1446815317312_new tender snt ju 24r 15 16
DESCRIPTION
tender NWRTRANSCRIPT
Signature of Tenderer/s Page 1 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
NORTH WESTERN RAILWAY
TENDER DOCUMENT
[Tender No. S&T/JU/24R/2015-16]
Name of work: Replacement of Batteries on age-cum-condition basis for
OFC Huts at 11 stations viz. RKB, MDB, MMY, TIW, SRK, MWT, STSN, KRC, KHTU, GOTN, SWF over Jodhpur division in North Western Railway.
OFFICE OF THE
Sr.DIVISIONAL SIGNAL & TELECOM
ENGINEER/WORKS NORTH WESTERN RAILWAY
JODHPUR
-------------------------------------
Price Rs. 3000/-
By Post Rs3500/--
Signature of Tenderer/s Page 2 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
TENDER DOCUMENT
Name of work: Replacement of Batteries on age-cum-condition basis for OFC Huts at 11 stations viz. RKB, MDB, MMY, TIW, SRK, MWT, STSN, KRC, KHTU, GOTN, SWF over Jodhpur division in North Western Railway.
1. Approximate cost of work : Rs. 2187317/-
2. Earnest Money : Rs. 43750/-
3. Completion Period : 06Months.
________________________________________________________________________
Tender sale closing date : 11.12.2015 upto 13.00 Hrs
Tender to be submitted up to : 11.12.2015. upto 15.00 Hrs
Tender opening Date : 11.12.2015 Soon after closing of tender
box at 15.00 Hrs.
________________________________________________________________________
NOT TRANSFERABLE
Issued by: Sr.Divisional Signal & Telecom Engineer/Works
North Western Railway Jodhpur.
Issued to: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ __
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ __ _ ___
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ __ __
_ _ _ _ _ _ _ _ _ __ _ _ _ _ _ _ _ _ _ _ _ _ _ _ __
Signature of Tenderer/s Page 3 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
Name of work:- Replacement of Batteries on age-cum-condition basis for OFC Huts
at 11 stations viz. RKB, MDB, MMY, TIW, SRK, MWT, STSN, KRC, KHTU, GOTN, SWF over Jodhpur division in North Western Railway.
INDEX
Sr No Description Page No
From To
1. Tender Form – First Sheet 4 4
2. Tender Form – Second Sheet 5 15
3. Special Condition of Contract (General) 16 47
4. Special Conditions of Contract (Non-Technical ) 48 67
5. Annexure (Non Technical) 68 88
6. (Technical requirement for the work) 89 119
7. Annexure (Technical) 120 126
8. Schedule of work 127 128
9. Rate Form 129 129
10 End of Document 130 130
Signature of Tenderer/s Page 4 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
TENDER FORMS (FIRST SHEET) Tender No: S&T/JU/24R/2015-16
Name of work : Replacement of Batteries on age-cum-condition basis for OFC Huts at 11 stations viz. RKB, MDB, MMY, TIW, SRK, MWT, STSN, KRC, KHTU, GOTN, SWF over Jodhpur division in North Western Railway.
To
The President of India
Acting through the
Sr.DSTE/W North Western Railway
Jodhpur
1. I/We …………………..have read the various conditions to tender attached here to and
agree to abide by the said conditions. I/We also agree to keep this tender open for
acceptance for a period of 90 days from the date fixed for opening the same and in default
thereof, I/We will be liable for forfeiture of my/our “Earnest Money”. I/We offer to do the
work North Western Railway, at the rates quoted in the attached schedule and hereby bind
myself/ourselves to complete the work in all respects within 06 months from the date of
issue of letter of acceptance of the tender.
2. I/We also hereby agree to abide by the General Conditions of Contract-2013 corrected up
to date and to carry out the work according to the Special Conditions of Contract and
Standard Schedule of Rates-March 2012 for S&T Works of North Western Railway,
corrected up to date for the present contract.
3. A sum of Rs 43750/-is herewith forwarded as Earnest Money in the form of Cash or
Bankers Cheque or Demand Draft in favour of FA&CAO NWR Jaipur. The full value of
the earnest Money shall stand forfeited without prejudice to any other right or remedies in
case my/our Tender is accepted and if:-
(a) I/We do not execute the contract documents within seven days after receipt of notice
issued by the Railway that such documents are ready; and
(b) I/We do not commence the work within ten days after receipt of orders to that effect.
4. I/We have downloaded this tender document from official website of North-Western
Railway and a sum of Rs3000/- in favour of Sr.DFM NWR Jodhpur is herewith
forwarded in the form of Cash or Bankers Cheque or Demand Draft as tender fee failing
which my/our offer shall be summarily rejected.
OR
I/We have purchased the Tender Form from the office of Sr.DSTE/Works North Western
Railway on payment of Rs3000/- as prescribed fee, vide…………………. (Receipt No.)
issued by Asst Div. Cashier/Cash /NWR/Jodhpur.
5. Until a formal agreement is prepared and executed, acceptance of this tender shall
constitute a binding contract between us subject to modifications, as may be mutually
agreed to between us and indicated in the letter of acceptance of my/our offer for this work.
Signature of Witness:- …….....……………
(1)………………… Signature of Tenderer(s)
(2)………………… Date………..
Signature of Tenderer/s Page 5 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
Address of the Tenderer(s)
TENDER FORMS (SECOND SHEET)
1. Instructions to tenders and conditions of tender: -
The following documents form part of Tender / Contract:-
(a) Tender forms – First Sheet and Second Sheet
(b) Special Conditions of Contract (enclosed)
(c) Schedule of approximate quantities (enclosed)
(d) General Conditions of Contract -2013 amended/corrected up to date as mentioned in First
Sheet of Tender Form, copies of which can be seen in the office of Sr.DSTE/JU or obtained
from the office on payment of prescribed charges.
(e) Standard Schedule of Rates(SOR)-March 2012 for S&T Works of North Western
Railway,corrected up to date as mentioned in first sheet of tender form, copies of which be
seen in the office of Sr.DSTE/JU or obtained from the office on payment of prescribed
charges
(f) All general and detailed drawings pertaining to this work which will be issued by the
Engineer or his representatives (from time to time) with all changes and modifications.
2. Drawings for the work: - The Drawing for the work can be seen in the office of the
SR.DSTE/JU at any time during the office hours. Generally the drawings are only for the
guidance of Tenderer(s). Detailed working drawings. (if required) based generally on the
drawing mentioned above, will be given by the Engineer or his representative from time to
time to successful tenderer after acceptance of his offer.
3. The Tenderer(s) shall quote his/their rates as a percentage above or below or at par the total
value of schedule of the tender. The quantities shown in the attached schedule are given as
a guide and are approximate only and are subject to variation according to the needs of the
Railway. The Railway does not guarantee work under each item of the schedule.
4. Tenders containing erasures and/or alterations of tender documents are
liable to be rejected. Any correction made by tenderer(s) in his/their entries must be
attested by him/them.
5. Earnest Money:
(a) The tender must be accompanied by a sum of Rs.43750/- as earnest money deposited in
cash or in form of Bankers cheque or Demand draft failing which the tender shall not be
considered.
(b) The Tenderer(s) shall keep the offer open for a minimum period of 90days from the date of
opening of the Tender. It is understood that the tender documents have been sold/issued to
the Tenderer(s) and the Tenderer(s), is / are permitted to tender in consideration of the
stipulation on his/their part that after submitting his/their tender subject to the period being
Signature of Tenderer/s Page 6 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
extended further if required by mutual agreement from time to time, he/they will not resile
from his/their offer or modify the terms and conditions thereof in a manner not acceptable
to the Sr.DSTE/Works/JU Should the tenderer fail to observe or comply with the foregoing
stipulation, the amount deposited as Earnest Money for the due performance of the above
stipulation, shall be forfeited by the Railway.
(c) If the tender is accepted, the amount of Earnest Money will be retained and adjusted as
Security Deposit for the due and faithful fulfillment of the contract. This amount of
Security Deposit shall be forfeited if the tenderer(s) fail to execute the Contract Agreement
within 7 days after receipt of notice issued by Railway that such documents are ready or to
commence the work within 10 days after receipt of the order to that effect.
(d) The Earnest Money of the unsuccessful tenderer(s) will, save as here-in-before provided, be
returned to the unsuccessful tender(s) within a reasonable time but the Railway shall not be
responsible for any loss or depreciation that may happen to the Security for the due
performance of the stipulation to keep the offer open for the period specified in the tender
documents or to the Earnest Money while in their possession nor be liable to pay interest
thereon.
(e) “The Earnest Money should be in the form of Cash recipt issued by Asst Div.
Cashier/Cash/NWR/Jodhpur, or/Bankers Cheque or demand drafts executed by State
Bank of India or any of the Nationalized Banks or by a Scheduled Bank.”
NOTE:
(i) Bankers Cheque and demand drafts should be drawn in favor of FA&CAO North Western
Railway Jaipur.
(ii) Deleted.
(iii) Deleted
(iv) Deleted.
(v) The facility of lump-sump earnest money will not be accepted from the registered
contractors of any railway and they are required to deposit earnest money along with their
offer.
6. Right of the Railway to deal with tender:- The authority for the acceptance of the tender
will rest with the Railway. It shall not be obligatory on the said authority to accept the
lowest tender or any other tender and no tenderers shall demand neither any explanation for
the cause of rejection of his/their tender nor the Railway to assign reasons for declining to
consider or reject any particular tender or tenders.
6.1 System of tendering:-
6.1.1 For value of tenders more than Rs. 10 (ten) crore, Two Packet System of tendering shall be
applicable. In this system, tenderers shall submit their quotations/offers in two sealed
envelopes; with one cover containing the Technical & Commercial offers and the other
Signature of Tenderer/s Page 7 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
cover containing the Financial Bids. The first packet shall be with the objective of
scrutinizing the capability, possession of appropriate machinery & equipments, financial
strength, experience etc. of the tenderers.
(a) The technical details and commercial conditions shall be read out before the tenderers or
their representatives at the time of opening of tenders and the same shall be evaluated by
the Tender Committee. If the offers are found acceptable by the competent authority (as
prescribed by Railway Board from time to time for the estimated value of tender invited),
the second packet shall be opened and the tenders shall be processed for finalization in the
normal manner.
(b) However, if on the basis of information contained in the first packet, the Tender Committee
needs clarification regarding designs, specifications etc discussions shall be held with each
individual party/tenderer after obtaining approval of the Competent Authority.
(c) Details of the documents to be submitted in the First Packet (Technical & Commercial Bid)
is given in Para 23 below. The envelope containing the First Packet (Technical &
Commercial Bid) shall be super scribed as under
First Packet (Technical & Commercial offer)
Tender No. ………………………
Name of Work……………………
(d) In the Second Packet (Financial Bid) only schedule of approximate quantities and offers
sheet of the tender documents duly filled in, stamped and signed by the tenderer (s) is to be
submitted. The envelope containing the Second Packet (Financial Bid) shall be super
scribed as under -
Second Packet (Financial Bid)
Tender No. ………………………
Name of Work……………………
(e) Both of the envelopes containing ‘Technical & Commercial offer’ and ‘Financial Bids’
shall then be put together in common envelope and submitted as detailed in Para 10 below.
6.1.2 For value of tenders upto Rs. 10 (ten) crores, normally single packet tender system will be
adopted. In this system, all the documents i.e. Technical & Commercial offer and Financial
Bid shall be sealed in one envelope only and submitted in accordance with clause 10 below.
6.2 An affidavit is required to be submitted by all tenderers (as given in Annexure- II). Based
this affidavit, Tender Committee will deliberate and decide eligibility of tenderers for first
packet.
Second packet (Finance Bid) of only eligible tenderers will be opened and relevant
documents of eligible tenderers will be got verified. The number of tenderers, whose
documents are to be got verified, will be decided by the Tender Committee.
Signature of Tenderer/s Page 8 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
If contents in documents submitted by tenderers are found to be incorrect/false action will
be taken against such tenderer’s as per provisions contained in Affidavit submitted by them
as Annexure- II.
7. If the tenderer(s) deliberately gives/give wrong information in his/their tender or creates /
create circumstances for the acceptance of his/their tender, the Railway reserves the right to
reject such tender at any stage.
8. If the tenderer(s) expires /expire after the submission of his/their tender or after the
acceptance of his their tender, the Railway shall deem such tender cancelled. If a partner of
a firm expires after the submission of their tender or after the acceptance of their tender, the
Railway shall deem such tender as cancelled, unless the firm retains its character.
9. Tenderer’s Credentials: - Documents testifying tenderer’s previously experience and
financial status should be produced along with the tender or when desired by competent
authority of the North Western Railway.
Tenderer(s) who has/have not carried out any work so far on this Railway should submit
along with his/their tender credentials to establish:-
(i) His capacity to carry out the works satisfactorily.
(ii) His financial status supported by Bank reference and other documents.
(iii) Certificates duly attested and testimonials regarding contracting experience for the type of
job for which tender is invited with list of works carried out in the past.
10. Tender must be enclosed in a sealed cover, superscripted “Tender
NoS&T/JU/24R/2015-16 and must be sent by registered post to the address of
Sr.Divisional Signal & Telecom Engineer/Works North Western Railway Harish Joshi
Marg Jodhpur so as to reach his office not later than 15.00 hours on the 11.12.2015 or
deposited in the special box allotted for the purpose in the office of Sr.DSTE North
Western Railway Jodhpur. This Special box will be sealed at 15.00 hours on
11.12.2015 The tender will be opened soon after closing of the tender box at 15:00
hours on the same day. The tender papers will not be sold after 13.00 hours on
11.12.2015
11. Tenders not comply with any of the conditions set forth therein above is liable to be
rejected.
12. Execution of Contract Documents:- The successful Tenderer(s) shall be required to
execute an agreement with the President of India acting through the Sr.Divisional Signal &
Telecom Engineer/Works North Western Railway Jodhpur or any other Officer
appointed to do so within competancy for carrying out the work according to General
conditions of Contract, Special conditions of Contract annexed to the tender and Indian
Railways Standard Specification as amended/corrected up to date as mentioned in tender
form (First Sheet).
The Tenderer whose tender is accepted shall be required to appear in person at the office of
the Sr.Divisional Signal & Telecom Engineer/Works North Western Railway Jodhpur
as the case may be, or if a firm or corporation, a duly authorized representative shall so
appear and execute the contract documents within 7 days after issue of notice by Railway
Signature of Tenderer/s Page 9 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
that the contract documents are ready. Failure to do so shall constitute a breach of the
agreement affected by the acceptance of the tender in which case the full value of the
earnest money accompanying the tender shall stand forfeited without prejudice to any other
rights or remedies.
If any tenderer whose tender is accepted shall refuse to execute the contract document as
here in before provided, the Railway may determine that such tenderer has abandoned the
contract and there upon his tender and acceptance thereof shall be treated as cancelled and
the Railway shall be entitled to forfeit the full amount of the Earnest Money and to recover
the damages for such default.
13. Partnership deeds, Power of Attorney Etc: - The tenderer shall clearly specify whether the
tender is submitted on his own or on behalf of a partnership concern. If the tender is
submitted on behalf of a partnership concern, he should submit the certified copy of
partnership deed along with the tender and authorization to sign the tender documents on
behalf of partnership firm. If these documents are not enclosed along with tender
documents, the tender will be treated as having been submitted by individual signing the
tender documents. The Railway will not be bound by any power of attorney granted by the
tenderer or by changes in the composition of the firm made subsequent to the execution of
the contract. It may, however recognize such power of attorney and changes after obtaining
proper legal advice, the cost of which will be chargeable to the contractor.
14. (a) For participating in tendering process :- Power of Attorney, duly stamped and authenticated
by a Notary Public from all partners of the firm in favour of one or more partners(s) or any
other persons(s) as per listed in Para 24 of this section.
(b) On award of work to successful tenderer :- One or more partners of the firm or any other
persons(s) shall be designated as the authorized person(s) on behalf of the firm, who will be
authorized by all the partners to act on behalf of the firm through a “Power of Attorney”,
specifically authorizing him/them to sign the agreement, receive payment, witness
measurements, sign measurement books, make correspondences, compromise, settle,
relinquish any claim(s) preferred by the firm, sign “No Claim Certificate”, refer all or any
dispute to arbitration and to take similar such action in respect of the said tender/contract. Such
“Power of Attorney” should be notarized/registered and submitted as per listed in Para 24 of
this section.
15. Employment/Partnership, etc of Retired Railway Employees:-
(a) Should a tenderer be a retired engineer of the Gazetted rank or any other Gazetted officer
working before his retirement, whether in the executive or administrative capacity, or
whether holding a pensionable post or not, in the S & T or any other department of any of
the railways owned and administered by the President of India for the time being, or should
a tenderer being partnership firm have as one of its partners a retired engineer or retired
Gazetted Officer as aforesaid, or should a tenderer being an incorporated company have any
such retired engineer or retired officer as one of its Directors, or should a tenderer have in
his employment any retired Engineer or retired Gazetted Officer as aforesaid, the full
information as to the date of retirement of such Engineer or Gazetted Officer from the said
service and in case where such Engineer or Officer had not retired from Government
service at least 2 years prior to the date of submission of the tender whether permission for
taking such contract, or if the contractor be a partnership firm or an incorporated company,
to become a partner or Director as the case may be, or to take the employment under the
Signature of Tenderer/s Page 10 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
contractor, has been obtained by the tenderer or the Engineer or Officer, as the case may be
from the President of India or any officer, duly authorised by him in this behalf, shall be
clearly stated in writing at the time of submitting the tender. Tenders without the
information referred above or a statement to the effect that no such retired Engineer or
retired Gazetted Officer is so associated with the tenderer, as the case may be’ shall be
rejected.
(b) Should a tenderer or contractor, have a relative(s) or in the case of partnership firm or
company of contractors one or more of his shareholder(s) or a relative(s) of the
shareholder(s) employed in gazetted capacity in the S & T or any other department of the
North Western Railway, the authority inviting tenders shall be informed of the fact at the
time of submission of tender, failing which the tender may be disqualified/rejected or if
such fact subsequently comes to light, the contract may be rescinded in accordance with the
provision in clause 62 of the General Conditions of Contract.
16 Omissions & Discrepancies: - Should a tender find discrepancies or omissions in the
drawings or any of the Tender Forms or should he be in doubt as to their meaning, he
should at once notify the authority inviting tenders who may send a written instruction to all
tenderers. It shall be understood that every endeavor has been made to avoid any error
which can materially effect the basis of the tender and the successful tenderer shall take
upon himself and provide for the risk of any error which may subsequently be discovered
and shall make no subsequent claim on account thereof.
17 . Care in Submission of Tenders:-
(a) Before submitting a tender, the tenderer or shall be deemed to have satisfied himself by
actual inspection of the site and locality of the works, that all conditions liable to be
encountered during the execution of the works are taken into account and that the rates he
enters in the tender forms are adequate and all inclusive to accord with the provisions in
Clause-37 of the General Conditions of Contract for the completion of works to the entire
satisfaction of the Engineer.
(b) When work is tendered for by a firm or company, the tender shall be signed by the
individual legally authorized to enter into commitments on their behalf.
(c) The Railway will not be bound by any power of attorney granted by the tenderer or by
changes in the composition of the firm made subsequent to the execution of the contract. It
may, however, recognize such power of attorney and changes after obtaining proper legal
advice, the cost of which will be chargeable to the contractor.
18. Right of Railway to deal with Tenders:- The Railway reserves the right not to invite
tenders for any of Railway work or works or to invite open or limited tenders and when
tenders are called to accept a tender in whole or in part or reject any tender or all tenders
without assigning reasons for any such action.
19. Should the Railway decide to negotiate with a view to bring down the rates, the tenderer
called for negotiations should furnish the following form of declaration before
commencement of negotiations:
Signature of Tenderer/s Page 11 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
I/we ………………………. do declare that in the event of failure of the contemplated
negotiations relating to Tender No.-------------------Dated---------- opened on ………. my
original tender shall remain open for acceptance on its original terms and conditions upto
the date specified in the tender or the date extended by mutual agreement from time to
time.
20. The tenderer/s are required to quote his/their rates as %(percentage) above/below/at par in
figures and words (both) on the total value for tender as per the rate sheet annexure of the
tender document and in case of discrepancy between rate quoted in figures and words, the
rate quoted in words shall be taken into account . Rates quoted only in figure shall not be
considered and the tender shall be summarily rejected.
21. Tender documents are not transferable.
22. MINIMUM ELIGIBILITY CRITERIA:- (Applicable for tenders more than Rs.50
Lakhs)
Only such tenderer(s) who satisfy the following criteria should submit their offer for this
work:
(i) Turnover:- Total contract amount received during last three financial years and in
current financial year upto date of opening of tender should be minimum 150% of
advertised tender value. Authentic Certificates shall be produced by the tenderer(s) to
the effect which may be an attested certificate from the employer/client, Audited
Balance Sheet duly certified by the Chartered Accountant etc.
(ii) Experience in similar nature of work:- The tenderer(s) should have completed in last
three financial years and in current financial year, at least one single work of similar
nature for a minimum value of 35% of the advertised tender value. Following works
will be treated as of similar nature:
Work of Similar nature means: Not applicable
NOTE
(a) Para 22(i) is self explanatory. Certificate issued by Chartered Accountants will also be
accepted.
(b) Para 22(ii) , the criteria for completed works shall be as under :-
(i) Entire work has to be completed in all respects as per contract agreement. Part
completed work shall not be considered.
(ii) The work(s) should have been directly awarded to the tenderer by Govt. Organization/
Semi Govt. Organization/ Public Sector Undertaking / Autonomous bodies/ Municipal
Bodies. Completion certificate should be as per proforma given in Annexure-IV.
(iii) Details of works physically completed is to be submitted in the proforma as per
‘Annexure-III’.
(iv) The value of completed work shall be reckoned from the total payment received by
the tenderer from the organization mentioned in (ii) above.
(v) The amount given at Sr. No. 9 in proforma vide Annexure-IV for the completion
certificate will be the value of completed work if nomenclature of work as given in
completion certificate matches with similar nature work mentioned in 22(ii).
(vi)The amount mentioned at Sr. No. 10 in ‘Annexure-IV’ for the completion certificate
shall be the value of completed work if the nomenclature of completed work includes
Signature of Tenderer/s Page 12 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
additional components of work which are not matching with similar nature of works
mentioned in 22(ii).
(vii)Certificate from private individuals for whom such works are executed will not be
considered for eligibility of tenderer for 22(ii)
(c) Conditional tenders are liable to be rejected straight away. Railway reserves
the right to reject such tenders summarily without assigning any reasons whatsoever.
Note:- Any false certificate submitted by tenderer shall lead to forfeiture of EMD and
further action as mentioned in affidavit at ‘Annexure-II’ will be taken.
23. The list of documents to be attached by the tenderer(s) for this tender:-
23.1 Following documents are common for all types of firms i.e. Sole proprietorship,
Partnership, Limited Company or JV.
a) Firm details for registration - Bank Account no., MICR no. and IFSC (Code) in
‘Annexure-I’
b) Affidavit as per proforma given in ‘Annexure-II’
c) List of similar nature of works physically completed in all respects in current and last
three financial years directly awarded by Govt./Semi Govt./Public sector undertaking
/ Autonomous bodies /Municipal bodies as per proforma given in ‘Annexure-III’
d) Attested copy of Completion Certificate of works mentioned in para (c) above from
the Organizations with whom they worked as per proforma given in ‘Annexure-IV’.
e) List of works on hand as per proforma given in ‘Annexure-V’
f) List of plants & Machinery available on hand (own) and proposed to be inducted
(own and hired to be given separately) for the subject work in ‘Annexure–VI’.
g) List of Personnel, Organization available on hand and proposed to be engaged for the
subject work in ‘Annexure –VII’.
h) Certificate for non-employment/partnership of retired Gazetted Railway Officers as
per proforma given in ‘Annexure-VIII’
i) Earnest Money in proper form – EMD should be purchased in the name of the
tenderer (Sole Proprietership/ Partnership/ Limited Co. / JV firm). EMD will be
verified from the issuing bank for name of the tenderer also. Offer submitted with
EMD in the name of any individual/entity shall not be considered.
j) Demand draft/pay order/Bankers cheque towards the cost of tender documents in case
tender documents are downloaded from website of North-Western Railway.
k) (i) For Two Packet System of Tender
First packet will contain complete tender documents except schedule of approximate
quantities and offer sheet, duly stamped & signed by the tenderer(s) as mentioned in
INDEX. Second packet will contain schedule of approximate quantities and offer
sheet duly filled in stamped & signed by the tenderer(s).
(ii) For Single Packet System of Tender
Complete tender documents duly stamped & signed by the tenderer(s)
l) Annual turnover for the last three years and current financial year with supporting
documents required as per para 22(i).
m) Attested copy of Permanent Account Number (PAN) issued by Income Tax
Department.
n) Attested copy of ISO 9000 certificate (if any).
o) The tenderers are required to submit the test report of the stone ballast, along with
their offer, issued from the approved laboratory as listed in the tender documents
Signature of Tenderer/s Page 13 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
otherwise their offer shall be summarily rejected. (This item will be applicable only in
those tenders whose tender schedule includes item of supply of ballast).
p) Any other document in support of his/their credentials/scheme
23.2 In addition to Para 23.1 above certain more documents are to be submitted by
tenderers
as per status of their firms. These documents are listed below –
23.2.1 For Sole Proprietorship firm
a) Affidavit as per ‘Annexure –IX’.
b) Attested copy of notarized Power of Attorney including ratification clause, if any. .
23.2.2 For Partnership firm
a) Attested copies of Partnership deed duly notarized/registered.
b) Undertaking from all the partners of the partnership firm that they have not been
black listed as per proforma given in ‘Annexure-X’.
c) Special Power of Attorney as per proforma given in ‘Annexure-XV’ to be
submitted by Partnership firm only.
23.2.3 For Limited Company
a) Attested copy of Memorandum & Articles of Association of Company.
b) Attested copy of resolution passed by Board of Directors authorizing its
Director/Employee to deal with tender on behalf of company.
c) Attested copy of Notarized Power of Attorney including ratification clause
duly signed by person authorized by the company vide above.
23.2.4 For JV firm – Documents listed in 23.2.1 or 23.2.2 or 23.2.3 are to be submitted as
per the status of firm participating in JV firm. In addition following documents are to
be submitted.
d) Memorandum of Understanding of JV as per proforma given in ‘Annexure-XI’
e) Certificate from each member of JV as per proforma given in ‘Annexure-XII’
f) Letter of consent as per proforma given in ‘Annexure-XIII’ to be submitted by a
partnership firm participating as a Member of JV firm (wherever applicable).
g) Special Power of Attorney as per proforma given in ‘Annexure-XIV’ to be
submitted by Limited Companies or Sole Proprietor participating as member of JV
firm (wherever applicable).
Note:-
(a) No post tender submission of documents shall be permitted in respect of item mentioned in item (b) below. Clarification only can, however, be called for by Railway in respect of any part / document submitted by the tenderer which shall be responded to by the tenderer within 10 working days of the date of issue of such letter for clarifications, failing which the offer shall be dealt with as per available documents.
(b) The documents required vide items 23.1(a)(b)(c)(d)(h)(i)(j)(k)(l)(o) and 23.2 in
above list are mandatory for submission with tender document. If any of these
documents is not submitted alongwith tender, the offer shall be summarily rejected.
Signature of Tenderer/s Page 14 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
24. Instruction for submitting the tenders as Partnership Firms in works tender
24.1. The Partnership Firms participating in the tender should be legally valid under the
provisions of Indian Partnership Act.
24.2. Partnership Firms are eligible to quote tenders of any value.
24.3. The partnership firm should have been in existence or should have been formed prior to
submission of tender. Partnership firm should have either been registered with the
competent registrar or the partnership deed should have been notarized prior to date of
tender opening as per Indian Partnership Act.
24.4. Separate identity/name should be given to the partnership firm. The partnership firm should
have PAN/TAN number in its own name and PAN/TAN number in the name of any of the
constituents partners shall not be considered. The valid constituents of the firm shall be
called partners.
24.5. Once the tender has been submitted, the constitution of firm shall not be allowed to be
modified/altered/terminated during the validity of the tender as well as the currency of the
contract except when modification becomes inevitable due to succession laws etc. in which
case prior permission should be taken from Railway and in any case the minimum eligibility
criteria should not get vitiated. The reconstitution of firm in such cases should be followed
by a notary certified Supplementary Deed. The approval for change of constitution of the
firm, in any case, shall be at the sole discretion of the Railways and the tenderer shall have
no claims what so ever. Any change in the constitution of Partnership Firm after opening of
tender shall be with the consent of all partners and with the signatures of all partners as that
in the Partnership deed. Failure to observe this requirement shall render the offer invalid and
full EMD shall be forfeited. If any partner/s withdraw from the firm after opening of the
tender and before the award of the tender, the offer shall be rejected. If any new partner join
the firm after opening of tender but prior to award of contract, his/her credentials shall not
qualify for consideration towards eligibility criteria either individually or in proportion to his
share in the previous firm. In case the tenderer fails to inform Railway beforehand about any
such changes/modification in the constitution which is inevitable due to succession laws etc.
and the contract is awarded to such firm, then it will be considered a breach of contract
conditions, liable for termination of contract under Clause 62 of General Condition of
Contract.
24.6. A partner of the firm shall not be permitted to participate either in his individual capacity or
as a partner of any other firm in the same tender.
24.7. The tender form shall be purchased and submitted only in the name of partnership firm and
not in the name of any constituent partner. The EMD shall be submitted only in the name of
partnership firm. The EMD submitted in the name of any individual partner or in the name
of authorized partner(s) shall not be considered.
24.8. A notary certified copy of registered or notarized partnership deed shall be submitted along
with the tender.
24.9. On award of the contract to the partnership firm, a single performance guarantee shall be
submitted by the firm as per tender conditions. All the guarantees like Performance
Guarantee, Guarantee for Mobilization advance, Plant and Machineries advance shall be
submitted only in the name of the partnership firm and no splitting of guarantees among the
partners shall be acceptable.
24.10.On issue of LOA, contract agreement with partnership firm shall be executed in the name of
the firm only and not in the name of any individual partner.
24.11.In case, the contract is awarded to a partnership firm, the following undertaking shall be
furnished by all the partners through a notarized affidavit, before signing of contract
agreement:-
Signature of Tenderer/s Page 15 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
a) Joint and several liabilities –The partners of the firm to which the contract is awarded, shall
be jointly and severally liable to the Railway for execution of the contract in accordance
with general and special conditions of the contract. The partners shall also be liable jointly
and severally for the loss, damages caused to the Railway during the course of execution of
the contract or due to non-execution of the contract or part thereof.
b) Duration of the partnership deed and partnership firm agreement – The partnership
deed/partnership firm agreement shall normally not be modified, altered, terminated during
the currency of contract and the maintenance period after the work is completed as
contemplated in the conditions of the contract. Any change carried out by partners in the
constitution of the firm without permission of Railway, shall constitute a breach of contract
liable for determination of contract under clause 62 of General Conditions of Contract.
c) Governing Laws – The partnership firm agreement shall in all respect be governed by and
interpreted in accordance with the Indian laws.
d) No partner of the firm shall have the right to assign or transfer the interest, right or liability
in the contract without the written consent of the other partner and that of the Railway in
respect of the tender/contract.
24.12.The tenderer shall clearly specify that the tender is submitted on behalf of a partnership
concern. The following documents shall be submitted by the partnership firm, with the
tender-
a) A copy of registered/notarized partnership deed duly authenticated by notary.
b) Power of Attorney duly stamped and authenticated by a Notary Public from all partners of
the firm in favour of one or more partner(s) or any other persons(s) as per Annexure-
“XV”.
c) Undertaking from all the partners of the partnership firm that they have not been black listed
or debarred as per proforma given in Annexure-“X” by Railways or any other Ministry/
Department/PSU of the Govt. of India/ any State Govt. from participation in
tenders/contract on the date of opening of bids either in their individual capacity or in any
firm in which they were/are partners. Concealment/wrong information in regard to above
shall make the contract liable for determination under clause 62 of General Conditions of
Contract.
24.13.Evaluation of eligibility of a partnership firm.
Technical and financial eligibility of the firm shall be adjudged based on satisfactory
fulfillments of the eligibility criteria by the firm in its own name and style. Share of
individual partners towards their performance in other firms shall not be considered.
***
Signature of Tenderer/s Page 16 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
SPECIAL CONDITION OF CONTRACT (GENERAL)
1. (1) Law governing the contract (Clause No.3 of GCC): - The contract shall be
governed by the law for the time being in force in the Republic of India.
(2) Compliance to regulations and bye-laws: - The Contractor shall conform to the
provision of any statute relating to the works and regulations and bye-laws of any local
authority and of any water and lighting companies or undertakings, with whose system the
work is proposed to be connected and shall before making any variation from the drawings
or the specifications that may be necessitated by so confirming give to the Engineer notice
specifying the variation proposed to be made and the reason for making the variation and
shall not carry out such variation until he has received instructions from the Engineer in
respect thereof. The Contractor shall be bound to give all notices required by statute,
regulations or bye-laws as aforesaid and to pay all fees and taxes payable to any authority in
respect thereof.
2. Communications to be in writing (Clause No.4 of GCC):- All notices,
communications, reference and complaints made by the Railway or the Engineer or the
Engineer's Representative or the Contractor interse concerning the works shall be in writing
and no notice, communication, reference or complaint not in writing shall be recognized.
3. Service of Notices on Contractors (Clause No.5 of GCC):- The Contractor shall
furnish to the Engineer the name designation and address of his authorized agent and all
complaints, notices, communications and references shall be deemed to have been duly
given to the Contractor if delivered to the Contractor or his authorised agent or left at or
posted to the address so given and shall be deemed to have been so given in the case of
posting on day on which they would have reached such address in the ordinary course of
post or on the day on which they were so delivered or left. In the case of contract by
partners, any change in the constitution of the firm shall be forthwith notified by the
Contractor to the Engineer.
4. Occupation and use of land (Clause No.6 of GCC):- No land belonging to or in
the possession of the Railway shall be occupied by the Contractor without the permission of
the Railway. The Contractor shall not use, or allow to be used, the site for any purposes
other than that of executing the works. Whenever non-railway bodies/persons are permitted
to use railway premises with competent authority’s approval, conservancy charges as
applicable from time to time may be levied.
5. Assignment or subletting of contract (Clause No.7 of GCC):- The Contractor
shall not assign or sublet the contract or any part thereof or allow any person to become
interested therein any manner whatsoever without the special permission in writing of the
Railway. Any breach of this condition shall entitle the Railway to rescind the contract under
clause 62 of these conditions and also render the contractor liable for payment to the
Railway in respect of any loss or damage arising or ensuing from such cancellation.
Provided always that execution of the details of the work by petty contractor under the
Signature of Tenderer/s Page 17 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
direct and personal supervision of the Contractor or his agent shall not be deemed to be sub-
letting under this clause. The permitted subletting of work by the Contractor shall not
establish any contractual relationship between the sub-contractor and the Railway and shall
not relieve the Contractor of any responsibility under the Contract.
6. Representation on Works (Clause No.12 of GCC):- The Contractor shall, when he
is not personally present on the site of the works place and keep a responsible agent at the
works during working hours who shall on receiving reasonable notice, present himself to
the Engineer and orders given by the Engineer or the Engineer's representative to the agent
shall be deemed to have the same force as if they had been given to the Contractor. Before
absenting himself, the Contractor shall furnish the name and address of his agent for the
purpose of this clause and failure on the part of the Contractor to comply with this provision
at any time will entitle the Railway to rescind the contract under clause 62 of General
Conditions of Contracts.
7. Excavated material (Clause No.14 of GCC):- The Contractor shall not sell or
otherwise dispose of or remove except for the purpose of this contract, the sand, stone, clay
ballast, earth, rock or other substances or materials which may be obtained from any
excavation made for the purpose of the works or any building or produced upon the site at
the time of delivery of the possession thereof but all the substances, materials, buildings and
produce shall be the property of the Railway provided that the contractor may, with the
permission of the Engineer, use the same for the purpose of the works either free of cost or
pay the cost of the same at such rates as may be determined by the Engineer.
8. Indemnity by Contractors (Clause No.15 of GCC):: - The Contractor shall
indemnify and save harmless the Railway from and against all actions, suit proceedings
losses, costs, damages, charges, claims and demands of every nature and description
brought or recovered against the Railways by reason of any act or omission of the
Contractor, his agents or employees, in the execution of the works or in his guarding of the
same. All sums payable by way of compensation under any of these conditions shall be
considered as reasonable compensation to be applied to the actual loss or damage sustained,
and whether or not any damage shall have been sustained.
9. (1) Security Deposit (Clause No.16 of GCC):: - The Earnest Money deposited by
the Contractor with his tender will be retained by the Railways as part of security for the
due and faithful fulfillment of the contract by the contractor. The balance to make up the
security deposit, the rates for which are given below, may be deposited by the Contractor in
cash or may be recovered by percentage deduction from the Contractor's "on account" bills.
Provided also that in case of defaulting contractor the Railway may retain any amount due
for payment to the Contractor on the pending "on account bills" so that the amounts so
retained may not exceed 10% of the total value of the contract.
(2) Unless otherwise specified in the special conditions, if any, the Security Deposit/rate of
recovery/mode of recovery shall be as under:
(a) Security Deposit for each work should be 5% of the contract value,
(b) The rate of recovery should be at the rate of 10% of the bill amount till the full security
deposit is recovered,
Signature of Tenderer/s Page 18 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
© Security Deposits will be recovered only from the running bills of the contract and no
other mode of collecting SD such as SD in the form of instruments like BG (except
Note (ii) below); FD etc. shall be accepted towards Security Deposit.
The Security Deposit shall be released only after the expiry of maintenance period,
warranty period and after passing the final bill. Before releasing the SD, an unconditional
and unequivocal no claim certificate from the contractor concerned should be obtained.
Note-(i) After the work is physically completed, security deposit recovered from the
running bills of a contractor can be returned to him if he so desires, in lieu of
FDR/irrevocable Bank Guarantee for equivalent amount to be submitted by him (ii) In case
of contracts of value Rs 50 crore and above, irrevocable Bank Guarantee can also be
accepted as a mode of obtaining security deposit.
(3) No interest will be payable upon the Earnest Money and Security Deposit or amounts payable
to the Contractor under the Contract, but Government Securities deposited in terms of Sub-
Clause (1) of this clause shall be payable with interest accrued thereon.
(4) Procedure for Releasing of S.D:-
(a). Deleted
(b) Deleted
(c) If Tender is floated for Telecommunication Work
Security Deposit (SD) shall be returned/released to the contractor after getting certified
by Competent Authority (CA):-
i).Work is physically completed in all respect and Final Acceptance Certificate (FAC) has
been issued to the contractor.
ii). Free maintenance period of 1 year is completed.
iii). Warranty period of 1 year is completed.
iv). Final bill has been passed.
Note:-
Before releasing the SD, contractor will submit the warranty certificates issued by OEMs
for all those Telecom equipments for which warranty period more than 1 year has been
decided/fixed by RDSO in the approved RDSO’s Specifications of the equipments.
Signature of Tenderer/s Page 19 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
(5) Performance Guarantee (P.G)
The procedure for obtaining Performance Guarantee is outlined below: -
(a) The successful bidder shall have to submit a Performance Guarantee (PG) within 30
(Thirty) days from the date of issue of Letter of Acceptance (LOA). Extension of time for
submission of PG beyond 30 (Thirty) days and up to 60 days from the date of issue of LOA
may be given by the authority who is competent to sign the contract agreement. However, a
penal interest of 15% per annum shall be charged for the delay beyond 30 days, i.e. from
31st day after the date of issue of LOA. In case the contractor fails to submit the requisite
PG even after 60 days from the date of issue of LOA, the contract shall be terminated duly
forfeiting EMD and other dues, if any payable against that contract. The failed contractor
shall be debarred from participating in re-tender for that work.
(b) The successful bidder should give a Performance Guarantee in any of the following forms,
amounting to 5% of the contract value :-
(i) A deposit of cash.
(ii) Irrevocable bank guarantee.
(iii) Government securities including state loan bonds at 5 percent below the market value.
(iv) Deposit receipts, pay orders, demand drafts and Guarantee bonds.
These forms of performance Guarantee should be either of the State Bank of India or of any
of the nationalized Banks.
(v) Guarantee Bonds executed or deposits receipts tendered by all scheduled banks.
(vi) A deposit in the Post Office Saving Bank.
(vii) A deposit in the National Savings Certificates.
(viii) Twelve years National Defence Certificates.
(ix) Ten years Defence Deposits.
(x) National Defence Bonds and
(xi) Unit Trust Certificates at 5 percent below market value or at the face value whichever is
less.
(xii) FDR in favour of FA & CAO NW Railway, Jodhpur (free from any encumbrance.)
Note– The instruments as listed above will also be acceptable for Guarantees in case of
Mobilization Advance.
(c) A performance guarantee shall be submitted by the successful bidder after the letter of
Acceptance (LOA) has been issued, but before signing of the contract agreement. This PG shall
be initially valid up to the stipulated date of completion plus 60 days beyond that. In case, the
time for completion of work gets extended, the contractor shall get the validity of Performance
Guarantee extended to cover such extended time for completion of work plus 60 days.
(d) The value of PG to be submitted by the contractor will not change for variation up to 25%
(either increase or decrease). In case during the course of execution, value of the contact
increases by more than 25% of original contract value, an additional Performance
Guarantee amounting to 5% (Five percent) for the excess value over the original contract
value shall be deposited by the contractor.
(e) Performance Guarantee (PG) shall be released after the physical completion of the work
based on the ‘Completion Certificate’ issued by the competent authority stating that the
contractor has completed the work in all respects satisfactorily. The security deposit shall,
however, be released only after the expiry of the maintenance period and after passing the
final bill based on ‘No Claim Certificate from the contractor.
(f) Wherever the contract is rescinded, the security deposit shall be forfeited and the Performance
Guarantee shall be encashed. The balance work shall be got done independently without risk
and cost of the failed contractor. The failed contractor shall be debarred from participating in
the tender for executing the balance work. If the failed contractor is a JV or a partnership firm,
Signature of Tenderer/s Page 20 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
then every member/partner of such a firm shall be debarred from participating in the tender for
the balance work in his/her individual capacity or as a partner of any other JV/partnership firm.
(g) The Engineer shall not make a claim under the Performance Guarantee except for amounts
to which the President of India is entitled under the contract (not withstanding and/or
without prejudice to any other provisions in the contract agreement) in the event of:-
i) Failure by the contractor to extend the validity of the Performance Guarantee as described
herein above, in which event the Engineer may claim the full amount of the Performance
Guarantee.
ii) Failure by the contractor to pay President of India any amount due, either as agreed by the
contractor or determined under any of the Clause/Conditions of the agreement, within 30
days of the service of notice to this effect by Engineer.
iii) If the contract is determined or rescinded under provision of the GCC, the Performance
Guarantee shall be forfeited in full and shall be absolutely at the disposal of the President of
India
iv) (a) It should be insisted upon the contractors, suppliers etc. that Bank Guarantees(BGs) to
be submitted by them should be sent to the concerned authorities as directed by the issuing
bank under Registered Post AD.
(b) In exceptional cases, where the BGs are received through the contractors, suppliers etc., the
issuing branch should be requested to immediately send by Registered Post AD an
unstamped duplicate copy of the Bank Guarantee directly to the Railways with a covering
letter to compare with the original BGs and to confirm that it is in order.
(h) MODEL FORM OF BANK GUARANTEE BOND To: The President of India Acting through the Sr. DFM/, North Western Railway, JODHPUR, Rajasthan .
1. In consideration of the President of India (hereinafter called “the Government”) having
agreed to exempt --------------(hereinafter called “the said Contractor(s)” from the demand,
under the terms and conditions of an Agreement dated -------- made between ---------- and --
---------- for ----------- (hereinafter called “the said Agreement”), of security deposit for the
due fulfillment by the said Contractor(s) of the terms and conditions contained in the said
Agreement, on production of a bank Guarantee for Rs.------- (Rupees------------------only)
we, ----------------------- (hereinafter referred to as “the Bank” at the request of --------------
(contractor(s) do hereby undertake to pay to the Government an amount not exceeding Rs. -
--------- ----- against any loss or damage caused to or suffered or would be caused to or
suffered by the Government by reason of any breach by the said Contractor(s) of any of the
terms or conditions contained in the said Agreement.
2. We------(indicate the name of the bank) and our local branch at Jodhpur i.e.--------------------
---(name, address and branch code of local branch at Jaipur) do hereby undertake to pay the
amounts due and payable under this guarantee without any demur, merely on a demand
from the Government stating that the amount claimed is due by way of loss or damage
caused to or would be caused to or suffered by the Government by reason of breach by the
said contractor(s) of any of the terms of conditions contained in the said Agreement or by
Signature of Tenderer/s Page 21 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
reason of the contractor(s) failure to perform the said Agreement. Any such demand made
on the bank shall be conclusive as regards the amount due and payable by the Bank under
this guarantee. However, our liability under this guarantee shall be restricted to an amount
not exceeding Rs. -------------
3. We under-take to pay to the Government any money so demanded notwithstanding any
dispute or disputes raised by the contractor(s)/supplier (s) in any suite or proceeding
pending before any court or Tribunal relating thereto our liability under this present being
absolute and unequivocal .
The payment so made by us under this bond shall be a valid discharge of our liability for
payment there under and the contractor(s)/supplier(s) shall have no claim against us for
making such payment.
4. We………..(indicate the name of bank) and our local branch at Jodhpur i.e.--------------------
---(name, address and branch code of local branch at Jodhpur) further agreed with the
guarantee herein contained shall remain in full force and effect during the period that would
be taken for the performance/of the said Agreement and that it shall continue to be
enforceable till all the dues of the Government under or by virtue of the said Agreement
have been fully paid and its claims satisfied or discharged or till --------- ---
office/Department) Ministry of -------- certifies that the terms and conditions of the said
Agreement have been fully and properly carried out by the said Contractor(s) and
accordingly discharges this guarantee. Unless a demand or claim under this guarantee is
made on in writing on or before the ------------ we shall be discharged from all liability
under this guarantee thereafter.
5. We………..(indicate the name of bank) and our local branch at Jodhpur i.e.--------------------
---(name, address and branch code of local branch at Jodhpur) further agree with the
government that the Government shall have the fullest liberty without our consent and
without affecting in any manner our obligations hereunder to vary any of the terms and
conditions of the said Agreement or to extend time of performance by the said contractor(s)
from time to time or to post opens for any time or from time to time any of the powers
exercisable by the Government against the said, Contractor(s) and to further or enforce any
of the terms and conditions relating to the said agreement and we shall not be relieved from
our liability by reason of any such variation, or extension being granted to the said
Contractor(s) or for any forbearance, act or commission on the part of the Government or
any indulgence by the Government to the said Contractor(s) or any such matter or thing
whatsoever which under the law relating to sureties would, but for this provision, have
effect of so relieving us.
6. This guarantee will not be discharged due to the change in the constitution of the bank or
the contractor(s)/Supplier(s).
7. We ----(indicate the name of bank) and our local branch at Jodhpur i.e.-----------------------
(name, address and branch code of local branch at Jaipur) lastly undertake not to revoke this
guarantee during its currency except with the previous consent of the Government in
writing.
Dated the----------- day of ---------2015
For ______(indicate the name of bank) and our local branch at Jodhpur i.e.--------------------
---(name, address and branch code of local branch at Jodhpur)
Signature of Tenderer/s Page 22 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
10. Force Majeure Clause no 17 of GCC 2013:-
If at any time, during the continuance of this contract, the performance in whole or in part
by either party of any obligation under this contract shall be prevented or delayed by reason
of any war, hostility, acts of public enemy, civil commotion, sabotage, serious loss or
damage by fire, explosions, epidemics, strikes, lockouts or acts of God (hereinafter, referred
to events) provided, notice of the happening of any such event is given by either party to the
other within 30 days from the date of occurrence thereof, neither party shall by reason of
such event, be entitled to terminate this contract nor shall either party have any claim for
damages against the other in respect of such non-performance of delay in performance, and
works under the contract shall be resumed as soon as practicable after such event has come
to an end or ceased to exist, and the decision of the Engineer as to whether the works have
been so resumed or not shall be final and conclusive, PROVIDED FURTHER that if the
performance in whole or in part of any obligation under this contract is prevented or
delayed by reason of any such event for a period exceeding 120 days, either party may at its
option terminate the contract by giving notice to the other party.
17 – A of GCC Subject to any requirement in the contract as to completion of any portions
or portions of the works before completion of the whole, the contractor shall fully and
finally complete the whole of the works comprised in the contract (with such modifications
as may be directed under conditions of this contract) by the date entered in the contract or
extended date in terms of the following clauses:-
(i) If any modifications have been ordered which in the opinion of the Engineer have
materially increased the magnitude of the work, then such extension of the contracted date
of completion may be granted as shall appear to the Engineer to be reasonable in the
circumstances, provided moreover that the Contractor shall be responsible for requesting
such extension of the date as may be considered necessary as soon as the cause thereof shall
arise and in any case not less than one month before the expiry of the date fixed for
completion of the works.
(ii) If in the opinion of the Engineer the progress of work has any time been delayed by any act
or neglect of Railway's employees or by other contractor employed by the Railway under
sub-clause (4) of clause 20 of these conditions or in executing the work not forming part of
the contract but on which contractor's performance necessarily depends or by reason of
proceeding taken or threatened by or dispute with adjoining or to neighboring owners or
public authority arising otherwise through the Contractor's own default etc. or by the delay
authorized by the Engineer pending arbitration or in consequences of the contractor not
having received in due time necessary instructions from the Railway for which he shall
have specially applied in writing to the Engineer or his authorized representative then upon
happening of any such event causing delay, the Contractor shall immediately give notice
thereof in writing to the Engineer within 15 days of such happening but shall nevertheless
make constantly his best endeavours to bring down or make good the delay and shall do all
that may be reasonably required of him to the satisfaction of the Engineer to proceed with
the works. The contractor may also indicate the period for which the work is likely to be
delayed and shall be bound to ask for necessary extension of time. The Engineer on receipt
of such request from the contractor shall consider the same and shall grant such extension
of time as in his opinion is reasonable having regard to the nature and period of delay and
the type and quantum of work affected thereby. No other compensation shall be payable for
Signature of Tenderer/s Page 23 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
works so carried forward to the extended period of time, the same rates, terms and
conditions of contract being applicable as if such extended period of time was originally
provided in the original contract itself.
(iii) In the event of any failure or delay by the Railway to hand over the Contractor possession
of the lands necessary for the execution of the works or to give the necessary notice to
commence the works or to provide the necessary drawings or instructions or any other
delay caused by the Railway due to any other cause whatsoever, then such failure or delay
shall in no way affect or vitiate the contract or alter the character thereof or entitle the
contractor to damages or compensation therefore but in any such case, the Railway may
grant such extension or extensions of the completion date as may be considered reasonable.
17-B of GCC Extension of time for delay due to contractor:-
The time for the execution of the work or part of the works specified in the contract
documents shall be deemed to be the essence of the contract and the works must be
completed not later than the date(s) as specified in the contract. If the contractor fails to
complete the works within the time as specified in the contract for the reasons other than
the reasons specified in clause 17 and 17 -A, the Railway may, if satisfied that the works
can be completed by the contractor within reasonable short time thereafter, allow the
contractor for further extension of time (Proforma Annexure-VII of GCC) as the Engineer
may decide. On such extension the Railway will be entitled without prejudice to any other
right and remedy available on that behalf, to recover from the contractor as agreed damages
and not by way of penalty a sum equivalent to 1/2 of 1 % of the contract value of the works
for each week or part of the week.
For the purpose of this clause, the contract value of the works shall be taken as value of
work as per contract agreement including any supplementary work order/contract
agreement issued. Provided also, that the total amount of liquidated damages under this
condition, shall not exceed the under noted percentage value or of the total value of the item
or groups of items of work for which a separate distinct completion period is specified in
the contract.
(i) For contract value up to Rs. 2 lakhs - 10% of the total value of the contract.
(ii) For contracts valued above Rs. 2 lakhs - 10% of the first Rs.2 lakhs and the 5% of the
balance.
Further competent authority while granting extension to the currency of contract under
clause 17 (B) of GCC may also consider levy of token penalty as deemed fit based on the
merit of the case. Provided further, that if the Railway is not satisfied that the works can be
completed by the Contractor and in the event of failure on the part of the contractor to
complete the work within further extension of time allowed as aforesaid, the Railway shall
be entitled without prejudice to any other right or remedy available in that behalf, to
appropriate the contractor's security deposit and rescind the contract under clause 62 of
these conditions, whether or not actual damage is caused by such default.
11.(1) Contractor's understanding(Clause No.19 of GCC):- It is understood and agreed
that the Contractor has, by careful examination, satisfied himself as to the nature and
location of the work, the conformation of the ground, the character, quality and quantity of
Signature of Tenderer/s Page 24 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
the materials to be encountered, the character of equipment and facilities needed
preliminary to and during the progress of the works, the general and local conditions, the
labour conditions prevailing therein and all other matters which can in any way affect the
works under the contract.
(2) Commencement of works:- The Contractor shall commence the works within 15 days
after the receipt by him of an order in writing to this effect from the Engineer and shall
proceed with the same with due expedition and without delay
(3) Accepted programme of work:- The Contractor who has been awarded the work shall
as soon as possible but not later than 30 days after the date of receipt of the acceptance
letter in respect of contracts with initial completion period of two years or less or not later
than 90 days for other contracts have to submit the detailed programme of work indicating
the time schedule of various items of works in the form of Bar Chart/PERT/CPM. He shall
also submit the details of organization (in terms of labour and supervisors) plant and
machinery that he intends to utilize (from time to time) for execution of the work within
stipulated date of completion. The programme of work amended as necessary by
discussions with the Engineer, shall be treated as the agreed programme of the work for the
purpose of this contract and the contractor shall endeavour to fulfill this programme of
work. The progress of work will be watched accordingly the liquidated damages will be
with reference to the overall completion date. Nothing stated herein shall preclude the
contractor in achieving earlier completion of item or whole of the works than indicated in
the programme.
(4) Setting out of works: -The Contractor shall execute the work as shown in the standard
drawings and as directed by the Engineer's representative and shall check these at frequent
intervals. The Contractor shall provide all facilities like labour and instruments and shall
co-operate with the Engineer's representative to ensure good quality of work. If, at any
time, during the progress of the works any error shall appear or arise in any part of the
work, the contractor, on being required so to do by the Engineer's representative shall, at his
own cost rectify such errors, to the satisfaction of the Engineer's representative. Such
checking shall not absolve the contractor of his own responsibility of maintaining accuracy
in the work.
12.(1) Compliance to Engineers Instructions (Clause No.20 of GCC::- The Engineer
shall direct the order in which the several parts of the works shall be executed and the
Contractor shall execute without delay all orders given by the Engineer from time to time
but the Contractor shall not be relieved thereby from responsibility for the due performance
of the works in all respects.
(2) Alterations to be authorised:- No alterations in or additions to or omissions or
abandonment of any part of the works shall be deemed authorised, except under instructions
from the Engineer, and the Contractor shall be responsible to obtain such instructions in
each and every case in writing from the Engineer.
(3) Extra works:- Should works over and above those included in the contract require to be
executed at the site, the contractor shall have no right to be entrusted with the execution of
such works which may be carried out by another contractor or contractors or by other
means at the option of the Railway.
Signature of Tenderer/s Page 25 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
(4) Separate contracts in connection with works:- The Railway shall have the right to
let other contracts in connection with the works. The Contractor shall afford other
contractors reasonable opportunity for the storage of their materials and the execution of
their works and shall properly connect and coordinate his work with theirs. If any part of
the Contractors work depends for proper execution or result upon the work of another
contractor(s), the Contractor shall inspect and promptly report to the Engineer any defects
in such works that render it unsuitable for such proper execution and results. The
Contractor's failure so-to inspect and report shall constitute an acceptance of the other
contractor's work as fit and proper for the reception of his work, except as to defects which
may develop in the other contractor's work after the execution of his work.
13. Instruction of Engineer's Representative (Clause No.21 of GCC):- Any
instructions or approval given by the Engineer's representative to Contractor in connection
with the works shall bind the Contractor as through it had been given by the Engineer
provided always as follows:-
(a) Failure of the Engineer's representative to disapprove any work or materials shall not
prejudice .the power of the Engineer thereafter to disapprove such work or material and to
order the removal or breaking up thereof.
(b) If the Contractor shall be dissatisfied by reason of any decision of the Engineer's
representative, he shall be entitled to refer the matter to the Engineer who shall there upon
confirm or vary such decision.
14 (1) Adherence to specifications and drawings (Clause No.22 of GCC)::- The
whole of the works shall be executed in perfect conformity with the specifications and
drawings of the contract. If Contractor performs any works in a manner contrary to the
specifications or drawings or any of them and without such reference to the Engineer he
shall bear all the costs arising or ensuing therefore and shall be responsible for all loss to
the Railway.
(2) Drawings and specifications of the works:- The Contractor shall keep one copy of
Drawings and Specifications at the site, in good order, and such contract documents as may
be necessary, available to the Engineer or the Engineer's Representative.
(3) Ownership of drawings and specifications:- All Drawings and Specifications and
copies thereof furnished by the Railway to the Contractor are deemed to be the property of
the Railway. They shall not be used on other works and with the exception of the signed
contract set, shall be returned by the Contractor to the Railway on completion of the work
or termination of the Contract.
(4) Compliance with Contractor's request for details:- The Engineer shall furnish
with reasonable promptness, after receipt by him of the Contractor's request for the same,
additional instructions by means of drawings or otherwise, necessary for the proper
execution of the works or any part thereof. All such drawings and instructions shall be
consistent with the Contract Documents and reasonably inferable there from.
Signature of Tenderer/s Page 26 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
(5) Meaning and intent of specification and drawings:- If any ambiguity arises as to
the meaning and intent of any portion of the Specifications and Drawings or as to execution
or quality of any work or material, or as to the measurements of the works the decision of
the Engineer thereon shall be final subject to the appeal (within 7 days of such decision
being intimated to the Contractor) to the Chief Signal & Telecom Engineer who shall have
the power to correct any errors, omissions, or discrepancies in aforementioned items and
whose decision in the matter in dispute or doubt shall be final and conclusive.
15. Working during night (Clause No.23 of GCC): - The Contractor shall not carry out
any work between sun-set and sun-rise without the previous permission of the Engineer.
But, if the Engineer is satisfied that the work is not likely to be completed in time, except
by resorting to night work, he may order the contractor/s to carry out the works even at
night without conferring any right on the contractor for claiming any extra payment for the
same. The contractor at his own cost shall make all arrangements in this connection. In any
case indoor wiring and testing will be carried out round the clock normally.
16. Damage to Railway property or private life and property (Clause No.24 of
GCC:: - The Contractor shall be responsible for all risk to the work and for trespass and
shall make good at his on expense all loss or damage whether to the works themselves or to
any other property of the Railway or the lives, persons or property of others from
whatsoever cause in connection with the works until they are taken over by the Railway and
this although all reasonable and proper precautions may have been taken by the Contractor,
and in case the Railway shall be called upon to make good any costs, loss or damages, or to
pay any compensation, including that payable under the provisions of the Workmen's
Compensation Act or any statutory amendments thereof to any person or persons sustaining
damages as aforesaid by reason of any act, or any negligence or omissions on the part of the
Contractor the amount of any costs or charges including costs and charges in connection
with legal proceedings, which the Railway may incur in reference thereto, shall be charged
to the Contractor. The Railway shall have the power and right to pay or to defend or
compromise any claim of threatened legal proceedings or in anticipation of legal
proceedings being instituted Consequent on the action or default of the Contractor, to take
such steps as may be considered necessary or desirable to ward off or mitigate the effect of
such proceedings, charging to Contractor, as aforesaid, any sum or sums of money which
may be paid and any expenses whether for reinstatement or otherwise which may be
incurred and the propriety of any such payment, defence or compromise, and the incurring
of any such expenses shall not be called in question by the Contractor.
17. Sheds, Stores houses and Yards (Clause No253 of GCC):: - The Contractor shall
at his own expense provide himself with sheds, storehouses and yards in such situations and
in such numbers as in the opinion of the Engineer is requisite for carrying on the works and
the Contractor shall keep at each such sheds, store-houses and yards a sufficient quantity of
materials and plant in stock as not to delay the carrying out of the works with due
expedition and the Engineer and the Engineer's representative shall have free access to the
said sheds, store houses and yards at any time for the purpose of inspecting the stock of
materials or plant so kept in hand, and any materials or plant which the Engineer may
object to shall not be brought upon or used in the works, but shall be forthwith removed
from the sheds, store houses or yards by the Contractor. The Contractor shall at his own
expenses provide and maintain suitable mortar mills, soaking vats or any other equipments
necessary for the execution of the works.
Signature of Tenderer/s Page 27 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
18. Provision of efficient and competent staff at work sites by the contractor
(clause 26 of GCC)
18.1 The Contractor shall place and keep on the works at all times efficient and competent staff
to give the necessary directions to his workmen and to see that they execute their work in
sound & proper manner and shall employ only such supervisors, workmen & labourers in
or about the execution of any of these works as are careful and skilled in the various trades.
18.2 The contractor shall at once remove from the works any agents, permitted sub-contractor,
supervisor, workman or labourer who shall be objected to by the Engineer and if and
whenever required by the Engineer, he shall submit a correct return showing the names of
all staff and workmen employed by him.
18.3 In the event of the Engineer being of the opinion that the Contractor is not employing on
the works a sufficient number of staff and workmen as is necessary for proper completion
of the works within the time prescribed, the contractor shall forthwith on receiving
intimation to this effect deploy the additional number of staff and labour as specified by the
Engineer within seven days of being so required and failure on the part of the Contractor to
comply with such instructions will entitle the Railway to rescind the contract under Clause
62 of these conditions.
18. A Deployment of Qualified Engineers At Work Sites by the contractor:
(Clause 26-A of GCC)
18A.1 The contractor shall also employ Qualified Graduate Engineer or Qualified Diploma Holder
Engineer, based on value of contract, as may be prescribed by the Ministry of Railways
(Para 18A.3) through separate instructions from time to time.
18A.2 In case the contractor fails to employ the Engineer, as aforesaid in Para 18A.1, he shall be
liable to pay penalty at the rates, as may be prescribed by the Ministry of Railways (Para
18A.4) through separate instructions from time to time for the default period for the
provisions, as contained in Para 18A.1.
18A.3 No. of qualified Engineers required to be deployed by the Contractor for various activities
contained in this works contract shall be as under:-
1) Graduate Engineer - Minimum …....... Nos.
2) Diploma Engineer – Minimum -------- Nos.
18A.4 Further for this work in case the contractor fails to employ the Qualified Engineer, as
aforesaid in Para 18A.1 above, he, in terms of provisions of Clause 18A.2 to the Conditions
of Contract, shall be liable to pay an amount of Rs.40,000/- and Rs.25,000/- for each month
or part thereof for the default period for the provisions, as contained in Para 18A.3 above
respectively.
19. (1)Workmanship and testing (Clause No.27 of GCC):- The whole of the works
and/or supply of materials specified and provided in the contract or that may be necessary
to be done in order to form and complete any part thereof shall be executed in the best and
most substantial workman like manner with materials of the best and most approved quality
of their respective kinds, agreeable to the particulars contained in or implied by the
Signature of Tenderer/s Page 28 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
specifications and as referred to in and represented by the drawings or in such other
additional particulars, instructions and drawings may be found requisite to be given during
the carrying on of the works and to the entire satisfaction of the Engineer according to the
instructions and directions which the Contractors may from time to time receive from the
Engineer. The materials may be subjected to tests by means of such machines, instruments
and appliances as the Engineer may direct and wholly at the expense of the Contractor.
(2) Removal of Improper work and materials:-The Engineer or the Engineer's
Representative shall be entitled to order from time to time:-
(a) the removal from the site within the time specified in the order of any materials which in
his opinion are not in accordance with the specifications or drawings.
(b) the substitution of proper and suitable materials, and
(c) the removal and proper re-execution, notwithstanding any previous tests thereof or on
account payments therefore, of any work which in respect of materials or workmanship is
not in his opinion in accordance with the specifications and in case of default on the part of
the Contractor in carrying out such order the Railway shall be entitled to rescind the
contract under Clause 62 of GCC
20. Facilities for Inspection (Clause No.28 of GCC):-The Contractor shall afford the
Engineer and the Engineer's Representative every facility for entering in and upon every
portion of the work at all hours for the purpose of inspection or otherwise and shall provide
all labour, materials, planks, ladders, pumps, appliances and things of every kind required
for the purpose and the Engineer and the Engineer's Representative shall at all times have
free access to every part of the works and to all places at which materials for the works are
stored or being prepared.
21. Examination of work before covering up (Clause No29 of GCC):- The
Contractor shall give 7 days notice to the Engineer or the Engineer's Representative
whenever any work or materials are intended to be covered up in the earth, in bodies or
walls or otherwise to be placed beyond the reach of measurements in order that the work
may be inspected or that correct dimensions may be taken before being so covered, placed
beyond the reach of measurement in default whereof, the same shall at the option of the
Engineer or the Engineer's Representative be uncovered and measured at the Contractor's
expense or no allowance shall be made for such work or materials.
22. Temporary Works (Clause No.30 of GCC):- All temporary works necessary for the
proper execution of the works shall be provided and maintained by the Contractor and
subject to the consent of the Engineer shall be removed by him at his expenses when they
are no longer required and in such manner as the Engineer shall direct. In the event of
failure on the part of the Contractor to remove the temporary works, the Engineer will cause
them to be removed and cost as increased by supervision and other incidental charges shall
be recovered from the Contractor. If temporary huts are provided by the Contractor on the
Railway land for labour engaged by him for the execution of works, the contractor shall
arrange for handing over vacant possession of the said land after the work is completed; if
the contractor's labour refuse to vacate, and have to be rejected by the Railway, necessary
expenses incurred by the Railway in connection therewith shall be borne by the Contractor.
23.(1)Contractor to supply water for works (Clause No.31 of GCC):- Unless
otherwise provided in the Contract, the Contractor shall be responsible for the arrangements
to obtain supply of water necessary for the works.
Signature of Tenderer/s Page 29 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
(2) Water supply from Railway System:- The Railway may supply to the Contractor part
or whole of the quantity of the water required for the execution of works from the,
Railway's existing water supply system at or near the site of works on specified terms and
conditions and at such charges as shall be determined by the Railway and payable by the
Contractor, provided that the Contractor shall arrange, at his own expense, to effect the
connections and lay additional pipe lines and accessories on the site and that the Contractor
shall not be entitled to any compensation for interruption of failure of the water supply.
(3) Water supply by Railway Transport:- In the event of the Railway arranging supply
of water to the Contractor at or near the site of works by travelling water tanks or other
means, the freight and other charges incurred thereby, including demurrage charges that
may be levied, shall be paid by the Contractor in addition to the charges referred to in sub-
clause (2) of the clause provided that the contractor shall not be entitled to any
compensation for interruption or failure of the water supply.
(4) (a)Contractor to arrange supply of Electric power for works: - Unless otherwise
provided in the contract, the Contractor shall be responsible for arrangements to obtain
supply of Electric Power for the works.
(b) Electric supply from the Railway system:- The Railway may supply to the
Contractor part or whole of the electric power wherever available and possible, required for
execution of works from the Railway's existing electric supply systems at or near the site of
works on specified terms and conditions and such charges as shall be determined by the
Railway and payable by the Contractor provided the cost of arranging necessary
connections to the Railway's Electric Supply systems, and laying of underground/overhead
conductor, circuit protection, electric power meters, transmission structure, shall be borne
by the Contractor and that the Contractor shall not be entitled to any compensation for
interruption or failure of the Electric supply system:
24.(1) Precaution during progress of works(Clause No.34 of GCC):- During the
execution of works, unless otherwise specified, the contractor shall at his own cost provide
the materials for and execute all shoring, timbering and strutting works as is necessary for
the stability and safety of all structures, excavation and works and shall ensure that no
damage , injury or loss is caused or likely to be caused to any person or property.
(2) Roads and Water courses:- Existing roads or water courses shall not be blocked cut
through, altered, diverted or obstructed in any way by the Contractor, except with the
permission of the Engineer. All compensations claimed for any unauthorized closure,
cutting through, alteration, diversion or obstruction to such roads or water courses by the
Contractor or his agent or his staff shall be recoverable from the Contractor by deduction
from any sums which may become due to him in terms of contract, or otherwise according
to law.
(3) Provision of access to premises:- During progress of work in any street or
thoroughfare, the Contractor shall make adequate provision for the passage of traffic, for
securing safe access to all premises approached from such street or thoroughfare and for
any drainage, water supply or means of lighting which may be interrupted by reasons of the
Signature of Tenderer/s Page 30 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
execution of the works and shall react and maintain at his own cost barriers, lights and other
safeguards as prescribed by the Engineer, for the regulation of the traffic, and provide
watchmen necessary to prevent accidents. The works shall in such cases be executed night
and day if so ordered by the Engineer and with such vigour so that the traffic way be
impeded for as short a time as possible.
(4) Safety of Public:- The Contractor shall be responsible to take all precautions to ensure
the safety of the public whether on public or Railway property and shall post such look out
men as may in the opinion of the Engineer be required to comply with regulations
appertaining to the work.
25. Use of Explosives (Clause No.35 of GCC):- Explosives shall not be used on the
works or on the site by the Contractor without the permission of the Engineer and then only
in the manner and to the extent to which such permission is given. Where explosives are
required for the works, they shall be stored in a special magazine to be provided by and at
the cost of the Contractor in accordance with the Explosive Rules. The Contractor shall
obtain the necessary license for the storage and the use of explosives and all operations in
which or for which explosives are employed shall be at the sole risk and responsibility of
the Contractor and the Contractor shall indemnify the Railway in respect thereof.
26.(1)Suspension of works (Clause No.36 of GCC):- The Contractor shall on the order
of the Engineer, suspend the progress of the works or any part thereof for such time or
times and in such manner as the Engineer may consider necessary and shall during such
suspension properly protect and secure the work so far as is necessary in the opinion of the
Engineer. If such suspension is:-
(a) Provided for in the contract, or
(b) Necessary for the proper execution of the works or by the reason of weather conditions or
by some default on the part of the Contractor, and or
(c) Necessary for the safety of the works or any part thereof.
(2) The Contractor shall not be entitled to the extra costs, if any, incurred by him during the
period of suspension of the works, but in the event of any suspension ordered by the
Engineer for reasons other than aforementioned and when each such period of suspension
exceeds 14 days, the Contractor shall be entitled to such extension of time for completion of
the works as the Engineer may consider proper having regard to the period or periods of
such suspensions and to such compensations as the Engineer may consider reasonable in
respect of salaries or wages paid by the Contractor to his employees during the periods of
such suspension.
(3) Suspension lasting more than 3 months:- If the progress of the works or any part
thereof is suspended on the order of the Engineer for more than three months at a time, the
Contractor may serve a written notice on the Engineer requiring permission within 15 days
from the receipt thereof to proceed with the works or that part thereof in regard to which
progress is suspended and if such permission is not granted within that time the Contractor
by further written notice so served may, but is not bound to, elect to treat the suspension
where it affects part only of the works as an omission of such part or where it affects the
whole of the works, as an abandonment of the contract by the Railway.
Signature of Tenderer/s Page 31 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
27. Rates for items of works (Clause No.37 of GCC):- The rates, entered in the
accepted Schedule of Rates of the Contract are intended to provide for works duly and
properly completed in accordance with the general and special (if any) conditions of the
contract and the specifications and drawings together with such enlargements, extensions,
diminutions, reductions, alterations or additions as may be ordered in terms of Clause 42 of
General Condition of Contract and without prejudice to the generality thereof and shall be
deemed to include and cover superintendence and labour, supply, including full freight, of
materials, stores, patterns, profiles, moulds, fittings, centering, scaffolding, shoring props,
timber, machinery, barracks, tackle, roads, pegs, posts, tools and all apparatus and plant
required on the works, except such tools, plant or materials as may be specified in the
contract to be supplied to the Contractor by the Railway, the erection, maintenance and
removal of all temporary works and, buildings, all watching, lighting, bailing, pumping and
draining, all prevention of or compensation for trespass, all barriers and arrangements for
the safety of the public or of employees during the execution of works, all sanitary and
medical arrangements for labour camps as may be prescribed by the Railway, the setting of
all work and of the construction, repair and upkeep of all centre lines, bench marks and
level pegs thereon, site clearance, all fees duties, royalties, rent and compensation to owners
for surface damage or taxes and impositions payable to local authorities in respect of land,
structures and all material supplied for the work or other duties of expenses for which the
Contractor may become liable or may be put to under any provision of law for the purpose
of or in connection with the execution of the contract, and all such other incidental charges
or contingencies as may have been specially provided for in the specifications.
28.(1) Rates for extra items of works (Clause No 39(1) of GCC):- Any item of work carried out by the Contractor on the instructions of the Engineer which is
not included in the accepted schedules of rates shall be executed at the rates set forth in the
"Schedule of Rates of North Western Railway" modified by the tender percentage and such
items are not contained in the latter, at the rate agreed upon between the Engineer and the
Contractor before the execution of such items of work and the Contractors shall be bound to
notify the Engineer at least seven days before the necessity arises for the execution of such
items of works that the accepted schedule of rates does not include rate or rates for the extra
work involved. The rates payable for such items shall be decided at the meeting to be held
between the Engineer and Contractor, in as short a period as possible after the need for the
special item has come to the notice. In case the Contractor fails to attend the meeting after
being notified to do so or in the event of no settlement being arrived at, the Railway shall be
entitled to execute the extra works by other means and the Contractor shall have no claim
for loss or damage that may result from such procedure.
(2) (Clause No 39(2) of GCC):- Provided that if the Contractor commences work or incurs
any expenditure in regard thereto before the rates as determined and agreed upon as lastly
hereunto fore mentioned, then and in such a case the Contractor shall only be entitled to be
paid in respect of the work carried out or expenditure incurred by him prior to the date of
determination of the rates as aforesaid according to the rates as shall be fixed by the
Engineer. However if the Contractor is not satisfied with the decision of the Engineer in this
respect he may appeal to the Chief Signal & Telecom Engineer, North Western Railway
within 30 days of getting the decision of the Engineer, supported by analysis of the rates
claimed. The Chief Signal & Telecom Engineer, North Western Railway decision after
hearing both the parties in the matter would be final and binding on the Contractor and the
Railway.
Signature of Tenderer/s Page 32 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
29. Modification to contract to be in writing (Clause No.41 of GCC)::- In the event
of any of the provisions of the contract requiring to be modified after the contract
documents have been signed, the modifications shall be made in writing and signed by the
Railway and the Contractor and no work shall proceed under such modifications until this
has been done. Any verbal or written arrangement abandoning, modifying, extending,
reducing or supplementing the contract or any of the terms thereof shall be deemed
conditional and shall not be binding on the Railway unless and until the same is
incorporated in a formal instrument and signed by the Railway and the Contractor, and till
then the Railway shall have the right to repudiate such arrangements.
30. (1) Powers of modification to contract (Clause No 42 (1) of GCC) :- The
Engineer on behalf of the Railway shall be entitled by order in writing to enlarge or extend,
diminish or reduce the works or make any alterations in their design, character position,
site, quantities, dimensions or in the method of their execution or in the combination and
use of materials for the execution thereof or to order any additional work to be done or any
works not to be done and the contractor will not be entitled, to any compensation for any
increase/reduction in the quantities of work but will be paid only for the actual amount of
work done and for approved materials supplied against a specific order.
(2) (Clause No 42 (2) of GCC)
(i) Unless otherwise specified in the special conditions of the contract, the accepted variation
in quantity of each individual item of the contract would be up to 25% of the quantity
originally contracted, except in case of foundation work. The contractor shall be bound to
carry out the work at the agreed rates and shall not be entitled to any claim or any
compensation whatsoever up to the limit of 25% variation in quantity of individual item of
works.
(ii) Not Applicable.
(iii) In case of foundation work, no variation limit shall apply and the work shall be carried out
by the contractor on agreed rates irrespective of any variation.
(3) Valuation of variations (Clause No 42 (3) of GCC) :- The enlargements,
extensions, diminution, reduction, alterations or additions referred to in sub-clause (2) of
this clause shall in no degree affect the validity of the contract but shall be performed by the
Contractor as provided therein and be subject to the same conditions, stipulations and
obligations as if they had been originally and expressively included and provided for in the
specifications and drawings and the amounts to be paid therefore shall be calculated in
accordance with the accepted schedule of rates. Any extra items/quantities of work falling
outside the purview of the provisions of sub-clause (2) above shall be paid for at the rates
determined under clause-39 of GCC.
(4) Variation in quantities of Items of Contracts (Clause No 42 (4) of GCC):-
(4.1) Individual NS items in contracts shall be operated with variation of plus or minus 25% and
payment would be made as per the agreement rate. For this, no finance concurrence would
be required.
(4.2) In case an increase in quantity of an individual item by more than 25% of the agreement
quantity is considered as unavoidable, the same shall be got executed by floating a fresh
tender. If floating a fresh tender for operating that item is considered not practicable,
Signature of Tenderer/s Page 33 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
quantity of that item may be operated in excess of 125% of the agreement quantity subject
to the following conditions:
(a) Operation of an item by more than 125% of the agreement quantity needs the approval of
an officer of the rank not less than SA Grade.
(i) Quantities operated in excess of 125% but up to 140% of the agreement quantity of the
concerned item, shall be paid at 98% of the rate awarded for that item in that particular
tender.
(ii) Quantities operated in excess of 140% but up to 150% of the agreement quantity of the
concerned item, shall be paid at 96% of the rate awarded for that item in that particular
tender.
(iii) Variation in quantities of individual item beyond 150% will be prohibited and would be
permitted only in exceptional unavoidable circumstances with the concurrence of associate
finance and shall be paid at 96% of the rate awarded for that item in that particular tender.
(b) The variation of quantities as per the above formula will apply only to the individual items
of the contract and not on the overall contract value.
(c) Execution of quantities beyond 150% of the overall agreemental value should not be
permitted and, if found necessary, should be only through fresh tenders or by negotiating
with existing contractor, with prior personal concurrence of FA & CAO and approval of
General Manger treating it as a single tender.
(4.3) In cases where decrease is involved during execution of contract:
(a) The contract signing authority can decrease the items up to 25% of individual item without
finance concurrence.
(b) For decrease beyond 25% for individual items or 25% of contract agreement value, the
approval of an officer not less than the rank of SA grade will be taken after obtaining No
Claim Certificate from the contractor and with finance concurrence giving detailed reasons
for each such decrease in the quantities.
(c) It should be certified that the work proposed to be reduced will not be required in the same
work.
(4.4) The limit for varying quantities for minor value items shall be 100% (as against 25%
prescribed for other items). A minor value item for this purpose is defined as an item whose
original agreement value is less than 1% of the total original agreement value.
(4.5) No such quantity variation limit shall apply for foundation items.
(4.6) As far as Schedule of Rate (SOR)-March 2012, items are concerned, the limit of 25%
would apply to the value of SOR schedule as a whole and not on individual SOR items.
However, in case of NS items, the limit of 25% would apply on the individual items
irrespective of manner of quoting the rate (single percentage rate or individual item rate)
(4.7) For the tenders accepted at Zonal Railway level, variations in the quantities will be
approved by the authority in whose powers revised value of the agreement lies.
(4.8) For tenders accepted by General Manager, variations up to 125% of the original agreement
value may be accepted by General Manager.
(4.9) For tenders accepted by Board Members and Railway Minister, variations up to 110% of
original agreement value may be accepted by General Manager.
(4.10) The aspect of vitiation of tender with respect to variation in quantities should be checked
and avoided. In case of vitiation of the tender (both for increase as well as decrease of value
of contract agreement), sanction of the competent authority as per single tender should be
obtained.
Signature of Tenderer/s Page 34 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
(5.0) In Para (4.4) above (Para 42 (4.4) of GCC) minor value NS item is defined. For such
item in case of excess beyond 100% (total quantity more than 200%) the provisions
of Para (4.2) (iii) above (Para 42(4.2)(iii) of GCC) will apply.
31. (1) Variation in quantity of individual Minor value item beyond 100%:- Variation in quantity of individual minor value item beyond 100% (ie total quantity
200%) will be prohibited & would be permitted only in exceptional unavoidable
circumstances with the concurrence of associated finance & shall be paid at 96% of the
rate awarded for that item in that particular tender upto further 100%. Thereafter prior
finance concurrence will be required.
31. (2) Above para 31(1) would be applicable only for the contracts which have been finalised
based on single percentage above/below the assessed cost of tender.
If the contract includes itemized rates for all items separately, the variation beyond
100% in minor value items would be dealt on case to case basis with finance
concurrence and approved by tender accepting authority. Normally this should be
prohibited. In exceptional circumstances, detailed reasons should be recorded on file.
32.(1) Monthly Statement of Claims (Clause No 43(1) of GCC):-The Contractor shall
prepare and furnish to the Engineer once in every month an account giving full and detailed
particulars of all claims for any additional expenses to which the Contractor may consider
himself entitled to and of all extra or additional works ordered by the Engineer which he
has executed during the preceding month and no claim for payment for and such work will
be considered which has not been included in such particulars.
(2) Signing of "No Claim" Certificate(Clause No 43(2) of GCC):- The Contractor
shall not be entitled to make any claim whatsoever against the Railway under or by virtue
of or arising out of this contract, nor shall the Railway entertain or consider any such claim,
if made by the Contractor, after he shall have signed a "No Claim" Certificate in favour of
the Railway in such form as shall be required by the Railway after the works are finally
measured up. The Contactor shall be debarred from disputing the correctness of the items
covered by "No Claim" Certificate or demanding a clearance to arbitration in respect
thereof.
33.0 Price Variation Clause [Clause 46A of IR’s General Conditions of Contract
(GCC)]:- Price Variation Clause is Not Applicable.
34.(1)Certificate of completion of works(Clause No.48 of GCC):- As soon as in the
opinion of the Engineer, the work has been completed and has satisfactorily passed any
final test or tests that may be prescribed, the Engineer shall issue a certificate of completion
duly indicating the date of completion in respect of the work and the free maintenance
period of 12 months of the work shall commence from the date of completion as mentioned
in such certificate. The Engineer may also issue such a certificate indicating date of
completion with respect to any part of the work (before the completion of the whole of
work), which has been both completed to the satisfaction of the Engineer and occupied or
used by the Railway. When any such certificate is given in respect of part of a work, such
part shall be considered as completed and the period of maintenance of such part shall
commence from the date of completion mentioned in the completion certificate issued for
that part of the work.
Note:- The completion certificate for the work will be issued at JAG level.
Signature of Tenderer/s Page 35 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
(2) Contractor not absolved by completion Certificate:- The Certificate of completion
in respect of the works referred to in sub-clause (1) of this clause shall not absolve the
Contractor from his liability to make good any defects imperfections, shrinkages or faults
which may appear during the free maintenance period of 12 months specified in the tender,
arising in the opinion of the Engineer from materials or workmanship not in accordance
with the drawings or specifications or instruction of the Engineer, which defects,
imperfections, shrinkages or faults shall upon the direction in writing of the Engineer be
amended and made good by the Contractor at his own cost; and in case of default on the
part of Contractor the Engineer may employ labour and materials or appoint another
Contractor to amend and make good such defects, imperfections, shrinkages and faults and
all expenses consequent thereon and incidental thereto shall be borne by the Contractor and
shall be recoverable from any moneys due to him under the contract.
35. Approval only by Maintenance Certificate(Clause No.49 of GCC):- No
certificate other than maintenance certificate referred to in Clause 50 of the conditions shall
be deemed to constitute approval of any work or other matter in respect of which it is issued
or shall be taken as an admission of the due performance of the contract or any part thereof
or of the accuracy of any claim or demand made by the Contractor or of additional varied
work having been ordered by the Engineer nor shall any other certificate conclude or
prejudice any of the powers of the Engineer.
36.(1)Maintenance Certificate(Clause No.50 of GCC):- The Contract shall not be
considered as completed until a Maintenance Certificate shall have been signed by the
Engineer stating that the works have been completed and maintained to his satisfaction. The
maintenance Certificate shall be given by the Engineer upon the expiration of the free
maintenance period or 12 months or as soon thereafter as any works ordered during such
period pursuant to sub clause (2) Clause 48 of these conditions shall have been completed
to the satisfaction of the Engineer and full effect shall be given to this Clause
notwithstanding the taking possession of or using the works or any part thereof by the
Railway.
(2) Cessation of Railway’s Liability:- The Railway shall not be liable to the Contractor
for any matter arising out of or in connection with the contract of the execution of the
works unless the Contractor shall have made a claim in writing in respect thereof before the
issue of the Maintenance Certificate under this clause.
(3) Unfulfilled Obligations:- Notwithstanding the issue of the Maintenance Certificate the
Contractor and (subject to sub-clause (2) of this clause) the Railway shall remain liable for
the fulfillment of any obligation incurred under the provision of the contract prior to the
issue of the maintenance Certificate which remains unperformed at the time such certificate
is issued and for the purposes of determining the nature and extent of any such obligations
the contract shall be deemed to remain in force between the parties thereto.
37. Wages to Labour (Clause No.54 of GCC):-The contractor shall be responsible to
ensure compliance with the provision of the Minimum Wages Act, 1948(hereinafter
referred to as the “said Act” and the Rules made there under in respect of any employees
directly or through petty contractors or sub-contractors employed by him for the purpose of
carrying out the contract.
Signature of Tenderer/s Page 36 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
If, in compliance with the terms of the contract, contractor supplied any labour to be used
wholly or partially under the direct orders and control of the Railways whether in
connection with any work being executed by the contractor or otherwise for the purpose of
the Railway such labour shall, for the purpose of this clause, still be deemed to be persons
employed by the contractor.
If any money shall, as a result of any claim or application made under the said Act be
directed to be paid by the Railway, such money shall be deemed to be moneys payable to
the Railway by the contractor and on failure by the contractor to repay the Railway any
moneys paid by it as aforesaid within seven days after the same shall have been demanded ,
the Railways shall be entitled to recover the same from any moneys due or accruing to the
contractor under this or any other contract with the Railways.
37-AApprentices Act: (Clause No.54 –A of GCC)- The Contractor shall be responsible to
ensure compliance with the provisions of the Apprentices Act, 1961 and the Rules and
Orders issued there under from time to time in respect of apprentices directly or through
petty contractors or sub-contractors employed by him for the purpose of carrying out the
Contract.
If the contractor directly or through petty contractors or sub-contractors fails to do so, his
failure will be a breach of the contract and the Railway may, in its discretion, rescind the
contract. The contractor shall also be liable for any pecuniary liability arising on account of
any violation of the provisions of the Act.
Note: The contractors are required to engage apprentices when the works undertaken by
them last for a period of one year or more and/the cost of works is rupees one lakh or more.
38. Implementation of “The Building and Other Construction Workers (Regulation of
Employment and Conditions of Service) Act, 1996” and “The Building and Other
Construction Workers” Welfare Cess Act, 1996 (Clause 55-C of GCC)
The tenderers for carrying out any construction work must get themselves registered from
the Registering Officer under Section-7 of the “Building and Other Construction Workers
Act, 1996” and rules made thereto by the concerned State Govt. and submit certificate of
Registration issued from the Registering Officer of the concerned State Govt. (Labour
Dept.). As per this Act, the tenderer shall be levied a cess @ 1% of cost of construction
work, which would be deducted from each bill. Cost of Material, when supplied under a
separate schedule item, shall be outside the purview of cess.”
39.(1) Right of Railway to determine the contract (Clause No.61 (1) of GCC):-: - The Railway
shall be entitled to determine and terminate the contract at any time should, in the Railway's
opinion, the cessation of work becomes necessary owing to paucity of funds or from any
other cause whatever, in which case the value of approved materials at site and of work
done to date by the Contractor will be paid for in full at the rate specified in the contract.
Notice in writing from the Railway of such determination and the reasons therefore shall be
conclusive evidence thereof.
2) Payment on determination of contract (Clause No 61 (2) of GCC):-Should the contract
be determined under sub clause (1) of this clause and the Contractor claims payment for
expenditure incurred by him in the expectation of completing the whole of the work, the
Signature of Tenderer/s Page 37 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
Railways shall admit and consider such claims as are deemed reasonable and are supported
by vouchers to the satisfaction of the Engineer.
The Railway's decision on the necessity and propriety of such expenditure shall be final and
conclusive.
(3) (Clause No 61 (3) of GCC):- The Contractor shall have no claim to any payment of
compensation or otherwise, howsoever on account of any profit or advantage which he
might have derived from the execution of the work in full but which he did not derive in
consequence of determination of contract.
40(1) Determination of contract owing to default of contractor (Clause No 62 (1)
of GCC):- If the Contractor should:-
(i) Becomes bankrupt or insolvent, or
(ii) make an arrangement with of assignment in favour of his creditors, or agree to carry out the
contract under a Committee of Inspection of his creditors, or
(iii) being a Company or Corporation, go into liquidation (other than a voluntary liquidation for
the purposes of amalgamation or reconstruction), or
(iv) have an execution levied on his goods or property on the works, or
(v) assign the contract or any part thereof otherwise than as provided in Clause 7 of these
conditions, or
(vi) abandon the contract, or
(vii) persistently disregard the instructions of the Engineer, or contravene any provision of the
contract, or
(viii) fail to adhere to the agreed programme of work by a margin of 10% of the stipulated period,
or
(ix) fail to remove materials from the site or to pull down and replace work after receiving from
the Engineer notice to the effect that the said materials or works have been condemned or
rejected under clause 25 and 27 of these conditions, or
(x) fail to take steps to employ competent or additional staff and labour as required under
clause 26 of the conditions, or
(xi) fail to afford the Engineer or Engineer's representative proper facilities for inspecting the
works or any part thereof as required under clause 28 of the conditions, or
(xii) promise, offer or give any bribe, commission, gift or advantage either himself or through
his partner, agent or servant to any officer or employee of the Railway or to any person on
his or on their behalf in relation to the execution of this or any other contract with this
Railway.
Signature of Tenderer/s Page 38 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
(xiii)(A)At any time after the tender relating to the contract, has been signed and submitted by the
Contractor, being a partnership firm admit as one of its partners or employ under it or being
an incorporated company elect or nominate or allow to act as one of its directors or employ
under it in any capacity whatsoever any retired engineer of the gazetted rank or any other
retired gazetted officer working before his retirement, whether in the executive or
administrative capacity, or whether holding any pensionable post or not, in the S & T
Department of the Railways for the time being owned and administered by the President of
India before the expiry of two years from the date of retirement from the said service of
such Engineer or Officer unless such Engineer or Officer has obtained permission from the
President of India or any officer duly authorized by him in this behalf to become a partner
or a director or to take employment under the contract as the case may be, or
(B) Fail to give at the time of submitting the said tender:-
(a) The correct information as to the date of retirement of such retired engineer or retired
officer from the said service, or as to whether any such retired engineer or retired officer
was under the employment of the Contractor at the time of submitting the said tender, or
(b) the correct information as to such engineers or officers obtaining permission to take
employment under the Contractor, or
(c) being a partnership firm, the correct information as to, whether any of its partners was such
a retired engineer or a retired officer, or
(d) being in incorporated company, correct information as to whether any of its directors was
such a retired engineer or a retired officer, or
(e) being such a retired engineer or retired officer suppress and not disclose at the time of
submitting the said tender the fact of his being such a retired engineer or a retired officer or
make at the time of submitting the said tender a wrong statement in relation to his obtaining
permission to take the contract or if the Contractor be a partnership firm or an incorporated
company to be a partner or director of such firm or company as the case may be or to seek
employment under the Contractor. Then and in any of the said clause, the Engineer on
behalf of the Railway may serve the Contractor with a notice (Proforma at Annexure IX of
GCC) in writing to that effect and if the Contractor does not within seven days after the
delivery to him of such notice proceed to make good his default in so far as the same is
capable of being made good and carry on the work or comply with such directions as
aforesaid of the entire satisfaction of the Engineer, the Railway shall be entitled after giving
48 hours notice (Proforma at Annexure X of GCC) in writing under the hand of the
Engineer to rescind the contract as a whole or in part or parts (as may be specified in such
notice) and after expiry of 48 hours notice, a final termination notice (Proforma at
Annexure XI of GCC) should be issued and adopt the following courses.
To measure up or the whole or part of the work from which the contractor has been
removed and get it completed by another contractor , the manner and method in which such
work is completed shall be in the entire discretion of the Engineer whose decision shall be
final.
40(2) Right of Railway after, rescission of contract owing to default of Contractor
(Clause No 62 (2) of GCC):- In the event of any or several of the courses, referred to
in sub-clause (1) of this clause, being adopted:-
(a) the Contractor shall have no claim to compensation for any loss sustained by him by reason
of his having purchased or procured any materials or entered into any commitments or
Signature of Tenderer/s Page 39 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
made any advances on account of or with a view to the execution of the works or the
performance of the contract and Contractor shall not be entitled to recover or be paid any
sum for any work thereto for actually performed under the contract unless and until the
Engineer shall have certified the performance of such work and the value payable in respect
thereof and the Contractor shall only be entitled to be paid the value so certified.
(b) the Engineer or the Engineer's Representative shall be entitled to take possession of any
materials, tools, implements, machinery and buildings on the works or on the property on
which these are being or ought to have been executed, and to retain and employ the same in
the further execution of the works or any part thereof until the completion of the works
without the Contractor being entitled to any compensation for the use and employment
thereof or for wear and tear or destruction thereof.
(c) the Engineer shall as soon as may be practicable after removal of the Contractor fix and
determine ex-parte or by or after reference to the parties or after such investigation or
enquiries as he may consider fit to make or institute and shall certify what amount (if any)
had at the time of rescission of the contract been reasonably earned by or would reasonably
accrue to the Contractor in respect of the work then actually done by him under the contract
and what was the value of any unused, or partially used materials, any constructional plant
and any temporary works upon the site. The legitimate amount due to the contractor after
making necessary deductions and certified by the Engineer should be released
expeditiously.
41. Matters finally determined by the Railway (Clause No.63 of GCC) –
All disputes and differences of any kind whatsoever arising out of or in connection with the
contract, whether during the progress of the work or after its completion and whether before
or after the determination of the contract, shall be referred by the contractor to the GM and
the GM shall within 120 days after receipt of the contractor’s representation make and
notify decisions on all matters referred to by the contractor in writing provided that matters
for which provision has been made in clauses 8, 18, 22(5), 39, 43(2), 45(a), 55, 55-A(5), 57,
57A,61(1), 61(2) and 62(1) to (xiii) (B) of General Conditions of contract or in any clause
of the special conditions of the contract shall be deemed as ‘excepted matters’ (matters not
arbitrable) and decisions of the Railway authority, thereon shall be final and binding on the
contractor; provided further that ‘excepted matters’ shall stand specifically excluded from
the purview of the arbitration clause.
42 Arbitration Clause No 64 of GCC
42(1)(i) Demand for Arbitration-In the event of any dispute or difference between the parties
hereto as to the construction or operation of this contract, or the respective rights and
liabilities of the parties on any matter in question, dispute or difference on any account or as
to the withholding by the Railway of any certificate to which
the contractor may claim to be entitled to, or if the Railway fails to make a decision within
120 days, then and in any such case, but except in any of the “excepted matters” referred to
in Clause 63 of these conditions, the contractor, after 120 days but within 180 days of his
presenting his final claim on disputed matters shall demand in writing that the dispute or
difference be referred to arbitration.
Signature of Tenderer/s Page 40 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
42(1)(ii) The demand for arbitration shall specify the matters which are in question, or subject of
the dispute or difference as also the amount of claim item wise. Only such dispute (s) or
difference (s) in respect of which the demand has been made, together with counter claims
or set off, given by the Railway, shall be referred to arbitration and other matters shall not
be included in the reference.
42(1)(ii)(a)The Arbitration proceedings shall be assumed to have commenced from the day, a
written and valid demand for arbitration is received by the Railway.
(b) The claimant shall submit his claim stating the facts supporting the claims along with all the
relevant documents and the relief or remedy sought against each claim within a period of 30
days from the date of appointment of the Arbitral Tribunal.
(c) The Railway shall submit its defence statement and counter claim(s), if any, within a period
of 60 days of receipt of copy of claims from Tribunal thereafter, unless otherwise extension
has been granted by Tribunal.
(d) The place of arbitration would be within the geographical limits of the Division of the
Railway where the cause of action arose or the Headquarters of the concerned Railway or
any other place with the written consent of both the parties.
42(1)(iii)No new claim shall be added during proceedings by either party. However, a party may
amend or supplement the original claim or defence thereof during the course of arbitration
proceedings subject to acceptance by Tribunal having due regard to the delay in making it.
42(1)(iv)If the contractor(s) does/do not prefer his/their specific and final claims in writing, within
a period of 90 days of receiving the intimation from the Railways that the final bill is ready
for payment, he/they will be deemed to have waived his/their claim(s) and the Railway
shall be discharged and released of all liabilities under the contract in respect of these
claims.
42(2) Obligation during Pendency of Arbitration - Work under the contract shall, unless
otherwise directed by the Engineer, continue during the arbitration proceedings, and no
payment due or payable by the Railway shall be withheld on account of such proceedings,
provided, however, it shall be open for Arbitral Tribunal to consider and decide whether or
not such work should continue during arbitration proceedings.
42(3)(a)(i) - In cases where the total value of all claims in question added together does not exceed
Rs.10,00,000/- (Rupees ten lakhs only), the Arbitral tribunal shall consist of a sole
arbitrator who shall be a Gazetted officer of Railway not below JA grade, nominated by the
General Manager.
The sole arbitrator shall be appointed within 60 days from the day when a written and valid
demand for arbitration is received by GM.
42(3)(a)(ii) - In cases not covered by the clause 64(3) (a)(i), the Arbitral Tribunal shall consist of a
Panel of three Gazetted Rly. Officers not below JA grade or 2 Railway Gazetted Officers
not below JA Grade and a retired Railway Officer, retired not below the rank of SAG
Officer, as the arbitrators. For this purpose, the Railway will send a panel of more than 3
names of Gazetted Rly. Officers of one or more departments of the Rly. which may also
include the name(s) of retired Railway Officer(s) empanelled to work as Railway
.Arbitrator to the contractor within 60 days from the day when a written and valid demand
Signature of Tenderer/s Page 41 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
for arbitration is received by the GM. Contractor will be asked to suggest to General
Manager at least 2 names out of the panel for appointment as contractor’s nominee within
30 days from the date of dispatch of the request by Railway. The General Manager shall
appoint at least one out of them as the contractor’s nominee and will, also simultaneously
appoint the balance number of arbitrators either from the panel or from outside the panel,
duly indicating the ‘presiding arbitrator’ from amongst the 3 arbitrators so appointed. GM
shall complete this exercise of appointing the Arbitral Tribunal within 30 days from the
receipt of the names of contractor’s nominees. While nominating the arbitrators it will be
necessary to ensure that one of them is from the Accounts department. An officer of
Selection Grade of the Accounts Department shall be considered of equal status to the
officers in SA grade of other departments of the Railway for the purpose of appointment of
arbitrator.
42(3)(a)(iii)- If one or more of the arbitrators appointed as above refuses to act as arbitrator,
withdraws from his office as arbitrator, or vacates his/their office/offices or is/are unable or
unwilling to perform his functions as arbitrator for any reason whatsoever or dies or in the
opinion of the General Manager fails to act without undue delay, the General Manager shall
appoint new arbitrator/arbitrators to act in his/their place in the same manner in which the
earlier arbitrator/arbitrators had been appointed. Such re-constituted Tribunal may, at its
discretion, proceed with the reference from the stage at which it was left by the previous
arbitrator (s).
42(3)(a)(iv)- The arbitral Tribunal shall have power to call for such evidence by way of affidavits
or otherwise as the Arbitral Tribunal shall think proper, and it shall be the duty of the
parties hereto to do or cause to be done all such things as may be necessary to enable the
Arbitral Tribunal to make the award without any delay. The Arbitral Tribunal should record
day to-day proceedings. The proceedings shall normally be conducted on the basis of
documents and written statements.
42(3)(a)(v)-While appointing arbitrator(s) under sub-clause (i), (ii) & (iii) above, due care shall be
taken that he/they is/are not the one/those who had an opportunity to deal with the matters
to which the contract relates or who in the course of his/their duties as Railway servant(s)
expressed views on all or any of the matters under dispute or differences. The proceedings
of the Arbitral Tribunal or the award made by such Tribunal will, however, not be invalid
merely for the reason that one or more arbitrator had, in the course of his service
opportunity to deal with the matters to which the contract relates or who in the course of
his/their duties expressed views on all or any of the matters under dispute.
42(3)(b)(i)-The arbitral award shall state item wise, the sum and reasons upon which it is based.
The analysis and reasons shall be detailed enough so that the award could be inferred there
from.
42(3)(b)(ii)-A party may apply for corrections of any computational errors, any typographical or
clerical errors or any other error of similar nature occurring in the award of a tribunal and
interpretation of a specific point of award to tribunal within 60 days of receipt of the award.
42(3)(b)(iii)-A party may apply to tribunal within 60 days of receipt of award to make an
additional award as to claims presented in the arbitral proceedings but omitted from the
arbitral award.
Signature of Tenderer/s Page 42 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
42(4) In case of the Tribunal, comprising of three Members, any ruling on award shall be made
by a majority of Members of Tribunal. In the absence of such a majority, the views of the
Presiding Arbitrator shall prevail.
42(5) where the arbitral award is for the payment of money, no interest shall be payable on
whole or any part of the money for any period till the date on which the award is made.
42(6) The cost of arbitration shall be borne by the respective parties. The cost shall inter-alia
include fee of the arbitrator(s), as per the rates fixed by the Railway Board from time to
time and the fee shall be borne equally by both the parties. Further, the fee payable to the
arbitrator(s) would be governed by the instructions issued on the subject by Railway
Board from time to time irrespective of the fact whether the arbitrator(s) is/ are appointed
by the Railway Administration or by the court of law unless specifically directed by
Hon’ble court otherwise on the matter.
42(7): Subject to the provisions of the aforesaid Arbitration and Conciliation Act 1996 and the
rules there under and any statutory modifications thereof shall apply to the arbitration
proceedings under this clause.
Note:-
(i) The provision of Clauses 63 and 64 of the General Conditions of contract will be
applicable only for settlement of claims of disputes between the parties for values less than
or equal to 20% of the value of the contract and when the claims and disputes are of value
more than 20% of the value of the contract, provisions of Clauses 63 & 64 and other
Clauses of the General Conditions of Contract will not be applicable and arbitration will
not be a remedy for settlement of such disputes.
(ii) The contractor shall not be entitled to ask for reference to arbitration before the
completion of the work assigned to him under this contract. The contractor shall seek
reference to arbitration to settle the disputes only once within the ambit of condition (i)
above.
(iii) These special conditions (i) & (ii) above shall prevail over existing Clauses 63 and 64 of
the “General Conditions of the Contract”.
(Authority: Chief Engineer’s Circular No. 1 on Contract Policy circulated vide letter No.
W-118/0/Policy dated 11/06/2003)
(iv) If there is any dispute arisen between the parties with respect to this agreement, then
any application or suit shall be initiated only in the court with the local limits, falling
under the jurisdiction of the North-Western Railway and both the parties shall be
bound by this clause.
(v) For settlement of disputes between one Government Departments and the other or between
the Government Department and Public Sector undertaking the following special
conditions shall be applicable.
“In the event of any dispute or difference between the parties hereto, such dispute or
condition shall be resolved amicably by mutual consultation through the good offices of
Signature of Tenderer/s Page 43 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
empowered agencies of the Government. If such resolution is not possible, then the
unresolved dispute or difference shall be referred to arbitration of an arbitrator to be
nominated by Secretary, Department of Legal Affairs (Law Secretary) in terms of office
Memorandum No.55/3/1/75/CF dated 19-12-75 issued by the Cabinet Secretariat
(Department of Cabinet Affairs) as modified from time to time.
The arbitration and Conciliation Act, 1996 or the arbitration clause contained in the
General Conditions of Contract shall not be applicable to the arbitration under this clause.
The award of the Arbitrator shall be binding upon parties in the dispute, provided
however; any party aggrieved by such award may make further reference for setting aside
or revision of the award to Law Secretary whose decision shall bind the parties finally and
conclusively”.
43. Participation of Joint Venture (JV) Firms in Works Tender (Clause No
65 of GCC) Instruction for Participation of Joint Venture (JV) Firms in Works Tender
This clause shall be applicable for works tenders of value more than Rs.10 Crores.
However, for not allowing participation of the JV firm in the tenders valuing more than
Rs.10 crore or for allowing participation of the JV Firm in tenders valuing less than Rs.10
crore, approval of the HAG officer shall be necessary on case to case basis; alongwith the
concurrence of Associate Finance based upon merit/justification for the individual case.
This decision shall invariably be communicated through the Notice Inviting Tender (NIT).
43.1. Separate identity/ name shall be given to the Joint Venture Firm.
43.2. Number of members in a JV Firm shall not be more than three, if the work involves only
one department (say Civil or S&T or Electrical or Mechanical) and shall not be more than
five, if the work involves more than one department.
43.3. A member of JV Firm shall not be permitted to participate either in individual capacity or
as a member of another JV Firm in the same tender.
43.4. The tender form shall be purchased and submitted only in the name of the JV firm and not
in the name of any constituent member.
43.5. Normally EMD shall be submitted only in the name of the JV firm and not in the name of
constituent member. However, in exceptional cases EMD in the name of
Lead Member can be accepted subject to submission of specific request letter from Lead
Member stating the reasons for not submitting EMD in the name of JV firm and giving
written confirmation from JV members to the effect that EMD submitted by the Lead
Member may be deemed as EMD submitted by JV firm.
43.6. One of the members of the JV Firm shall be its Lead Member who shall have a majority
(at least 51%) share of interest in the JV Firm and also, must have satisfactorily completed
in the last three previous financial years and the current financial year upto the date of
opening of the tender, one similar single work for a minimum value of 35% of advertised
tender value. The other members shall have a share of not less than 20% each in case of
Signature of Tenderer/s Page 44 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
JV Firms with upto three members and not less than 10% each in case of JV Firms with
more than three members. In case of JV Firm with foreign member(s), the Lead Member
has to be an Indian Firm with a minimum share of 51%.
43.7. A copy of Memorandum of Understanding (MOU) executed by the JV members shall be
submitted by the JV Firm along with the tender. The complete details of the members of
the JV Firm, their share and responsibility in the JV Firm etc. particularly with reference
to financial, technical and other obligations shall be furnished in the MOU. (The MOU
format for this purpose is enclosed as Annexure-“XI” in this document).
43.8. Once the tender is submitted, the MOU shall not be modified / altered / terminated during
the validity of the tender. In case the tenderer fails to observe/comply with this stipulation,
the full Earnest Money Deposit (EMD) shall be liable to be forfeited.
43.9. Approval for change of constitution of JV firm shall be at the sole discretion of the
Employer (Railways). The constitution of the JV Firm shall not be allowed to be modified
after submission of the tender bid by the JV Firm, except when modification becomes
inevitable due to succession laws etc. and in any case the minimum eligibility criteria
should not get vitiated. However, the Lead Member shall continue to be the Lead Member
of the JV Firm. Failure to observe this requirement would render the offer invalid.
43.10. Similarly, after the contract is awarded, the constitution of JV Firm shall not be allowed to
be altered during the currency of contract except when modification become inevitable
due to succession laws etc. and in any case the minimum eligibility criteria should not get
vitiated. Failure to observe this stipulation shall be deemed to be a breach of contract with
all consequential penal action as per contract conditions.
43.11. On award of contract to a JV Firm, a single Performance Guarantee shall be submitted by
the JV firm as per tender conditions. All the Guarantees like Performance Guarantee,
Bank Guarantee for Mobilization Advance, Machinery Advance etc. shall be accepted
only in the name of the JV Firm and no splitting of guarantees amongst the members of
the JV Firm shall be permitted.
43.12. On issue of LOA (Letter Of Acceptance), an agreement among the members of the JV
Firm (to whom the work has been awarded) shall be executed and got registered before the
Registrar of the Companies under Companies Act or before the Registrar/ Sub-Registrar
under the Registration Act, 1908. This JV Agreement shall be submitted by the JV Firm to
the Railways before signing the contract agreement for the work. In case the tenderer fails
to observe/comply with this stipulation, the full Earnest Money Deposit (EMD) shall be
forfeited and other penal actions due shall be taken against partners of the JV and the JV.
This Joint Venture Agreement shall have, inter-alia, following Clauses :
43.12.1. Joint and Several Liability – Members of the JV Firm to which the contract is awarded,
shall be jointly and severally liable to the Employer (Railways) for execution of the
project in accordance with General and Special Conditions of Contract. The JV members
shall also be liable jointly and severally for the loss, damages caused to the Railways
during the course of execution of the contract or due to non-execution of the contract or
part thereof.
Signature of Tenderer/s Page 45 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
43.12.2. Duration of the Joint Venture Agreement – It shall be valid during the entire currency of
the contract including the period of extension, if any and the maintenance period after the
work is completed.
43.12.3. Governing Laws – The Joint Venture Agreement shall in all respect be governed by and
interpreted in accordance with Indian Laws.
43.13. Authorized Member – Joint Venture members shall authorize one of the members on
behalf of the Joint Venture Firm to deal with the tender, sign the agreement or enter into
contract in respect of the said tender, to receive payment, to witness joint measurement of
work done, to sign measurement books and similar such action in respect of the said
tender/contract. All notices/correspondences with respect to the contract would be sent
only to this authorized member of the JV firm.
43.14. No member of the Joint Venture Firm shall have the right to assign or transfer the interest
right or liability in the contract without the written consent of the other members and that
of the employer (Railways) in respect of the said tender/contract.
43.15. Documents to be enclosed by the JV Firm along with the tender.
43.15.1. In case one or more of the members of the JV Firm is/are partnership firm(s), following
documents shall be submitted.
(a) Notary certified copy of the Partnership Deed.
(b) Consent of all the partners to enter into the Joint Venture Agreement on a stamp paper of
appropriate value (in original).
(c) Power of Attorney (duly registered as per prevailing law) in favor of one of the partners of
the partnership firm to sign the JV Agreement on behalf of the partnership firm and create
liability against the firm.
43.15.2. In case one or more members is/are Proprietary Firm or HUF, the following documents
shall be enclosed.
Affidavit on Stamp Paper of appropriate value declaring that his/her concern is a
Proprietary Concern and he/she is sole proprietor of the Concern OR he/she is in position
of “KARTA” of Hindu Undivided Family (HUF) and he/she has the authority, power and
consent given by other partners to act on behalf of HUF.
43.15.3. In case one or more members is/are limited companies, the following documents shall be
submitted :
(a) Notary Certified copy of resolutions passed by Board of Directors of the Company,
permitting the company to enter into a JV agreement, authorizing MD or one of the
Directors or Mangers of the Company to sign JV Agreement, such other documents
required to be signed on behalf of the Company and enter into liability against the
company and/or do any other act on behalf of the company.
(b) Copy of Memorandum and Articles of Association of the Company.
(c) Power of Attorney (duly registered as per prevailing law) by the Company Authorizing the
person to do/act mentioned in the Para (a) above.
43.15.4. All the Members of JV shall certify that they are not black listed or debarred by Railways
or any other Ministry/Department of the Govt. of India/ State Govt. from participation in
Signature of Tenderer/s Page 46 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
tenders/contracts on the date of opening of bids either in their individual capacity as
members of the JV or the JV Firm in which they were/are members.
43.16. Credentials & Qualifying Criteria :- Technical and financial eligibility of the JV Firm
shall be adjudged based on satisfactory fulfillment of the following criteria:
43.16.1. Technical Eligibility Criteria (‘a’ or ‘b’ mentioned hereunder) :-
(a) Either the JV Firm or Lead Member of the JV Firm must have satisfactorily completed in
the last three previous financial years and the current financial year upto the date of
opening of the tender, one similar single work for a minimum of 35% of advertised value
of the tender.
OR
(b)(i) In case of composite work (e.g. works involving more than one distinct component, such
as Civil Engineering works, S&T works, Electrical works, OHE works etc. and in the case
of major bridges – substructure, superstructure etc.), for each component, at least 35% of
the value of any of such components individually for single similar nature of work should
have been satisfactorily completed by the JV Firm or by any member of the JV Firm in the
previous three financial years and the current financial year upto the date of opening of
tender. The member satisfying technical eligibility criteria for the largest component of the
work shall be the Lead Member and that Member shall have a majority (at least 51%)
share of interest in the JV firm.
(ii) In such cases, what constitutes a component in a composite work shall be clearly pre-
defined with estimated tender cost of it, as part of the tender documents without any
ambiguity. Any work or set of works shall be considered to be a separate component, only
when cost of the component is more than Rs.2 crore each.
(iii) However, as long as the JV Firm or any member of the JV firm meets with the
requirements, in one or more components of the work, and has completed a minimum of
35% of the advertised value of the tender for the same value of the component, and
resultantly, all the members of the JV collectively, then meet the prescribed technical
eligibility criteria, the JV shall stand technically qualified.
Note :-Value of a completed work done by a Member in an earlier JV firm shall be
reckoned only to the extent of the concerned member’s share in that JV Firm for the
purpose of satisfying his/her compliance to the above mentioned technical eligibility
criteria in the tender under consideration.
43.16.2. Financial Eligibility Criteria: - The contractual payment received by the JV firm or the
arithmetic sum of contractual payments received by all the members of JV Firm in the
previous three financial years and the current financial year upto the date of opening of
tender shall be at least 150% of the estimated value of the work as mentioned in the
tender.
Note: - Contractual payment received by a Member in an earlier JV firm shall be reckoned
only to the extent of the concerned member’s share in that JV Firm for the purpose of
satisfying compliance of the above mentioned financial eligibility criteria in tender under
consideration.
Signature of Tenderer/s Page 47 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
In this regard all correspondence & Notices to the Joint Venture shall be addressed
of J.V. firm or Lead Partner only……………………………………..
(Name with full address)
An account will be opened in any scheduled Bank/ Nationalized Bank in the name of
the Joint Venture Firm which will be operated by the authorized representative of
the J.V. firm. The name of Bank shall be intimated to the Railway by Lead Partner
of the J.V. and payment by the Railways shall be made to the said bank account only.
Now the parties have joined hands to form this joint venture of this
date………………… ( DD/MM/YY) with reference to and in confirmation of their
discussions and understanding Brought of record on date ………………………. (
DD/MM/YY).
In witness thereof All/Both the above named parties have set their respective hands
on this Joint Venture Agreement on the Day, Month & Year first above mentioned ,
in the presence of the following witnesses :-
Witness:-
1……………………. First Party (Authorized Signatory)
2……………………. Second Party (Authorized Signatory)
Third Party (Authorized Signatory)
Place:-----------------------
Dated:----------------------
Signature of Tenderer/s Page 48 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
SPECIAL CONDITIONS OF CONTRACT (NON-TECHNICAL)
1. These special conditions and the work schedule shall govern the works to be executed
under this contract in addition to and/or in part suppression of the General Conditions of
Contract-2010 corrected up to date and to carry out the work according to Standard
Schedule of Rates (SOR)-March 2012 for S&T Works of North Western Railway,
corrected up to date,on or before the opening of tender.
2. Where there is any conflict between the Special Conditions of Contract on one hand and
Standard Schedule of Rates-March 2012 for S&T Works on the other hand, the former
shall prevail.
3. Any special condition stated by the tenderer(s) in the covering letter submitted along with
the tender shall be deemed as part of contract to such extent only as have explicitly been
accepted by the Railway.
4. As far as possible the tenderer(s) bid should not have any condition or specification or
assumption contrary to the provisions in these tender documents on which the tenderer(s)
bid is based. Tenderer(s) own special conditions, not in conformity with the tender
specifications, are required to be listed separately & shall be supplemented by the details
of exact financial implications if applicable. Tenderer(s) special conditions, not in
conformity with the tender specifications, are required to be listed separately. Railway will
not take cognizance of any other conditions/variations from the drawings etc. except under
the format specified in the tender documents for such special conditions if any. It needs to
be emphasized that only such conditions/stipulations which are at variance with the tender
conditions, codal provisions, stipulated in the tender documents need be mentioned, in
case tenderer(s) choice to stipulated such special condition taking into account the
restrictions mentioned elsewhere in the tender document. Only such of the special
conditions/specifications stipulated by tenderer(s) which have been specifically approved
by the Railways in writing shall be deemed to have been accepted by the Railways. The
tenderer(s) conditions/stipulations/codal are at variance with the tender conditions/codal
provisions shall be withdrawn by the tenderer(s)
5. Use of Railway Land:
5.1 Use of Railway land required by the contractor(s) for constructing temporary offices,
quarters, hutments etc. for the staff and for storing materials etc. would be permitted to
him/them free of charges by Railway, if available. The location of these offices, hutments,
stores etc., will be subject to the approval of the engineer or his authorized representative.
The land will be restored to Railway by the contractor(s) in the same condition as when
taken over or in vacant condition as desired by the engineer, after completion of the work
or at any earlier day, as specified by the Engineer. The failure to do so will make the
contractor(s) liable to pay the cost incurred by the Railway for getting possession of land.
Signature of Tenderer/s Page 49 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
5.2 The tenderer(s) shall also acquaint himself/themselves with the availability of land,
working space for his/their works etc. The Railway will not acquire any land for the
purpose of movement of vehicles of the Contractor/s for executing the work by the
contractor/s.
6 Use of Private Land
The Contractor will have to make his/their own arrangements for use of private land,
outside Railway limits for due fulfillment of contract or for borrow pits, approaches, etc.,
directly with the land owners or local authority and to pay such rents if any as are payable
as may be mutually agreed upon between them.
7 Cess Charges:
7.1 For Contractor's labour employed/residing at stations and in colonies where railway
sanitary facilities exist, Contractor(s) will be required to pay cess charges as per rules in
force on the Railway from time to time.
7.2 For labour working between stations or at isolated places where railway facilities do not
exist, the Contractor(s) shall be required to provide necessary facilities for their labour in
terms of clause 59(4) of the General Conditions of Contract. In case of any failure on
his/their part, the Railway Administration at the cost of Contractor(s) shall provide the
necessary facilities and expenditure thus incurred will be recovered from his/their bills.
7.3 As per Railway Board letter No.2008/CE-I/CT/6 DATED 09.07.2008 (for
implementation of-The Building and other Construction Workers (RECS) Act, 1996 and
The Building and Other Construction Workers Welfare Cess Act,1996 in Railway
Contracts) the cess shall be levied and collected @ 1% of the cost of construction incurred
by an employer .
“The tenderer for carrying out any construction work in
Rajasthan/Haryana/Punjab/Gujarat Govt must get themselves registered from the
registering officer under Section-7 of the Building and other Construction Workers
Act,1996 and rules made thereto by the Rajasthan/Haryana/Punjab/Gujarat Govt and
submit certificate of Registration issued from the Registering Officer of the
Rajasthan/Haryana/ Punjab/Gujarat Govt.(Labour Deptt). For enactment of this Act, the
tenderer shall be required to pay cess @ 1% of the cost of construction work to be
deducted from each bill. Cost of material shall be outside the purview of cess, when
supplied under a separate schedule item.”
8 Contractor's Responsibility to arrange Tools, Plants, Machinery etc. 8.1 The Contractor should make his/their own arrangements for all plants and tools required
for the successful completion of the work in time. However, railway may, if available,
provide on their terms and at the cost of the contractor(s) (cost and terms as fixed by the
Railway as per extant rules) Railway's tools and plants, machinery, stores and other
facilities which the Contractor may require for the expeditious completion of this contract
and which in the opinion of Engineer is necessary but the Railway undertakes no
responsibility for doing so. The rates quoted by the tenderer will include cost of all tools
Signature of Tenderer/s Page 50 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
& plants, machineries, labour, materials etc. which will be required for successful and
methodical completion of the work. Nothing extra will be paid on this account.
8.2 The tenderer(s) shall supply along with his/their offer a list of special tools, plants and
equipments required for proper execution, inspection/maintenance of work. The detailed
descriptions/specifications of these tools, plants and equipments with full cost of each and
the sources of availability thereof shall be indicated along with the offer.
8.3 Either at the contractor/s request or suo-moto in order to prevent possible delay in the
execution of the work or due to contractor/s inability to make adequate arrangements for
plant or machinery tools and other equipments or due to any other reasons, the Railway
may give such plant and machinery, tools and other equipments on hire as can be readily
made available and as can be conveniently spared from Railway's Stock on usual hire
charges but this is not binding on the railway.
8.4 The decision of the Engineer in regard to hiring of equipment will be final and binding on
the contractor/s and the non-supply of such equipment shall not be entertained as a reason
for delay in the execution of works or the cause of any claims.
8.5 If the Railways make arrangements to supply tools, plants and machinery, the same will
be given on hire basis to the Contractor/s on such terms and conditions as may be
prescribed by the Railways and incorporated in Special agreement. The Hire and Staff
charges for operational and maintenance of plants will be fixed as per the Railway rules,
terms and conditions as prevailing at the time of hire.
9.0 Procedure of Material Accountal
9.1. For every work, a Tally book shall be opened by store In charge. Receipt/dispatch/ transfer/Balance entries are shown in Tally Book. Separate page is nominated for each item in Tally Book as per work schedule.
9.2. Material is received based on request of contractor. Contractor gives in writing the details of item including serial number and quantity of work schedule to SSE/Store. SSE/Store will inspect the material and its related documents mandatory as per contract agreement and material is entered to the Tally Book assigned for this particular work if found in order as per contract.
9.3. Whenever material is required for execution of work at site, contractor will request SSE/Store for issuing of material on his letter head/demand signed and stamped by his authorised person.
9.4. For issuing the material required by contractor as above, SSE/Store shall fill E-49 Form (Called HR) mentioning all relevant details and this form shall be signed by both SSE/Store incharge and authorised representative of contractor. There after material is taken by contractor for site of work and stored temporarily under his own custody. Material so stored temporarily at site shall be secured and protected by the contractor at his own resources.
9.5. While filling up measurement book, reference of E-49 and Tally Book are to be mentioned wherever required (applicable for both running & final bills).
9.6. Work site register will be maintained by the contractor for recording daily work
Signature of Tenderer/s Page 51 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
progress and measurements which is also signed by Railway’s representative deployed by SSE/Store incharge.
Note: Paras 9.1, 9.2, 9.3, 9.4, 9.5 and 9.6 above, are applicable for accountal of material supplied by the contractor of sanctioned works costing less than Rs.2.5 Crores.
9.7. Procedure for accountal of material supplied by the contractor of sanctioned
works costing more than Rs.2.5 Crores:- In addition to accountal of material supplied by the contractor of sanctioned work costing less than Rs.2.5 Crores as mentioned in Para 9.1, 9.2, 9.3, 9.4, 9.5 and 9.6 above, field units should also maintain register and accountal of register at site MAS (Material at Site) in accordance with Para 1436 to 1446 of Engineering Code. The contractor will provide necessary assistance for this purpose.
9.8 CONSIGNEE: The consignee for this work will be Senior Section Engineer
(/Tele/JU or other nominated JE/SSE by Sr.DSTE/Works/JU ----------. 9.9. LOADING/UNLOADING OF MATERIAL: All the material shall be transported by
the contractor from Store of SSE (Sig./Tele)/Con)/Ajmer/Jodhpur/Jaipur/Bikaner to the site of the work and vice versa with his own cost.
9.10. Before issuing Railway material to the Contractor, Store in charge will ensure
that contractor has already indemnified all the Stores handed over to him and executed the Indemnity Bond for this purpose on standard Performa given along with these documents in Annexure-XVI.
The material which will be supplied by the Railway for execution of work will also be
transported by the contractor from the Store of SSE (Tele.)/Con)/Ajmer/Jodhpur/ Jaipur/ Bikaner to the site of the work.
9.11. All stores drawn by the tenderer shall be accounted for either as installed as per
site measurements recorded or as per surplus stores returned to the Site Inspector-in-charge.
9.12. Empty cable drums will be the property of the Railway and shall be returned back
to SSE/Store incharge by the contractor. If cable drums are not fully empty then cable shall be rolled back in same cable drum and handed over to SSE/Store. If empty cable drums are not returned back to SSE/Store incharge then recovery @Rs.560/per empty cable drum will be recovered from the running/final bill of the contractor.
9.13. Security of Material
9.13.1. Once the material is handed over to the contractor, the contractor shall be responsible for the security of material irrespective of the fact that the material is kept in Railway premises. The contractor shall make adequate arrangements at site as deemed necessary for guarding the same from the thefts by outsiders or his labour or damage of any sort.
9.13.2. The cost of stores lost shall be realized by the Railway out of any payments due to the contractor in this contract or from any other contract executed by Govt.of
Signature of Tenderer/s Page 52 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
India.
9.14 Return of Surplus Store
9.14.1 The stores found to be surplus shall be returned to Consignee by the Contractor with his
own staff with immediate effect and proper (-) minus hand receipt will be issued to
contractor on receipt of surplus material by the Railway depot staff.
9.14.2 The contractor shall account for all material that was issued to him. A register shall be
maintained by the contractor, which shall be signed by the Contractor as a token of
receipt of material. All the issued material shall either be used in the installation or
returned to Consignee.
9.15 Return of Released Store
Released material shall be handed over to Consignee in systematic manner. Proper care
should be taken while releasing & transporting the material at General Stores, ------------
--------------(for the material to be D-S8ed) and other released material at
Telecommunication Stores, -------------------(which will not be D-S8ed).
9.16 Royalty, Octroi and other charges on materials to be supplied by the contractor for
construction of work except those to be supplied by the Railway will be borne by the
contractor/s.
10. Safety Precautions to be Taken While Permitting Plying of Vehicles in the
vicinity of working site
10.1 Safe working of contractors (Extract of Para 826 of IRPWM):– A large
number of men and machinery are deployed by the contractors for track renewals, gauge
conversions, doublings, bridge rebuilding etc. It is therefore essential that adequate safety
measures are taken for safety of the trains as well as the work force. The following
measures should invariably be adopted.
(i) The contractor shall not start any work without the presence of railway supervisor at site.
(ii) Wherever the road vehicles and/or machinery are required to work in the close vicinity of
railway line, the work shall be so carried out that there is no infringement to the Railway’s
schedule of dimensions. For this purpose, the area where road vehicles and/or machinery
are required to ply, shall be demarcated and acknowledged by the contractor. Special care
shall be taken for turning/ reversal of road vehicles/machinery without infringing the
running track. Barricading shall be provided wherever justified and feasible as per site
conditions.
(iii) The look out and whistle caution orders shall be issued to the trains and speed restrictions
imposed where considered necessary. Suitable flagmen/detonators shall be provided
where necessary for protection of trains.
(iv) The supervisor/workmen should be counseled about safety measures. A competency
certificate to the contractor’s supervisor as per Performa annexed shall be issued by the
officer, which will be valid only for the work for which it has been issued.
Signature of Tenderer/s Page 53 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
(v) The unloaded S&T materials after unloading along track should be kept clear off moving
dimensions and stacked as per the specified heights and distance from the running track.
(vi) Supplementary site specific instructions, wherever considered necessary shall be issued by
the Engineer in Charge.
10.2. Plying of road vehicles & working of machineries close to running tracks.
(i) Normally, the road vehicles shall be run or machinery shall be worked so as not to come
closer than 6.0m from centre line of nearest running track.
(ii) The land strip adjacent to running tracks, where road vehicle is to ply or machinery is to
work, shall be demarcated by lime in advance in consultation with the Railway’s
Supervisor. Wooden pegs at interval not exceeding 75mts shall be provided along the line
marking as permanent marks. The road vehicles shall ply or machinery shall work so as
not to infringe the line of demarcation.
6.0M FROM CENTER
LINE OF TRACK RUNNING TRACK
LIME MARKING
WOODEN PEGS
AT INTERVAL NOT
EXCEEDING 75M.
ROAD VEHICLE/MACHINERY
(iii) If a road vehicle or machinery is to work closer to 6.0m due to site conditions or
requirement of work, following precautions shall be observed.
a. In no case the road vehicle shall run or machinery shall work at distance less than 3.5m
from centre line of track.
b. Demarcation of land shall be done by bright coloured ribbon/nylon chord suspended on
75cm high wooden/bamboo posts at distance of 3.5 m from centre line of nearest running
track.
c. Presence of an authorized Railway’s representative shall be ensured before plying of
vehicle or working of machinery.
d. Railway’s Supervisor shall issue suitable caution order to Drivers of approaching train
about road vehicles plying or machineries working close to running tracks. The train
drivers shall be advised to whistle freely to warn about the approaching train. Whistle
boards shall be provided wherever considered necessary.
e. Lookout men shall be posted along the track at a distance of 800m from such locations
who will carry red flag and whistles to warn the road vehicle/machinery users about the
approaching trains.
f. On curves where visibility is poor, additional lookout men shall be posted.
(iv) If vehicle/machinery is to be worked closer to 3.5m from running track. Under unavoidable conditions, if road vehicles is to ply or machinery is to work closer to
3.5m due to site conditions or requirement of work, following precautions shall be
observed:
a. Plying of vehicles or working of machinery closer to 3.5m of running track shall be done
only under protection of track. Traffic block shall be imposed wherever considered
Signature of Tenderer/s Page 54 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
necessary. The site shall be protected as per provisions of Para No. 806 & 807 of P-Way
Manual as case may be.
b. Presence of a Railway’s Supervisor shall be ensured at worksite.
c. Railway’s Supervisor shall issue suitable caution order to Drivers of approaching train
about road vehicles plying or machineries working close to running tracks. The train
drivers shall be advised to whistle freely to warn about the approaching train.
(v) Precaution to be taken while reversing road vehicle along side the track. The location where vehicle will take a turn shall be demarcated duly approved by
Railway’s representative. The road vehicle driver shall always face the Railway track
during the course of turning/reversing his vehicle. Presence of an authorized Railway
representative shall be ensured at such location.
(vi) Road vehicle shall not be allowed to run along the track during night hours generally. In
unavoidable situations, however, vehicles shall be allowed to work during night hours
only in the presence of an authorized Railway’s representative and where adequate
lighting arrangements are made and where adequate precautions as mentioned earlier have
been ensured.
(vii) Road vehicles/machinery/plant etc. when stabled near running tracks shall be properly
secured against any possible roll off and always be manned even during off hours.
10.3. Execution of works close to or on running lines
(i) Any work close to or on running tracks shall be executed under the presence of a
Railway’s Supervisor only.
(ii) Precaution to be taken to ensure safety of trains while execution of work close to the
running line or on running lines.
a. Such works shall be planned and necessary drawings particularly with regard to
infringement to moving dimensions shall be finalized duly approved by competent
authority before execution of work. The work shall be executed only as per approved
procedure and drawings.
b. All temporary arrangements required to be made during execution of work shall be made
in such a manner that moving dimension do not infringe.
c. Suitable speed restriction shall be imposed or Traffic block shall be ensured as required.
d. The site shall be protected as per provisions of Para No. 806 & 807 of P-Way Manual as
case may be
e. Necessary equipment for safety of trains during emergency shall be kept ready at site.
(iii) Precaution to be taken to ensure safety of electrical/signal/ telephone cables while
excavating near tracks. a. Particular care shall be taken to mark the locations of buried electrical/signal/telephone
cables on the plans jointly with S & T/Electric supervisor and also at site so that these are
not damaged during excavation.
b. Copy of the cable plan should be given to the contractor’s authorised representative before
handing over the site to start the work.
c. Due care shall be taken to ensure that any part of the equipment or machinery or
temporary arrangement does not come close to cables while working.
(iv) Precaution to be taken during execution of works requiring traffic blocks.
Signature of Tenderer/s Page 55 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
a. Any work, which infringes the moving dimensions, shall be started only after the traffic
block has been imposed.
b. Before closing the work, the track shall be left with the proper track geometry so that the
trains run safely.
c. After completion of work the released sleeper and fittings should be properly stacked
away from the track to be kept clear of moving dimensions.
d. Block shall be removed only when all the temporary arrangement, machineries, tools,
plants etc. have been kept clear of moving dimensions.
(v) Precaution to be taken during execution of works during night. The work close to running line, generally, shall be carried out only during day hours. At
locations, however, where night working is unavoidable, proper lighting arrangement
should be made. The engineering indicator boards shall be lightened during night hours as
per the provisions of P-Way Manual. The staff deputed for night working should have
taken adequate rest before deploying them in night shift. We can specify duration of night
shift from 20.00 hrs to 04.00 hrs. All other safety precautions applicable for day time work
should be strictly observed during night working.
(vi) Precautions to be taken to ensure safety of workers while working close to running
lines. a. Necessary lookout men with red flags and whistles shall be provided to warn the workmen
about the approaching train.
b. Railway’s supervisor shall issue suitable caution order to Drivers of approaching train for
whistling to warn the workers about the approaching train. Whistle boards shall be
provided wherever considered necessary.
c. A “First aid kit” shall always be kept ready at site.
(vii) Precaution shall be taken for safety of public or passengers, while executing works at
locations, used by passengers and public. The worksite shall be suitably demarcated to keep public and passengers away from work
area. Necessary signage boards such as “Work in progress. Inconvenience is regretted”
etc. shall be provided at appropriate locations to warn the public/ passengers. Adequate
lighting arrangement of worksite wherever required shall be done to ensure safety of
public/passengers during night.
(viii) Precaution to be taken before stacking materials along side the track to ensure that
safety of trains is not affected. The following precautions shall be taken before stacking the materials along the track for
stacking of ballast, rails, sleepers etc.
a. The sites for material stacking should be selected in advance in such a manner to ensure
that no part of the material to be stacked is infringing to the Standard Moving Dimensions.
A plan of proposed stacking locations be made and signed jointly by an authorized
Railway’s representative and contractor’s representative.
b. The selected locations shall be marked by lime in advance.
c. Presence of an authorized Railway’s representative while unloading and stacking shall be
ensured.
d. The material shall be stacked in such a height so as to not to infringe SOD in case of
accidental roll off.
Signature of Tenderer/s Page 56 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
10.4. Protection of track during emergency
(i) Action to be taken when a contractor’s supervisor or vehicle operator apprehends
any unusual circumstances likely to infringe the track and endanger safe running of
trains.
At any time if a contractor’s supervisor or vehicle operator observes any unusual
circumstances likely to infringe the track and apprehend danger to safe running of track,
he shall take immediate steps to advise a Railway official of such danger and assist him in
protection of track.
The track shall be protected as under. One person shall immediately plant a red flag (red
lamp during night) at the spot and proceed with all haste in the direction of approaching
train with a red flag in hand (red lamp during night) and plant a detonator on rail at a
distance of 600m from the place of obstruction of BG track (400m for MG track) after
which he shall further proceed for not less than 1200m from the place of obstruction from
BG track (800m for MG track) and plant three detonators at 10m apart on rails. After this
he shall display the red flag (red lamp during night) at a distance of 45m from the
detonators.
Attempts shall also be taken to send an advise to nearest Railway station about the
incident immediately.
600m FOR BG,
400M FOR MG
1200m FOR BG,800M FOR MG
Detonator
Red flag
Red lamp
10m
Location of Danger
RUNNING TRACKDIRECTION
OF TRAIN
45m
(ii) Action to be taken if train is seen approaching to site of danger and there is no time
to protect the track as per guidelines mentioned above? In such a case the detonators shall be planted on rails immediately at distance away from
place of danger as far as possible and attention of driver of approaching train shall be
invited by whistling, waving the red flag vigorously, gesticulating and shouting.
(iii) What action shall be taken if more than one track is obstructed?
a. In case of single line protection as above shall be done in both the directions from place of
danger.
b. In case of double line or multiple lines, if other tracks are also obstructed, the protection as
above shall be done for other track also.
c. The protection shall be done in that direction and on that track first on which train is likely
to arrive first.
d. The Contractor’s Supervisors, Operators and lookout men shall be properly explained
about the direction of trains on running tracks.
Signature of Tenderer/s Page 57 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
(iv) Equipment required for protection of track.
Minimum compliment of protection equipment i.e. 10 detonators, 4 red hand flags, 4 red
hand lamps, 4 banner flags and whistles etc. shall always be kept ready at worksites for
use in case of emergency. Railway will arrange to provide detonators, whereas Contractor
shall arrange other equipment at his own cost.
(v) Arrangement of lookout men and competency required for lookout man to warn
labour about approaching train.
a. Contractor will provide lookout men.
b. The lookout men shall be properly trained in warning to staff at worksite about
approaching train.
c. Only those lookout men shall be provided at site who have been issued with a competency
certificate by the Railway’s Supervisor.
d. In case, it is felt necessary to provide lookout men by Railway, the charges for the same as
fixed by Railway Administration shall be recovered from Contractor.
10.5. Training to Supervisors and Operators of Contractor.
The Supervisors and Operators of the contractor proposed to be deployed at wok site,
which is close to the running track, shall be imparted mandatory training by the Railway at
site free of cost about the safety measures to be adopted while working in the vicinity of
running track. Engineer-in charge of the work shall decide the scale, extent & adequacy
of training. In case training is imparted at a recognized Railway training institute, the
charges for the same, as decided by Railway, shall be recovered from contractor. A
competency certificate to this effect to the individual Supervisor/Operator shall be issued
as given below, by a Railway Officer not below the rank of Assistant level. No
Supervisor/Operator of the Contractor shall work or allowed to work in the vicinity of
running track who is not possession of valid competency certificate.
All the labour, materials, tools, plants etc. except detonators, required for ensuring safe
running of trains shall be provided by Contractor at his own cost. Wherever lookout men
are provided by Railway, charges at the rate of Rs.500/- per man day shall be recovered
from Contractor.
Signature of Tenderer/s Page 58 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
Competency Certificate
Certified that Shri ____________________________________ Supervisor/Operator of
M/s. __________________________________ has been trained and examined in safety
measures to be followed while working in the vicinity of running railway track for the
work _________________________________. His knowledge has been found
satisfactory and he is capable of supervising the work safely.
This certificate is valid only for the work mentioned in this certificate only.
Signature and designation of the officer
10.6 Returns:
The tenderer shall furnish to the Incharge Engineer every week during the progress of the
work, a classified return of the number of the people employed on the work during the
week preceding the period. The contractor shall also furnish to the In charge Engineer a
report of any accident which may have occurred within 24 hours of its occurrence.
11. The Railway will not acquire any land for the purpose of movement of
vehicles of the contractor/s in doing earthwork.
12. Trespass
The Contractor shall at all times be fully responsible for any damage or trespass
committed by his agents or workmen in carrying out the work, even if such trespass is
authorised by the Engineer.
13. Inflammable Articles
Inflammable materials, such as petrol, oil, etc. shall be stored separately from other
materials and all due precautions as required under the Indian Explosives Act, or any other
act shall be taken by the Contractor(s) to prevent any fires etc.
14. Figures, Dimensions, etc.
Figures, dimensions and drawings shall supersede measurements by scale and drawing to
larger scale shall take precedence over those to a smaller scale. Special dimensions or
directions in the specification shall supersede all else.
Signature of Tenderer/s Page 59 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
15. Plea of Custom
The plea of custom prevailing will not on any account be permitted as excuse for an
infringement of any of the conditions of the contract or specifications.
16. Arrangements for Permits or License
Arrangements for permits and license for materials will not be made by the Railway or
any assistance given. The Contractor will have to make his own arrangements. No import
license shall be arranged by the railway for this work.
17. Taxes and Royalties
17.1 All rates quoted in the tender shall be deemed to be inclusive of all taxes, royalties’
payable by the Contractor(s) to the government or public body or local authority and no
additional amount will be paid or claim entertained on this account by the Railway.
17.2 All taxes such as Income tax, Sales tax and other taxes as prescribed by Central/State
Govt. from time to time shall be applicable. The Contractor shall be fully responsible
for payments of all such taxes without any liability of Railway Administration. Deductions
towards such taxes shall be made from the payments of the contractor in accordance with
rules in force from time to time.
17.3 Income Tax:-The Railway will deduct income tax @ 2% of the gross amount and
surcharge on income tax of each bill as prescribed by Government from time to time and
such deduction of Income Tax shall be recovered while making payment to the
Contractor/s. The settlement of income tax should be made by the contractor with the
Income Tax authorities.
18. Notice to Public Bodies The Contractor(s) shall give to the municipality, police and other authorities all notices
that may be required by law and obtain all requisite licenses for temporary obstructions,
enclosures and pay all fees, taxes and charges, which may be leviable on account of his
operations in executing the contract. He should make good any damage to adjoining
premises whether public or private and supply and maintain any lights, etc., required at
night.
19. Damage by Accident, Floods or Tides
19.1 The contractor shall take all precautions against damage from accident, floods or tides.
No compensation will be allowed to the contractor for his plant or part or material lost or
damaged by any cause whatsoever. The contractor shall be liable to make good the
damages to any structure or part of structure, plant or material of every description
belonging to the administration lost or damaged by any cause during the course of the
contractor's work.
19.2 The administration will not be liable to pay to the contractor any charges for rectification
or repairs to any damage which may have occurred from any cause, whatsoever, to any
part of the new/existing structure, during construction.
Signature of Tenderer/s Page 60 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
20. First Aid
The Contractor shall maintain in a readily accessible place first aid appliances including
an adequate supply of sterilized cotton wool. The appliances shall be placed under the
charge of a responsible person who shall be readily available during working hours.
21. Foreign Exchange Requirement
Any demand of foreign exchange for importing of equipments and materials shall not be
accepted.
22. Service Roads
22.1 The Contractor/s will be permitted to make use of existing service roads, or service roads
constructed by the Railway for its use free of cost. New service roads required by the
contractor/s either near the work site or elsewhere within or outside railway limits for
carriage of materials or for any other purpose whatsoever, will have to be constructed and
maintained by the contractor/s at his/their own cost. For the purpose of constructions of
service roads on railway land, permission will be given free of any charge. If any land
other than railway land is necessary to be acquired or to be entered upon, permission to
enter in the land will have to be arranged by the contractor/s at his/ their cost. The
contractor/s will not refer any claim, whatsoever on this account. The Railway, however,
reserves the right to make use of such service roads as may be constructed by the
contractor/s without payment of any charges.
23. Emergency Works
In the event of any accident or failure occurring in, on or about the work or arising out of
or in connection with the construction, completion or maintenance of the works, which in
the opinion of the Engineer requires immediate attention, the Railway may bring its own
workmen or other agency execute or partly execute the necessary work or carry out
repairs if the Engineer considers that the contractor/s is/are not in a position to do so in
time and charge the cost thereof, which will be determined by the Chief Signal &Telecom
(C), North Western Railway, to the contractor.
24. Free Maintenance Period
24.1. After the equipments, system/sub-system have been installed and commissioned, the
contractor shall be responsible for proper maintenance & supervision, free of cost, of the
equipments, system/sub-system till a period of 12 months as per Clause 47 of General
Conditions of Contract-2010, from the date of commissioning of the station.
24.2. During this free maintenance period, if any deficiency/fault is noticed in the functioning as
a result of any defect in design or manufacture, the same will be rectified by the contractor
at his own cost. During such rectification, if any faulty equipment/modules/
cards/system/subsystem/part either in hardware or in software or any other form, need
replacement or repair, they shall be provided by the contractor free of cost from the set of
equipments or modules that the contractor should bring to the site of installation in
addition to all the materials to be supplied against this contract.
Signature of Tenderer/s Page 61 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
24.3. In the free maintenance period, contractor will provide all the spares required for such
maintenance free of cost.
24.4. In addition to Para 24.1, 24.2 and 24.3 above, free maintenance period for EI will also
includes:-
(a) Maintenance and upkeep of all hardware, software & peripheral equipments;
(b) Attending to break-downs immediately;
(c) Periodical preventive maintenance (monthly);
(d) Repair/replacement of defective card/module/sub-system/system/part either in
hardware or in software or in any form;
(e) Modification to software and hardware required to run the existing system
satisfactorily.
24.4.1. For this purpose, contractor shall prepare a maintenance plan and make available the
services of maintenance Engineer and staff who will maintain and supervise the system.
24.4.2. If any failure takes place, then the maintenance personnels so deputed will immediately
attend & rectify the failure. If he fails to rectify the failure within six hours from the time
of information communicated to him by means of fax, telegram, telephone or any other
method at the address as specified by the contractor within geographical jurisdiction of ----
-----------------N.W.Railway, a penalty will be imposed @ Rs.100/- per hour per system
and part thereof, which will be recovered from the payments due to the contractor or from
the security deposit payable to the contractor. Working hours for the system will be twenty
four hours a day. Further if any failure is not rectified within 12 hrs from the time of
information communicated to him as above, Railway may proceed to rectify it
departmentally at contractor’s risk and penalty of Rs.2000/- plus cost of such rectification
will be deducted from the payments due to the contractor or from the security deposit
payable to the contractor.
Note:- No part refund of Security Deposit shall be permitted during the maintenance
period mentioned above.
25. Instructions/Directives of the Engineer’s Representative
25.1. The contractor shall at all times, execute the contract work only in the presence and under
the supervision of the Engineer's Representative or a Railway employee specifically
appointed on his behalf. No work under the contract shall, therefore, be commenced by
the contractor without the express permission of the Engineer’s representative.
25.2. The contractor shall always execute the work under this contract in strict compliance with
the instructions/directives by the Engineer's representative. Any act of non-compliance
with the instruction/directives issued by the Engineer's representative shall be considered
as a default of the contractor where after the
Railway shall be free to take further appropriate action as provided in the contract for
dealing with such defaults of the contractors. The decision of the Engineer-in-charge
whether there has been an act of non-compliance with the instruction/ directives of the
Engineer's representative for the purpose of this clause shall be final and conclusive.
Signature of Tenderer/s Page 62 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
25.3. The instructions/directives by the Engineer's representative shall not, however, absolve
the contractor of his responsibility or reduce his responsibility in any manner whatsoever
in regards to maintaining at all times the safe working conditions at the work site.
26. Non-compliance with the instructions/directives of the Engineer’s
representative
26.1. The contractor shall always comply with the instructions/directives issued by the
Engineer's representative from the time to time. In the event of any non-compliance with
such instructions/directives, apart from and in addition to other remedies available to the
Railway as specified herein above the Engineer's representative may employ at the works
Railway's workmen with necessary equipment as considered appropriate and adequate by
him to provide the requisite conditions for the safe and unhampered movement of Railway
traffic. The decision of the Engineer's representatives in regard to the need of
appropriateness and adequacy of the deployment of the Railway Workmen with necessary
equipment shall be final and conclusive.
26.2. When the Railway workmen with necessary equipment are deployed in the above manner,
recovery at the following rate shall be made from the contractor's dues under this contract
or any other money of the contractor available with the Railway under this contract. The
recovery for the total Railway Workmen Hours employed at the rate of Rs. 100/-
(Rupees Hundred only) per Workmen-Hour irrespective of the type and grade of the
Railway Employee actually employed. The aggregate period of the Workman-Hours for
the above recoveries shall be reckoned from the time the Railway Workmen are actually
deployed at the work site till the work is completed to the satisfaction of the Engineer's
Representative whose decision in this regard shall be final and conclusive.
26.3. During the above-mentioned period of suspension of work, the contractor shall not in any
manner attempt to carry out any work at the work site. Any such attempt of the contractor
shall be deemed to be an unauthorized work on the work site. For such acts, the contractor
shall then be liable for further appropriate action under the relevant provisions of the
Indian Railway Act.
27. Warranty
27.1. The contractor shall warranty that all materials & equipments to be supplied and installed
as per this tender, shall be free from defects and faults in design, material, workmanship
and manufacture and shall be of the highest grade and consistent with the established and
generally accepted standard for materials of the type ordered and in full conformity with
the contract specifications.
27.2. This warranty shall start from the date of commissioning of system installed at the
station and shall expire 1 years after commissioning of the station. Whether the
maintenance of the installation is taken over by the Railways or an AMC is done, the
Contractor shall be responsible for the proper functioning of the system for the period of
warranty.
27.3. The equipments/system/sub system/modules/cards etc for which warranty period of
more than 1 year has been decided/fixed by RDSO in approved RDSO’s Specifications,
then for those equipments/system/sub system/modules/cards etc, contractor will submit the
warranty certificate issued by the OEM’s for the period as decided/fixed by RDSO.
Signature of Tenderer/s Page 63 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
27.4. During the period of Warranty, the contractor shall remain responsible to arrange
replacement and for setting right at his own cost any equipment/subsystem either in
hardware or in software or any other form supplied by him which is of defective
manufacture or defective design or defective material/component becomes unworkable
due to any cause whatsoever. The decision of the Railway to attend to any damage or
defect in work shall be final and binding on the Contractor.
27.5. If it becomes necessary for the contractor to replace or renew any defective portions of the
system under this clause, the provisions of this clause shall apply to the portion of
system/subsystem so replaced for further period of 12 months from the date of such
replacement or renewal or until the end of the warranty period whichever may be later. If
any defect is not remedied within reasonable time, the Railway may proceed to do the
work at contractor’s risk and expense, but without prejudice to any other rights, which the
Railway may have against the contractor in respect of such defects.
27.6. All inspections, replacements or renewals carried out by the contractor during the
warranty period shall be subject to the same conditions of the contract.
27.7. All replacement and repairs and design change that the Railway shall call upon the
contractor to deliver or perform under this warranty shall be delivered and performed by
the contractor within one month, promptly and satisfactorily.
27.8. The decision of the railway in regard to contractor’s liability and the amount, if any,
payable under this warranty shall be final and conclusive.
27.9. Due to analysis of failures, if any design deficiency is pointed out by the Railway, the
contractor shall rectify it at his own cost.
27.10. After the plant has been taken over and during the period of warranty, the contractor shall
be responsible to the extent expressed in this clause for any defects that may develop
under the conditions provided for by the contract and under proper use, arising from faulty
materials, design or workmanship in the plant or from faulty erection of the equipment
under the supervision of the contractor, but not otherwise and shall remedy such defects at
his own cost and when called upon to do so by the purchaser who shall state in writing in
what respect the portion is faulty.
28. Shifting of Electrical/Telegraph Wires
In some stretches, high-tension grid towers /electric telegraph/telephones wires or posts
etc. are to be shifted. It is expected that the electric lines/towers will be shifted in good
time but in case, there is any delay on this account suitable extension in date of
completion will be considered and given to the contractor for only the effected portion
and no compensation whatsoever in this respect or due to the delay thus caused will be
payable and contractor has to adopt such methods of execution of earthwork so as not to
cause any damage to existing structure lines etc.
29. Handing Over of Site for Work
The entire site, required for execution of work, will be handed over to the contractor.
However, Railway may not hand over the entire site required for completion of this work,
suitable extension in the completion period of the contract, will be granted without any
payment of extra claim to the contractor.
Signature of Tenderer/s Page 64 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
30 Mode & Terms of Payment:
30.1 All payments will normally be made only for finished works on the basis of mode and
terms of payments agreed upon and provided in the contract. For Schedule (N.S Items)
a) )80% of the accepted cost of the items of the Schedule ‘(duly inspected by the nominated Inspection Authority) will be paid on receipt of the equipment by the Consignee.
b)10% of the accepted cost (in addition to the 80% released above) shall be paid after installation/erection of that particular equipment.
c)The balance 10% of Schedule will be paid after completion of work..
100% will be paid for spares & for items, which are not required to be erected by the contractor, on receipt of the equipment and no loss certificate by consignee.
Note1: For items pertaining to consignee inspection necessary purchase Voucher of the items is to be submitted.
Note:2 On the basis of final acceptance certificate from the Railways engineer for all the works in all the sections covered in this contract and reconciliation of materials issued the final bill for the balance payment for each item of work shall be submitted by the contractor along with a clear “ No claims certificate”.
Note3: FINAL SETTLEMENT
On expiry of the warranty period and issue of certificate of final acceptance of the entire installations the security deposit will be refunded to the contractor after adjustment of any dues payable by the contractor.
30.1.2 IMPLICATION OF MODVAT RULES:
The liability of the purchaser to reimburse exercise duty is limited to such sum as may be found legally due and payable in respect of contract goods after availing the full credit on all inputs used in the manufacture of the finished products irrespective of whether the contractor has in fact availed of the said credit or not.
30.1.3 In case of vitiation due to variation in quantities the amount by which vitiation occurs will not be payable to the contractor.
30.1.4 MOBILISATION ADVANCE: Mentioned vide para no. 32 of special conditions ( Non technical ) mobilization advance is not applicable for this tender.
30.2. MANNER OF PAYMENT: Payment to the contractor will be made through Electronic
Fund Transfer (EFT) for payment of running and final bills. The tenderers will also fill the
Annexure-I indicating the bank account number, name of bank and bank specific code
number (MICR/IFSC) as enclosed. The conditions and Annexure-I will be part of the
tender document.
31. Accident/natural calamities:-
31.1 Vehicle and equipments of the contractor can be drafted by Railway Administration in
case of accidents/natural calamities involving human lives.
31.2 For payment purpose, the item may be operated as New Non-Schedule (NS Item) as per
existing norms and powers delegated.
31.3 Contractor may submit list of vehicles and equipment available with him.
Signature of Tenderer/s Page 65 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
32. MOBILIZATION ADVANCE (For Contract Value Rs.25 Crores and Above):-
32.1 This shall be limited to 10% of the contract value and payable in 2 stages as indicated
below:-
Stage-I: - 5% of Contract Value on signing of the contract agreement.
Stage-II:-5% on mobilization of site-establishment, setting up offices, bringing in
equipment and actual commencement of work.
The two stages of advances shall be payable immediately after signing of contract
documents and at the time of mobilization, respectively.
32.2. The rate of interest on ‘Mobilization Advance’ is @ 4.5% per annum above the Base Rate
of State Bank of India as effective on the date of approval of payment of Mobilization
Advance by the Competent Authority.
32.3. The Mobilisation Advance Clause shall be restricted only for high value tenders of Rs.25
crore and above.
32.4. The Mobilisation Advance shall be against an irrevocable Bank Guarantee of value 110%
of the sanctioned advance amount. The Bank Guarantee shall be from a Nationalised
Bank in India or State Bank of India, all scheduled Banks in India, National Savings
Certificate etc.
32.5 Method of Recovery of Interest:
“Interest will be recovered on the advance outstanding for the period commencing from
the date of the payment of advance till date of particular on account bill (through which
recovery of principal is effected) and adjusted fully against on account bill along with pro-
rate principal recovery. In the event of the any shortfall the same will be carried forward
to the next on account bill and will attract interest @ 4.5% per annum above the Base Rate
of State Bank of India as effective on the date of approval of payment of mobilization
advance by the Competent Authority.
33.0 Stage Payment on supply of steel in the Works Contract (For contract
value Rs. 15.00 crores & above) :- Deleted (Not applicable for S&T
tenders)
34.0 Incentive Bonus Payment Clause (For Plan head Doubling and Traffic
Facilities works only):- Deleted (Not Applicable for S&T tenders)
35. Joint procedure order for undertaking digging work in the vicinity of
underground Signalling, Eelectrical & Telecommunication Cables
Following joint procedure shall be followed while carrying out any digging work near to
existing signaling & telecommunication and electrical cables so that the instances of cable
cut due to execution of works can be controlled and minimized.
35.1 Before taking up any digging activity on a particular work by any agency, Sr.
DSTE/DSTE or Sr. DEE/DEE of the section shall be approached in writing for permitting
Signature of Tenderer/s Page 66 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
to undertake the work. Sr.DSTE/DSTE or Sr. DEE/DEE, after ensuring that the concerned
executing agencies including the contractor have fully understood the S&T and Electrical
cable route plan, shall permit the work in writing within 7 days of the request made for the
same.
35.2. After getting the permission from S&T or Electrical department as the case may be, the
relevant portion of the cable route plan shall be attached to the letter through which
permission is issued to the contractor for commencement of work and ensuring that the
contractors have fully understood the cable route plan and precautions to be taken to
prevent damage to the underground cables. The contractor shall be asked to study the
cable plan and follow it meticulously to ensure that the safety of the cable is not
endangered.
35.3. In all the sections where major project are to be taken up/going on S&T department shall
deploy their official to take preventive/corrective action at site of work. As regards
Electrical Department, the official may be deputed on need basis.
35.4. No new OFC or quad cable shall be laid close to the existing track. It shall be laid close to
the Railway boundary on one side of the Railway track to the extent possible to avoid any
interference with the future works (doubling etc). It shall be ensured in the new works of
cable laying that the cable route is properly identified with electronic or concrete markers.
Wherever multiple cables are laid in a trench, RFID markers may be provided for easy
identification of the cable. Henceforth, wherever cable laying is planned, before
undertaking the cable laying work, the cable route plan of the same shall be prepared by
the Dy.CSTE/C or Dy.CEE/C and shall be got approved from the concerned Sr.
DSTE/DSTE or Sr. DEE/DEE and also from the concerned Dy.CE/C for new lines and
from the concerned Sr. DEN for all other projects including doubling GC etc., to avoid
possible damage in future. Such approval shall be granted within 15 days of the
submission of the request.
35.5. The works of excavating the trench and laying of the cable should proceed in quick
succession, leaving a minimum time between the two activities.
35.6.In case damage is caused to OFC/Quad cable/Electrical cable/Signalling cable during
execution of the work, the contractor is liable to pay a penalty for damaging the cable.
Penalty shall not be levied in case of the following:-
(i) Detailed cable route plan is not provided or cable is not protected as per laid down
procedures.
(ii) The alignment of the cable does not tally with the information provided to the contractor.
(iii) No representative of S&T department was available at site guarding the cables on the
fixed pre determined date and time.
35.7. Penalty to be imposed for damages to cable as per Railway Board Telecom Circular
No.17/2013 issued vide Railway Board letter no.2003/Tele/RCIL/ 1Pt.IX dated
24.06.2013.
35.8. In case of damage to OFC, owner department of OFC should be paid 5/6th
of the penalty
recovered. In case owner is RCIL, 5/6th
of the penalty recovered will be paid to RCIL.
Signature of Tenderer/s Page 67 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
35.9. All types of signalling & OHE bonds i.e. rail bond, cross bond and structure bond shall be
restored by the contractor with a view to keep the rail voltage low to ensure safety of
personnel.
35.10. S&T cable and electrical cable route plan should be prepared by the concerned S&T and
Electrical officers respectively and got approved before undertaking the work. The
completion cable route plan should be finalized block section by block section as soon as
the work is completed.
35.11. All cable laying works shall be executed as per laid down technical specifications, such as
protection measures/ protective cover, compaction of refilled material etc.
*****
Signature of Tenderer/s Page 68 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
ANNEXUREI”
1. Full name of Contractor/s
Construction firm and year of
establishment.
:
2. Registered Head Office Address :
3. Branch Office in India :
4. Constitution of firm giving full details
including name of Partners/
Executive/s Power of Attorney holders
etc.
:
5. Particulars of registration with
Government semi Govt. Organization,
public sector undertaking and local
bodies etc.
:
6 The bank account number, name of
bank and bank specific code number
(MICR/IFSC)
Note: - The information furnished above shall be supported by authentic documents
Including registration number of the firm. The copies of documents submitted shall be
duly attested by Gazetted officers.
Signature of Tenderer/s
Dated:--------------------
Signature of Tenderer/s Page 69 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
“ANNEXURE-II”
FORMAT FOR AFFIDAVIT TO BE SUBMITTED BY TENDERER ALONGWITH THE
TENDER DOCUMENTS
(To be executed in presence of Public Notary on non-judicial stamp paper of the value of Rs.
100/- . The stamp paper has to be in the name of the tenderer)**
I …………………………………... (Name and designation)** appointed as the
attorney/authorized signatory of the tenderer (including its constituents), M/s.
______________________ (hereinafter called the tenderer) for the purpose of the Tender
documents for the work of ______________ as per the Tender No.______________ of North
Western Railway, do hereby solemnly affirm and state on behalf of the tenderer including its
constituents as under:
1. I/We the tenderer (s), am/are signing this document after carefully reading the contents.
2. I/We the tenderer (s) also accept all the conditions of the tender and have signed all the
pages in confirmation thereof.
3. I/We hereby declare that I/We have downloaded the tender document from North western
Railway website www.northwesternrailway.gov.in and printed the same. I/We have verified
the content of the printed document from the website and there is no addition, no deletion or
no alteration to the content of the tender document. In case of any discrepancy noticed at
any stage i.e. evaluation of tenders, execution of work or final payment of the contract, the
master copy available with the Railway Administration shall be final and binding upon
me/us.
4. I/We declare and certify that I/we have not made any misleading or false representation in
the forms, statements and attachments in proof of the qualification requirements.
5. I/We declare that the information and documents submitted along with the tender by me/us
are correct and I/we are fully responsible for the correctness of the information and
documents, submitted by us.
6. I/We understand that if the certificates regarding eligibility criteria submitted by us are
found to be forged at any time during process for evaluation of tenders, it shall lead to
forfeiture of the tender EMD. Further, I/we [insert name of the tenderer]**_______ and all
my/our constituents understand that my/our offer shall be summarily rejected.
Signature of Tenderer/s Page 70 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
7. I/We also understand that if the certificates submitted by us are found to be false at any time
after the award of the contract, it will lead to termination of the contract, along with
forfeiture of EMD/SD and Performance Guarantee.
DEPONENT
SEAL AND SIGNATURE
OF THE TENDERER
VERIFICATION
I/We above named tenderer do hereby solemnly affirm and verify that the contents of
my/our above affidavit are true and correct. Nothing has been concealed and no part of it is false.
DEPONENT
SEAL AND SIGNATURE
OF THE TENDERER
Place :-
Dated:-
** The contents in Italics are only for guidance purpose.
Details as appropriate, are to be filled in suitably by tenderer.
Attestation before Magistrate/ Notary Public.
Signature of Tenderer/s Page 71 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
“ANNEXURE III”
Details of works of similar nature physically completed in all respect as per contract agreement and directly awarded
by Govt./Semi Govt./ Public Sector Undertaking/Autonomous bodies/Municipal Bodies in last three and current
financial year as on date………….
SN
Nam
e o
f w
ork
Nam
e o
f o
rgan
izat
ion f
or
wh
om
wo
rk p
hy
sica
lly
com
ple
ted
Ty
pe
of
org
aniz
atio
n
(Go
vt.
/ S
emi
Go
vt.
/PS
U/
Au
ton
om
ou
s b
od
ies/
Mu
nic
ipal
Bo
die
s) f
or
wh
om
wo
rk e
xec
ute
d
Co
ntr
act
Ag
reem
ent
No
. &
Dat
e
Ori
gin
al v
alu
e of
con
trac
t
agre
emen
t
Fin
al v
alu
e o
f co
ntr
act
as
com
ple
ted
Pay
men
t re
ceiv
ed t
ill
op
enin
g o
f p
rese
nt
ten
der
(On
acc
oun
t/fi
nal
bil
l)
Time taken for
completion of work
Pri
nci
pal
fea
ture
of
the
wo
rk i
n b
rief
Date of
award of
contract
Date of
actual
completion
1 2 3 4 5 6 7 8 9 10 11
1.
2.
3.
Note:- (i) Above detail should be given only for works which have been physically completed in all
respects. Part completed work shall not be considered.
(ii) Certificate from Private individual firms for whom such works are executed shall not be
Considered for eligibility of tenderers.
Signature of Tenderer/s Page 72 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
(iii) The tenderers must attach attested performance certificate issued by the organizations for
whom the work was carried out in the proforma as per Annexure-IV.
(iv) Not more than five certificates should be attached.
Signature of Tenderer/s Page 73 of 131 For Sr.DSTE/Works
North-Western Railway,
Jodhpur
“ANNEXURE-IV”
(Completion Certificate by Govt./Semi Govt./ Public Sector Undertaking/
Autonomous bodies/ Municipal bodies for work directly awarded by them)
Name of Organization
Postal address, Phone No., Email ID, Fax No
Letter No. Date :-……….
1. Name of work
2. Contract Agreement (C/A) No. and date
3. (i) Name of Firm/Organization with address
(ii) In case of JV……. Name and % share of individual
firms.
4. Original value of contract agreement.
5. Final value of contract as completed. (if final bill paid)
6. Date of award of contract
7. Has the work physically been completed in all respect
as per contract agreement?
( Yes / No )
8. If yes, then actual date of physical completion.
9. Total payment made in above contract till the date of
opening of present tender.
10. In case of composite work:
Component of payment made in respect of similar
nature of work e.g. earthwork /Track/Bridges etc. (as
defined in eligibility criteria) out of the total payment
made under Sr. No. 9 above.
I hereby certify that above mentioned work has been physically completed in all respect as
per contract agreement. Performance of the contractor while executing the work had been
satisfactory.
(Signature)
Name and Designation of officer
Mobile No. of officer
Seal of officer
Note:- (i) Submission of false certificates by tenderer shall lead to, forfeiture of EMD
and other action including penal action (Annexure-II).
(ii) Copy of certificate duly attested shall be submitted along with tender
document.
(iii) Payment made as indicated in above certificate (At Sr. No. 9/ Sr. No. 10)
will be considered as value of completed work for the purpose of eligibility
under Para 22 (ii) of Instructions to tenderers and conditions of tender.
Signature of Tenderer/s Page 74 of 131 For Sr.DSTE/Works
North-Western Railway,
Jodhpur
“ANNEXUREV”
List of awarded works under execution
Sr. No
Name of work Organization for whom work is
being done
Date of award of contract
Contract Agreement
No & Date
Contract Value
Value of balance work yet
to be done
Schedule of completion
Date of Commence-
ment
Expected date of
completion
1 2 3 4 5 6 7 8 9
1
2
3
4
5
6
7
8
NOTE: - The information furnished above shall be supported by authentic documents. The copies of documents submitted should be duly attested by a Gazetted officer.
Signature of Tenderer/s
Dated:--------------------
Signature of Tenderer/s Page 75 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
“ANNEXUREVI”
List of Plants & Machinery available on hand and proposed to be inducted (Own and hired to be
given separately) for the subject work
Sr.
No.
Particulars of
Plants/Machinery
No.
of
Unit
Kind
and
make
Capacity
Age &
Conditions
Owned
by
firm
Proposed to be purchased
Date of
placing
order
Likely date
of receipt
1 2 3 4 5 6 7 8 9
1
2
3
4
5
6
7
8
9
Note: Indicate clearly, whether (i) Owned by firm, or (ii) To be purchased by firm giving date of
placing order and likely date of receipt.
Signature of Tenderer/s
Dated:--------------------
Signature of Tenderer/s Page 76 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
“ANNEXUREVII”
List of Personnel, Organization available on hand and proposed to be engaged for the subject
work.
Sr.
No.
Name &
Designation
Qualification Professional experience Remarks
1. 2 3 4 5
1
2
3
4
5
6
7
8
9
Signature of Tenderer/s
Dated:--------------------
Signature of Tenderer/s Page 77 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
Annexure-VIII
CERTIFICATE FOR NON EMPLOYMENT/ PARTNERSHIP OF RETIRED RAILWAY
EMPLOYEES
(1) For Proprietorship firms (Either as Sole Tenderer or as Partner of JV)
a) It is to certify that I, the tenderer have not retired from Railway service as Gazetted Officer
within 02 years from the date of submission of this tender form.
b) It is to certify that I, the tenderer, have retired as Gazetted Officer form Railway service and
have obtained permission from the President of India to participate in the Tenders as tenderer.
Copy of the permission granted to me is enclosed.
(Note :- Strike off the para which is not applicable).
Signature …………….
Name:-……………….
(2) For Partnership Firms or Limited Companies (Either as Partnership Firm/Limited Company
participating as tenderer byself or partner of JV firm)
a) It is to certify that none of the Directors/Employee of the company or partners/employee of the
firm has retired from Railway service as Gazetted Officer within 02 years from the date of
submission of this tender form.
b) It is to certify that following persons working as Directors/Employee of the company or
partners/employee of the firm are retired from Railway service within 02 years from the date
of submission of this Tender Form and he/she/they have obtained permission from the
President of India to become partner or take employment in this Firm/Company which is
participating in such tenders as tenderer.
Sr.
No.
Name of Person &
Designation
Date of
Retirement
Copy of permission granted
enclosed (Reference no.etc.)
1.
2.
3.
(Note :- Strike off the para which is not applicable).
Signature ………………
Name:- …………………
Signature of Tenderer/s Page 78 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
Annexure-IX
AFFIDAVIT
(For sole proprietorship firm)
I ……………………….……………… (Indicate Name – Sole Proprietor) S/o
……………….………… Proprietor of M/s……………….……….. (Indicate Name – Proprietary
firm) situated at ………………….……… do hereby solemnly affirm & declare as under:-
1. That I am the “Sole Proprietor” of the firm working in the name & style of
M/s………………………. (Indicate Name – Proprietory firm) at ……………
2. That the submission of facts stated in para 01, is true & correct.
DEPONENT
VERIFICATION
I, the above named deponent do hereby solemnly affirm & verify that the
contents of my above affidavit are true & correct. Nothing has been concealed and no
part of it is false.
DEPONENT
Place :-
Date :-
Necessary Note:- The stamp duty shall be governed by the provision of the Law relating to stamp in force in that State at the time when such AFFIDAVIT is being executed. Affidavit may be affirmed before the Oath Commissioner/Notary Public. vko’;d fVIi.kh%& okLrs izksijkbVjh QeZ ij LVkEi M;wVh] lEcfU/kr jkT; ds LVkEi vf/kfu;e ds
rgr~ ns; gksxhA ’kiFk&i= dk Affirmation **vksFk dfe’kuj** ds }kjk fd;k tkuk visf{kr gSa A
Signature of Tenderer/s Page 79 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
Annexure-X
UNDERTAKING FROM ALL THE PARTNERS OF THE PARTNERSHIP, FIRM FOR NOT
BEING BLACK LISTED OR DEBARRED BY RAILWAY or ANY OTHER MINISTRY/
DEPARTMENT OF THE GOVT. OF INDIA/PSU (PUBLIC SECTOR UNDERTAKING) etc.
We …………………………..all the partners of the partnership firm………………………
(Name of firm) do hereby declare that, we have not been black listed or debarred by Railways or any
other Ministry/Department/Public Sector Undertaking of the Govt. of India/ any State Govt. from
participation in tenders/ contract on the date of opening of bids either in our individual capacity or in
any firm in which we are partners.
(1) Signature ……………………….
Name :- ……………………….
(2) Signature ……………………….
Name :- ……………………….
(3) Signature ……………………….
Name :- ……………………….
(4) Signature ……………………….
Name :- ……………………….
(5) Signature ……………………….
Name :- ……………………….
Name of Firm :
Seal/Stamp of the Firm
Signature of Tenderer/s Page 80 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
‘Annexure-XI’
MEMORANDUM OF UNDERSTANDING FOR JV
(The memorandum of understanding shall be submitted in following
format on the non judicial stamp of Rs.100/-)
NOW THIS Memorandum of Understanding is executed at …………………. (Name of
Place) on this date ………………… (DD/MM/YY) between M/s ……………………..(Name of first
constituent and address) as the first party represented by Shri ………………………………and
M/s…………………………… (Name of 2nd
constituent and address )represented by
Shri……………………….. as the second party and so on ( the expression and words of first and
second and other shall mean and include their heirs successors, assigns, nominees, execution,
administrators and legal representatives respectively) and so on 3rd
, 4th
& 5th
subsequent parties.
WHEREAS all the parties are engaged mainly in the business of execution of Civil
Engineering and general contracts for various Government Departments and organizations.
AND WHEREAS the parties herein above mentioned are desirous of entering into a joint
venture for carrying out civil engineering and/or contract works in connection with Tender
No………………………..“………………………………………………………………………………
……………………………………………………………………………………………………………
…………………………………………………………… (Name of work) “as mutually decided
between members of Joint Venture Agreement.
1. That we M/s…………………………….. (JV firm) on behalf of all members of this joint
venture agreement agreed that M/s / Shri ……………………………… will be “Lead Partner”
of this Joint Venture.
2. That under this MOU, the work will be done jointly by M/s / Shri………………………….. the
first party and M/s / Shri ……………………… the second and so on ……………..in the name
and style of ……………………………….(Name ) ( joint venture firm).
3. That we JV firm M/s …………………………. on behalf of all the members of JV firm shall
be legally liable, severally and jointly responsible/ liable for the satisfactory/ successful
execution/ completion of the works including maintenance period in all respects and in
accordance with terms and conditions of the contract.
4. That we M/s JV firm…………………………….. on behalf of all the members of the JV firm
to which the contract is awarded, shall be jointly and severally liable to the Employer
(Railways) for execution of the project in accordance with General and Special Conditions of
the Contract. The JV members shall also be liable jointly and severally for the loss, damages
caused to the Railways during the course of execution of the contract or due to non-execution
of the contract or part thereof.
Signature of Tenderer/s Page 81 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
5. M/s ……………………(Name of Lead Firm ) of JV firm shall be the lead member of the JV
firm who shall have a majority ……………..% share of interest in the JV firm. The other
(One/Two) members shall have following share: - M/s ………….. (Name of Second Firm)
have ……. % and M/s ………….. (Name of Third Firm if any ) have ………% share of
interest in the JV Firm.
6. That this JV shall be valid during the entire currency of the contract including the period of
extension, if any ,and the maintenance period after the work is completed.
7. That we all the Joint Venture members shall authorize M/s
…………………………………….…one of the members on behalf of the JV firm to deal
with the tender, sign the agreement or enter into contract in respect of the said tender, to
receive payment, to witness joint measurement of work done, to sign measurement books and
similar such action in respect of the said tender/contract. All notices/ correspondence with
respect to the contract would be sent to this authorized member……………………………….
(address) of the JV firm.
8. That no member of the JV shall have the right to assign or transfer the interest right or liability
in the contract without the written consent of the other members and that of the employer
(Railways) in respect of the said tender/contract.
9. That we all the members of the JV shall certify that we have not been black listed or debarred
by Railways or any other Ministry/Department /PSU (Public Sector Undertaking) of the Govt.
of India/ State Govt. from participation in tenders/contract in the past either in our individual
capacity or as a member of the JV firm or partnership firm in which they were
members/partners.
10. That this Joint Venture MOU shall in all respect be governed by and interpreted in accordance
with Indian Laws.
11. That a member of JV firm shall not be permitted to participate either in individual capacity or
as a member of another JV firm in the same tender.
12. That the tender form shall be purchased and submitted only in the name of the JV firm and not
in the name of any constituent member.
13. That the EMD shall normally be submitted only in the name of the JV firm and not in the name
of constituent member. However, in exceptional cases EMD in the name of lead partner can be
accepted subject to submission of specific request letter from lead partner stating the reasons
for not submitting the EMD in the name of JV and giving written confirmation from the JV
partners to the effect that the EMD submitted by the lead partner may be deemed as EMD have
been submitted by JV firm.
14. Once the tender is submitted, the MOU shall not be modified/ altered/ terminated during the
validity of the tender. In case the tenderer fails to observe/comply with this stipulation, the full
Earnest money Deposit (EMD) shall be forfeited. In case of successful tenderer, the validity of
this MOU shall be extended till the currency of the contract expires.
Signature of Tenderer/s Page 82 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
15. Similarly, after the contract is awarded, the constitution of JV firm shall not be altered during
the currency of contract except when modification become inevitable due to succession laws
etc. and in any case the minimum eligibility criteria should not get vitiated. Failure to observe
this stipulation shall be deemed to be breach of contract with all consequential penal action as
per contract conditions.
16. Approval for change of constitution of JV firm shall be at the sole discretion of the Employer
(Railways). The constitution of the JV firm shall not be allowed to be modified after
submission of the tender bid by the JV firm except when modification becomes inevitable due
to succession laws etc. and in any case the minimum eligibility criteria should not get vitiated.
In any case the Lead Member should continue to be the Lead Member of the JV firm. Failure
to observe this requirement would render the offer invalid.
17. An account will be opened in any Schedule Bank / Nationalized Bank in the name of the Joint
Venture firm which will be operated by the authorized representative of the JV firm. The name
of the bank shall be intimated to the Railway by lead partner of the JV, and payment by the
Railways shall be made to the said bank account only.
18. A copy of this Memorandum of Understanding (MOU) executed by the JV members shall be
submitted by the JV firm along with the tender. The complete details of the members of the JV
firm, their share and responsibility in the JV firm etc. particularly with reference to financial
technical and other obligations shall be furnished in the MOU.
19. On award of contract to a JV firm a single Performance Guarantee shall be required to be
submitted by the JV firm as per tender conditions. All the Guarantees like Performance
Guarantee Bank Guarantee for Mobilization advance, machinery advance etc. shall be accepted
only in the name of the JV firm and no splitting of guarantees amongst the members of the JV
firm shall be permitted.
20. On issue of LOA, an agreement among the members of the JV firm (to whom the work has
been awarded) has to be executed and got registered before Office of the Sub-Registrar
concerned. This agreement shall be submitted by the JV firm to the Railways before signing
the contract agreement for the work. In case the tenderer fails to observe/comply with this
stipulation, the full Earnest Money Deposit (EMD) shall be forfeited and other penal actions
due shall be taken against partners of the JV and the JV.
21. Documents to be enclosed by the JV firm along with the tender :
22.1 In case one or more of the members of the JV firm is/are partnership firm(s), following
documents shall be submitted:
(a) Notary certified copy of the Partnership Deed.
(b) Consent of all the partners to enter into the Joint Venture Agreement
on a stamp paper of appropriate value (in original).
(c) Power of Attorney (duly registered as per prevailing law) in favour of one of the partners
to sign the MOU and JV Agreement on behalf of the partners and create liability against the
firm.
22.2 In case one or more members is/are Proprietary Firm or HUF, the
following documents shall be enclosed:
Signature of Tenderer/s Page 83 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
Affidavit on Stamp Paper of appropriate value declaring that his concern is a Proprietary
Concern and he is sole proprietor of the concern OR he is in position of “KARTA” of Hindu
Undivided Family and he has the authority, power and consent given by other partners to act
on behalf of HUF:
22.3 In case one or more members is/are limited companies, the following
documents shall be submitted :
(a) Notary certified copy of resolutions passed by Board of Directors of the Company,
permitting the company to enter into a JV agreement, authorizing MD or one of the
Directors or Managers of the Company to sign MOU, JV Agreement, such other documents
required to be signed on behalf of the Company and enter into liability against the
company and/or do any other act on behalf of the company.
(b) Copy of Memorandum and articles of Association of the Company.
(c) Power of Attorney (duly registered as per prevailing law) by the company authorizing the
person to do/act mentioned in the para (a) above.
23 Credentials & Qualifying criteria
Technical and financial eligibility of the JV firm shall be adjudged based on
satisfactory fulfillment of the following criteria:
23.1 Technical eligibility criteria :
Either the JV firm or Lead Member of the JV firm must have satisfactorily completed in the
last three previous financial years and the current financial year up to the date of opening of
the tender, one similar single work for a minimum value of 35% of advertised tender value.
OR
In case of composite works (e.g. works involving more than one distinct component such as
Civil Engineering works, S&T works, Electrical works, OHE works etc. and in the case of
major bridges, substructure and superstructure etc.), at least 35% of the value of each such
component of similar nature should have been satisfactorily completed by the JV firm or any
one of the members of the JV firm in the previous three financial years and the current
financial year up to the date of opening of tender.. In such cases, what constitutes a
component in a composite work shall be clearly defined as part of the tender condition
without any ambiguity.
NOTE:
Value of a completed work done by a Member in an earlier partnership firm or a JV firm
shall be reckoned only to the extent of the concerned member’s share in that partnership
firm/JV firm for the purpose of satisfying his compliance of the above mentioned technical
eligibility criteria in the tender under consideration.
23.2 Financial eligibility criteria :
Signature of Tenderer/s Page 84 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
The contractual payments received by the JV firm or the arithmetic sum of contractual
payments received by all the members of JV firm in the previous three financial years and the
current financial year upto the date of opening of tender shall be at least 150% of the
estimated value of the work as mentioned in the tender.
NOTE
Contractual payment received by a member in an earlier JV firm shall be reckoned only to
the extent of the concerned member’s share in that JV firm for the purpose of satisfying
compliance of the above mentioned financial eligibility criteria in tender under consideration.
NOW THE PARTIES HAVE JOINED HANDS TO FORM THIS MOU ON THIS
date ………………….. (DD/MM/YY) WITH REFERENCE TO AND IN
CONFIRMATION OF THEIR DISCUSSIONS AND UNDERSTANDING BROUGHT ON
RECORD ON date …………………. (DD /MM /YY).
IN WITNESS THEREOF ALL/BOTH THE ABOVE NAMED PARTIES HAVE
SET THEIR RESPECTIVE HANDS ON THIS MOU ON THE DAY, MONTH AND YEAR
FIRST ABOVE MENTIONED, IN THE PRESENCE OF THE FOLLOWING
WITNESSES:-
WITNESS:-
1. FIRST PARTY (Authorized Signatory)
2. SECOND PARTY (Authorized Signatory)
3. THIRD PARTY (If Any) (Authorized Signatory)
Signature of Tenderer/s Page 85 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
‘ANNEXURE-XII’
(Certificate from all members of JV)
CERTIFICATE FROM LEAD PARTNER OF JV
This is to certify that I/We the member of ……………………………… (name of JV
firm) do hereby declare that I/we are not black listed or debarred by Railways or any other
Ministry/Department/PSU (Public Sector Undertaking) of the Govt. of India/ State Govt. from
participation in tenders/ contracts.
Signature…………….
(…………………………….)
(Name of Authorized Person who
has signed the MOU for JV)
For……..……………………
(Name of original firm/s)
CERTIFICATE FROM SECOND PARTNER OF JV
This is to certify that I/We the member of …………………………… (name of JV
firm) do hereby declare that I/we are not black listed or debarred by Railways or any other
Ministry/Department/PSU (Public Sector Undertaking) of the Govt. of India/ State Govt. from
participation in tenders/ contracts.
Signature…………….
(…………………………….)
(Name of Authorized Person who
has signed the MOU for JV)
For……..………………………………
(Name of original firm/s)
CERTIFICATE FROM THIRD PARTNER OF JV (IF ANY)
This is to certify that I/We the member of ……………………………… (name of JV firm)
do hereby declare that I/we are not black listed or debarred by Railways or any other
Ministry/Department/PSU (Public Sector Undertaking) of the Govt. of India/ State Govt. from
participation in tenders/ contracts.
Signature…………….
(…………………………….)
(Name of Authorized Person who
has signed the MOU for JV)
For……..…………………
(Name of original firm/s)
Note :- In case of more than 03 members in the JV firm then all other members should sign such
Certificate for which another sheet may be added.
Signature of Tenderer/s Page 86 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
Annexure-XIII
“Letter of Consent” ( To be submitted by Partnership Firm participating as member of JV )
We the following partners of M/s………………………………… (indicate name of firm)
(1)……………………………………….…2……………………………………………
3…………………………………….………4………………………………………
5……………………………………….……6………………………………………having its office
at …………………………..hereby give our consent on behalf of M/s……. …………..(Indicate
name of firm) in favour of Mr………………………………….. (Indicate name of Partner) of
M/s…………………………………….. for entering into Joint Venture Agreement with
M/s……………………………… (indicate name of Co.)……………… having office at
……………………………. in connection with T. No…………………Name of work ……………
to sign & execute the M.O.U., J.V. Agreement and all other required documents pertaining to
above said tender.
We have read the contents of this letter of consent & accept the same and we hereby
agree to or ratify all acts, deeds & things of them or any documents executed by the said
partner in the scope of this letter of consent.
This letter of consent is made at ……………. on ………………
Name of Partner/s
Accepted
……………………………
(Signature & name of the
authorised partner)
1…………………………………….
2…………………………………….
3…………………………………….
4…………………………………….
5…………………………………….
Necessary Note:- The stamp duty on letter of consent has already been decided as Rs.100/- by Railway Board. Letter of consent shall be duly attested by Notary Public.
vko’;d fVIi.kh%& LVkEi M;wVh iwoZ esa gh jsyos cksMZ }kjk jkf’k :- 100@& fu/kkZfjr dh tk pqdh gSa A mDr
lgefr ij lk>snkjksa ds gLrk{kj tfj;sa uksVsjh ifCyd vuqizekf.kr djok;k tkuk visf{kr gSa A
Signature of Tenderer/s Page 87 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
Annexure-XIV
Special Power of Attorney
(To be submitted by Limited Companies or Sole Proprietor participating as member of JV) BE IT KNOWN To all that I …………….. (Indicate name of Director/Sole Prop.)……… at the
Company/Proprietary firm (Indicate Name of Co. / Sole Proprietary firm) ………. having its office at
…………………… do hereby for and on behalf of the said Company/Proprietary firm appoint
Sh.…………….S/o Shri …………age….. (Indicate Name of Nominee) of the Company/Prop. firm as
our Attorney, to execute the M.O.U./ J.V. Agreement & all other required documents with M/s
……………. (Indicate Name of Co./Prop. firm)………….. situated at …………… in connection with the
following tender invited by North Western Railway:-
“T.No………………………Name of work………………………………………
……………………………………………………………………..………………………………””
We/ I have read the content of this Special Power of Attorney & accept the same, and We/ I
hereby agree to ratify & confirm & do hereby ratify & confirm all acts, deeds & things lawfully done or
caused to be done by our said Attorney.
In witness where of I…………….(Indicate name of Director/
Sole Prop.) of M/s………………… (Indicate name of Co./ Prop. Firm) the above named Director /
Proprietor has executed this Power of Attorney.
For M/s…………………
(Indicate name of Co./Prop. Firm)
Place :-…………
(Name……………..)
Date :-………….
Title………………………………….
Witnesses:-
1……………..
Accepted
2……………..
(Name & signature of
Power of Attorney Holder)
Necessary Note:- The stamp duty shall be governed by the provision of the Law relating to
stamp in force in that State at the time when such Power of Attorney is being executed.
Power of Attorney shall be duly attested by Notary Public.
vko’;d fVIi.kh%& LVkEi M;wVh lEcfU/kr jkT; ds vuqlkj ns; gksxh A ikWoj vkWQ vVksZuh dks tfj;s uksVsjh
ifCyd lE;d:is.k vuqizekf.kr fd;k tkuk vko’;d gksxkA
Signature of Tenderer/s Page 88 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
Annexure-XV
Special Power of Attorney (For Partnership Firms only)
BE IT KNOWN To all that we (1) …….……………..(2)………..…………...
(3)………………………(4)……………..…………..(5)………….……………. all the partners of the
firm…………………… having its registered office at …………..………………………. do hereby, for
and on behalf of the said firm appoint Shri………………………… (name & designation) Special
Attorney of the said firm and authorize the said Shri…………….…………… (name) to do all or any of
the following acts deeds and/or things on behalf of the said firm and to represent the firm in respect
for the tender No…………………………. (Name of work)………………………………………… invited
by North Western Railway.
1. To appear before office of North Western Railway related to the process of tendering for the
above said tender.
2. To procure/download the tender documents for the above said tender.
3. To sign the above said tender documents and submit the offer to North Western Railway.
4. To attend meetings and submit clarifications including negotiations, if any, called by North
Western Railway.
We further state that if our offer for the above said tender is accepted then, for day to day
execution of work and contract agreement a separate Power of Attorney will be submitted.
Executants Partner
(Signature of Sri……………………) (Name & signature)
Attested 1.
2.
(Signature of all Partners) 3.
4.
5.
Seal of Firm Seal of Firm
Note:- This special Power of Attorney may be executed on Stamp Paper,
duly notarized.
Signature of Tenderer/s Page 89 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
Annexure-XVI
INDEMNITY BOND
Indemnity Bond for safe custody of Railway material to be supplied to M/s ------------------
____________________________________________ under Tender No.___________________
We, M/s.___________________________________________ (hereinafter called the Contractor) do
hereby undertake that we shall hold in our custody for and on behalf of the President of India acting in
the premises through the General Manager, Western Railway or for him all Railway materials which
have been handed over to us against the contract for Tender no. ____________________ dt.________
for the work of “___________________________________
____________________________________________________________________________” by the
Railway for the purpose of execution of the said contract until such time the materials are duly
installed and/or erected or otherwise handed over to the Railway.
We shall be entirely responsible for the safe custody and protection of the said materials against all
risk till they are duly delivered as installed and/or erected equipment to the Railway or as directed
otherwise and shall indemnify the Railway against any loss, damage or deterioration whatsoever in
respect of the said materials. The said materials shall at all time be opened to Inspection by any
Officer authorised by the General Manager, Western Railway or his nominee.
Should any loss, damage or deterioration of materials occur or surplus materials disposed off and a
refund becomes due, the Railway shall be entitled to recover from us the full cost and compensation
determined in terms of the contract for such loss or damage, if any, along with the amount to be
refunded without prejudice to any other remedies available to him by deduction from any sum due or
any sum which at any time thereafter becomes due to us under the said or any other contract.
In the event of any loss or damage as aforesaid the assessment of such loss or damage and the
assessment of the compensation therefore would be made by the President of India acting through the
General Manager, Western Railway or his authorised nominee shall be final and bind upon us.
Signed at _____________________________
on this day of __________________________________
Signature of Witness: ___________________________
for & on behalf of ____________________________
M/s._______________________________
Name of Witness in
BLOCK LETTERS
ADDRESS:
Signature of Tenderer/s Page 90 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
TECHNICAL REQUIREMENTS
Signature of Tenderer/s Page 91 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
TECHNICAL REQUIREMENTS
1. General:
This section covers the general requirement of 48 V DC SMPS Based Power Plants, based on High Frequency Switch Mode Techniques using switching frequencies of 20KHz and above for use in Indian Railway Network.
2.0 SMPS Based Power Plants is intended to be used in Auto Float Rectifier-cum Float-Charger
(FR-FC) and/or Float Rectifier cum Boost Charger (FR-BC) mode as a regulated DC Power Source.
2.1 Power System Configuration: The configuration of 48 V DC Power Plants with FR-FC & FR-
BC Modules shall be as under:
SN Basic SMR Module Configuration Permissible Ultimate Capacity*
1 12.5 A FR-FC (n+1) 50 Amp
2 25 A FR-FC (n+1) 150 Amp
3 50 A FR-FC (n+1) 800 Amp
4 12.5 A FR-BC (n+2) 50 Amp
5 25 A FR-BC (n+2) 150 Amp
6 50 A FR-BC (n+2) 800 Amp
The FR-FC or FR-BC modules shall be housed in (n+1) or (n+2) parallel configuration in a single rack where ‘n’ is the actual required number of FR-FC, FR-BC modules for meeting the particular load requirement.
Railway shall indicate the Type, Number and Configuration of SMR Modules, depending upon the load requirement. Railway shall also indicate Ultimate Expandable Capacity considering future expansion requirement.
* Permissible Ultimate Capacity stipulate that with particular Basic SMR Module, the ultimate Capacity can not be more than as defined in this column. However Ultimate Expandable Capacity for a particular product of manufacturer can be less than the Permissible Ultimate Capacity defined in this column.
2.3 Rack Configuration : Rack is composed of following units accommodated in sub racks
a) Float Rectifier cum Float Charger (FR-FC) Modules or Float Rectifier cum Boost Charger
(FR-BC) Modules b) Distribution-Switching-Control-Alarm Arrangement (DSCA) c) The number and rating of FR-FC, FR-BC Modules shall be provided as per purchaser’s
requirement. The Distribution-Switching-Control-Alarm Arrangement (DSCA) shall be provided for the Ultimate Expandable Capacity. All factory wirings for the rack shall be for the Ultimate Expandable Capacity so that only plugging-in of FR-FC or FR-BC module shall enhance the DC Power output.
Further details of System Rack Configuration are given in SECTION 3. 2.4 The Electrical and Mechanical requirement of FR-FC & FR-BC Modules are given in
SECTION 4 & SECTION 6 respectively.
Signature of Tenderer/s Page 92 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
2.5 The Electrical and Mechanical requirement of Distribution-Switching-Control-Alarm
Arrangement (DSCA) are given in SECTION 5.
2.6 Parts & Components 2.6.1 The Parts & Components including Fuses and Circuit Breakers for manufacturing of the SMPS
Based Power Plants shall be of Industrial Grade. These Parts & Components shall be procured from reputed manufacturers to ensure prompt and continuous service and delivery of spare parts.
2.6.2 The Components approved by recognized National/International Institutions like LCSO/CACT/UL/CSA/VDE/TUV shall only be used in manufacturing of SMPS Power Plant.
2.6.3 Power Transformers and Chokes shall use Class B or Higher Grade of insulation. The Transformers and Chokes shall be wound with copper wire provided with adequate insulation.
2.6.4 Component mounting and fixing methods shall be secured.
2.7 Wiring: 2.7.1 All insulated conductors except those within the confines of a printed circuit board assembly
shall be of the rating enough to withstand the maximum current voltage during fault and overload.
2.7.2 All wiring shall be neatly secured in position and adequately supported. Where wires pass through any part of Metal Panel or Cover, the hole through which they pass shall be suitably bushed with rubber grommet.
2.8 Bus Bars:
2.8.1 Bus bars shall be of high conductivity electrolytic copper strips capable to with-stand 1.5 times the maximum load current. The Bus bar shall be capable to carry current density of 2
Amps/mm2 but shall not be less than 25mmx5mm in any case. The size of bus bars chosen for
battery and load path shall be capable to take care of the current of maximum power plant capacity for which it is designed.
2.8.2 Bus-bar Riser height wherever applicable shall be 250mm for both load and battery.
2.9 Earthing: All non-current carrying metal parts shall be bonded together and earthed. An earth
terminal suitable for taking minimum 4 mm dia wire and with suitable marking shall be provided.
2.10 Qualities and Workmanship 2.10.1 The guidelines contained in Quality Manuals QM-202, QM-204, QM-205, QM-206 and QM-
207 of QA wing of BSNL for proper quality & workmanship shall be followed. 2.10.2 All materials and workmanship shall be of professional quality to ensure the MTBF
requirements. 2.10.3 The equipment and components shall not use any material which support combustion.
2.11 Climatic Requirements: 2.11.1 The Power Plant shall operate at specified ratings and conforms to requirements contained in
as per IS-9000 (Pt-III), IS-9000 (Pt.V/Section-2). Power Plant includes FR-FC Modules, FR-BC Modules and DSCA Modules.
2.11.2 The SMPS Based Power Plants shall be designed & manufactured for continuous operation at rated load in the ambient temperature range of 0ºC to 55ºC with RH up to 95%. For extreme temperature conditions of 0ºC & 55ºC, the efficiency shall remain as given below: A. efficiency:
1. Units working on Single Phase
a) Nominal Input, Output & Full rated load - better than 85%
Signature of Tenderer/s Page 93 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
b) For other specified Input, Output conditions - better than 80%
2. Units working on three phase
a) At Nominal Input, Output & Full rated load - better than 90%
b) For other specified Input, Output conditions - better than 85% B. Power Factor: a) At nominal Input/Output & load 75% to 100%, the Power Factor should be between
0.95 lag & 0.98 lead b) For other than specified Input/Output conditions & load between 25% to 100%, the
Power Factor should be between 0.90 lag & 0.90 lead 2.11.3 The fully equipped SMPS Based Power Plants shall be capable of withstanding Burn-In Test as
per Clause 7.8. 2.12 Insulation Resistance and Voltage Proof 2.12.1 The insulation resistance of a fully wired FR-FC and FR-BC Modules when tested with a 500V
DC Megger shall be as given below: a) AC input and Earth - Greater than 2 Mega Ohm
b) DC Output and Earth - Greater than 1 Mega Ohm
c) AC input and DC output - Greater than 5 Mega Ohm. 2.12.2 With EMI/RFI Capacitors and MOVs/Transzorbs removed from the circuit, and a test voltage
of 1500V/50Hz is applied for one minute. - between earth and interconnected output terminals
- between input and output terminals
No breakdown or abnormal temperature rise shall occur.
2.13 Lightning Protection : The SMPS Based Power Plants shall have modular type Type I/Class B and Type II/Class C type surge protection in TT configuration of wiring. Both the Type I/Class B and Type II/Class C arrestors should be from the same manufacture and shall be mounted as per the specific installation recommendations of the manufacturer to achieve perfect coordination. The schematic diagram of surge and lightning protection is as per Annexure I.
2.13.1 Type I/Class B Protection : The product shall be tested as per the latest VDE 0675 and IEC 61643 standard. The protection shall be in compliance with IEC 61312. IEC 61024 and with the following characteristics.
Parameter of Type I/Class B Protection Rating
Maximum Continuous Operating Voltage Between R,Y,B and N
SMPS Power Plant with 3 Phase Power Supply ≥ 285 Volt
SMPS Power Plant with Single Phase Incoming Power > 285 Volt
Supply within range of 165V-260V
SMPS Power Plant with Single Phase Incoming Power > 320 Volt
Supply within range of 90V-300V
Voltage Protection Level/Response Time ≤ 1.5 KV/ <100 ñsec
Minimum Lightning impulses current R Y, B and N 50 KA, 10/350 s
Minimum Lightning Impulses Current between N and PE 100 KA, 10/350 s
Line follow current extinguisher capacity of arrester connected ≥ 10 KA r.m.s.
between R, Y, B and N at arrester rated voltage without back up
fuse
Signature of Tenderer/s Page 94 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
2.13.2 Type II/ Class C Protection
The Class C arrester in the modular and pluggable form shall be provided. The products shall be tested as per the latest VDE 0675 and IEC 61643 standard. The protection shall be in compliance with IEC 61312, IEC 61024 and have the following characteristics.
Parameter of Type II/Class C Protection Rating
Nominal voltage between R, Y, B and N 230 V working
Maximum Continuous Operating Voltage Between R,Y,B and N
SMPS Power Plant with 3 Phase Power Supply ≥ 285 Volt
SMPS Power Plant with Single Phase Incoming Power > 285 Volt
Supply within range of 165V-260V
SMPS Power Plant with Single Phase Incoming Power > 320 Volt Supply within range of 90V-300V
Nominal discharge current of the arrester between R,Y,B and N ≥ 10KA (8 / 20 s)
Maximum voltage protection level 1.6 KV
Response Time ≤ 25 nano second 2.13.3 Coordination Between Class B/Type I and Class C/Type II Protection
There shall be a perfect coordination between Class B/Type I and Class C/Type II stages. The coordinating inductor /cable distance is not required for coordination between class B/type I and class C/type II
The proper coordination of the SPD system as well as safety of operation shall be specifically ensured.
2.13.4 Parallel/Series arrangement of Spark Gap (SG) with MOVs is not permitted in Type I/Class B as well as Type II / Class C.
2.13.5 In built Thermal Disconnect arrangement and remote indication for type II/class C connected between R.Y B and N should be available.
2.13.6 The manufacturer shall clearly give the earthing guidelines required for the purpose.
2.13.7 Type III/Class D Protection All external 48 V DC Power Lines connected to the SMPS Power Plant shall be protected by using pluggable Type-III/Class D Surge Protection Device which consists of a combination of Varistors and GD Tube with voltage and current limiting facilities. The device shall be in compliance to IEC 61643-1 and VDE 0675 Part-6. These devices are to be connected in parallel to the SMPS Power Plant output connected to the load as given in the figure 1.3 Annexure-II. These Class-D/Type-III devices shall be having a visual indication as well as remote indication function to indicate the prospective life and failure mode to facilitate replacement of the overstressed SPDs. These protection device shall be equipped with thermal disconnection, as a protection against SPD failure due to open and short circuit. General Specification of the Devices.
Nominal Voltage 48 Volt
Maximum Continuous Operating Voltage(Uc) > 75 Volt
Nominal Discharge Current(In) 8/20 s > 2.5 KA
Rated Load Current 25 Amp
Maximum Discharge Current(Imax) 8/20 s > 5 KA
Voltage Protection Level between L-L(Up) < 500 V
Signature of Tenderer/s Page 95 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
Voltage Protection Level between L-G < 700 V
Response Time < 25 ns 2.14 Radio Frequency Interference Suppression: The module shall be designed to minimize the
level of electromagnetic interference (EMI), both conducted and radiated, detected in its vicinity and generated by Switch Mode Power Conversion Equipment operating within the rack. The radiated and conducted noise shall be within the limits as specified in ANNEXURE-V.
2.15 Finish and painting: The finish of steel and panels shall conform to relevant IS specification. The colour scheme shall be as follows: (a) Rack & doors : Pebble gray – RAL 7032
(b) FR-FC Module or FR-BC module: Shall harmoniously match with rack colour.
2.16 Marking & Labellng
2.16.1 Component marking 2.16.2 Each electrical component should be possible to be located on the PCB by the layout/circuit
drawings. Switch Mode diodes may be marked as a block in the layout/circuit diagram. The wiring shall be clearly and permanently identified with a designation of a colour code which corresponds to the equipment circuit diagram. Where non standard colours are used, cable function shall be clearly and permanently labeled at both ends.
2.16.2.1 Fuse holder identification shall include details of the fuse rating and type. In case of fuses on PCBs, the rating shall be either on the fuse or PCB.
2.16.2.2 A cabling diagram, screen printed or any other better arrangement ensuring better life expectancy shall be placed on the inside of the front door or any other convenient place for ready reference of the maintenance staff.
2.16.2.3 Procedure for adjustment of float voltage, boost voltage, battery current limit and other adjustments required to be done in the field shall be printed or any other better arrangement ensuring better life expectancy shall be placed in the inside of the front door or any other convenient place for ready reference of maintenance staff.
2.17 Name plate : A name plat etched/engraved/anodized or any other better arrangement ensuring better life expectancy shall be suitably fixed on each rack/module and contain following information. 1. Specification Number
2. Type of Unit
3. Manufacturer’s name and identification
4. Model No. 5. Unit Serial No.
6. Input Voltage and phase 7. Output Voltage and current
8. Year of manufacture 9. Suitable for battery capacity
2.18 Instruction and Maintenance Manual:
2.18.1 Two copies of the Instruction Manual shall be supplied along with each unit. The manual has to include dimensioned layout drawings, detailed circuit and schematic diagrams, PC card layouts and detailed interconnecting drawings of modules and switching arrangement. Details of testing and adjustment procedure, initial checks on receipt at site, detail installation & commissioning procedures, maintenance procedure, proposed routine maintenance tests, actual test results obtained for the particular and at the factory and a detailed trouble shooting chart shall be outlined in the manual. Feedback format is also to be included in the Instruction Manual. A copy of the Installation and Maintenance Manual shall also be provided on a
Signature of Tenderer/s Page 96 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
CD(Compact Disk). 2.18.2 Instruction Manual is to be prepared using good quality paper with clear and crisp printing. All
the drawings in clear printing shall be attached to the handbook binding. One set of flow chart drawings necessary for troubleshooting shall be provided with lamination with each manual. The handbook shall have a thick polythene sheet cover with plastic spiral binding or comb-binding.
2.18.3 The manufacturer shall submit certificate of the equipment for its satisfactory performance for
24 months. During the warranty period, any defect should be repaired free of cost.
2.19 Noise & Vibration: The fully equipped rack at full load shall not contribute more than 15dB (weighted) to the ambient noise level taken as 45dBA. It shall be measured at a distance of 1 meter from the unit and 1.25m above the floor level in the Acoustic Range. The correction factor for Total Noise when the ambient noise level is more than 45dBA shall be as given below:
AMBIENT CORRECTION AMBIENT CORRECTION AMBIENT CORRECTION NOISE FACTOR NOISE FACTOR NOISE FACTOR 45dBA 0dB 51dBA 1.41dB 57dBA 3.69dB
46dBA 0.18dB 52dBA 1.73dB 58dB 4.17dB
47dBA 0.39dB 53dBA 2.07dB 59dBA 4.68dB
48dBA 0.61dB 54dBA 2.47dB 60dBA 5.21dB
49dBA 0.86dB 55dBA 2.82dB
50dBA 1.12dB 56dBA 3.25dB
Note: The correction factor shall be added to the limit of 60dBA to arrive at the limit when the ambient is greater than 45dBA
2.20 Module Replacement Time & MTBF: 2.20.1 Module Replacement Time. The mean time to replace a faulty rectifier module shall be less
than 20 minutes. 2.20.2 The MTBF of the system shall not be less than 70,000 hours. Calculation details of MTBF
shall be furnished by the manufacturer at the time of Type Approval. Based on the MTBF figures, 3 Years Maintenance Spare shall be specified by manufacturers during Type Approval.
2.20.3 The fans provided shall have MTBF better than 70,000 hours at 40 C 2.20.4 In case of fan failure, the module shall have automatic protection to switch off with extension
of suitable alarm. It shall not cause any fire hazard. 2.21 Packing: 2.21.1 Power plants complete shall be packed in suitable boxes/crates, strong enough, to prevent
damage or loss to the unit during transit. Loose space inside the box/crate shall be filled up with suitable packing material.
2.21.2 It is desirable that the fragile components such as meters and PC cards are individually packed to prevent damage.
2.21.3 Each box shall be legally marked at one end with code numbers, contents quantity and name of manufacturer/supplier.
Signature of Tenderer/s Page 97 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
SECTION 3
SYSTEM AND RACK CONFIGURATION
3.0 Scope: This section deals with the mechanical and electrical requirements of the rack.
3.1 Rack Configuration: Rack shall be capable of accommodating the following equipment/units as
given below:
a) Float Rectifier – cum – Float Charger (FR-FC) Modules or Float Rectifier – cum – Boost
Charger FR-BC Modules. b) Distribution-Switching-Control-Alarm Arrangement..
3.2 Constructional features of Rack:
3.2.1 The FR-FC or FR-BC Modules shall be accommodated in a rack. The system shall employ a
modular configuration to provide flexibility, keeping in view the future load requirements of DC power. Suitable mechanical structure/arrangement for holding modules in position shall be provided so that the module is held firmly by sliding through it.
3.2.2 The rack structure shall be made up of rigid frame work of anti-corrosive steel profiles conforming to IS: 226. The sides of rack may have suitable ventilating arrangements. The front door (if provided) and rear door may be of hinged or removable type. The rear door shall be provided with proper ventilation arrangement. The ventilator opening shall be less than 3 mm size for protection against entry of lizards etc. The rack shall conform to IP 31 type of protection as specified in table 1 of specification No. IS 2147 – 1962. The FR-FC or FR-BC Module shall have ventilation opening as per IP 20 Protection Enclosures.
3.2.3 The rack shall be treated with Zinc Chromate Primer followed by Electrostatic Epoxy Powder Coating Paint finished. Passivation shall be done through seven stage process. Small metal parts such as nuts, bolts and washers shall be either galvanized or chrome plated. All other metal parts of the rack shall be plated for protection against corrosion.
3.2.4 The structural strength of the rack shall be able to withstand the mechanical load for Ultimate
Expandable Capacity of the Power Plant without any deformity.
3.2.5 The depth of rack shall not be more than 600mm from front door (when provided) to rear with
door fitted and height shall be not more than 2200mm.
3.2.6 The case of rack shall ensure uniform floor loading of not more than 975 kg/Sq.mt. Lifting
facilities shall be provided by removable eyebolt located at the top of the rack. The necessary arrangement for fixing the rack on the floor shall also be provided.
3.2.7 The top of the rack shall be fully covered except for proper ventilation and bus bar or cable
entries. Each air flow vent shall be covered by a grill to prevent foreign material larger than 5mm dropping into the rack.
3.2.8 The rack shall be free of sharp edges & sharp corners.
Signature of Tenderer/s Page 98 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
3.2.9 With doors in position, all the common visual alarms and meters shall be clearly visible. In
case of hinged door, meters and alarm indications are permitted on door also. However, the fixtures on the door shall not restrict the movement of door in any way.
3.3 Dimensions: Dimensions of the rack for all the capacities shall be as follows:
Height: 2200mm (max)
Depth: 600mm (max)
Width: 600mm (max)
3.4 The rack shall be designed for easy maintenance and installation.
3.5 Rack mounting arrangement shall be such as to provide easy access from front, rear and top for
installation and maintenance.
3.6 The FR-FC & FR-BC Modules shall be provided as per requirement. The prescribed FR-FC or
FR-BC Modules ratings are 12.5A, 25A & 50A.
3.7 The Distribution-Switching-Control-Alarm Arrangement shall be provided for the Ultimate Expandable Capacity as explained in Clause 2.2. All AC, DC or control/alarm cabling/wiring shall be pre-wired for the ultimate capacity so that mere plugging-in of FR-FC & FR-BC Module shall add to the DC power output.
3.8 The individual FR-FC or FR-BC Module shall be easily mounted to/removed from the rack. The FR-FC and FR-BC Module shall be designed to slide into the rack on a suitable mechanical arrangement. The associated AC input, DC output connections, Control/alarms and interface cable connecting the modules shall be disconnected/installed easily without causing any interruption/damage to the supply and working module.
3.9 Proper thermal engineering of hardware design shall be done by the manufacturer so as to ensure the uninterrupted use of the equipment. The rack complete with all panels fitted shall be designed to allow cooling by natural convection. For the racks using 50A modules, DC fans are permitted in the rack or FR-FC & FR-BC module. If cooling is provided at rack level, it shall be provided with additional fan with facility for manual switch over. Proper fitting shall be provided to control dust ingress. There shall be an arrangement for automatic switching off of fans during AC input failure. If required, individual modules may be separated by air baffle to provide effective convection. The manufacturer shall also ensure that the failure of fan does not cause any fire hazards. The failure of any of the fans shall draw immediate attention of the maintenance staff.
3.10 Facility shall be made to connect external AC power at the top/bottom of rack and alarm cable & DC output distribution module at the top of the rack. Where cables pass through metal panels suitable bushing shall be provided to protect cables from damage. Bus-bars if used shall be suitably spaced and insulated to prevent any possibility of short circuit between bus-bar and or rack.
3.11 Electrical requirements:
Signature of Tenderer/s Page 99 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
3.11.1 AC input supply: The Power Plant using FR-FC or FR-BC modules of 12.5 & 25 Amps shall
operate from single phase AC input and FR-FC or FR-BC modules of 50A capacity may operate from single phase or 3 phase 4 wire AC input. The nominal input frequency is 50Hz which may vary from 48-52Hz. The input voltage range shall be as given below:
a) Single Phase (nominal 230V) :
(i) For Power Plant to be used at stations having poor power supply regulation, incoming
power supply range shall be from 90 V AC to 300 V AC. (ii) For Power Plant to be used at stations having reasonable power supply regulation,
incoming power supply range shall be from 165 V AC to 260 V AC.
b) Three Phase/4 Wire 400V+10%/ - 15% (Nominal 400V)
3.11.2 There shall be an automatic arrangement for shutting off the FR-FC or FR-BC Modules wherever the input voltage is beyond the specified operating limits with suitable alarm indication. It shall resume normal working automatically when the input is restored within the working limits. Hysteresis within specified working limits shall not cause shutting down of the
FR-FC or FR-BC Modules. A tolerance of 5V may be acceptable for protection & alarm operation. All the FR-FC or FR-BC Modules shall switch OFF simultaneously.
3.11.3 FR-FC or FR-BC Modules working from 3 phase/4 wire input shall work satisfactorily for
unbalance of 10% of nominal input. The module shall be isolated ( if required for the protection of the unit) in the event of unbalance beyond 10% and shall restore when the input is within limits.
Signature of Tenderer/s Page 100 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
SECTION 4
FLOAT RECTIFIERS CUM CHARGER (FR-FC) MODULES
4.0 Scope: This section deals with electrical and mechanical requirement of FR-FC Modules.
4.1 General: The FR-FC Modules used shall be such as to be accommodated in a rack in the
standardized capacities of 12.5A, 25A & 50Amps.
4.2 Mechanical Requirements
4.2.1 The FR-FC Modules shall be cooled by natural convection for smaller capacities i.e. 12.5 Amp
and by natural/forced cooling for higher capacity i.e. 25 Amp and 50 Amps.
4.2.3 The FR-FC module shall be removable from the front of the rack only. All AC input, DC
output and alarm/control/monitoring cables interconnecting the modules and racks shall be easily disconnected by disconnecting the male-female of directly PCB mounted pluggable plugs or connectors.
4.3 DC Output Characteristics
4.3.1 The module shall be capable of operating in ‘Auto Float-cum-Charge’ mode and it shall be
programmed to operate as a Float Rectifier or a Float Charger depending on the condition of the battery sets being sensed by the Distribution-Switching-Control-Alarm Unit.
4.3.2 Auto Float Mode
a) The float voltage of each rectifier module shall be continuously adjustable & pre- settable at any value in the range of –48V to –56V. The prescribed float voltage setting is – 54V for VRLA battery.
b) The DC output voltage shall be maintained within 1% of the half load preset voltage in the range 25% load to full load when measured at the output terminals over the full specified input range.
4.3.3 Auto Charge Mode: In Auto Charge Mode FR-FC shall supply battery & equipment current till terminal voltage reaches set value, which is normally 2.3V/Cell (55.2V) & shall change over to constant voltage mode it shall remain in this mode till a change over to float mode signal is received.
4.4 Efficiency: The efficiency of the single phase and three phase unit shall be as given below: -
4.4.1 Units working on Single Phase AC
a) At nominal input, output and full rated load better than 85%
b) For other specified input, output conditions better than 80%
and load between 25% to 100%.
Signature of Tenderer/s Page 101 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
4.4.2 Units working on Three Phase AC
a) At nominal input, output and full rate load better than 90%
b) For other specified input, output condition better than 85% and load between 25% to 100%
4.5 Input Power Factor: The input power factor at nominal input, output voltage and load 75% to
100% shall be between 0.95 lagging and 0.98 leading but it shall remain between 0.90 lag and 0.90 lead in any other working condition and load between 25% to 100%.
4.6 Total Harmonic Distortion:
4.6.1 Total Voltage Harmonic Distortion: The total line harmonic voltage distortion shall not be
more than 10%.
4.6.2 Total Current Harmonic Distortion: The total current harmonic distortion contributed by the unit at the input shall not exceed 10% for input voltage range 90V-300V/165V-260V(as the case may be) for single phase units and 340V to 440V for 3 phase respectively for load 50 to 100% of the rated capacity.
4.7 Current limiting (Voltage Droop)
4.7.1 The current limiting (Voltage Droop ) shall be provided for Float Charge operation. The
Float/Charge current limiting shall be continuously adjustable between 50 to 100% of rated output current for output voltage range of –44.4V to –56 volts. For test purposes upper limit of 100% +5% and lower limit of 50% - 5% shall be acceptable.
4.7.2 The float and charge current limit adjustment shall be provided on the front panel of the
rectifier module.
4.7.3 The FR-FC modules shall be fully protected against short circuit. It shall be ensured that short
circuit does not lead to any fire hazard.
4.8 Soft Start Feature:
4.8.1 Slow start circuitry shall be employed such that FR-FC module input current and output
voltage shall reach their nominal value within 10 seconds.
4.8.2 The maximum instantaneous current during start up shall not exceed the peak value of the
rectifier input current at full load at the lowest input voltage.
4.9 Voltage overshoot/undershoot
4.9.1 The requirements of clauses 4.9.2 to 4.9.4 shall be achieved without a battery connected to the
output of FR-FC module.
4.9.2 The FR-FC modules shall be designed to minimize output voltage overshoot/undershoot such
that when they are switched on the DC output voltage shall be limited to 5% of the set voltage
Signature of Tenderer/s Page 102 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
& return to their steady state within 20ms for any load of 25% to 100%.
4.9.3 The DC output voltage overshoot for a step change in AC mains shall not cause shut down of
FR-FC module and the voltage overshoot shall be limited to 5% of its set voltage and return to steady state within 20 ms.
4.9.4 The modules shall be designed such that a step load change of 25 to100% shall not result in
DC output voltage overshoot/undershoot of not more than 5% and return to steady state value within 10ms without resulting the unit to trip.
4.10 Electrical Noise
4.10.1 The rectifier (FR-FC) modules shall be provided with suitable filter on the output side.
4.10.2 A resistor shall be provided to discharge the capacitors after the rectifier modules have stopped
operation and the output is isolated.
4.10.3 The Psophometric Noise (e.m.f weighted at 800 Hz) with a battery of appropriate capacity connected across the output should be within 2mV while delivering the full rated load at nominal input (400V AC for 3 phase supplies and 230V for single phase supply). For test purposes, this shall be taken as equivalent to 4mV when the battery is not connected and other conditions remaining the same as per ITU-T Rec P53.
4.10.4 The Peak to Peak Ripple: Voltage at the output of the rectifier module on full load without
battery connected shall not exceed 300mV at the Switching Frequency measured by an Oscilloscope of 50/60 MHz band-width (typical).
4.11 Parallel Operation:
4.11.1 FR-FC modules shall be suitable for operating in parallel with one or more modules of similar
type, make and rating, other output conditions remaining within specified limits.
4.11.2 The current sharing shall be within 10% of the average current per rectifier module and within individual capacity of each rectifier module in the system (mounted in the same or different racks) when loaded between 50 to 100% of its rated capacity for all other working conditions.
4.12 Protection:
4.12.1 DC over voltage protection.
4.12.1.1 Each rectifier module shall be fitted with an internal over-voltage protection circuit.
4.12.1.2 In case output DC voltage exceeds –57V the over voltage protection circuit shall operate &
shut off the faulty module. A tolerance of 0.25V is permitted in this case. Restoration of the module shall be through a reset switch/push button.
4.12.1.3 Shutting-off of faulty FR-FC module shall not affect the operation of other FR-FCs operating
Signature of Tenderer/s Page 103 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
in the rack.
4.12.1.4 Operation of over-voltage shut down shall be suitably indicated on the module and also
extended to monitoring/control unit.
Signature of Tenderer/s Page 104 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
4.12.1.5 The circuit design shall ensure protection against the discharge of the battery through the
FR-FC module in any case. 4.12.1.6 The over voltage protection circuit failure shall not cause any safety hazard.
4.12.2 Fuse/Circuit Breakers: Fuses or circuit breakers shall be provided for each FR-FC module as
follows:
1. Live AC input line
2. Negative DC output
3. Against failure of Control sensing circuit
4.12.2.1 All fuses/circuit breaker used shall be suitably fault rated.
4.12.3 AC Under/Over Voltage Protection: AC input Under/Over voltage protection shall be provided
as per clause 3.11.
4.12.4 Over Load/Short Circuit Protection: The FR-FC shall be protected for Over load/Short circuit
as per clause 4.7.
4.13 Alarms and Indicating Lamps
Visual indications/display such as LEDs, LCDs or a combination of both shall be provided on each FR-FC module to indicate.
Functional Indications:
A Mains available B FR-FC on Auto Float C FR-FC on Auto Charge
Alarm Indications
A AC/DC Rectifier module Over Voltage, Under voltage or Output Fail B FR-FC Over Load (Voltage Droop) C Fan fail (due to any reason)
Functional indications shall be extended as status and alarm indications as “FR-FC” Fail to Distribution-Switching-Control and Alarm Arrangement.
4.14 Termination:
A The AC Input Connection to the rectifier module shall be by means of Pluggable
Connectors. These Connectors shall be made of complete non-ferrous metal parts. Housing material if any shall be of Polyamide 6.6 of V0/V2 inflammability class as per UL94. The male connectors shall preferably be mounted in the FR-FC Module and female connectors be terminated to the cable.
Signature of Tenderer/s Page 105 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
The DC Output Connection from the rectifier module for smaller rating (up to 25
Amps) shall be by means of Pluggable Connectors. These Connectors shall be made of
complete non-ferrous metal parts. Housing material if any shall be of Polyamide 6.6 of
V0/V2 inflammability class as per UL94.
For higher rating suitable termination lugs shall be provided.
The male connectors shall preferably be mounted in the FR-FC Module and female connectors shall be preferably terminated to the cable.
C The output of each rectifier in the negative lead shall be taken through the full rated
Fuse/MCB in the Distribution-Switching-Control-Alarm Arrangement (DSCA) or in the FR-FC Module.
Signature of Tenderer/s Page 106 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
SECTION-5
DISTRIBUTION/SWITCHING/CONTROL AND ALARM AARANGEMENT(DSCA)
5.0 General:
Depending on the system requirements and manufacturer’s design, Power Plant racks shall be provided with a Distribution-Switching-Control-Alarm Arrangement (DSCA) for the Ultimate Expandable Capacity as defined in Clause 2.2.
The unit shall comprise of the following:
a) Termination for the batteries
b) Termination for the load c) Interconnecting arrangement for power equipment d) Battery Switching Arrangement (Connection to/isolation from system) e) Termination for AC input to the rack
f) Termination for AC and DC to FR-FC modules
g) Circuit Breakers/fuses etc.
5.1 Dimensions:
5.1.1 The Distribution/Switching Sub-System of the equipment shall preferably be in the modular
form whereas Control/Alarm & Monitoring Sub-System shall be modular only. The Distribution/Switching Sub-System may be accommodated in a rack with other FR-FC or in a separate rack. These sub-systems shall be rack mountable.
5.1.2 The unit shall preferably be housed in the upper portion of the rack above the FR-FC modules.
5.1.3 The DSCA shall be provided for ultimate capacity of SMPS Based Power Plant. All AC, DC
Control, Alarm cabling/wiring shall be pre-wired for the ultimate capacity so that mere plugging-in of FR-FC module shall add to the DC Power Output.
5.2 Accessibility:
5.2.1 All the termination points shall be easily accessible from front, rear or top.
5.2.2 The AC modular earth terminal should be touch proof with universal yellow green housing
symbolizing the potential earth with all non ferrous metal parts including the screws.
5.3 AC Termination Arrangement:
5.3.1 The Input Terminals shall be clearly marked as R, Y, B and N for three phase and L and N for
single phase as applicable.
AC Termination should be modular in design These Termination shall be made of complete non-ferrous metal parts. Housing material if any shall be of Polyamide 6.6 of V0/V2 inflammability class as per UL94. The Termination Block should be as per IEC-947-7-1.
Signature of Tenderer/s Page 107 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
5.3.2 AC input termination shall be suitably protected against the accidental touch/contact with the
working staff for their protection and shall also have clear and prominent “DANGER” Marking.
5.3.3 Screening shall be provided between AC & DC components to prevent accident.
5.3.4 All the connections between DSCA and FR-FC shall be through properly rated cables only.
5.3.5 Fuses and Circuit Breakers for each FR-FC shall be easily accessible and properly rated.
5.3.6 Proper terminations for AC at the input of the circuit breakers and its output to the FR-FC.
5.4 DC Terminations:
5.4.1 Connection between FR-FC and DC Distribution shall be through a properly rated lugged
Cable/Buster. Wherever cables are used, the same shall be terminated through the appropriately screw locking type Terminal Blocks. These Terminal Blocks shall be made of complete non-ferrous metal parts. Housing material if any shall be of insulating material with dielectric strength not less than 4 KV and of V0/V2 inflammability class as per UL94.
5.4.2 The DC output to battery and load shall be through cable.
5.4.3 The provision for interconnection between load & FR-FC or battery (along with switching
arrangement) and terminations for load, battery & FR-FC shall be made. The isolation of any of the battery from the load shall create an alarm.
5.4.4 The proper rated fuses/circuit breakers shall be provided on the –ve DC lead from the FR-FC
(if not provided at FR-FC module).
5.4.5 All the AC, DC and control/alarm cabling shall be supplied with the rack.
5.4.6 All DC + ve and –ve loads shall be clearly marked.
5.4.7 All conductors shall be properly rated to prevent excessive heating.
5.5 Alarms.
5.5.1 Following visual indications/display such as LEDs, LCDs or a combination of both shall be
provided to indicate.
Functional Indications:
a) Mains Available ( not mandatory if provided at module level)
b) FR-FC in Float Mode
c) FR-FC in Charge Mode
Signature of Tenderer/s Page 108 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
Alarm Indications:
a) Load Voltage High (above 57V)/Low (below 44.4V)
b) FR-FC Fail (Any failure condition as per clause 4.13.
c) Mains Out of Range d) System Over Load
e) Mains ‘ON’/Battery Discharge f) Fan Fail (incase fan provided at rack level)
g) Temperature Compensation Fail h) Battery Fail/Isolated
5.5.2 All alarm circuits shall be provided with suitable delay to ensure that they do not operate to
transients.
5.5.3 All the protections/alarms shall be within tolerance of 0.25V in case of DC voltage and 1% in
case of current. For AC voltage it shall be 5V.
5.5.4 Every alarm condition shall be accompanied with an audio alarm with audio cut-off facility.
5.5.5 Two nos. of Potential Free Contacts (one for alarm and one redundant) shall be provided for
extension of alarms to Centralized Display.
5.5.6 Two numbers of potential free contacts for connecting to network monitoring system for monitoring DC output fail, DC output over voltage, DC output under voltage and mains fail shall be provided. Alternatively, the Power Plant shall have provision for RS-232 or RS-485 or SNMP over TC/IP connectivity compatible for remote control monitoring of the above system parameters depending upon the user’s requirements.
5.6 Battery Monitoring
5.6.1 Battery Under Voltage Isolation: To cater for the requirements of unattended stations like microwave repeater stations and other similar systems, the provision for automatic isolation of battery bank from the load shall be made available. The tendering authority shall specify for such type of power plants, the load and battery capacity. The operate and release voltages for the above conditions shall be as follows:
Cut-off: 1.85V/cell (44.4 V+0.25V) Reconnect: 1.90V/cell (45.6V+0.25V)
5.6.2 Battery Health Monitoring in Auto Mode: To keep the battery in healthy state, the battery condition shall be continuously monitored. On restoration of AC mains after an interruption, depending on the battery condition (depth of discharge) sensed, the system shall change over to Auto Charge mode to charge the battery at higher voltage of 55.2 V till the battery is fully recouped.
5.6.3 Battery Current Limiting Circuit: In auto mode, to ensure the availability of required load and
safety of the battery, battery path current limit shall be settable as per the battery bank requirements so that the battery path current is kept to 10% of battery AH capacity.
Signature of Tenderer/s Page 109 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
Tending authority will give the capacity of the battery to be used for this purpose. For the type approval, the manufacturer shall demonstrate the facility and undertake to make provision as per order.
5.6.4 Temperature Compensation for Battery: There shall be provision for monitoring the temperature of battery and consequent arrangement for automatic temperature compensation of the FR-FC, FR-BC output voltage to match the battery temperature dependant charge characteristics. The output voltage of the rectifier in float/charge operation shall decrease or increase at the rate of 72m V (3mV/cell, 24 cell battery) per degree increase or decrease in temperature over the set voltage. The output voltage shall decrease till the open circuit voltage of the battery is reached. The open circuit voltage range shall be settable between 2.1V/cell to 2.2V/cell. The increase in output voltage due to decrease in temperature has been taken care of
by the tripping of the unit due to output voltage high (57V) protection. A tolerance of 5mV may be acceptable over the specified rate of 72mV/deg. C. Failure of temperature compensation circuit including sensors shall create an alarm and shall not lead to abnormal change in output voltage.
5.6.5 Battery Reverse Polarity Protection: Protection for battery reverse polarity shall be provided in
the system.
5.6.6 D.C. Contactor: High quality DC contactors, UL approved should be used for battery path disconnection circuit. The contact tips should be brazed accordingly for long life and trouble free operation and the coil should be of H class insulation level. In case of battery disconnection due to low battery condition the battery shall be reconnected to the DC bus only after resumption of mains, the SMRs getting ON and ready to deliver the rated output. There shall also be a provision to switch on the contractor manually. DC contactor from Albright, Prestolite or Powernix should only be used.
5.7 Meters:
There shall be provision to monitor AC voltage (either at module or at the control unit), DC current and voltage with the help of analogue or digital (with digital display of height 12mm) meters to read the voltage and current of the system, batteries or any of the individual FR-FC (at individual FR-FC module also permitted) Normally the meters mounted at Distribution-Switching-Control-Alarm Arrangement shall indicate the system voltage and current.
Accuracy of the meters shall be as given below:
A Current: Analogue: 1.5% of F.S.D. or better
Digital: 1.5% of the range or better, shall be able to read up to 1 place
decimal for meter range up to 99A and full digit in case of higher range.
B Voltage:
Analogue: 1.5% of F.S.D. or better
Digital 1.5% of the range or better with a resolution of one decimal Point in case of DC voltmeter and full digit in case of AC voltmeters.
Signature of Tenderer/s Page 110 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
SECTION-6
POWER PLANTS COMPATIBLE WITH CONVENTIONAL BATTERIES
6.0 Introduction: The conventional lead acid batteries have special requirement of periodic boost charging @ 2.7 V per cell. To meet this requirement, the Power Plant shall be so configured that in addition to the specification requirements, detailed in Section-1 to Section-5, shall also have a provision of a group of FR-BC (as per battery capacity) for charging the batteries @ 2.7V/cell.
6.1 Float rectifier-float-charger-boost charger (FR-BC): In addition to requirement of FR-FC
Modules, the FR-BC Modules shall meet the following additional requirement.
6.1.1 The FR-BC module shall be programmable to work as FR-FC or FR-BC. When programmed
as FR-FC, it shall be capable of working as FR-FC with other FR-FCs and shall comply with all the requirements of FR-FC.
The rated capacity of the FR-BC when programmed as FR-FC shall be same as that of the other FR-FCs. The prescribed float voltage setting for conventional batteries is 52.8 V.
6.1.2 It shall also be programmable as a Boost Charger (BC) under manual control after isolating it
from the float bus.
6.1.2.1 As a boost charger its output voltage shall be continuously adjustable and presettable at constant current up to 100% for voltage range 44.4 to 56 V and up to 50% to 70% rated capacity at any value in the range of 56V to 64.8V as per design of the FR-BC. The firm has to specify the percentage of rated capacity of FR-BC module when it is working in the boost charging mode (56 to 64.8V).
6.1.2.2 The boost voltage shall be maintained within 1% of the set value over the full boost current
range as specified.
6.1.2.3 When programmed in Boost Charging Mode, FR-BC modules shall work in parallel load
sharing arrangement with other FR-BC modules in the same mode, keeping other output conditions within specified limits.
The current sharing shall be within 10% of the average current per FR-BC module ( in Boost Charging Mode) in the system (mounted in the same or different racks) when loaded between 50 to 100% of its rated capacity (as BC) for all other working conditions.
6.1.3 In addition to the Visual indications/display specified for FR-FC the following shall also be
provided in FR-BC Module.
Functional Indications: FR-BC on Boost Mode
Alarm Indications: Following Alarms shall actuate in BC mode:
A. FR-BC Over Voltage.
B FR-BC Over Load (Voltage Droop)
Signature of Tenderer/s Page 111 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
6.1.4 Protection: The module shall also be protected against DC over voltage in BC Mode.
6.1.4.1 Shutting-off of faulty FR-BC module in FR-BC mode shall not affect the operations of other
FR-BC & FR-BC in FR-FC mode.
6.2 Distribution-Switching-Control-Alarm Arrangement: The Distribution-Switching-
Control-Alarm Arrangement, in addition to the facilities specified in Section-5 shall also provide for switching arrangement under SCHEME 1 and SCHEME 2 as elaborated in Clause
6.3 and 6.4 respectively. .
6.3 SCHEME 1 Switching Arrangement: A Block Diagram is shown in Annexure-III. This Scheme is necessary if two nos. of battery bank of identical capacity are used and the total load requirement is more than 50 Amp. This uses two nos battery selection switches(as shown as SW4 and SW5 in Annexure III) and for boost extended charging of anyone battery bank at a time, operator has to carry out manual operation.
The switching arrangement may have knife-switches, Rotary switches or any other suitable arrangement in the same or separate rack for the following facilities.
a) FR-BCs in Auto Float
b) Selection and switching a Group FR-BC for Boost or Float charge operation
To achieve the above, the switching arrangement shall be capable of selecting
6.3.1 Battery Auto Float Charge/Boost Charge selection arrangement for selecting.
i) All the batteries in Auto Float Charge Mode
ii) Battery 1 on boost, others on auto float charge iii) Battery ‘N’ Boost, others on auto float charge
6.3.1.1 The above arrangement shall be provided with a suitable inter-locking arrangement so
that one of the batteries is always on float. In case interlocking arrangement is not feasible due to the rack size, a provision of Alarm shall be made in the event of all the batteries are isolated accidentally.
6.3.1.2 The capacity and number of batteries shall be as order.
6.3.1.3 In case of failure of FR Module(s) supplying load the group of FR-BC modules can be
used to supply load with battery floated across it by operation of the normal/emergency switch(shown as SW3 in Annexure III). By doing so while one pole of this switch will connect Boost bus to load its another pole will ensure that FR-BC modules do not go to boost. Once FR modules have been set right this switch position can be put to normal (as shown).
6.3.2 FR-BC Switching Arrangement shall be provided for connection of FR-BC group to the float
bus for auto float charge operation or boost charge bus for boost charging of the battery after its isolation from the float bus.
6.4 SCHEME 2 Switching Arrangement : The schematic diagram of the scheme as per Annexure-
Signature of Tenderer/s Page 112 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
IV may be implemented or otherwise the manufacturer may adopt another suitable design to
The scheme is useful with only one Battery Bank used at a station. However it can also be used with two battery banks is parallel. The scheme is to be used for total requirement upto 50 Amp(using 12.5 Amp FR-BC Modules only). However it can also be used beyond 50 Amp load and upto 100 Amp load using 25 Amp FR-BC Modules as per users choice. Its details are given as under.
6.4.1 The dropper diodes shall be using 14 nos. of diodes of at least 2 times rated current mounted on
suitable heat dissipation platform.
6.4.2 The bypass contact C shall be DC rated to carry at least 1.5 times rated current and coil be
rated at 48V DC nominal.
6.4.3 The control card shall sense the Battery Voltage and will cut in dropper diodes in the Battery to
load path so that the voltage across load remains within 45V to 56.5V at rated load while voltage across Battery may vary between 48V to 64.5V.
6.4.4 The contact C must close automatically in case the AC main has failed or voltage across
Battery Bank is 48V or less.
6.5 The Distribution-Switching-Control-Alarm Arrangement in addition to the facilities specified
in Section-5 shall also provide for :
Functional indications: FR-BCs in Boost Charge Mode.
Alarm Indications: Boost Load Voltage High(above 66V)/Low (below 44.4V)
Signature of Tenderer/s Page 113 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
SECTION-7
TESTS AND REQUIREMENTS
7.1 Conditions of tests: Unless otherwise specified, all tests shall be carried out at ambient and
atmospheric conditions.
7.2 Type Tests
The following shall comprise type tests.
a) Visual Inspection (Clause 7.5)
b) Insulation Resistance Test (Clause 7.6)
c) Applied High Voltage Test (Clause 7.7)
d) Radio Frequency Interference Suppression Test (Clause 7.13)
e) Burn-in Test (Clause 7.8)
f) Performance Test (Clause7.9)
g) Test for Protection Device (Clause7.10)
h) Climatic Test (Clause 7.11)
i) Vibration Test (Clause 7.12)
j) MTBF Clculation (Clause 2.20.2)
7.2.1 Only one Power Plant shall be tested for this purpose. The Power Plant shall successfully pass all the type tests for proving conformity with this specification. If the module fails in any of the type test the purchaser or the nominee at his discretion, may call for further module of the same type and output rating and subject it to all the tests or to the test (s) in which failure occurred. No failure shall be permitted in the repeat test (s).
7.3 Acceptance Tests:
The following shall comprise acceptance test:
a) Visual Inspection (Clause 7.5)
b) Insulation Resistance Test (Clause 7.6)
c) Applied High Voltage Test (Clause 7.7)
d) Performance Test (Clause 7.9)
e) Test for Protective Device (Clause 7.10)
7.3.1 Visual Inspection, insulation resistance test and performance test shall be carried out on all
SMPS Based Power Plant.
Signature of Tenderer/s Page 114 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
Page 29 of 40 Effective from 10.12.2008 RDSO/SPN/TL/23/99 Version 4.0
The following sampling plan shall be adopted for the remaining tests:
Lot Size Sample Size
2-8 2
9-15 3
16-25 5
26-50 8
51-100 13
101-150 20
151-200 32
7.3.1.1 For acceptance of the lot there shall be no failure in any of the test as mentioned under clause
7.3 above.
7.4 Routine Tests
Following shall constitute routine test and shall be conducted by manufacturer on every equipment and test results will be submitted during the inspection.
a) Visual Inspection (Clause 7.5)
b) Insulation Resistance Test (Clause 7.6) c) Applied High Voltage Test (Clause 7.7)
d) Performance Test (Clause 7.9)
7.4.1 The performance test may be carried out only at nominal input voltage during the routine test.
7.5 Visual Inspection:
The system shall be visually inspected to ensure compliance with the relevant requirements of sections 2, 3, 4, 5 & 6.
7.6 Insulation Resistance Test:
This test shall be carried out after Applied High Voltage Test.
The measurement shall be made at a potential of not less than 500V DC. The insulation shall be measured between:
a) AC line terminals and earth
b) DC line terminals and earth
c) AC terminals and DC terminals
The Insulation Resistance values shall comply with clause 2.12.1
7.7 Applied High Voltage Test:
Signature of Tenderer/s Page 115 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
This test should be done as per clause no. 2.12.2. Note:
1. Module and Rack should be tested separately
Page 30 of 40 Effective from 10.12.2008 RDSO/SPN/TL/23/99 Version 4.0
2. In Routine Test only one FR-FC, FR-BC module shall be tested.
7.8 Burn-In Test:
The fully equipped rack shall be capable of withstanding Burn-In Test for 72 hours during Type Test ( 8 Hours during Acceptance Test) at an ambient temperature of 50(+ 2) ºC when the equipment is working at full rated load. This test may be performed in a temperature-controlled room with free airflow. The ambient temperature shall be measured at a distance of 1 foot from the equipment under test. The necessary set up for the purpose shall be provided by the manufacturer. The temperature rise of the heat dissipating components above the ambient measured directly or at heat sink in the first eight hours of the test shall not be more than
a) Transformers and Chokes: 70ºC for Grade B insulation. However for higher grade of
insulation, higher temperature rise may be permissible subjected to the following conditions.
i) It is at least 20º C below the permissible limit for the grade of insulation used. ii) The temperature rise shall be at least 30ºC below Curie temperature of the
magnetic material. iii) This temperature shall neither affect the other components nor shall lead to fire
hazard.
b) Transistors/Thyristor/Diodes/FETs/Semiconductor Devices : 60º C or as per
components specification.
7.9 Performance Test:
The Power Plant shall be tested for its output performance (Efficiency, Power Factor, Harmonic Distortion, Psophometric Noise and Ripple Voltage) at the AC Input Voltages 90V/165V, 230V and 260V/300V at different terminals for the Auto Float Mode and Auto Charge Mode respectively.
7.9.1 In Auto Float Mode, reading shall be taken for float voltage setting of 2.2V/cell at load current
in the range 25% load to full load.
7.9.2 In Auto Charger Mode readings shall be taken for boost voltage setting of 2.3V/cell at load
current in the ranges 25% load to full load.
7.9.3 During the performance test the Power Plant shall fulfill the requirement of Efficiency, Power
Factor, Harmonic Distortion, Psophometric Noise, Ripple Voltage etc as given under clauses 4.4, 4.5, 4.6 & 4.10 of this specification.
Signature of Tenderer/s Page 116 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
7.9.5 The current sharing of the module working in parallel shall be tested as per Clause 4.11.
7.9.6 All other performance tests shall be carried out as mentioned in sections 2, 3, 4, 5 & 6.
7.10 Tests for Protective Devices:
7.10.1 Short Circuit: During this test, system shall be connected to AC input voltage of 265V/305V.
Output terminals shall be short circuited through a suitable arrangement. Steady short circuit current shall be measured. It should not exceed rated current +5%. There shall not be any damage to charger. Working of over load/ short circuit indications/alarms will also be checked on the FR-FC. This shall be achieved by controlling output current and voltage under short circuit conditions and not by switching off the input/output voltage under short circuit condition.
7.10.2 Reverse Battery Connection: A fully charged battery shall be connected in reverse polarity to
output terminals of charger. There shall be no emission of smoke of undue temperature rise of any component of charger. Working of corresponding indication/alarm will also be checked.
7.10.3 Other protection such as current limiting, voltage overshoot/undershoot, battery monitoring
tests shall be as per clause nos. 4.7, 4.9 & 5.6 respectively.
7.10.4 For lightning protection manufacturer must submit a certificate of Class B and Class C type
protection as per Clause 2.4.4 from International or National Agency.
7.11 Climatic Tests:
7.11.1 The Climatic Tests shall consists of:
i) Dry heat at 55±2 deg C as per IS: 9000 (Pt. III) for 16 hours duration. ii) Damp Heat (Cyclic) Test as per Variant 1 for 6 Cycles with severity of
Upper Temperature 55oC as per IS: 9000 (Pt V/Sec.2) : 1981.
iii) Cold test at 0 deg C for two hours duration as per IS: 9000 (Pt.III).The equipment will be kept inside the chamber in the energized condition in auto charge mode of operation.
7.11.2 These tests shall be performed by configuring the SMPS Based Power Plants as follows.
i) Control & Monitoring Arrangements of ratings for Ultimate Expandable Capacity. ii) One FR-FC or FR-BC module with one standby FR-FC or two standby FR-BC module
i.e. with minimum configuration as per Cl. 2.2.
7.11.3 The climatic test shall be carried out by setting the system in auto charge mode of operation.
During the period of exposure in each test the system shall be connected to supply mains of nominal input voltage and shall deliver the rated output voltage of 2.3V/Cell to a resistive load.
7.11.4 During climatic test, after every climatic cycle, 2-4 hour restoration time in ambient, after completion of climatic tests as specified in para 7.11.1 above, 4 hours restoration time shall be given and insulation and protection tests shall be repeated. There shall not be any malfunction during test.
7.12 Vibration Test (Sinusoidal)
Signature of Tenderer/s Page 117 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
7.12.1 The vibration test shall be conducted to withstand the following test conditions.
(i) Frequency 5 to 350 Hz
(ii) Amplitude ±6mm constant displacement or 1.5 g
constant acceleration whichever is less.
(iii) Direction of vibration X,Y,Z
(iv) Duration/axes 2 Hours
7.12.2 Endurance test by Frequency sweep: Frequency shall be varied at the rate of 1 octave per
minute from min (5 Hz) to max (350 Hz) and maximum to minimum constituting one full sweep. The total duration of the endurance shall be 6 hours and this shall be conducted in all the three axis preferably with equal distribution.
7.12.3 The equipment is to be vibrated in three mutually perpendicular directions.
7.12.4 The frequency is to be varied continuously from the lowest to the highest value over the specified range, at such rate that resonances can be easily detected. The rate of change of frequency will not normally exceed one octave in one minute. Resonances may be observed by stroboscope or other means. All frequencies at which assemblies are detected to resonate shall be noted.
In case the Vibration Tests are not feasible on the SMPS Based Power Plants, the same may be conducted on basic modules mounted in Card-Cage in a packed condition or in a box.
7.12.5 At the end of the test the equipment is to be examined for mechanical damages and electrical
performance.
Note: Vibration test is to be conducted on one FR-FC, FRBC module. In case the vibration tests are not feasible on the unit the same may be conducted on control cards mounted in card-edge, in a packed condition or a Box.
7.13 Radio Frequency Interference Suppression Test
This test shall be done to examine compliance with Clause 2.14 and shall be conducted during Type Test only. Separate Test will be required for power plants working on three phase and single phase input AC. EM/RFI test shall be conducted on one FR-FC-BC module of each type viz 12.5A, 25A, 50A SMPS Module separately.
7.14 Final examination and measurements:
After completion of vibration test the equipment is finally to be checked for any mechanical damages and performance tests as specified in clause number 7.9 are to be conducted.
7.15 Training Documents
Comprehensive Training Documents shall be submitted during Initial Type Approval. Training Documents should include Design Details, Detailed Circuit Diagram, Component Layout Plan,
Signature of Tenderer/s Page 118 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
Preventive Maintenance Procedures, Corrective Maintenance Procedures etc. The Training Documents shall be structured in the form of Instructors Notes, Power Point Presentations, Trainee Notes, Course Materials etc. This Training Documents shall be reviewed by IRISET/SC and subsequently manufacturers shall supply copies of these Training Documents to Training/Maintenance Units along with delivery of Power Plant(s).
Signature of Tenderer/s Page 119 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
SECTION 8
INFORMATION TO BE SUPPLIED BY THE PURCHASER
8.1 The type of battery to be used, VRLA or Conventional Lead Acid (Clause. 1.1, Section I)
8.2 For Single Phase, Incoming Power Supply range either 90V-300V or 165V-260V. (Clause 1.3
of Section 1).
8.3 Battery capacity (Clause. 5.6.3 of Section 5) and numbers. of battery bank.
8.4 Ultimate Expandable Capacity of the Power Plant in terms of load(Clause 2.2 of Section 2). 8.5 Type, Number& Configuration of SMR Modules (Clause. 2.2, Section 2) 8.6 Power Plant will work on Single phase or 3 phase (Cl. 2.4.1, Section 2) 8.7 Power Plant to work as Float Rectifier–cum–charger (FR-FC) Mode or Float Rectifier– cum-
charger–Boost Charger (FR-FC-BC) Mode.
Signature of Tenderer/s Page 120 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
ANNEXTURE & DRAWINGS(Technical)
Signature of Tenderer/s Page 121 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
ANNEXURE-I
Signature of Tenderer/s Page 122 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
ANNEXURE-II Schematic Diagram for connection of Class D Surge Arrestor for SMPS Power Plant
Signature of Tenderer/s Page 123 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
ANNEXURE-III
Power Plant having Manual Boost Charging Changeover Arrangement using a least two Battery Banks.
Signature of Tenderer/s Page 124 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
ANNEXURE-IV
Power Plant having Automatic Boost Charging Changeover Arrangement using only one or more Battery Banks.
Signature of Tenderer/s Page 125 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
ANNEXURE-V
General Requirements : Radio Frequency Interference Suppression: The system (FR-FC, FR-BC & DSCA modules) shall be designed to minimize the level of electromagnetic interference (EMI), both conducted and radiated, detected in its vicinity and generated by the module and shall comply the following clause.
1. Radiated Emission from the single phase and three Phase power equipment.
Requirement: Any network of conductors and apparatus connected thereto shall not exceed the level of field strength specified in IEC-CISPR 22 'A' as given below:
Frequency (F) (MHz) Distance (Meters) Quasi peak limits dB(VV/m)
30-230 10M 40 dB ((VV/m) 230-1000 10 M 47 dB ((VV/m)
1. The lower limit shall apply at the transition frequency. 2. Additional provisions may be required for cases where interference occur.
Test Procedure: Test setup, Test procedure & Measurements shall be conducted as per IEC – CISOPR 22.
2. Conducted Emission Limits: All conducted emissions from power equipment or accessories
connected thereto, intended to be connected to the power lines of a public utility shall not exceed. the limits specified in IEC-CISPR 22'A' as given below :
Frequency (MHz) Quasi peak limits Average limit dB(VV)
dB(VV)
0.15 – 0.5 79 dB ((VV) 66 dB ((VV)
0.5 – 30.0 73 dB((VV) 60 dB ((VV/m)
The lower limit shall apply at the transition frequency..
Test Procedure: Test set up, Test procedure & Measurements shall be conducted as per IEC-CISPR 22.
3. Conducted Susceptibility Limits : Power equipment used in Telecom Network shall not
malfunction when high voltage surge as specified below is superimposed at the input power mains to the power equipment, for more than two seconds as per IEC 61000 – 4-12 9(b). The equipment shall also not fail or degrade in performance after the surge is withdrawn.
Test levels: Voltage Rise time (First peak): 75 nano sec ±20% Oscillation Frequencies : 100 KHz & 1 MHz ±10%
Repetition rate : at least 40/s for 100KHz and 400/s for 1 MHz Decaying : 50% of the peak value between the 3rd & 6th periods.
Burst duration : not less 2 S Surge amplitude : 250V (-10%) to 2.5 KV (+ 10%)
Signature of Tenderer/s Page 126 of 131 For Sr.DSTE/Works
North-Western Railway, Jodhpur
Test Procedure: Test set up, Test procedure & Measurements shall be as per IEC 61000-4-12. EMI surge of specified levels injected on power leads of test sample shall not cause degradation of performance or malfunction
4. Electrostatic discharge (ESD) immunity limits: the limits shall be as per IEC 61000 -4-2,
9(1) (Both contact discharge method and Air discharge method) as given below :
Test level:
Contact discharge Air discharge
Level Test voltage KV Level Test voltage KV
4 8 4 15
Test Procedure: This test shall be conducted as per IEC 61000-4-2 for both requirements &
unit shall comply of clause 9(1) of IEC 61000-4-2.
5. Electrical fast transient/Burst immunity limits : The limits shall be as specified in IEC
61000-4-4.
Test level:
Open-circuit output test voltage (±20%)
Level On power supply port, Protection Earth
Voltage peak KV4 Repetition rate KHz
4 4 2.5
Rise time of one Pulse -5 ns ±30%
Impulse duration - 50 ns ±30%
Test Procedure: This test shall be conducted as per IEC 61000-4-4. Test results shall be in compliance of clause 9(1) of IEC 61000-4-4.
6. Radiated radio-frequency Electromagnetic field immunity limits: The limits as per IEC
610004-3.
Test level:
Frequency range: 80MHz to 1000 MHz
Level Test field strength V/m
3 10
Test Procedure: This test shall be conducted as per IEC 61000-4-3. Test results shall be in compliance of clause 9(a) of IEC 61000-4-3.
7. Surge Immunity limits: The limits as per IEC 61000-4-5.
Test level:
Signature of tenderer Page 127 of 131 For Sr.DSTE/Works.
North Western Railway, Jodhpur
Level Open circuit test voltage (± 10%) KV
1 0.5 2 1.0
3 2.0
4 4.0
Voltage surge – 1.2/50Vs Amplitude - 2KV (DM)
- 4KV (CM) - After testing for 4KV, the amplitude shall also be increased to 6KV (1.2/50 Vs Combined wave form as per EEE C62 41 – 1991 to cover lightening/Surge protection test also.
Test results shall be in compliance of clause 9(b) of IEC 61000-4-5.
Test Procedure: This test shall be conducted as per IEC 61000-4-5. After testing for 4KV, the amplitude shall also be increased to 6KV (1.2/50 Vs). Combined wave form as per EEE C62.41-1991 (to cover Lightening/Surge protection test also.).
Note: The rated voltage of the MOVs issued for the above shall not be less than 320V.
8. Radio Frequency Conducted Susceptibility immunity limits: The limits as per IEC 61000-4-6.
Test level:
Frequency range: 150 KHz – 80 MHz
Level Voltage level ( e.m.f.)
3 10
Test Procedure: This test shall be conducted as per IEC 61000-4-6. Test results shall be compliance of clause 9(a) of IEC 61000-4-6
Signature of tenderer Page 128 of 131 For Sr.DSTE/Works.
North Western Railway, Jodhpur
PART II
SCHEDULE OF WORK
Signature of tenderer Page 129 of 131 For Sr.DSTE/Works.
North Western Railway, Jodhpur
Name of Work:-Replacement of Batteries on age-cum-condition basis for OFC Huts at 11 stations viz.
RKB, MDB, MMY, TIW, SRK, MWT, STSN, KRC, KHTU, GOTN, SWF over Jodhpur division in North
Western Railway
SN Description of Item Unit Qty Rate Amount Inspection Authority
Schedule- NS Items
1 Supply of SMPS based Battery Chargers
as per RDSO Spec for Telecom use 48
volts, 25 Amps in 2+1 configuration
modules of 25 Amps with ultimate
expandable capacity 50 Amps, automatic
switching between the modules as per
RDSO Spec No.
RDSO/SPN/TL/23/99/V3 or latest.Along
with two potential free contacts.
No. 11 83282.70 916109.70 RDSO
2 Module for SMPS 25 Amps/48VDC
suitable for item no 1
No. 11 24188.89 266077.80 Consignee
3 Supply of Maintenance free free VRLA
Batteries set of 48V-200 AH as per
RDSO specification IRS Spec. No.
IRS:S.93/96(A) with amendments-1(Each
battery set shall be of 24 batteries of
2V200AH)
No. 11 88980.66 978787.26 RDSO
4 Installation of Battery chargers, batteries,
Battery rack, Power distribution Board
along with MCBs of suitable ratings and
wiring and commissioning of External
alarm contacts through EMS. The work
includes supply of battery rack, MCBs,
battery cable and battery lugs and other
accessories required for installation of
power plant.
No. 11 2394.75 26342.25 Consignee
Total 2187317.01
Signature of tenderer Page 130 of 131 For Sr.DSTE/Works.
North Western Railway, Jodhpur
NORTH WESTERN RAILWAY, JODHPUR DIVISION
TENDER FORM ( RATE FORM) ( Rate should be quoted both in figures as well as in words
1. NIT NO. : S&T/JU/24R/2015-16 2. Date of opening : 11.12.2015 3. Name of Work : Replacement of Batteries on age-cum-condition basis for OFC Huts
at 11 stations viz. RKB, MDB, MMY, TIW, SRK, MWT, STSN, KRC, KHTU, GOTN, SWF over
Jodhpur division in North Western Railway. 4. Cost of Work : Rs2187317/-R/O 5. Earnest Money : Rs.43750/- in favour FA & CAO NWR Jaipur. 6. Completion period : 06 Months. 7. Tender Form Cost : Rs3000/- in favour of Sr.DFM NWR Jodhpur. 8. Similar Nature of work: Not applicable.
I/We hereby agree and abide to do the work as per schedule as per below
S.No Reference of SOR S&T2012/N.S items
Total Basic Cost Rate to be quoted by the tenderer Above/Below/At Par in percentage on Basic Cost/ base rate.
In Figures In Words
1. Schedule N.S Items
Rs. 2187317.01/-
1. Rate to be quoted by the tenderer inclusive of all Taxes as per extend rules. 2. The quantities shown in above schedule are approximate & are as a guide to give the
tenderer(s) an idea of quantities of work involved. The Railway reserves the right to increase/ decrease and/ or include any of quantity given in the schedule of work and no extra rate will be allowed on this account.
Signature of the Tenderer(S)
Signature of tenderer Page 131 of 131 For Sr.DSTE/Works.
North Western Railway, Jodhpur
END OF DOCUMENT