document shall be made by the contractor before entering rates or prices against each item in the Bill of Quantities.

26.0 SITE STAFF OF CONTRACTOR: Minimum qualifications and experience required for principal technical rep.

and other minimum technical staff other than supervisor shall be deployed as under.

Sl. No.

Personnel Qualification &Experience No.

1 Senior Site Engineer (Degree Holder)

B.E. Civil + having minimum 5 Years experience in similar type of Building works

1 No.

2 Site Engineer • Diploma in Civil Engineering having minimum 3 years building experience.

• Diploma in Electrical Engineering having minimum 3 years building experience.

1 No.

1No.

3 Supervisor / Formen Trained in Civil Works 5 Nos.4 Accounts clerk, store

keeper 1 No.

each5 Security Guard. From registered security agency for

(24x7days)3 Nos.

If Contractor fails to deploy minimum Technical staff as mentioned above, recovery on account of non-deployment of each Technical/Non technical/Clerical staff shall be made from subsequent RA Bills as under: a) Graduate Engineer at ` 60,000/- per month.

b) Diploma Holder at ` 40,000/- per month. c) Supervisor/Store keeper/Accounts clerk at ` 15,000/- per month. d) Security Guards at ` 10,000/- per month.

27.0 It will be the sole responsibility of contractor to obtain all statutory approvals

and completion clearance from all the relevant statutory bodies for all other services as included in the scope of contract etc. from the concerned department as required within the stipulated time frame. Liaison work on behalf of EPI with the local bodies will also have to be done by the contractor. Nothing extra shall be payable to contractor on this account. No claim whatsoever in this regard shall be entertained.



28.0 The contractor shall make necessary safety arrangement at site including as

mentioned in GCC and indemnify EPI and client against any consequence of accident at site.

29.0 Deduction (non-refundable) at the rate of 1% or at the rates applicable from

time to time in the state of Uttarakhand from gross amount of each running bill and from final dues of contractor shall be made towards provision for workers “welfare Cess Act 1996”.

30.0 The Contractor shall furnish details whether they are covered under micro, small and Medium Enterprise Development Act 2006. If yes, clearly indicate under which category they are covered alongwith documentary evidence. This information is required to be furnished along with the bid.

31.0 Contractor will be responsible to arrange day to day housekeeping as required at site as per instruction of Engineer in charge.

32.0 FACILITIES TO BE PROVIDED BY SUCCESSFUL BIIDDER TO EPI Clause No. 28.3 of GCC is modified as below.

Immediately on placement of LOI/Work Order (whichever is earlier) by EPI on the successful bidder, the successful bidder, at its own cost shall provide furnished office, facilities etc. exclusively for the use of personnel of EPI as per details given below. These facilities are in addition to the facilities to be provided to the clients/ client’s consultant, if any, as per terms of main contract with clients. The successful bidder shall make his rates in their offer sufficiently comprehensive to cover the cost of the facilities as per details shown below and the successful bidder, shall not be entitled for any extra payment for the same:

DESCRIPTION

A) OFFICE ACCOMMODATION Furnished Office/ Office cum Residential accommodation at one or more locations as per direction of EPI with basic amenities like Toilets, Drinking water arrangement, lights, fans etc. for exclusive use of EPI’s Engineers & Staff and maintenance of the same till Defect Liability Period. The Specifications and Design of accommodation shall be as

1000 Sq.ft

B)

FURNITURE OF TOTAL VALUE

Rs 1.00 Lac

C) OFFICE EQUIPMENT

a) Fax Machine 01 Nos.



b) Latest Computer (Desk Top) with minimum 500 GB HDD along with UPS & Operator (In case Computer Operator is not provided by the PARTY, recovery of Rs. 10000/- per month / per computer operator shall be made from the PARTY’s bills in this regard) and Latest version of Software like MS Project, Windows, MS Office etc.

01 Nos.

c) All in one with fax, scan, copy and print (Heavy duty). Laser or any other Printer of equiv. Amount of A4 size.

01 Nos.

d) Internet Facilities (broad band / data card with unlimited downloading facility) 01 Nos. e) Refrigerator (165 Itr.) or any other gadget of equivalent cost as decided by EPI 01 Nos.

f) Air Conditioner with cooling & heating (1.5Ton Capacity) or any other gadget of equivalent cost as decided by EPI.

02 Nos.

g) UV/RO type water purifier (Drinking Water) or any other gadget of equivalent cost as decided by EPI

01 Nos.

h) Digital Camera 8MP with video facility 01 Nos.

D) CONSUMABLES

a) All consumables like Stationary, ink etc. shall be provided by PARTY till end of defect liability period. (Stationary items are inclusive of visiting cards, rubber stamps, letter pads, photocopies, photocopy papers & other items of daily office use). Amount

Rs. 5000 /-

be restricted to: Per month

b) Running & Maintenance of the equipment mentioned above are to be done by the PARTY at his own cost.

As per Actual

E) TELEPHONE WITH STD FACILITY AND INSTRUMENT

a) Office Telephone (Fixed Line) 01 No.

b) Mobile Phone 03No.

Monthly operational expenditure on account of all telephones shall be restricted to. Rs. 8000/-. The cost of each Mobile Phone Instrument shall be restricted to Rs 6, 000/- per Month

F) 01 No. VEHICLE – Scorpio / Xylo / Innova make or equivalent with Driver and accessories with Monthly running shall be restricted to : 4000Kms.

The vehicle has to be in very good condition and shall not be more than 01 year old and shall be provided with driver on full time basis. Consumables like diesel/petrol/oil lubricants and spare parts etc. shall be provided by the PARTY at their cost. The vehicles shall be maintained in good working condition. In case of breakdown, replacement of vehicles shall be provided by PARTY immediately. The cost of registration, transportation etc. shall be borne by the PARTY. In case a vehicle is not required by EPI, a recovery of Rs. 45,000/- per month per vehicle shall be made from the PARTY for this purpose till the end of defect



liability period. In case Driver, POL, maintenance of any vehicle is not required by EPI for any vehicle, a recovery of Rs. 30,000.00 per month per vehicle shall be made from the PARTY for this purpose till the end of defect liability period. The above gadgets and facilities should be brand new and of reputed make and all facilities shall be provided and maintained properly (including clearing payment of water & electricity bills etc.) by the PARTY at Project site or at any other office related with execution of this project till completion of work, handing over, defect liability period in all respect at his own cost. The PARTY shall also make stand-by arrangement for water & electricity to ensure un-interrupted supply. The equipment/items shall be the property of PARTY at the end of contract. The PARTY shall be responsible for watch and ward of site office and other facilities etc. In case of theft/damage of any equipment/items, the PARTY shall immediately replace the same within a maximum period of two days. The PARTY shall provide ‘Sign Board(s)’ as per design approved by EPI and/or Client. In case the above facilities are not provided by the PARTY within 10 (ten) days of award of work or replacement is not provided within the specified period, EPI shall arrange the same and debit to the PARTY and make the recoveries from the bills of the PARTY. The decision of EPI shall be final and binding on the PARTY in this regard.

G) OFFICE BOY CUM COOK on Full time basis for EPI 02 Nos.

33.0 Time Control 33.1 Programme

Within the time stated in the contract data the contractor shall submit to the Engineer for Approval a programme showing the general methods, arrangements. Order and timing for all the activities in the works along with monthly cash flow forecast.

An update of the progamme shall be programme showing the actual programme achieved on each activity and the effect of the progress achieved on the timing of the remaining work including any changes to the sequence of the activities.

The contractor shall submit to the Engineer, for approval an updated programme at intervals no longer than the period stated in the contract data. If the contractor does not submit an updated programme within this period, the Engineer may withhold the amount until the next payment after the date on which the over due programme has been submitted.

The Engineer’s approval of the programme shall not alter the contractor is obligations. The contractor may revise the programme and submit it to the Engineer at any time. A revised programme is to show the effect of Variations and compensation Events.



33.2 Extension of the Intended Completion Date.

The engineer shall extend the Intended completion Date if a Compensation Event occurs or a Variation is issued which makes it impossible for completion to be achieved by the Intended Completion Date without the contractor taking steps to accelerate the remaining work and which would cause the Contractor to incur additional cost.

The Engineer shall decide whether and by how much to extend the Intended completion data within 35 days of the contractor asking the engineer for a decision upon the effect of a compensation Event or Variation and submitting full supporting information. If the contractor has failed to give early warning of a delay or has failed to cooperate in dealing with a delay, the delay by this failure shall not be considered in assessing the new intended completion date.

The Engineer shall within 14 days of receiving full justification from the contractor for extension of intended completion date refer to the employer his decision. The employer shall in not more than 21 days communicate to the engineer the acceptance of otherwise of the Engineer’s decision. If the EPI / USIDCL fails to give his acceptance, the Engineer shall not grant the extension and the contractor may refer the matter to the Dispute Review Expert under Clause no. 24.1.

34.0 Management Meetings

Either the Engineer or the contractor may require the other to attend management meeting. The business of a management meeting shall be to review the plans for remaining work and do deal with matters raised in accordance with the early warning procedure.

The Engineer shall record the business of management meetings and is to provide copies of his record to those attending the meeting and to the employer. The responsibility of the parties for action to be taken is to be decided by the engineer either at the management meeting or after the management meeting and stated in writing to all who attended meeting.

35.0 Quality Control 35.1 Identifying defects

The engineer shall check the contractor’s work and notify the contractor of any defects that are found. Such checking shall not affect the contractor’s responsibilities. The Engineer may instruct the contractor to search for a



Defect and to uncover and test any work that the Engineer considers may have a Defect.

35.2 Work to be open to inspection

All works under or in the course of executive or executed in pursuance of the contract shall at all times be open to the inspection & supervision of the Engineer-in-charge & his subordinates, & the contractor shall at all times during the usual working hours and at all other times, at which reasonable notice of intention of the Engineer-in-charge or is subordinate to visit the works shall have been given to the contractor, either himself be present to receive order and instruction or have a responsible agent duly accredited in writing present for that purpose. Orders given to the contractor’s agent shall be considered to have the same force as they had been given to the contractor himself.

35.3 Notice to be given before work is covered up.

The contractor shall not give less than five days, notice in writing to the Engineer-in-charge before covering up or otherwise placing beyond the reach the measurement of any work in order that the same be measured and correct dimension thereof be taken before the same is so covered up or placed beyond the reach of measurement of any work without the consent in writing of the Engineer-in-Charge of the work & if the work shall be covered up or placed beyond the reach of measurement without such notice having been given or consent obtained, the same shall be uncovered at the contactor’s expense, and in default thereof no payment or allowance shall be made for such work or the materials with which the same was executed.

35.4 Tests

If the engineer instructs the contractor to carry out a test not specified in the specification to check whether any work has a defect and the test shows that it does, the contractor shall pay for the test and any samples, if there is no Defect the test shall be a compensation Event.

Test laboratory and testing equipments required for the project should be available at site.

35.5 Correction of defects.

The engineer shall give notice to the contractor of any Defects before the end of the defects liability period, which beings at completion and is defined in the contract data. Every time notice of a defect is given, the contractor shall correct the notified defect within the length of time specified by the Engineer’ notice.



35.6 Uncorrected defects.

If the contractor has not corrected a defect within the time specified in the Engineer’s notice, the Engineer will assess the cost of having the defect corrected, and the contractor will pay this amount.

36.0 Variations

All variations shall be included in updated programmes produced by the contractor. The Engineer-in-Charge shall have power to make any alteration, omissions, additions and substitution in the original specification, drawings, designs & instructions that may appear to him to be necessary during the progress of the work & the contractor shall carry out the work in accordance with any instruction which may be given to him in writing signed by the Engineer-in-charge & such alterations, omissions, additions, substitutions, shall not invalidate the contract & any altered, additional or substituted work which the contractor may be given delivered to do in the manner above specified as part of the work shall be carried out by the contractor on the same conditions in all respects on which he agreed to do the main work. The time for the completion of the work shall be extended in the proportion that the altered, additional or substituted work bears to the original contract work & the certificate of the Engineer-in-Charge shall be conclusive as to such proportion. Over & above this, a further period to the extent of 25% of the time so extended may be allowed to the contractor. The rate for such additional, altered or substituted work under this clause shall be worked out in accordance with the following provisions in their respective orders:-

a) If the rates for the additional altered or substituted work are specified in

the contract for the work, the contractor is bound to carry out the additional, altered or substituted work at the same rates as are specified in the contract of the work.

b) If the altered, additional or substituted work includes any work for which, no rates are specified in the contract for the work or cannot be derived from the similar class of work in the contract then such work will be carried out at the rates entered in the schedule of rates of relevant Distt./Minus/Plus/Percentage, which the total tendered amount bears to the estimated cost of the entire work put to tender.

c) If the rates for the altered, additional or substituted work cannot be determined in the manner specified in the Sub-Clauses (a) to (b)



above, then the rates for such work shall be worked out on basis of schedule of rates of the Distt. Specified above Minus/Plus the percentage which the total tendered amount bears to the estimated cost of the entire work put to tender provided always that if the rate for a particular parts or parts will be determined by the Engineer on behalf of the EPI when the work was tendered.

d) If the rates for the altered, additional or substituted work cannot be determined in the manner specified in the Sub-Clauses (a) to (c) above, then the contractor shall within 7 days of the date of receipt of the order to carry out the work, inform the officer accepting the contract on behalf of the EPI of the rate which he intends to charge for such class of work, supported by analysis of the rate or rates claimed & the EPI shall determine the rates on the basis of the prevailing market rates & pay the contractor accordingly. However, the Engineer-in-charge on behalf of the EPI by notice in writing will be at liberty to cancel his order to carry out such class of work & arrange to carry out it in such manner or as any consider reasonable. But under no circumstances, the contractor shall suspend the work on the plea of no settlement of rates of times, failing under this clause. The rates under sub clauses (a) to (b) & (c) shall be worked out by officer accepting the contract on behalf of the EPI.

37.0 TECHNICAL EXAMINATION / AUDIT

In case of Technical Examination/ Audit of state / Central Government Authorities, any time during execution or even after 15 months of completion of work, the contractor shall be liable for defects/ quality of the work and financial consequences as a result of deficiencies observed/ recorded in Technical Examination/ audit report. Necessary documents/ supporting vouchers (In Original) for purchase of cement and steel and other construction material, store registers/ records, materials test report, field test results, abstract of payments, manufacturers test certificates and any other details as asked for during Technical examination/ Audit by the concerned authority shall be provided by the Contractor to the full satisfaction of Technical Examiner during Technical Examination/ Audit of the work. If as a result of such audit and/ or technical examination any sum is found to have been overpaid, the Contractor shall be liable to refund the amount of over-payment and it shall be lawful for the Engineer-In-Charge to recover the same from him in any manner permissible under the contractor legally.



38.0 Liquidated Damages/ compensation for delay

The contractor shall pay liquidated damages to the employer at the rate per week stated in the contract data for week day that the completion date is later than the Intended completion date(for the whole of the works or the milestone as stated in the contract data). The total amount of liquidated damages shall not exceed the amount defined in the contract data. The employer may deduct liquidated damages from payments due to the contractor. Payment of liquidated damages does not affect the contractor’s liabilities. The payment or deduction of such damages shall not relieve the contractor from his obligation to complete the works or from any other of his obligations and liabilities under the contract. In addition to above, if the delay has occurred due to the reasons attributable to the contractor, then a recovery of Rs 1,50,000.00 (Rupees One Lac Fifty Thousand only) per month shall be made against delayed period from the contractor’s bill towards compensation for overstay expenses of EPI.

39.0 Securities Deposit for Reinforcement Steel Bars and Cement being

supplied by EPI.

Reinforcement steel and cement shall be issued free of cost to the contractor. The party shall submit a Bank Guarantee of Rs. 40.00 Lacs (Rupees Forty Lacs) lump sum from Nationalized / Scheduled Bank towards security deposit as per EPI’s proforma against supply of reinforcement steel and cement within 15 days from the date of award of work. The Bank Guarantee shall remain valid till completion of work and all the materials issued have been fully consumed / reconciled. The party shall maintain a complete record of receipts / consumptions / stock of steel and cement supplied by EPI on daily basis and the record shall be made available to EPI as and when required.

40.0 Cost of Repairs

Loss or damage to the works or materials to be incorporated in the works from the start date and upto the end of the defects liability period shall be remedied by the contractor at his own cost, if the loss or damage arises from the contractor’s acts or omissions.

41.0 Completion Certificate

The contractor shall request the engineer to issue a certificate of completion of the works and the Engineer after satisfying himself will issue the certificate to the effect.



42.0 Taking Over

The client shall take over the site and the works within one month from the date of completion of work by the contractor in all respect.

43.0 Final Account (Final Bill)

The contractor shall supply to the engineer-in-Charge a detailed account of the total amount that the contractor considers payable before the end of the defect liability period. The engineer-in-Charge shall issue a defect liability certificate and certify any final payment that is due to the contractor within 56 days of receiving the contractor’s account if it is correct and complete. If it is not, the Engineer-in-Charge shall issue within 56 days a schedule stating the scope of the corrections or additions that are necessary. If the final account is still unsatisfactory after it has been resubmitted, the engineer-in-Charge shall decide on the amount payable to the contractor and issue a payment certificate, within 56 days of receiving the contractor’s revised account.

44.0 Payment upon termination.

If the contract is terminated because of a fundamental breach of contract by the contractor, the engineer-in-Charge shall issue a certificate for the value of the work done less advance payments received up to the date of the issue of the certificate, less other recoveries due in terms of the contract, less taxes due to be deducted at source as per applicable law and less the percentage to apply to the work not completed as indicated in the contract data. If the total amount due to the employer exceeds any payment due to the contractor, the difference shall be recovered from the contractor by encashing their Bank Guarantee or any other securities. If the contract is terminated at the employer’s convenience or because of fundamental breach of contract by the employer, the engineer-in-Charge shall issue a certificate for the value of the work done, the cost of balance material brought by the contractor for and available at site. The reasonable cost of removal of equipment repatriation of the contract personnel employed solely on the works, and the contractor’s costs of protecting and security the profit and less advance payments received up to the date of the certificate, less other recoveries due in terms of the contract and less taxes due to be deducted at sources as per applicable law.

45.0 Contract Data

a)The Name of Principal Employer is : USIDCL 3/3, Industrial Area, Patel Nagar, Dehradun-248001.



b) Name of authorized Representative of the Principal Employer - will be intimated later c) The Engineer in charge/Engineer of the Principal employer is - Project Manager, USIDCL, Bhimtal Unit. d) Name of authorized Representative of EPI - Will be intimated later

e) The Defects Liability Period is 365 days from the date of handing over.

f) The Start Date shall be 10 days from the date of issue of the Notice to proceed with the work/ issue of Work Order or LOI.

g) The intended completion date for the whole of the work is 15 months after start date of work. Work programme of which shall be submitted by the contractor and got approved from Engineer before start of the work.

h) The site is located at Chandak, Near Mostamanu Temple,

Pithoragarh. The work consists of Construction of Non Residential Buildings for Base Hospital Pithoragarh.

i) The work shall be carried out as mentioned in the Bill of Quantity,

inter alia, include the following, as specified or as directed.

I) Building Works:-

Site development, setting out and layout, excavation of foundation & Basement, laying base concrete, R.C.C. footing, brick work in foundation and up to plinth, fixing door and window frames. Brick work in superstructure, laying of R.C.C. slab, plaster work, laying of floors, fixing of door and window shutters, painting and varnishing work, white washing, cement paint, construction of drain, all respect of quality assurance of various components of the works. Rectification of the defects in the completed works during the defect liability period, submission of “As built” drawing. and any other related documents and other items of work as may be required to be carried out for completing the works, in accordance with the drawings and provisions of the contract to ensure safety.

II) Electrical works:- PVC conduit, wiring, fixing of switches & switch boards, sub main wiring, cabling, power points, fixing of distribution board, all internal & external electrification works etc. complete.



III) Water Supply & Sanitation works:- Open and concealed GI pipe works of all dia. including all fittings, fixing of gate valve, SCI/PVC pipes sanitation works including all fittings, construction of man hole chamber, soakage pit, septic tank, fitting of water supply and sanitary fixtures, under ground & roof water tanks, all internal & external water supply and sanitation works etc. complete.

j) Other Items:

• Any other items as required to fulfill all construction obligation as per

the Bid documents.

• The law, which applies to the contract, is law of Union of India.

• The language of the contract documents is English.

• The minimum insurance cover for physical property injury and death is Rs. 5.00 Lac per occurrence with the number of occurrence limited to four. After each occurrence contractor will pay additional premium necessary to make insurance valid for four occurrences always.

• The Site Possession Date shall be Date of agreement/Work Order.

• The period for submission of the work programme for approval of Engineer shall be 21 days from the issue of letter of Acceptance.

• The Period between programme updates shall be 7 days.

• The amount to be withheld for late submission of an updated

programme shall be Rs. 5000/- .

• The currency of the contract is Indian Rupees

• The proportion of payments retained (retention money) shall be 5% from each bill subject to a maximum of 5% of contract price.

• Amount of liquidated damaged for delay in completion of works shall

be 0.5% of the Total contract price, rounded off the nearest thousand, per week. Maximum limit of liquidated damages for delay in completion of work shall be 10% of the Total Contract Price rounded off to the nearest thousand.



46.0 Advance Payment and Security

The Employer will provide an Advance Payment on the Contract Price as stipulated in the Conditions of Contract, subject to maximum amount, as stated in the Contract Data. The amount of the advance payment are:

Nature of Advance

- Mobilization advance Not applicable. - Equipment advance Not applicable. - Secured advances on non- perishable materials brought to site (Applicable as per clause no. 35.0 of GCC)

47.0 Repayment of secured advance:

Advance shall be repaid from each succeeding monthly payments to the extent materials have been incorporated into the works. SECURITIES: The securities shall be for the following minimum amount as a percentage of the Contract Price. Performance Security/Performance Guarantee for 5% of contract value Rs…………….. (To be decided after evaluation of the bid) plus as additional security. The standard form of Performance Security acceptable to the employer shall be an unconditional Bank Guarantee and as per EPI’s Proforma valid upto …………..

48.0 The date by which ‘as built’ drawing (in scale as directed) in 2 sets are

required is within 28 days of issue of certificate of completion of whole or section of the work, as the case may be. An amount of Rs 1.00 lac shall be withheld for failing to supply ‘as built’ drawing by the date required.

49.0 The percentage to apply to the value of the work not completed representing

the Employer’s additional cost for completing the works shall be 20 percent.

--------------

Arbitration

Both EPI and CONTRACTOR shall make efforts to settle disputes, if any amicably. Only if amicable settlement is not possible, the same shall be referred to the Sole Arbitration of the Chairman & Managing Director (CMD) of EPI or the person appointed by the CMD, EPI and the decision of the arbitrator shall be final and binding on the “CONTRACTOR”. Arbitration will be according to “Conciliation” Clause, which is enclosed at Annexure I

Annexure – II CONCILIATION AND ARBITRATION Before resorting to arbitration as per the clause given below, the parties if they so agree may explore the possibility of conciliation as per the provisions of Part – III of the Arbitration Conciliation and Act. 1996. When such conciliation has failed, the parties shall adopt the following procedure for arbitration :- 1 Except where otherwise provided for in the contract, any disputes and

differences relating to the meaning of the specifications, designs, drawings and instructions herein before mentioned and so to the quality of workmanship or materials used in the work or as to any other question, claim, right, matter or thing whatsoever in any way arising out of or relating to the contract, designs, drawings, specifications, estimates, instructions or these conditions or otherwise concerning the works or the execution or failure to execute the same whether arising during the progress of the work or after the completion or abandonment thereof shall be referred to the Sole Arbitration of the Chairman and Managing Director (CMD) of Engineering Projects (India) Limited (EPI), or any other person discharging the functions of CMD of EPI and if CMD or such person discharging the functions of CMD of EPI is unable to act, to the Sole Arbitration of some other person appointed by the CMD of EPI or such other person discharging the functions of CMD of EPI. There will be no objection if the arbitrator so appointed is an employee of EPI. However, such an employee shall not have directly dealt with the said contract or the works there under on behalf of EPI. Such Arbitrator shall be appointed within 30 days of the receipt of letter of invocation of arbitration duly satisfying the requirements of this clause.

2. If there arbitrator so appointed resigns his appointment, is unable or

unwilling to act due to any reason whatsoever, or dies the Chairman & Managing Director aforesaid or in his absence the person discharging the duties of the CMD of EPI may appoint a new arbitrator in accordance with these terms and conditions o the contract, to act in his place and the new arbitrator so appointed may proceed from the stage at which it was left by his predecessor.

3. It is a terms of the contract that the Contractor invoking the arbitration shall

specify the dispute/ differences or questions to be referred to the arbitrator under this clause together with the amounts claimed in respect of each dispute.

4. The arbitrator may proceed with the arbitration ex-parte, if either Contractor,

in spite of a notice from the arbitrator, fails to take part in the proceeding 5. The work under the contract shall continue, if required, during the arbitration

proceedings

6. The Arbitrator shall make speaking Award and give reasons for his decision in respect of each dispute/ claim alongwith the sums awarded separately on

each individual item of dispute or difference or claims. The Arbitrator shall make separate award on each reference made to him.

7. The award of the arbitrator shall be final, conclusive and binding on both the

parties. 8. Subject to the aforesaid, the provisions of the Arbitration and Conciliation

Act, 1996 or any statutory modifications or re-enactment thereof and the Riles made there under and for the time being in force shall apply to the arbitration proceedings and arbitrator shall publish his award accordingly.

Note : Notwithstanding anything contained here in above, this clause shall not

be applicable where the dispute is between EPI and an another Public Sector Enterprise or Govt. Department for which a separate Arbitration Clause is provided vide Clause No. A given below :-

A. ARBRATION BETWEEN PUBLIC SECTOR ENTERPRISE INTERSE/GOVERNMENT DEPARTMENTS.

1. In the event of any dispute or difference relating to the Interpretation and

application of the provisions of the contract, such dispute or difference shall be referred by either Contractor to the arbitration as per the Instructions (Office Memorandums/circulars) issued by Govt. Deptt. and another, one Govt. Deptt. and a Public Sector Enterprise and Public Sector Enterprises interse.

2. Subject to any amendment that may be carried out by the Government of

India from time to time, the procedure to be followed in arbitration shall be as is contained in D.O. No. DPE/4 (10)/2001 –PMA – GLI dated 22/01/2004 of Department of Public Enterprise Ministry of Heavy Industries and Public Enterprise or any modification issued in this regard.

TECHNICAL SPECIFICATION

SPECIFICATION

1- All work shall be carried out as per detailed CPWD specifications.

2- Action where no specification is given

3- In the case of any class of work for which there is no specification in the Contract, such work shall be carried out in accordance with the detailed CPWD/ PWD specifications & in the event of there being no detailed specifications for the same, work shall be carried out in all respects in accordance with the instructions of the Engineer-in-Charge and good engineering practices.

4- The make for the Civil & Electrical items is as follows:- (a) Civil:-

S. No.

Item Manufacturer's Name

1 Grey Cement (OPC 43 Grade) ACC, Ultratech, JK, CCI,India Cement,JP2 White Cement J.K, Birla or equivalent3 Reinforcement Steel (TMT

bars) Tata, sail, Rashtriya Ispal Nigam ( RINL).

4 Structural Steel sections Sail, Vizag, Tata5 Concrete Additives Fosroc, Cico-tl, Sika6 Anti termite Chemical Pest Control India Ltd., Pest Con India, Pest

Control Incorporated. 7 Tile grouts, Joint Filler Laticrete, “Roff Rainbow Tile Mate” of Roff,

Construction Chemicals Pvt. Ltd., Winsil 20, Silicon Sealant of GE Bayer Silicon, Matrix Group.

8 Polysulphide Sealant Pidilite, Fosroc, STP.9 Silicone Sealant GE Bayer Silicone, Dow Corning, Wacker.10 Epoxy over flooring Fosroc, Sika or equivalent

11 Water Proofing Membrane –Bitumen Based

Sika, fosroc, Stp

12 Non Shrink grouts Fosroc, cico, Sika13 Non Metallic Floor Hardeners Fosroc, sika, cico, Stp.14 Bitumen Shalimar tar products, Mathura oil refinery15 Synthetic Enamel Paints Berger ( Luxol Gold), Nerolac( Full Gloss

Hard Drying), Asian ( Apcolite), ICI Dulux ( Gloss)

16 Oil Bound Distemper Asian ( Tractor), Berger ( Durocem Extra), Narolac

( super Acrylic)17 Cement Paint Snowcem Plus, Berger( Durocem Extra),

Nerolac ( Nerolac with Titanium) 18 Plastic Emulsion Paint ICI, Nerolac, Asian19 Other Paints & Primer ICI Dulux, Asian, Berger, Nerolac 20 Textured Coating Spectrum, Heritage, Unitile 21 Melamine ICI Dulux, Timberstone Melamine Coating22 Polyurethane Paint MRF or equivalent23 Silicon Water Repellent

Solution GE Bayer Silicon (I) Pvt. Ltd., Metroark P Ltd., or “Silicon Waterpeller” by STP Ltd., “Nisiwa-SH” of Mc- Baucheme (I) P Ltd., “Techrepel” of Choksy chemicals P Ltd.

24 Ceramic Tiles (Glazed , Matt, Others)

Kajaria, HR Johnson,Somany.

25 Vitrified Porcelain Tiles Kajaria, Rak, Samany, Varmora. 26 Laminated Wooden flooring Krono, pergo, Berry.27 PVC Flooring Polyflor, LG, Square foot28 Vinyl Flooring Armstrong, Royal House, Premier Vinyl,

Nittobo 29 Terrazzo Tile NITCO, Modern, Hindustan 30 Interlock Tiles, Glass Paver

Block Nimco Prefab, Unistone, Modern

31 Cement Concrete Tiles, Designer Tiles

Unistone, Ultra, Eurocon, Rerra Firma

32 Laminates Duro, Formica, Greenlam. 33 MDF Grade-I as per IS-

12406& Ecomark Nuwud, URO or equivalent

34 Adhesive for wood work Dunlop, Fevicol, Vamicol, Pidilite 35 Pre Laminated Particle

Board Novopan, Bhutan, Kitlam, Greenlam, Century

36 Plywood, Block Board, Soft Board

Archidply , Century, Duro, Alpro, Greenply ,

37 Free Access Flooring Unitile - United Access Floors Pvt Ltd, Heweston

38 Paving Stones Unistone or equivalent39 Wax Polish Mansion , Reckitt & Colman 40 Polyethane Sealant MBT, Choksey, Chemtal Rai, Fosroc, Pidilite41 Polyethelene Board,Back Up

Rod Supreme Industries or Equivalent

42 Stainless Steel Hinges Canon, Union, haflon43 Mirror & Float Glass Modi Float Glass, Asahi Glass, Saint Gobain44 Door Hardware , Closer Godrej,Dorset,Dorma, Hettich. 45 Locks and Handles Godrej,Dorset,Dorma, Hettich. 46. Aluminum Building Expansion

Joints Vexcolt, Watson Bowman, Acme, , Z- Tech India, JMetco.

47 Water Stopper Fixopan, Caliplast or equivalent

48 Aluminium Composite Panel Alucobond, Alupan, Aludecor , Durabuild , Alstrong

49 Asphalt Emulsion STP, Karnak Chemical Corporation. 50 Expansion Fastener Fischer, Hilti, Anchor.51 Stainless Steel Salem, Jindal, Cavelier52 Anchor Fastener , Anchor

Bolts Hilti, Fisher or equivalent

53 Corner Guards Arpitha or equivalent54 Gypsum Partition & Gypsum

Ceiling India Gypsum, Lafarge or equivalent

55 Impregnated Fibre Board STP or equivalent56 Joint Filler and Bitumen

Products STP or equivalent

57 Electrodes Advani-Overlikon, ESAB, Dwekam 58 Mineral Fibre Ceiling System Armstrong, AMF, USG , DAIKIN 59 H.T. Bolts Unbrako or equivalent60 Steel Doors (General purpose) Shakti Met-Dor or equivalent 61 Steel Doors (Fire rated) Global Fire Protection Company, Radient safe

Fire Doors, Godrej, Navair, Shakti Met-Dor 62 Fire Door ( Wooden ) Navair , Aadhunic , Radient 63 Aluminum Sections Jindal, Hindalco, Indal64 Rolling Shutter Shivam, Milestones, Rama, Prakash 65 Pre-coated Roof Sheeting Multicolor, BHP, Bluescope, Japan Metal

Systems, Lloyds, CRIL 66 Glass wool and related

products, Mineral wool UP-Twiga, Owens Corning, Lloyds

67 Polycarbonate sheets GE Plastics , Polygal, Sunlite 68 Self drilling Screws Hilti, Builtex or equivalent 69 Logo, Signs, Name plates D-Line,Sign Sutra or Equivalent. 70 Pre - Engineered Building Kirby Building , Tiger Steel or equivalent71 Flush Doors Archidply ,Duro, Century, Alpro 72 MS Sliding Motorized Door Shivam Associates - Beninca RI524 K

System or equivalent 73 Water proofing compound Pidilite, Cico , Fosroc74 Fasteners Gun, Atul or equivalent75 Aluminum fittings Indal, hindalco76 Extruded vitrified clay tile Unitile or equivalent77 POP Sriram or equivalent78 outdoor furniture ( sitting

bench, dustbin ) Arihant or equivalent

79 Modular furniture Godrej, Merino, Blowplast 80 Chairs and Sofas Godrej, Geeken, Featherlite 81 Acoustical paneling Armstrong, Anutone or equivalent 82 Modular Toilets Merino ,Green ,Dorma83 Mosaic tiles Nitco, surya, Laxmi84 Acoustical False Ceiling Anutone or equivalent85 Exterior tiles Unitile, Dovtexor Equivalent

86 Patch Fitting/ Spider Fitting/ Furniture Fittings

D-Line, Hettich ,Dorma, Godrej

87 UPVC Door & Window Fenesta , Rajashri or Equivalent 88 Acid and alkali resistent tiles Somany , Restile , Durato 89 Ceramic Rainscreen ventilated

faced tile Faveton , Moeding, NBK

90 Roller Blinds Hunter Douglas / Mac/Vista PLUMBING SYSTEM 1 VITREOUS CHINA SANITARYWARE PARRYWARE/CERA/HINDWARE

2 PLASTIC W.C.SEATS & COVERS PARRYWARE/CERA/HINDWARE

3 C.P. FITTINGS: BIB COCK (LONG BODY/SHORT BODY), PILLAR COCK, SINGLE HOLE BASIN MIXTURE, WALL MIXER, SHOWER MIXER, ANGLE VALVE, CONCEALED STOP COCK, SHOWER WITH WALL FLANGE, C.P. WASTE 32-40 mm DIA,BOTTLE TRAP, HEALTH FAUCET WITH STEEL BEDED CONNECTING PIPE.

PARKO / CERAMIX /ESS ESS

4 AUTOMATIC WATER TAPS, AUTOMATIC URINAL FLUSHING SYSTEM


5 TOWEL RING, TOWEL ROD, TOWEL RACK, COAT HOOK etc. (304 Grade S.S.)


6 CHROMIUM PLATED / STAINLESS STEEL / POLY VENYL CHLORIDE GRATING

Cummun, Neer, Chilly

7 STAINLESS STEEL SINK JAINA / NEELKANT

8 SAND CAST IRON SPUN PIPE,CENTIFUGALLY CASTED S & S AS PER IS: 3989

NECO / RAJ IRON FOUNDRY/ RIF/SKF

9 CAST IRON PIPE, HORIZONTALLY / VERTICALLY CASTED S & S AS PER IS:1729

NECO / RAJ IRON FOUNDRY/ RIF/SKF

10 G.I. & M.S. PIPES PART-I IS: 1239 UPTO 150 mm AND M.S. PIPES PART-II IS: 3589 ABOVE 150 mm

TATA STEEL (TUBE DIVISION)/ JINDAL PIPES LIMITED

11 G.I. AND M.S. FITTINGS UNIQUE./ ZOLOTO / KENT

12 uPVC PIPES & FITTINGS 4 kg./sqm, 6 kg./sqm, 10 kg./sqm PRESSURE.

SUPREME INDUSTRIES LIMITED/ FINOLEX INDUSTRIES/ PRINCE PIPES & FITTINGS PRIVATE LIMITED

13 cPVC PIPES SDR12.5 SCHEDULE-40 ASTRAL POLYTECHNIC PRIVATE LIMITED/ ASHIRVAD ENTERPRISES PRIVATE LIMITED/ JAIN PLASTICS & CHEMICALS LIMITED

14 HDPE PIPE

JAIN PLASTICS & CHEMICALS LIMITED/ CHEMI PLAST INDUSTRIES STUROY POLYMERS LIMITED/ KISAN GROUP OF COMPANIES

15 C.I.CLASS LA PIPES

KESORMA PUN PIPE & FOUNDRIES, CALCUTTA/ SUPER ENTERPRISES/ INDIAN IRON & CO. LTD. CALCUTTA.

16 R.C.C. PIPES

PRAGATI CONCRETE UDYOG/ K.K. SPUN PIPES/ J. K. SPUN PIPES/SOOD &SOOD

17 STONEWARE PIPES & GULLY TRAP

DEVRAJ ANAND CERAMIC (P) LIMITED./ PERFECT POTTERI JABAL PUR (MP)/ BURN POTTERIES, JABALPUR

18 GUNMETAL VALVES(FULLWAY, CHECK, GLOBE AND NON RETURN VALVES)

LEADER VALVES LIMITED/ ARKAY SALSE CARPORATION DELHI

19 BALL VALVE

TBS ENGINEERS PVT. LTD./ VIRGO ENGINEERING LTD./ GOOJARMAL GANPATRAI/ AUDCO INDIA LIMITED

20 BUTTERFLY VALVE (LEVER TYPE) LEADER VALVES LIMITED/ CASTLE VALVES LIMITED/ AUDCO INDIA LIMITED

21 BUTTERFLY VALVE (GEAR TYPE)

LEADER VALVES LIMITED/ CASTLE VALVES LIMITED/ AUDCO INDIA LIMITED/ GUOJARMAL GANPATRAI

22 C.I.DOUBLE FLANGED SLUICE VALVE & GATE VALVES

KIRLOSKAR BROTHERS LIMITED/ AARKO MANUFACTURING COMPANY/ ARROW ENGG.LTD

23 FLOAT VALVE (GUNMETAL) UPTO 40M

SANT INDUSTRIAL CONTROLS (P) LIMITED/ BOMBAY METAL & ALLOYS/ LEADER VALVES LIMITED

24 FLOAT VALVE (CI) 50M AND ABOVE LEADER VALVES LIMITED/ INDIAN VALVE CO. LTD.

25 FOOT VALVE / CHECK VALVES (BRASS)

LEADER VALVES LIMITED/ INDIAN VALVE CO. LTD. CALCUTTA/ ADVANCE VALVES (P) LIMITED/ GOOJARMAL GANPATRAI,/ AARKO MANUFACTURING COMPANY

26 AIR RELEASE VALVES (BRASS / CAST IRON)

LEADER VALVES LIMITED/ ADVANCE VALVES (P) LIMITED/ AARKO MANUFACTURING COMPANY/ GOOJARMAL GANPATRAI

27 C.I. MANHOLES COVER & G. I. GRATING

K. K. MANHOLE & GRATING CO. PRIVATE LIMITED/ BANGAL IRON COMPANY WEST BANGAL/ SHINING ENGINEERING WORKS (FOUNDRY) AGRA.

28 HAND DRIER (304 Grade S.S.)

THE VEERA TRADING COMPANY/ KOPAL ENGG. CORPN.NEW DELHI/ ASKON ENGINEERS BOMBAY

29 LIQUID SOAP DISPENSER (304 Grade S.S.)

THE VEERA TRADING COMPANY/ ASKON ENGINEERS BOMBAY

30 STORAGE TYPE WATER HEATER VENUS / RACOLD/BAJAJ OR EQUIVALENT

31 INSULATION THERMAFLEX OR EQUIVALENT

32 SOLAR HOT WATER EQUIPMENT TATA -BP/ SOLAHART

33 ELECTRICAL HOT WATER HEATER VENUS/ KINGSTON

34 PVC FOOT REST & SFRC COVERS KK MANHOLES OR EQUIVALENT (b) Electrical:- SI. No. Name of the Item Recommended Marks

1 Cage clamp copper Connector Wago/ Elmex / Equivalent 2 PVC Conduit (Heavy Duty) AKG/ BEC/ Precision/ Ploy Cab 3 Flexible Conduit Preciflex/ Polycab4 PVC Casing Capping AKG/ Prcision/ Polycab 5 Fan Boxes Jindal/ ISI Mark6 Electrical copper wires

(Multistranded FR) Finolex/ RPG/ Poly Cab/ RRKable

7 Telephone wires/cables Dlton/ Finolex/ Ploycab 8 Bakelite sheet Hylem/ Formaica 9 Phenolic Sheet Hylem/ Formica

10 Ordinary Electrical accessories SSk (topline)/Anchor (penta)/ Cona/ Northwest (R-Series)

11 Modular switch & soket Legrand/ MK(Honeywell)/ Siemens/ North west

12 Call bells/Buzzer Anchor/ Cona 13 Distribution Boards Legarand/ L&T (Hagger)ABB/ Siemens 14 Miniature Circuit Breaker Legrand/L&T (Hager)/ABB/Siemens 15 Industrial Plug tip and socket,

sleeve type Legrand/ L&T(Hager)/ ABB/ Siemens/ Havells

16 Electrical Fixture (Indoor) Philips/ Bajaj/ Wipro 17 Electrical Fixture (Outdoor) Philips/ Bajaj/ Wipro 18 Lamps/Tubes Philips/ Osram/ Bajaj 19 Ceilling fans Crompton Greaves (High Breeze)/

Khaitan (Epro Magnet)/ Bajaj (Grace)/ Havells (Velocity)

20 Exhaust Fans Alstom/ Havells/ Cromton Greaves 21 Ventilation Fans/Fresh air Fans Alstom/ Cromton Greaves / Havells/ Usha 22 Fan down rods Jindal/ Tata/ Prakesh 23 G.I. Pipes Jindal/ Tata/ Prakeshz 24 Moulded case ciruit Breaker Legrand/ Simence/ Merlin- Gerin

Compact)/ ABB 25 Current Transformer Alfa/ Kappa/ AE 26 Ammeter/Voltmeter AE/ Rishabh 27 LED type indication lamp Siemence/ GE/ L&T (Esbee)/ BCH 28 Selector Switch L&T (Salazer)/ GE/ HPL/ Siemens 29 Geyser Spherehot/ Racold/ Bajaj/ Usha-Luxhes 30 AI Power LT Cable Gloster/ Grandly/ Raillison/ Havells/

Polycab 31 Cable Lugs Jainsons/ Dowell’s/ Elcon 32 Cable Glands Gripwell/ Comet/ Metal Craft 33 Fire extinguisher Cease-fire 34 Rubber Mating ISI mark 35 Wall mounting fan Usha/ Khaitan/ Bajaj/ Havells 36 Any other items

As approved by Engineer in Charge, in case of any changes in company names and brand range approval of Engineer In Charge should be taken before installation.

37 LT Panel

IS code 5039:1983 Modern Switch Gears LKO, GEWIS, MEI, JYOTI, GAURAV , HPL, C&S.

- 98 -

- 99 -

- 100 -

- 101 -

ADMIN

OFFICER

3130 X

6640

D

MEDICAL

RECORD

OFFIC

ER

3130 X

6640

MEDICAL

RECORD

PROCESSING

3130 X 66

40

RECEPTION

3270 X

1800

RECEPTION

3270 X

1800

3 000

6500

6500

6500

6500

6500

6500

6500

6500

6500

65 006500

Y Y1

Y2

Y3

XX1

X2

X3

X4

X5

X6

X7

X8

X9

3000

6500

6500

6500

6500

6500

6500

6500

6500

6500

65006500

Y Y1

Y2

Y3

XX1

X2

X3

X4

X5

X6

X7

X8

X9

CUTOUT

500X2100

CUTOUT

500X2100

USIDCL

UTTARAKHAND STATE IN

FRASTRUCTURE DEVELOPMENT

CORPORATION LTD.

UNIT BHIM

TAL (N

AINITAL)

info@ddfgrou

p.com

DDF Consultants Pvt. L

td.

NEW DELHI-11

0034 PH: 47400500

NETAJI SUBHASH PLACE, PITAMPURA

www.ddfg

roup.com

AN(IS

O - 90

01 : 2

000 CERTIFIED)

501, B-9 I.T

.L TWIN TOWER,

CLIENT'S NAME:

ARCHITECT CONSULTANT :

STRUCTURE CONSULTANT :

MEP CONSULTANT :

DEALT

DWG. N

O.

Revision Suffix

APPROVED BY

DRAWN

SCALE

REF. NO.

CHECKED BY

DATE

NORTH

SUFFIX

DATE

DETAILS

REVISIONS DETAILS

ISSUED BY

TITLE OF DRAWING:

USIDCL

PROJECT NAME:BASE HOSPITAL

AT PITHORAGARH, UTTRAKHAND

HOSPITAL BUILDING

BLOCK - 01 (G

ROUND FLOOR & FIRST FLOOR PLAN)

3601-0

2-AR-01

BDDF-B

HP/03

601

REENA

23-06

-11

DEEPAK SINGH

1:200

WRITTEN PERMISSION OF THE AR

CHITECTS.

2. T

HIS DRAWING IS

THE PROPERTY OF THE ARCHITECTS AND WILL

NOT BE REPRODUCED , C

OPIED, E

XHIBITED , U

SED W

ITHOUT THE

DEEPAK SING

H

BLOCK =02

BLOCK =03

BLOCK =01

KEY PLAN

BLOCK-1 THIRD FLOOR PLAN

G. TOILET

3130X4310

B. TOILET

3300X4310

TOILE

TTOILE

T

1.5X1.8

1.5X

1.8

- - - 2400 W

IDE PASSAGE - - -

WW

W

WW

WW

WW

W W

VV

W1

W1

W1

W1

W1

W1

W1

W1

W1

W1

W1

GL

D

D

D1

D1

D1

D1

D1

D3

D3

MEDICAL

STORE

3000 X

6640

GENERAL

EN

ERAL

304

0 X 6

640

WW

W

WW

WW

WW

W W

VV

W1

W1

W1

W1

W1

W1

W1

W1

W1

W1

W1

GL

D

DD

D1

D1

D1

D1

D1

D3

D3

V1

V1

W1

W1

D1

D1

D1

D1

D1D1

D1

D1

D1

D1

D1

D1

D1

D1UP

DN

UP

DN

W1

W1

V1

V1

W1

W1

D1

D1

D1

D1

D1D1

D1D1

D1

W1

W1

D1

DD

V900

W3000

900

LINTEL LVL.

1200

1200

S.NO.INDICATION

WIDTH

SILL LVL

HEIGHT

1.

2.

3.

4.

5.

6.

7.

8.

900

W1

2100

2100

1200

DOOR &

WINDOW DETAIL

D-

2100

1500

2100

D1

-2100

1000

2100

D2

-2100

900

2100

D3

-2100

750

2100

D4

-2550

1800

2550

2100

2100

2100

1200

900

W2

1500

2100

1200

900

W3

1295

2100

V1

900

1200

700

2100

9.

10.

11.

MS O

FFIC

E

8220 X

664

0

PS

LIBRARY C

UM C

ONFEREN

CE

NURSIN

G O

FFIC

ER

ACCOUNTS

CASHIE

RPUR

CHASE

LABO

UR

WELF

ARE/

SECUR

ITY / R

ECORDS

SEC

URITY

CLERICAL STAFF

291

0 X 6

640

941

0 X

664

0

H. TO

ILET

1880X2100

6490

X 66

40

OFFIC

ER

291

0 X

664

03130

X 66

40OFFIC

ER

2910 X

664

0

OFFICE

3130

X 66

40

627

0 X 6

640

OFFIC

ER

2910

X 66

40

LIFT

2740X3000

LIFT

2740X3000

12770 X 16140

RECEPTION/ W

AITING

12770 X 9270

STO

RE

313

0 X 6

640

RECEPTION/ W

AITING

12770X9270

H. TO

ILET

1880X2100

LIFT

2740X3000

LIFT

2740X3000

MEDIC

AL R

ECORD STORE

(activ

e upto

2 ye

ars)

MEDIC

AL R

ECORD ST

ORE

(inactive

)

6490

X 66

40627

0 X 6

640

STAFF O

FFIC

E

627

0 X 6

640

COM

PLE

TIO

N R

OOM

6270

X 66

40

DOCTOR

RECORD

VARIO

US A

UTO

MATIO

N

605

0 X

664

0

ROO

M FO

R

314

0 X 6

640

LIN

EN S

TORE

6270

X 66

40

FUR

NITU

RE STORE

6270 X

6640

SURGIC

AL ST

ORE

6270 X

664

0

STO

RE

291

0 X

664

0288

5 X 6

640

290

0 X 6

640

3155 X

664

0

BLOCK-1 SECOND FLOOR PLAN

G. TOILET

3130X4310

B. TOILET

3300X4310

TOILE

TTOILE

T1.5X

1.81.5X

1.8

STATIO

NARY

STO

RE

STOR

ES

OFFIC

ESTATIO

NAR

Y

STORE

GENERAL

STORE

- - - 2400 W

IDE PASSAGE - - -

- - - 2400 WIDE PASSAGE - - -

- 102 -

WW

W1

W

W

D1

FEMALE

TOILET

3565X

4125

D1

FEMALE

TOILET

3600 X 6275

V

V

GL

D1D1

D2

WAITING AREA

13890 X 6775

D2

O.T.

SCRUB

INSTRUMENT

SCRUB

INSTRUMENT

W1

W1

W1

W1

W1

W1

W1

W1

D1

D1

D1

D1

D1

DD

DDD

D

D4

D4

D4

W

W

D1

D1

D1

D1

D1

D1

D3

GASTROENTOLOGIC

CLINIC & SURGICAL CLINIC

WAITING AREA

13550 X 6505

SKIN & STD CLINIC

WAITING AREA

13550 X 6520

LOBBY

12055 X 7335

W1

D1

UP

DN

LIFT

2700 X 3000

LIFT

2700 X 3000 LOBBY

5630 X 3270

W1

W1

CLERICAL STAFF

14.76 SQMT.

UP

W

LIFT

2700 X 2700

2995 X 5000

B. TOILET

3775 X 3100

G. TOILET

2700 X 2700

LIFT

- - - 2 400 WIDE PASSA GE - - -

- - - 2400 WIDE PASSAGE - - -

V

V

W

W

W

W

W

D1

D1

D1

D1

D1

D1

D1

D1

D1

D1

W1

W1

W1

W1

W1

W1

W1

W1

D1

D1

WW

W

W1

W

W1

D1

D1

D1

D1

D1

D1

D1

INVESTIGATION

ROOM

3270 X 5365

CONL.& EXAM.

ROOM

3265 X 6265

CONL.& EXAM.

ROOM

3380 X 6640

SPECIALIST

ROOM

3145 X 5365

TREATMENT

ROOM

3200 X 6635

SKIN

LABORATORY

3385 X 6630

H.O.D

ROOM

3805 X 6280

SPECIALIST

ROOM - 1

3275 X 5575

SPECIALIST

ROOM - 2

3260 X 5580

SPECIALIST

ROOM

3380 X 5365

H.O.D

ROOM

3795 X 6275

TREATMENT

ROOM

2965 X 6275

CONL.& EXAM.

ROOM

3270 X 6270

CONL.& EXAM.

ROOM

3165 X 6040

SUPERFICAL

THERAPY

2770 X 6300

CONL.& EXAM.

ROOM

3145 X 6620

CONL.& EXAM.

ROOM

3350 X 6640

CONL.& EXAM.

ROOM

3410 X 6640

6490 X 6285

O.T.

6490 X 6270

DELIVERY ROOM

4440 X 2385

CHILD BIRTH

3110 X 6270

EXAMINATION

2910 X 6270

STORAGE

STERILE

3355 X 6270

& LINEN

INSTRUMENT

2700 X 6270

RECOVERY

3110 X 6270

ANAESTHESIA

19280 X 6270

NURSERY

WARD

- - - 2400 WIDE PASSAGE - - -

6285 X 6270

- - - 1800 W ID E PA SSAGE - - -

CONL.& EXAM.

ROOM

3350 X 5675

CONL.& EXAM.

ROOM

3170 X 5705

7975 X 7985

WAITING

BLOCK-2 F

IRST FLOOR PLAN

LABOUR

2910 X 6270

TREATMENT

ROOM

3990 X 6290

WW

WW

WW

WW

WW

WW

W1

W1

W1

W1

W1

W1

W

W

W

NURSING

STATION

TREATMENT

ROOM

3050 X 5365

D

SERVICE

ROOM

3335 X 6270

30006500

6500

6500

6500

6500

6500

6910

6910

X15

6500 3000 6500

70 00

7000

7000

7000

4650

5540

7000

7000

7 000

7000

Y

Y1

5595 905

Y2

Y3

Y4

Y5

Y Y1

Y2

Y3

Y4

Y5

4895

XX1

X2

X3

X4X5

X6

X7

X8

X16

X17

X18

X19

X20

X21

X22

7000

610

140°

1 40 °

140 °

140 °

1 40 °

144°

14 4°

1 44 °

4895

7 020

1 48 0

X10

X11

X12

X13

X14

12 55

144°

144°

144°

X9

3000

6500

6500

6500

6500

6500

6500

6500

6500

6500

65006500

Y Y1

Y2

Y3

XX1

X2

X3

X4

X5

X6

X7

X8X9

V1

UP

DN

ROOM

3130 X 6640

V1

D1

D1

D1

D1

D1

D1

WW

WW

WW

W W

W1

W1

W1

W1

W1

W1

W1

W1

W1

W1

W1

W1

W1

W2

- - - 2400 W I DE PASSAGE - - -

2085X3000

SCRUB

INSTRUMENT

2085X3000

info@

ddfgrou

p.com

DDF Consultan

ts Pvt. L

td.

NEW D

ELHI-1

10034 PH: 47400500

NETAJI S

UBHASH PLACE, PITAMPURA

www

.ddfgro

up.com

AN(IS

O - 9

001 : 2

000 CERTIFIED)

501, B

-9 I.T

.L TWIN TOWER,



MEP CONSULTANT :

DEALT

DWG. N

O.

Revis

ion Suffix

APPROVED BY

DRAWN

SCALE

REF. N

O.

CHECKED

BY

DATE

NORTH

SUFFIX

DATE

DETAILS

REVISIO

NS DETAILS

ISSUED BY

TITLE OF DRAWING:

USIDCL



HOSPITAL BUILDING (R

.C.P.)

BLOCK - 0

1 ( G

ROUND FLOOR PLAN )

3601-0

2-AR-02

DDF-BHP/03601

REE

NA

23-06

-11

DEE

PAK

SINGH

1:350

DEEP

AK SIN

GH

BLOCK =02

BLOCK =03

BLOCK =01

KEY PLAN

BLOCK - 0

2 ( F

IRST FLO

OR PLAN )

USIDCL


FRASTRUCTURE DEVELO

PM

ENT

CORPORATIO

N LTD.

UNIT BHIM

TAL (N

AIN

ITAL)

CLIENT'S

NAME:

EXAMINATION

EXAMINATION

ECG

FRACTURE

TREATMENT

X-RAY

MEDICO

RESUSITATION

EMERGENCY

WARD

CLINICAL LAB

OBSERVATION ROOM

BLOOD STORE

DRUG

DISPENCING

ON DUITY

NURSE

ON DUITY

DOCTOR

DRIVER

PANTRY

6490X6640

CHANGE ROOM

6270 X 6640

3130 X 3205

3130 X 3205

3130 X 6640

6050 X 6640

3130 X 6640

3130 X 6640

2910 X 6640

H. TOILET

1880X2100

LIFT

2740X3000

LIFT

2740X3000

O.T.

6270 X 6640

3130 X 3200

3130 X 3200

3130 X 3200

2910 X 6640

2910 X 6640

6490 X 6640

2910 X 6640

6270 X 6640

3640 X 2215

3640 X 2100

3640 X 2100

- - - 2400 WIDE PASSAGE - - -

RECEPTION

3025 X 3000

6155 X 3230

3360 X 3000

WAITING LOBBY

12770 X 12910

BLOCK-1 GROUND FLOOR PLAN

G. TOILET

3130X4310

B. TOILET

3300X4310

EXAMINATION

W3

VV

GL

DD

D

D

DD

DD1

D1

D1

D1

D1

D1

D1

D1

D2

D

D1

D1

D1

D1

D3

D3

D4

D4

D1

D1 D1

- 103 -

W1

TERRACE

30006500

6500

6500

6500

6500

6500

6910

6910

X15

6 500 3000 6500

70 00

7000

70 00

7 000

4650

5540

7000

7000

7000

7000

Y

Y1

5595 905

Y2

Y3

Y4

Y5

Y

Y1

Y2

Y3

Y4

Y5

4895

XX1

X2

X3

X4X5

X6

X7

X8

X16

X17

X18

X19

X20

X21

X22

7000

610

140°

140°

140°

140°

140°

144°

144°

14 4°

4895

70 20

1480

X10

X11

X12

X13

X14

1255

14 4°

144°

144°

X9

DEEPAK SIN

GH

BLOCK =02

BLOCK =03

BLOCK =01

KEY PLAN

V900

W3000

900

LINTEL LVL.

S.N

O.

INDICATION

WIDTH

SILL

LVL

HEIGHT

1.2.3.4.5.6.7.

900

W1

2100

900

1200

DOOR &

WINDOW DETAIL

D-

2100

1500

2100

D1

-2100

1000

2100

D2

-2100

1200

2100

D3

-2100

750

2100

2100

2100

2100

1200

1200

8.D4

-2100

1800

2100

UP

DN

LIFT

2700 X 3000

LIFT

2700 X 3000 LOBBY

5630 X 3270

UP

W

LIFT

2700 X 2700

2700 X 2700

LIFT

LOBBY

12055 X 7335

GL

D2

D

W

D

W1

BLOCK-2 TERRACE PLAN

USIDCL



CORPORATION LTD.

UNIT BHIMTAL (NAINITAL)

info@

ddfg

roup.co

m

DDF Consulta

nts Pvt. L

td.

NEW DELHI-110034 PH: 4

7400500

NETAJI S

UBHASH PLACE, P

ITAMPURA

www.ddfg

roup.co

m

AN(IS

O - 9

001 : 2

000 CERTIFIED)

501, B

-9 I.T

.L TWIN TOWER,

CLIENT'S NAME:



MEP CONSULTANT :

DEALT

DW

G. N

O.

Revision Suffix

APPROVED BY

DRAWN

SCALE

REF. N

O.

CHECKED BY

DATE

NORTH

SUFFIX

DATE

DETAILS

REVISIONS DETAILS

ISSUED BY

TITLE OF DRAWING:

USIDCL



HOSPITAL BUILDING

BLOCK - 0

2 ( T

ERRACE PLAN )

3601-02

-AR-02

DDDF-BHP/03

601

REENA

23-0

6-11

DEEPAK SINGH

1:300

- 104 -

& LINEN

INSTRUMENT

3090 X 6270

CONL.&EXAM.

ROOM

3270 X 5365

CONL.& EXAM.

ROOM

3170 X 5705

SERVICE

ROOM

3130 X 6270

RECEPTION

30006500

6500

6500

6500

6500

6500

6910

6910

X15

6500 3000 6500

70 00

7000

7000

70 00

4650

5540

7000

7000

7000

7000

Y

Y1

5595 905

Y2

Y3

Y4

Y5

Y Y1

Y2

Y3

Y4

Y5

4895

XX1

X2

X3

X4X5

X6

X7

X8

X16

X17

X18

X19

X20

X21

X22

7000

610

140°

140 °

140°

1 40°

140°

144°

144°

144°

4895

70 2 0

14 8 0

X10

X11

X12

X13

X14

1255

14 4°

14 4°

1 44°

X9

3000

6500

6500

6500

6500

6500

6500

6500

6500

6500

65 0065 00

Y Y1

Y2

Y3

XX1

X2

X3

X4

X5

X6

X7

X8

X9

ARCHITECT`S SIGNATURE :

CLIENT`S SIGNATURE :

NORTH

WW

WW

WW

WW

WW

WW

W

W

W

W

W

W

W

W

D1

D1

D1

D1

D1

D1

D1

D1

D1

D1

W1

W1

W1

W1

W1

W1

W1

W1

D1

D1

D1

D1

D1D1

D1

D1

D1

D1

D1

D1

W1

W1

W1

W1

W1

W1

WW

W

W1

W

W1

D4

W

W

D1

D1

W1

W1

DD1

D1

D1

D1

D1

D1

D1

D1

DD

DD

D4

W1

D1

UP

DN

LIFT

2700 X 3000

LIFT

2700 X 3000

LOBBY

5630 X 3270

W1

W1

14.76 SQMT.

USIDCL

UTTARAKHAND STATE INFRASTRUCTURE DEVELOPMENT

CORPORATION LTD.


CLIENT'S NAME:

TITLE OF DRAWING:

USIDCL



HOSPITAL BUILDING (R.C.P.)

BLOCK - 0

1 ( F

IRST FLOOR PLAN )

BLOCK =02

BLOCK =03

BLOCK =01

KEY PLAN

SPECIALIST

ROOM

3150 X 5365

PLASTER

ROOM

2760 X 6630

CONL.& EXAM.

ROOM

3995 X 6585

H.O.D

ROOM

3806 X 6280

SPECIALIST

ROOM - 1

3275 X 5580

SPECIALIST

ROOM - 2

3255 X 5580

SPECIALIST

ROOM

3380 X 5365

H.O.D

ROOM

3795 X 6275

CARDIOGRAPHIC

EXAM.

2965 X 6275

CONL.& EXAM.

ROOM

3270 X 6270

PLASTER

CUTTING

ROOM

2770 X 6300

CONL.& EXAM.

ROOM

3385 X 6635

RECOVERY

ROOM

3160 X 6615

CONL.&EXAM.

ROOM

3350 X 6640

CONL.&EXAM.

ROOM

3410 X 6640

6490 X 6270

O.T.

6490 X 6270

O.T.

9185 X 6270

CHANGE ROOMS

3130 X 6270

STORAGE

STERILE

2945 X 6270

CASULATY

FRACTURE

PLASTER

2945 X 6280

PREPARATION

9630 X 6270

RECOVERY ROOM

6270 X 6270

PREOPERATIVE

2910 X 6270

3355 X 6270

ROOM

ANAESTHESIA

CONL.&EXAM.

ROOM

3165 X 6640

CONL.&EXAM.

ROOM

3380 X 6640

CONL.&EXAM.

ROOM

3050 X 5365

INSTRUMENT

2010X2400

SCRUB

2295X2400

CLERICAL STAFF

7990 X 7985

WAITING

- - - 2400 WIDE PASSAGE - - -

- - - 2400 WIDE PASSAGE - - -

CONL.& EXAM.

ROOM

3350 X 5675

CONL.& EXAM.

ROOM

3265 X 6265

BLOCK-2 SECOND FLOOR PLAN

ANAESTHETIST

MEDDICALCLINIC

WAITING AREA

13550 X 6505

TREATMENT

ROOM

3985 X 6290

ORTHOPADEIC

WAITING AREA

13550 X 6520

WW

WW

WW

W

W W

VV

VW1

W1

W1

W1

W1

W1

W1

W1

W1

W1

W1

GL

DD

DD

DD

DD

D1

D1

D1

D1

D1

D

D1

D1

D1

D1

D1

D

D1

D1

DD

DD

D1

W1

W1

D1

D1

D1

BLOCK-1 FIRST FLOOR PLAN

UP

DN

CUTOUT

500X2100

6275 X 9270

WAITING

6050 X 6640

MINOR O.T.

- - - 2400 WIDE PASSAGE - - -

STERILIZATION

INSTRUMENT

4215X2805

2405X3000

SCRUB

INSTRUMENT

1695 X 3000

- - - 18 00 WID E PASS AG E - - -

- - - 2400 WI DE PAS SAG E - - -

BLOCK - 0

2 ( S

ECOND FLOOR PLAN )

DOCTOR

ON DUITY

3130 X 6640

NURSE

3130 X 6640

CLINICAL LAB

2910 X 6640

ROOM

EXAMINATION

ROOM

COUNCILLING

6270 X 6640

CHANGE ROOM

2910 X 6640

LINEN STORE

2910 X 6640

EQUIP. STORE

6490 X 6640

MINOR O.T.

6270 X 6640

O.T.

6490 X 6640

OT-4

2405X3000

SCRUB

INSTRUMENT

1695X3000

2010 X 2400

SCRUB

INSTRUMENT

2115 X 2400

2395X4940

ARE

A FOR

SERVICES

- - - 2400 W

IDE

PASS

AGE

- - -

G. TO

ILET

31

30X4310

B. TO

ILE

T

3300X

4310

3130 X 6640

WW

FEMALE

TOILET

3565X

4125

D1

FEMALE

TOILET

3600 X 6275

V

V

LOB

BY

12055 X 7335

GL

D1D1

D2

WAIT

ING

AREA

13890 X 6775

D3

D3

D3

D2

H. TOILET

1880X2100

LIFT

2740X3000

LIFT

2740X

3000

I.C.U.

6490 X

6640

I.C

.C.U

.

6270 X 6640

R.I.C.U.

6270 X 6640

N.I.C

.U.

6490 X 6640

P.I.C

.U.

6270 X 6640

ON DUITY

2910 X 6640

UP

W

LIFT

2700 X 2700

2995 X 5000

B. TOILET

WATER

DRINKING

3775 X 3100

G. TOILET

1720 X 1670

2700 X 2700

LIFT

- - - 24 00 WI DE PASSAGE - - -

- - - 2400 WIDE PASSAGE - - -

V

V

W1

W1

W1

W1

W1

W1

WW W1

W

W

D1

- 105 -

USIDCL


CORPORATION LTD.


info@

ddfg

roup.com

DDF Consulta

nts Pvt. L

td.

NEW DELHI-1

10034

PH: 4

7400500

NETAJI S

UBHASH PLACE, P

ITAMPURA

www.ddfg

roup.co

m

AN(IS

O - 90

01 : 2

000 CERTIFIED)

501, B

-9 I.T.L TWIN TOWER,

CLIENT'S NAME:



MEP CONSULTANT :

DEALT

DWG. NO.

Revisio

n Suffix

APPROVED BY

DRAWN

SCALE

REF. NO.

CHECKED BY

DATE

NORTH

SUFFIX

DATE

DETAILS

REVISIO

NS D

ETAILS

ISSUED BY

TITLE OF DRAWING:

USIDCL



HOSPITAL

ELE

VATIO

N-A &

B AND SECTIO

N X

-X & Y-Y

3601-0

6-AR-01

DDF-B

HP/03601

REENA

28-05-11

AMIT

1:200

AMIT

ELEVATION -A

ELEVATION -B

SECTION X-X

SECTION Y-Y

- 106 -

NURSING

STATION

SERVICE

ROOM

3335 X 6270

TOILET

6270 X 5100

D4

LOBBY & WAITING AREA

11785 X 16100

6500300

0

6500

XX1

X2

X3

X4

X5

X7

X9

Y

Y1

Y2

Y3

6500

6500

6500

6500

6500

6500

65 00

6500

6500

6500

65 00

6500

3482

X6

X10

X8

X11

X12

X13

6500

3000

6500

6858

4126

2851

2765

2550

30006500

6500

6500

6500

6500

6500

6910

6910

X15

6500 3000 6500

7000

70 00

7000

70 00

46 50

5540

7000

7000

7000

7000

Y

Y1

5595 905

Y2

Y3

Y4

Y5

Y Y1

Y2

Y3

Y4

Y5

4895

XX1

X2

X3

X4

X5

X6

X7

X8

X16

X17X18

X19X2

0X21

X22

7000

610

1 40°

140°

1 40 °

140°

140°

1 44°

144°

144°

4895

7 02 0

1 48 0

X10

X11

X12

X13

X14

1255

144°

1 44 °

144 °

X9

UP

DN

D4

W

W

W1

LIFT

2700 X 3000

LIFT

2700 X 3000 LOBBY

5630 X 3270

14.76 SQMT.

UP

LIFT

2700 X 2700

2995 X 5000

B. TOILET

3775 X 3100

G. TOILET

2700 X 2700

LIFT

- - - 240 0 WIDE PASS AGE - - -

- - - 2400 WIDE PASSAGE - - -

V

V

W

FEMALE

TOILET

3565X4125

D1

FEMALE

TOILET

3600 X 6275

VV

- - - 2400 WIDE PASSAGE - - -

- - - 2400 WIDE PASSAGE - - -

- - - 2400 WIDE PAS SAGE - - -

- - - 240 0 WIDE PASS AGE - - -

- - - 2400 WIDE PASSAGE - - -

WAITING AREA

13890 X 6775

BLOCK-2 LOWER GROUND FLOOR PLAN

CHEST & RESPIRATORY

& CARDIOLOGYT

WAITING AREA

13550 X 6500

D1

D1

D1

D1

D1

D1

D1

D1

D1

D1

D1

D1

D1

D1

D1

D1

D1

D1

D1

D1

D1

D1

D1

D1

D1

D1

D1

D1

D1

D1

DD

D

DD

W1

W1

W1

W1

W1

W1

W1

W1

W1

W1

W1

W1

W1

W1

W1

W1

W1

W1

W1

W1

W1

W1

W1

W1

W1

W1

W1

W1

W1

WW

W1

WW

WW

WW

WW

WW

WW

W

W

W

W

W

W

W

W

WW

WW1

W

W1

info@ddfgrou

p.com

DDF Consultants Pvt. L

td.

NEW D

ELHI-1

10034 PH: 47400500

NETAJI S

UBHASH PLACE, P

ITAMPURA

www.ddfgrou

p.com

AN(IS

O - 90

01 : 2

000 C

ERTIFIED)

501, B

-9 I.T

.L TWIN TOWER,



MEP CONSULTANT :

DEALT

DWG. N

O.

Revision Suffix

APPROVED BY

DRAWN

SCALE

REF. N

O.

CHECKED BY

DATE

NORTH

SUFFIX

DATE

DETAILS

REVIS

IONS DETAILS

ISSUED BY

TITLE OF DRAWING:

USIDCL



HOSPITAL BUILDING (R.C.P.)

360

1-02-AR

-02DDF-B

HP/0360

1

REE

NA

23-06-11

DEEPAK

SINGH

1:350

DEE

PAK SINGH

USIDCL


CORPORATION LTD.

UNIT BHIM

TAL (NAINITAL)

CLIENT'S NAME:

LOBBY

12055 X 7335

GL

W

D1D1

D2

D2

NURSING

STATION

6365 x 6640

WARD-2

6270 X 6640

WARD-3

6395 x 6640

WARD-4

3020X4270

NURSE

ON DUITY

DOCTOR

ON DUITY

3020X4270

NURSING STATION

- - - 2400 WIDE PASSAGE - - -

- - - 2400 WIDE P ASSAGE - - -

3020X4270

NURSE

ON DUITY

DOCTOR

ON DUITY

3020X4270

LIFT

2.5X3.0

LIFT

2.5X3.0

6365x6635

WARD-2

6365x6635

WARD-3

6365x6635

WARD-4

6380 X 6640

WARD

6380 x 6640

WARD

6270 x 6652

WARD

6270 X 6640

WARD

6380 x 6640

WARD

6380 x 6645

WARD

TERRACE

TERRACE

W

W

W

W

W

W

W

W

WW

W

W1

W1

W1

W1

TOILET

6270 X 5095

V1

V1

D1

D1

D1

D1

D2

D2

D2

D2

D2

D2

D2

D2

D2

D2

D2

D2

D3

D3

D3

D3

D4

BLOCK-3 S

ECOND FLOOR PLAN

LVL +7200

LVL +7200

UP

DN

RAMP DOWN

RAMP DOWN

ENT & EYE CLINIC

INVESTIGATION

ROOM

3270 X 6040

INVESTIGATION

ROOM

3410 X 6040

TREATMENT

ROOM

3350 X 6040

AUDIOMETRIC

ROOM

2760 X 6260

CONL.& EXAM.

ROOM

4000 X 6990

H.O.D

ROOM

3980 X 5760

SPECIALIST

ROOM - 1

3160 X 6130

SPECIALIST

ROOM - 2

3160 X 6135

DARK ROOM

2770 X 5770

MINOR

SURGERY&

TREATMENT

ROOM

2540 X 6965

CONL.& EXAM.

ROOM

4000 x 6260

H.O.D

ROOM

4000 X 5760

TREATMENT

ROOM

2330 X 5770

SPECIALIST

ROOM - 1

3265 X 6135

SPECIALIST

ROOM - 2

3265 X 6135

SPECIALIST

ROOM

3380 X 6140

H.O.D

ROOM

3800 x 6280

CONL.&

EXAM.

ROOM

2745 x 6280

CONL.& EXAM.

ROOM

3270 X 6265

CONL.& EXAM.

ROOM

3265 X 6265

CONL.& EXAM.

ROOM

3160 X 5770

CONL.& EXAM.

ROOM

3160 X 5770

TREATMENT

ROOM

3270 X 6040

19270 X 6270

DIALYSIS

12770 X 6270

ENDOSCOPY

9630 X 6270

CT SCAN

6270 X 6270

X-RAY

6490 X 6270

CONTRAST STUDIES

FILM DEVEOPING/ DRYING/

RADIOLOGIST

TECHNICIAN

CLERICAL STAFF

STORES

2910 X 6270

3130 X 6270

3130 X 6270

WAITING AREA

13550 X 6520

WAITING

8065 X 7900

- 107 -

LOBBY & WAITING AREA

11785 X 16100

6500300

0

6500

XX1

X2

X3

X4

X5

X7

X9

Y

Y1

Y2

Y3

6500

6500

6500

6500

6500

6500

650 0

6500

65 00

6500

650 0

6500

3482

X6

X10

X8

X11

X12

X13

6500

3000

6500

6858

4126

2851

2765

2550

30006500

6500

6500

6500

6500

6500

6910

6910

X15

6500 3000 6500

7000

7000

70 00

7000

4650

5540

700 0

7000

7000

7000

Y

Y1

5595 905

Y2

Y3

Y4

Y5

Y Y1

Y2

Y3

Y4

Y5

4895

XX1

X2

X3

X4

X5X6

X7

X8

X16

X17

X18

X19

X20

X21

X22

7000

610

14 0°

1 40 °

140°

140°

14 0°

1 44 °

144°

1 44°

4895

70 2 0

14 8 0

X10

X11

X12

X13

X14

125 5

144 °

14 4°

14 4°

X9

info@ddfg

roup

.com

DDF Consultan

ts Pvt. L

td.

NEW DELHI-1

10034 P

H: 47400500

NETAJI S

UBHASH PLACE, PIT

AMPURA

www.ddfg

roup.com

AN(IS

O - 90

01 : 2

000 CERTIFIE

D)

501, B

-9 I.T

.L TWIN TOWER,



MEP CONSULTANT :

DEALT

DWG. N

O.

Revis

ion Suffix

APPROVED BY

DRAWN

SCALE

REF. N

O.

CHECKED BY

DATE

NORTH

SUFFIX

DATE

DETAILS

REVISIONS DETAILS

ISSUED BY

TITLE OF DRAWING:

USIDCL



HOSPITAL BUILDING (R

.C.P.)

3601-0

2-AR-02

DDF-B

HP/036

01

REE

NA

23-0

6-11

DEEPA

K SINGH

1:350

DEEPA

K SINGH

USIDCL


CORPORATION LTD.

UNIT BHIMTAL (N

AINITAL)

CLIE

NT'S NAME:

D1

FEMALE

TOILET

3565X

4125

FEMA

LE

TOILET

3600 X 6275

V

V

LOB

BY

12055 X 7335

GL

D1D1

D2

WAITING AREA

13890 X 6775

D4

D3

D3

D2

6270 x 6642

WAR

D-3

6395 x 6645

WARD-4

3020X4270

NURSE

ON DU

ITY

DOCTOR

ON DUITY

3020X4270

NUR

SING

STATIO

N

- - - 2400 WIDE PASSAGE - - -

- - - 240 0 WIDE PASSA GE - - -

3020X4270

NURSE

ON DUITY

DOCTOR

ON DUITY

3020X4270

LIFT

2.5X3.0

LIFT

2.5X3.0

6270 x 6667

WAR

D-3

6395 X 6665

WARD-4

6400 x 6640

WARD

6380 X

6640

WARD

6270 X 6640

WARD

6270 X 6640

WARD

TERRACE

TERRACE

TREATMENT

ROOM

3350 X 6640

SOCIAL

WORK

ER

ROOM

3165 X 6640

CON

L.& EXAM.

ROOM

3180 X 5705

H.O

.D

RO

OM

3980 X 6290

SPECIALIST

ROOM - 1

3385 X 6630

RECOVERY

RO

OM

3150 X 6625

H.O.D

ROOM

3985 X 6270

H.O.D

ROO

M

3800 X 6275

W

W

W

W

V1

W

W

W

W

W1

W1

W1

W1

W

TOILET

6255 X 5095

TO

ILET

6270 X 5100

V1

D2

D2

D2

D2

D2

D2

D2

D2

D3

D3

D3

D3

D1

D1

D1

D1

D4

D4

BLOCK-3 THIRD FLOOR PLAN

LVL +10800

LVL +10800

UP

DN

CO

NL.& EXAM.

ROOM

2965 X 6275

DENT.

HYG

INIST

RO

OM

2770 X 6290

IMM

UNIZATION

ROOM

3410 X 6640

SPECIALIST

ROOM

3150 X 5365

SPECIALIST

ROOM

3380 X 5365

CONL.& EXAM.

ROOM

3270 X 5365

CONL.& EXAM.

ROOM

3040 X 5365

3095 X 6270

LAB-1

2945 X 6270

LAB-2

3095X 6270

LAB-3

RECORD

2945 X 6270

2945 X 6270

TECH

NICIAN

DISPOSAL

& SPECIMEN

3095 X 6270

BIOCHEMISTRY

2945 X 6270

MICROB

IOLOGY

3095 X 6270

MEDIA ROOM

2945 X 6270

PATHOLOGY

CLINICAL

3315 X 6270

HISTOLOGY

2720 X 6270

STERILIZING

WASHING &

STORES

3130 X 6270

2945 X 6270

ULTRA VIOLET

3090 X 6270

INFRA RED

3130 X 6270

RADIANT HEAT

TRACTION

TREATMENT

COMBINED

2945 X 6270

TRACTION

TREATMENT

COMBINED

2950 X 6270

GYM

2915 X 6270

OFFICE

3085 X 6270

PHYSIOTHER

APIST

CONL.& EXAM.

ROOM

3275 X 5575

PLASTER

3560 X 6595

FRACTURE

3200 X 6630

PLASTER

CU

TTING

2770 X 6300

CONL.& EXAM.

ROOM

3355 X 5675

OFFICE &

- - - 2400 W

IDE PASSAGE - - -

- - - 2400 WIDE PASSAGE - - -

RA MP DOWN

PHARMACY

3260 X 5580

SERVICES

3135 X 6270

AREA FOR


CENTRAL

INJECTION

ROOM

3265 X 6280

SPECIMEN

COLLECTION

ROOM

3380 X 6640

WAITING

7995 X 7985

HYDROTHERAPY

3125 X 6270

ORTHO

PAEDIC

&

DENTAL

WAIT

ING

AREA

13550 X 6520

D1

D1

D1

D1

NEPHR

OLOG

IC CLINIC &

OBS

TECT

RIC

& GYNAE

13550 X 6505

D1

D1D1

D1

D1

D1

D1

D1

D1

D1

D1

D1

D1D1

D1

D1

D1D1

D1

D1

D1

D4

WW

WW

WW

WW

WW

W

W1

W1

W1

W1

W1

W1

W1

W1

W1

W1

UP

W

WW

W

W1

W

W1

D1

D1

D1

D1

D1

D1

D1

W1

W1

W1

W1

W1

W1

W1

W1

D1

D1

D1

D1

D1

D1

D1

D1

D1

W1

W1

W1

W1

W1

W1

W1

W1

D1

D1

D1

D1

W

W

W

W

W

W

W

W

D4

W

W

W1

D1

UP

DN

LIFT

2700 X 3000

LIFT

2700 X 3000 LOB

BY

5630 X 3270

W1

W1

14.76 SQ

MT.

REC

EPTION

RAMP DOWN

LIFT

RAMP

GROUN

D TO

FIR

ST FLOOR

2700 X 2700

2995 X 5000

B. TOILET

3775 X 3100

G. TOILET

2700 X 2700

LIFT

RECEPTION

REC

EPTION

OFF

ICE

2630 X

3655

REC

EPTION

OFFICE

2630 X 3655

- - - 2 400 WIDE PASS AGE - - -

- - - 2 400 WIDE PASS AGE - - -

- - - 2400 WIDE PASSAGE - - -

V

V

WW

W1

W

- 108 -

LIFT

2.5X3.0

LIFT2.5X

3.0

TERRACE

D2

BLOCK-3 TERRACE PLAN

LVL +

14400

USIDCL



CORPORATION LTD.

UNIT BHIM

TAL (NAINITAL)

info@ddfgrou

p.com

DDF Consu

ltants Pvt. Ltd.

NEW DELHI-1

10034 PH: 47400500

NETAJI SU

BHASH PLACE, P

ITAMPURA

www.d

dfgroup.com

AN(IS

O - 900

1 : 2000 C

ERTIFIED)

501, B-9

I.T.L TWIN TOWER,

CLIENT'S NAME:



MEP CONSULTANT :

DEALT

DWG. N

O.

Revis

ion Suffix

APPROVED BY

DRAWN

SCALE

REF. N

O.

CHECKED BY

DATE

NORTH

SUFFIX

DATE

DETAILS

REVISIONS DETAILS

ISSUED BY

TITLE OF DRAWING:

USIDCL



HOSPITAL BUILDING

3601-02

-AR-03C

DDF-BHP/036

01

REENA

23-06-11

DEEPAK SING

H

1:250

DEEPAK SINGH

W

BLOCK =02

BLOCK =03

BLOCK =01

KEY PLAN

DN

6500

3000

6500

XX1

X2

X3

X4

X5

X7

X9

Y

Y1

Y2

Y3

6500

6500

6500

6500

6500

6 500

6500

6500

6500

6500

65 00

6500

3 4 82

X6

X10

X8

X11

X12

X13

6500

3000

6500

6858

4126

2851

2765

2550

- 109 -

LOBBY & W

AITIN

G AREA

11785

X 16100

65003000

6500

XX1

X2

X3

X4

X5

X7

X9

Y

Y1

Y2

Y3

6500

6500

6 500

6500

65 00

6500

6500

6500

6500

6500

6500

6500

34 82

X6

X10

X8

X11

X12

X13

6500

3000

6500

6858

4126

2851

2765

2550

USIDCL


CORPORATION LTD.

UNIT BHIMTAL (N

AINITAL)

info@dd

fgroup.co

m

DDF C

onsulta

nts Pvt. L

td.

NEW

DELHI-1

10034 PH: 47

400500

NETAJI SUBHASH PLACE, P

ITAMPURA

www.ddfgrou

p.com

AN(IS

O - 9

001 : 2

000 C

ERTIFIE

D)

501, B

-9 I.T

.L TW

IN TO

WER,

CLIENT'S NAME:



MEP CONSULTANT :

DEALT

DWG. N

O.

Revis

ion Suffix

APPROVED BY

DRAWN

SCALE

REF. N

O.

CHECKED BY

DATE

NORTH

SUFFIX

DATE

DETAILS

REVISIO

NS DETAILS

ISSUED BY

TITLE OF DRAWING:

USIDCL



HOSPITAL BUILDING

3601-0

2-AR-03C

DDF-BH

P/03601

REENA

23-06-11

DEEPAK SIN

GH

1:250

DEEPAK SINGH

BLOCK =02

BLOCK =03

BLOCK =01

KEY PLAN

RAMP DO

WN

ROOM

16

ROOM

15

ROOM 14

ROOM 13

NURSING

STATION

TERRACE

3115X

6665

Room

-13115X

6665Room-2

3115X

6665

Room

-33115

X6665

Room-4

3115X6665

Room-5

3115X6665

Room-6

3115

X6665

Room

-73115X

6665

Room-8

3115X6665

Room-9

3115

X6665

Room-10

6365

x6635

WARD-1

TOILET

1.5X1.8

TOILET

1.5X1.8

TOILET

1.5X1.8

TOILET

1.5X1.8

TOILET

1.5X1.8

TOILET

1.5X1.8

TOILET

1.5X1.8

TOILET

1.5X1.8

TOILET

1.5X1.8

TOILET

1.5X1.8

WC

1.5X1.8

BATH

1.5X1.8

6365x

6635

WARD-2

6365x

6635

WARD-3

6365x

6635

WARD-4

3020X4270

NURSE

ON DUITY

DOCTOR

ON DUITY

3020X4270

NURSING

STATION

WC

1.5X1.8

BATH

1.5X1.8

WC

1.5X1.8

BATH

1.5X1.8

WC

1.5X1.8

BATH

1.5X1.8

- - - 2400 W

IDE P

A SSAG

E - - -

- - - 2400 WI DE PASSAG

E - - -

3020X

4270

NURSE

ON D

UITY

DOCTOR

ON D

UITY

3020X

4270

LIFT

2.5X3.0

LIFT

2.5X3.0

TERRACE

W

W

W

W

W

W

W

W

W1

W1

W1

W1

W2

W2

W2

W2

W2

W2

W2

W2

W2

W2

W2

W2

W2

W2

W2

W2

W2

W2

V

V

V

V

VV

VV

VV

VV

VV

6270 X 66

40

WARD-10

6380

X 6640

WARD-09

TOILET

6270 X

5095

6270 X 66

40

WARD-11

6380

X 6640

WARD-12

V1

D1

D1

D1

D1

D1

D1

D1

D1

D1

D1

D1

D1

D1

D1

D

D

D

D

DD

D

D

D

DD

DD

D

D

DD

D

D2

D2

D2

D2

D2

D2

D2

D2

D2

D2

D2

D2

D3

D3

D3

D3

D4

BLOCK-3 FIRST FLOOR PLAN

LVL +3600

LVL +3600

UP

DN

- 110 -

WAITING

LOBBY

6500 X 6240

WAITIN

G

LOB

BY

6490 X 60

40

STE

WARDS &

STAFF

3060 X

6640

COOKIN

G AREA

19270

X 16140

LOB

BY & W

AITING AR

EA

11785

X 16100

KITCHEN

RECEIPT

COUNTER

2740 X 6640

DRY RATION

STORAGE

3300 X 6640

DIETIC

IAN

3200 X 6640

WALK

IN CO

LD

STO

RAGE

3000 X 6640

WASH

ING AR

EA

9540 X 6640

UPDN

6500

3000

6500

XX1

X2

X3

X4

X5

X7

X9

Y

Y1

Y2

Y3

6500

6500

6500

6500

6500

6500

6500

6500

6500

6500

6500

6500

34 8 2

X6

X10

X8

X11

X12

X13

6500

3000

6500

6858

4126

2851

2765

2550

USIDCL



CORPORATION LTD.


info@ddfg

roup.co

m

DDF Consultan

ts Pvt. Ltd

.

NEW DELHI-1

10034 PH: 47400500

NETAJI S

UBHASH PLACE, P

ITAMPURA

www

.ddfgroup

.com

AN(ISO - 9001 : 2000 CERTIFIED)

501, B-

9 I.T.L TW

IN TO

WER,

CLIE

NT'S NAME:



MEP CONSULTANT :

DEALT

DWG. N

O.

Revisio

n Suffix

APPRO

VED BY

DRAWN

SCALE

REF. NO

.

CHECKED BY

DATE

NORTH

SUFFIX

DATE

DETA

ILS

REVISIONS DETAILS

ISSUED BY

TITLE OF D

RAWING:

USIDCL



HOSPITAL BUILDING

BLOCK - 03

( GROUND FL

OOR PLAN )

3601-02

-AR-03

DDF-B

HP/03601

REE

NA

23-06-11

DEE

PAK

SINGH

1:250

DEE

PAK

SINGH

CSS

D93

20 X 16165

W

W

W

W

W

W

W

W

W

W

W

W

W

W

W

W

W

LIFT2.5X

3.0

LIFT

2.5X3.0


D3

D3

D3

BLOCK =02

BLOCK =03

BLOCK =01

KEY PLAN

LAUNDARY

SUPERVISOR

OFFICE

3130 X 6665

LAUNDARY

STAFF ROOM

3130 X 6665

DIRTY CLOTHES

RECEIVING &

SORTING

2660 X 6640

WAITING

LOBBY

3600 X 9270

TAILOR DESK

2700 X 6665

BOILER

ROOM

2700 X 6640

LAUND

RY

9840 X

16165

RECEIPT

COUNTER

5190 X 2800

TECHNICIANS

ROOM

3000 X 6640

CLASS ROOM

3130 X 6665

OFFICER IN

CHARGE

3145 X 6665

- 111 -

additional conditions of contract accengineeringprojects.com/tender/uploadfiles/1582_vol--ii.pdf ·...

Documents